Upload
duongthuy
View
326
Download
5
Embed Size (px)
Citation preview
LAHORE ELECTRIC SUPPLYCOMPANY
(LESCO)
TENDER
Document No. 85/2016-17
SERVICES CONTRACT REGARDING
INTEGRATED ASSET MANAGEMENT SOLUTION INCLUDING TAGGING,
SOFTWARE IMPLEMENTATION & INTEGRATION WITH EXISTING
ERP AND BILLING SYSTEM
OFFICE OF DIRECTOR GENERAL (IT)
LESCO I.T DIRECTORATE, 132-KV GHAZI GRID STATION BARKI ROAD,
LAHORE Tel: 042-36636815, Fax # 042-36636814
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
2
TABLE OF CONTENTS
1. INTRODUCTION............................................................................................................................... 4
2. DESCRIPTION OF WORK .............................................................................................................. 4
3. BID TIMINGS ..................................................................................................................................... 4
4. EXISTING ENVIRONMENT ........................................................................................................... 5
4.1 CURRENT LESCO OFFICES AND EMPLOYEE COUNT ......................................................................... 5 4.2 CURRENT APPLICATIONS .................................................................................................................. 6 4.3 CURRENT ERP INFRASTRUCTURE ..................................................................................................... 6 4.4 EXISTING ERP APPLICATION - FIXED ASSET PROCESS ..................................................................... 7
5. SCOPE OF WORK ............................................................................................................................. 8
5.1 INTEGRATED ASSET MANAGEMENT SYSTEM (LOT 1) ...................................................................... 8 5.1.1 General Guidelines for Implementation of Integrated Asset Management System ................12 5.1.2 Integration with Existing ERP & Billing System ...................................................................13 5.1.3 Deliverables ...........................................................................................................................13 5.1.4 Review Mechanism ................................................................................................................15 5.1.5 Acceptance Criteria ...............................................................................................................15 5.1.6 Data Entry and Conversion/Migration ..................................................................................15 5.1.7 Software Licenses ..................................................................................................................15 5.1.8 User Trainings .......................................................................................................................16 5.1.9 Preliminary Acceptance Testing (PAT) .................................................................................16 5.1.10 Performance Evaluation Period .......................................................................................16 5.1.11 Warranty, Maintenance and Support Agreement ..............................................................17 5.1.12 Post Production Support Model ........................................................................................17 5.1.13 Service Level SLAs ............................................................................................................18 5.1.14 Classification of Severity Levels .......................................................................................19 5.1.15 Infrastructure Requirements .............................................................................................19 5.1.16 Special Conditions ............................................................................................................20 5.1.17 Price Summary ..................................................................................................................20 5.1.18 PAYMENT .........................................................................................................................20 5.1.19 INSPECTION/ACCEPTANCE ..........................................................................................21
5.2 ASSET TAGGING...............................................................................................................................22 5.2.1 Special Conditions .................................................................................................................22 5.2.2 PAYMENT TERMS ................................................................................................................23
6. BIDDERS SELECTION CRITERIA ...............................................................................................25
7. INSTRUCTIONS TO BIDDERS ......................................................................................................25
8. CONSIGNEE .....................................................................................................................................26
9. SUBMISSION OF BID ......................................................................................................................26
10. LATE BID ..........................................................................................................................................26
11. RIGHTS RESERVED BY THE LESCO .........................................................................................26
12. FAILURE AND TERMINATION....................................................................................................27
13. GENERAL INSTRUCTIONS FOR THE BIDDERS .....................................................................28
14. THE FINANCIAL BID SHALL COMPRISE OF THE FOLLOWING ......................................29
15. FORFEITURE OF SECURITY BOND/GUARANTEE (PERFORMANCE BOND) .................29
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
3
16. COST OF BIDDING ..........................................................................................................................29
17. CLARIFICATION OF BIDDING DOCUMENT ...........................................................................30
18. LANGUAGE OF BID ........................................................................................................................30
19. BID PRICES .......................................................................................................................................30
20. BID SECURITY .................................................................................................................................30
21. PRELIMINARY EXAMINATION ..................................................................................................30
22. FORCE MAJEURE ...........................................................................................................................31
23. THE TECHNICAL BID SHALL COMPRISE OF THE FOLLOWING .....................................31
24. DOCUMENTS / SAMPLES / CERTIFICATES TO BE SUBMITTED ALONG WITH THE
BID 32
25. LAWS GOVERNING THE CONTRACT .......................................................................................32
26. GLOSSARY .......................................................................................................................................34
27. APPENDIX (A): TECHNICAL EVALUTION CRITERIA (LOT 1/ LOT 2) ..............................35
28. APPENDIX (B): BID PRICES FORMAT (LOT 1) ........................................................................36
NOTE: ..........................................................................................................................................................36
29. APPENDIX (B): BID PRICES FORMAT (LOT 2) ........................................................................37
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
4
1. INTRODUCTION
Lahore Electric Supply Company Ltd (LESCO) is the electricity distribution
company serving more than 4 million consumers through distribution of an extensive
network in five districts of Punjab. The company is serving its customers in Lahore,
Kasur, Sheikhpura, Okara and Nankana districts.The company has over the years of
experience in operation and maintenance of electricity distribution systems. LESCO
operates in a region of the nation that has a rapidly growing demand for electricity
due to significant industrial development.The LESCO has more than 20 million fixed
assets segregatedin majorclassifications includes;
Transmission Lines and Grids (T&G)
Power Distribution Network Assets
Vehicles
Land
Buildings
IT Equipment
Office Equipment
Furniture
Others etc
2. DESCRIPTION OF WORK
LESCO invites single stage two partssealed bids (i.e. technical and commercial
separately) from the potential biddersto carry outService Contract for Integrated Asset
Management solution including tagging, software implementation & integration with
existing ERP and Billing System in 2 different LOTS. a bidder may be participate in any
single or both LOTS.
The details of services required are mentioned in Section (5.1) Scope of Work (LOT 1)
and Section (5.2) Scope of Work (LOT 2) of this document. The bids will be evaluated
on separate LOT basic.The qualifying criteria of technical bid would be 70 percent of
total technical marks. The financial bids of only technically qualified firms shall be
opened and shall be evaluated on lowest solution cost basis.
3. BID TIMINGS
Last Date for Obtaining Tender Documents: 29-09-2016 till 04:00 p.m.
Last Date for submission of bids: 30-09-2016 at 10:30 a.m.
Date & time of opening of bids: 30-09-2016at 11:00 a.m.
Prices quoted in the tender shall remain valid for 120 days after opening date.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
5
4. EXISTING ENVIRONMENT
4.1 Current LESCO Offices and Employee Count
LESCO, since its inception, has grown manifold as a result of continued efforts,
progressive outlook and dynamic approach in its operations. LESCO offices are as
follows:
S.No LESCO Offices
1 Chief Executive Office
2 Office of Chief Financial Officer
3 Material Management
4 IT Directorate
5 Project Construction Office
6 Project Management Unit
7 Grid Station Construction Office
8 Grid Station Operation Office
9 Civil Works
Distribution Operational Circle
10 Total Operational Circles 07
XEN/Division Offices
11 Total Divisions 32
Revenue Offices(RO)/CSO
12 Total RO/CSO 32
Sub Divisions
13 Total Sub Divisions 186
Other Accounting Units
14 Other Accounting Units 08
Regional Store
15 Total RegionalStore01
Inventory Field Stores
16 Total Inventory Field Stores 12
Ware House
17 Total Ware House 01
IT Directorate Inventory Store
18 Total IT Directorate Inventory Store 01
LESCO employs over 20,000 employees at all locations including operations and projects.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
6
4.2 Current Applications
Product: Oracle E-Business Suite
Release: 12.2.4
Database: Oracle 12c Database
Modules implemented:
Oracle General Ledger
Oracle Fixed Assets
Oracle Cash Management
Oracle Payables
Oracle Receivables
Oracle iExpense
Oracle Order Management
Oracle Purchasing
Oracle Inventory Management
Oracle Project Costing
Oracle Payroll
Oracle Self Service HR
Oracle Human Resources
Oracle iRecruitment
Other Applications:
Customer Information & Billing System (CIBS)
Customized application developed in JAVA with ORACLE Database 11g
(Windows Server Enterprise Edition 2003 (64 bit))
4.3 Current Infrastructure
LESCO has established a network of 114 nodes. Details of LESCO Network
Connectivity as follows:
Sr.
# Technology
Number Of
sites Bandwidth Latency
1 DXX 111 01 Mb 20-30ms
2 DXX 2 03 Mb 20-30ms
3 Fiber 1 40 Mb 4ms
Total 114
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
7
System Specifications:
S.No Environment System Specifications Qty Operating System
1 Production Dell R920Server 2 Processor x
16 Cores, 128 GB RAM 3
ORACLE LINEX EE
v.6.5 (64 bit)
2 Development Dell R730 Server 2 Processor x
16 Cores, 128 GB RAM 1
ORACLE LINEX EE
v.6.5 (64 bit)
3 Test Dell R730 Server 2 Processor x
16 Cores, 128 GB RAM 1
ORACLE LINEX EE
v.6.5 (64 bit)
4 Disaster Recovery Site Dell R730 Server 2 Processor x
16 Cores, 128 GB RAM 1
ORACLE LINEX EE
v.6.5 (64 bit)
Storage Area Network (SAN)
o Model: Dell EQUALLOGIC
o Storage Capacity: 65 TB
o Cache: 96 GB
Being maintained and database synchronized through data guard.
4.4 Existing ERP Application - Fixed Asset Process
The existing process of accounting for fixed assets includes maintenance of ERP based
Fixed Assets Register at HO, which includes the following:
1. Assets definition – define assets in Oracle Assets
2. Assets assign to employees – assign assets to employee
3. Assets depreciation value – define the depreciation rule
4. Material issue for Maintenance – Issuance of material to work from oracle
inventory to specific account.
5. Purchase of Assets – initiate purchasing process in Oracle purchasing.
6. Assets capitalization – capitalize assets in oracle assets.
High level gaps are:
1. There is no visibility in the system on specific assets maintenance cost.
2. Unable to online review of assets maintenance cost based on which decision to
capitalized or not can be taken.
3. Assets Maintenance details (Work Orders, resource availability, spare parts
availability, outside processing, vendor processing cost, maintenance plans etc).
4. No visibility in the system on material and resource cost charge to specific assets.
5. Moreover there is no proper coding for identification of the entire fixed assets of
the Corporation, which can result in a material loss on account of
misappropriation as a result of collusion at divisions and subdivisions or
otherwise negligence.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
8
On account of the risk being faced, LESCO is planning to undertake a complete
revamping of the fixed assets Tagging, Accounting, and Valuation and Recording
procedure as a Corporation wide strategy.
5. SCOPE OF WORK
The overall scope of work of this project will include:
I. LOT 1: Integrated Asset Management Software acquisition, Implementation
& Integration with existing ERP Oracle E-Business Suite R12.2.2 and Billing
System.
Integrated software solution to support asset management objectives.
Software system configuration, implementation, maintenance and support.
Systems training to ensure effective use/operation of software application.
Mobile Software of Handheld device.
The scope is discussed in detail in Section (5.1).
II. LOT 2: Asset Tagging
Supply Barcode tags
Supply of Android handheld devices
Installation of these tags is part of scope
The scope is discussed in detail in Section (5.2).
5.1 Integrated Asset Management System (LOT 1)
The bidder should propose the IAMS software with following minimum features.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
9
Assets Management
System should have the Self Service User Interface with powerful search capability,
comprehensive asset information, mass updates and multiple-asset deployment
System should provide the Single repository of physical, financial and service information
System should provide the complete history of assets.
System should be able to Automatic fixed asset creation upon receipt or after in-service
Facility of Serialized asset grouping for capitalization
Automatic handling of costs, units and location updates in FA for inventory transfers, asset
deployment or redeployment.
Support for asset re-classification scenarios
Facility for Asset creation based on project/task/serial number
Facility to create a unique asset for each serial number or one asset for a group of items
If any financial asset created directly in existing ERP Assets will trigger a notification for the
creation of the physical asset in IAMS Asset Tracking application.
System should allow users to perform deployment transactions such as install, in-service, out of
service, or asset moves through an Applications Framework User Interface.
Assets can also be deployed in service at field locations directly from inventory.. Assets can be
brought back to a warehouse and issued to another location. Throughout all the asset
movement, the link to ERP Fixed Assets is maintained.
Integration
Proposed system should be integrated with ERP system.
Provides integration and synchronization with Oracle Assets. These integration processes
automate mass additions, cost updates, and asset transfers, thereby significantly reducing
the amount of manual intervention required to maintain financial accuracy along with
physical tracking
All integration points should be clearly defined and documented.
Mobile Application
Empower employees with modern mobile apps with intuitive user experience and self-
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
10
service capabilities that allow them be more productive - anywhere, anytime, at their
convenience.
Native application that is capable of working on Android and should be able to collect data
offline in areas where internet access is limited
Mobile app will be used for asset verification i.e. locate asset by Asset details (Asset
number, Asset Status etc...), locate asset by GIS Area (Radius, Polygon) etc.
Mobile app should be capable for input necessary verification data regarding asset health,
performance, spare parts and other necessities and should be able to collaborate with the
central system for integrated data exchange
Asset Tag installation, data gathering and Geo-Tagging will be done through mobile app
Maintenance schedules should be accessible and viewable on mobile app with necessary
alerts and data gathering
Maintenance
Facility should be there to generate a work order for Equipment maintenance, in case of
scheduled maintenance, work order should be auto-generated according to the schedule
Facility for pre-configured templates for preventive scheduled maintenance according to
the asset categoriesOR nature of process
Support for all types of asset locations: user-defined areas, internal inventory locations,
external physical locations, etc.
Fully supported asset moves and asset transfers, preserving asset attribute integrity,
maintenance strategy and history
System should have the ability of Asset check-in/check-out
Facility should be there to transfer all jobs for costing after checking materials used and
repair stage.
Facility should be there to record details of repair and facility to trace the history of job
order.
System should have the ability to recordinspection, downtime, user-defined variable data
System should Streamline work requests with approval Workflow
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
11
System should have the Inspection, lubrication and routine preventive maintenance work
orders
• Emergency work orders
• Pre-planned work orders
• Audit trail
• User-defined work order types and work order statuses
• Work order relationship, including parent/child and follow up work orders
System should have the Rebuild able component replacement
• Flexible work completion process options (for specified work steps and/or work order)
• Data capture at work order completion (meter readings, collection plan entries, failure
data)
System should have the Stores Management in place with existing ERP inventory
management
• Flexible material request and issues process, including one-step issue
• Auto material allocation
• Available to promise status
• Direct requisitions (description based and non-stock material), with supplier catalog
support
System should have comprehensive Maintenance Cost Management
• Cost estimation
• Actual cost calculation (material, labor and equipment resource usage)
• Cost rollup based on work order relationship or asset hierarchy
• Work order cost billing
• Work order cost capitalization
Time based Maintenance
Facility should be there to set frequency for time-based maintenance and last date of
carrying maintenance.
Facility should be there to record identified list of items required for scheduled time based
maintenance work.
Corrective and Preventive Maintenance
System should have the Preventive Maintenance forecast generation and work order
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
12
implementation
System should have the Extensive work scheduling abilities, including part requests,
equipment resource scheduling and employee scheduling
System should have the easy parts inventory look up from work orders and from the
Maintenance Workbench
System should have the easy workflow configuration for work order approval
System should have the Multiple-activity preventive maintenance
System should have the Rule-based preventive maintenance strategy definitions (date rules
or meter rules).
Facility should be there to highlight jobs, which have outstanding actions according to
action plan.
Down time Machine maintenance
Facility should be there to maintain machine down time and production down time. This
should include at least following
Job reported time
Job started time
Job completed time
Equipment stopped time
5.1.1 General Guidelines for Implementation of Integrated Asset Management
System
1. The bidder shall implement all the business processesrelated totransformers will be
decided in requirement gathering phase.High level requirements are following but
limited:
Assets Life Cycle Management from procurement to disposal
Assetsmaintenance Management
Assets repair work management
2. Bidder to provide agreed upon project plan and project Implementation methodology.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
13
3. As part of the project the bidder is expected to provide the solution as per the business
requirements of LESCO through standard functionalities of the software or through
customization including RICE (Reports, Interfaces, Conversions and Extensions)
components, Forms Personalization/customization and database objects (Views,
Procedure, Functions, Packages etc.)
4. The bidder shall impart process based and role based training of featuresto the
persons nominated by LESCO. Each participant should be given role based training
kit, which is the main resource that will be used for training purposes. Training may
comprise of Role Based User Manuals, Help Videos etc. All trainings should be
carried out on the basis of Bidder’s supplied training aids and instructor guides.
5. The system shall be configured to provide online help of the modules function/screen
and field levels, to display information applicable to the task at hand.
6. The system must provide clear, comprehensive error messages at the field and screen
level which fully describe the situation that caused the error and the action necessary
to correct the error.
7. The system shall be configured to include a transaction log which provides an audit
trail for all transactions.
5.1.2 Integration with Existing ERP & Billing System
1. The bidder is required to take measures in the implementation to facilitate the
integration of proposed IAMS with existing ERP (Oracle EBS R12.2.4)and billing
system and with any Oracle application, 3rd
party, open source etc. that is based on
open standards. The integration points will be expected with Inventory, Purchasing,
Core HR, Fixed Assets, Project costing, Payables and General Ledger modules of
existing ERP.
2. The system shall provide Out-Of-the-Box Single Sign on adapter for integration with
Oracle E-business Suite.
3. The integration platform shall adhere to but shall not be limited to the following
standards (where applicable):
o SOAP, Integrated SOA Gateway, WSDL,WebService, REST, HTTP
5.1.3 Deliverables
1. The bidder shall be required to provide all documentation according to decided
Application Implementation Methodology in relation to the system implementation,
configuration, system integration, system requirements, maintenance, programming,
and training of all the components of Scope of Work modules. Documentation shall
be included in the acceptance procedure, and should be received by LESCO as part of
the system implementation.
2. The deliverables for each area of Scope of Work shall be approved by LESCO. The
bidder shall understand and accept that the areas specified in Scope of Work are
separate work activities/ implementations and LESCO reserves the right to set the
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
14
deliverables to generate an effective delivery.
3. For all the issues with the supplied baseline products, which are and may in future be
obstacle in implementing the End-to–End ERP solution, the responder shall provide
and implement a workaround to go around and/or resolve the issues.
4. In case base product versions are different from the ones specified in this documentat
the time of ordering, then the responder should ensure that all products are compatible
while supplying and implementing the solutions.
5. All documents (e.g.: System Requirement Specifications, AS-IS and To-BE
Study,Gap Analysis, Test Cases, Design Documents, Code with Comments,
TrainingMaterial etc) should be kept in sync with the implemented solution
throughout the lifecycle of the project, which also invariably includes maintenance
and changemanagement.
6. All deliverables will be reviewed and approved by LESCO.
7. The project will have the following deliverables but is not limited to :
a) System manual (High Level Design Document (HLDD), Detailed
DesignDocument (DDD))
b) Software Requirement Specification (SRS) AS-IS Study, Mapping TO-BEStudy –
Functional Design Document (FDD), Gap Analysis Document
c) Project Management Plan
d) Quality Plan
e) High Level Design Document/ System Design Document
f) Detailed Design along with Database Design Document
g) User Manual(s), Technical Manual(s), Troubleshooting Guide, HelpdeskManual
etc.
h) Test Cases, Test Data, Test Plans and Results (Unit Testing, IntegrationTesting,
System Testing)
i) Applications Setup Documents
j) Security Policy and Plan
k) Maintenance Plan
l) Patch Management Plan
m) Configuration Management Plan
n) Backup and Disaster Recovery Guide, including Risk Mitigation Plan (Only
documentation required)
o) Change Management Plan
p) Well Commented Source code with all Data Structures
q) Test Data (Or scripts used for generating test data) for unit testing,
integrationtesting, system testing, performance testing, load testing, stress testing,
penetrationtesting etc.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
15
5.1.4 Review Mechanism
The review mechanism for all deliverables will be as follows:
1. The deliverables will be provided to the LESCOProject Manager (PM) at least 7 days
in advance of review finalization date.
2. The bidder will make a presentation on the deliverables to the designated committee.
If required, on the day of the review, and the committee may ask for additional
information or changes.
3. LESCO will issue a formal acceptance of the deliverables subject to above reviews.
4. Codereview will also be carried out by LESCO. This will be carried out during the
POC (Prove of Concept)testing. Any observations and comments in this regard
leading to a code change shall be done in mutual consultation of LESCO and the
bidder.
5.1.5 Acceptance Criteria
All acceptances by LESCO will be given in writing, by the LESCO Project Manager
(PM) and/or their nominee. The acceptance criteria for various deliverables are as follow:
1. Document Delivery: Review Comments incorporated and sign off by LESCO.
2. Code Delivery: No errors and sign off by LESCO after code reviewand testing
3. Data: Accuracy and completeness as specified by LESCO
4. Training: Review comments on training material incorporated andsatisfactory course
feedback
5. Acceptance criteria for any other activity not covered by this document will be
decided between LESCO and bidder in their fortnightly status review meetings
andthen will be signed off by LESCO.
5.1.6 Data Entry and Conversion/Migration
The biddershall be responsible forConversion of the existing data of transformers into the
required format of each relevant solution. The bidder will write any additional code if
required for the purpose. Validation of the converted data at each stage, i.e. conversion
from hard copy to soft copy and after conversion to the relevant format, shall be
performed by bidder and that will be concluded by signing-off a Conversion Certificate.
5.1.7 Software Licenses
As per the software requirements described above, Shall the bidder intends to propose
software licenses of 50 users including Operating System (OS) and mobile application
access other than existing environment.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
16
5.1.8 User Trainings
Training shall include user manuals, documentation and training environment. The
training shall be planned so as to enable LESCO personnel to start using the system as
soon as it has been implemented. Initially, LESCO intends that bidder should have
provision to train about XXXusers; exact number of users will be communicated to the
implementer after the project award.Training documentation (User Manuals) shall be
received by LESCO a maximum of thirty (30) days prior to the start of the first Training
Class. Any changes suggested by LESCO will need to be incorporated in the above
documentation.
5.1.9 Preliminary Acceptance Testing (PAT)
Bidder shall be required to provide a framework, including but not limited to time frame and
procedures, for successful achievement of Acceptance Testing. Acceptance Testing will be
carried out to ensure whether the System conforms to LESCO Business needs.
The bidder shall be required to submit the test procedures atleast one (1) months prior to
commencement of PAT. These procedures will be subject to approval by LESCO.
PAT shall be conducted mutually by the bidder and LESCO staff. LESCO must be notified
about the date of PAT atleast 15 days earlier. PAT shall be completed within 15 days. Within
fifteen (15) days from completion of the PAT, LESCO shall give the Contractor a written
notice whether the system or tested parts thereof is accepted or not.
If the System or any tested functionality thereof is not accepted by LESCO, for not
complying with the specification, the above written notice shall specify the setups or
functions which have been found with defects and where the same are alleged to exist or to
have occurred.
A Defects List will be created by LESCO in cooperation with the bidder prior to the issue of
Preliminary Acceptance Certificate. This list shall identify all minor deficiencies, if any, that
in the opinion of LESCO is acceptable to grant the bidder a Preliminary Acceptance
Certificate, without relieving the obligation of the bidder to correct the said deficiencies at a
certain date fixed by LESCO. The format of Defect List will be defined by the bidder in
consultation with LESCO. The bidder shall correct all the modules functionality specified in
this Defects List prior to System Performance Evaluation (SPE).
5.1.10 Performance Evaluation Period
Thebidder shall provide a one (1) month Performance Evaluation Period.
During the Performance Evaluation Period, the bidder shall be responsible for maintenance
and support of the Applications and hardware/other equipment installed.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
17
During the Performance Evaluation Period, the bidder shall perform an SPE over aThirty
(30) days period.
During the Performance Evaluation Period, LESCO shall execute any activities they find
necessary to verify the business requirements by also involving the selected end users.
The Performance Evaluation Period is terminated by a Final Acceptance Test (FAT). Upon
approval, LESCO will provide a Final Acceptance Certificate (FAC).
The Performance Evaluation Period commences immediately after LESCO's approval of the
final Preliminary Acceptance Test.
5.1.11 Warranty, Maintenance and Support Agreement
1. After PEP and migration to production environment, the bidder will provide warranty
support for a period of one (1) year. The warranty period will start from the date of
migration to production environment and on Final Acceptance Certificate (FAC). In
case of Implementation & Rollout Plan in phases, it will cover the support of all the
phases as when they will be completed. This periodwill be utilized for fixing of bugs
during rollout, implementation of enhanced functionality of configured processes,
performance issues, resolution of integration issues etc. and shall,free of charge, make
corrections and modifications required to fix the problem during this period for the
product/modules upgraded/ purchasedand will ensure smooth rollout operations.
2. The bidder shall also provide a resident Functional and Technical Consultants at IT
Directorate, during office hours throughout the implementation and rollout phases
accompanied by a team of support engineers as required.
3. LESCO shall have the right to purchase maintenance and support for a period of
minimum two(2) year. Further extendable on yearly basis with the consent of both the
parties.
5.1.12 Post Production Support Model
LESCO prefers to ensure complete functional resource & technical resource support to
the end user by adopting an onsite support model as follows:
Sr # Application Area Onsite
1 Application Functional 2
2 Application Technical 2
3 DBA 1
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
18
The bidder is requested to provide full technical proposals for the following preferred
support model. Please provide details of how thesupport process will work including
service levels.
Please provide details of your support methodology and anything that you feel would
NOT be in-scope and any assumptions that you have made.
Please explain how you would ensure smooth running of the IAMS environment. Please
explain how will you ensure smooth transition and assume responsibility of each module,
including the technical environment from the incumbent Service provider.
5.1.13 Service Level SLAs
Type of
request
Acknowledgment
of request
Guidance on
expected
time to
resolve - On
best-effort-
basis
Initial
Resolution
Final
resolution
or Fix
provided
Emergency
Priority
Within 2 hour 2-4 hours
Workaround and
agreed action
plan within 8
Hours.
As per the
agreed
action plan.
High
Priority
Within 4 hours 6-8 hours Workaround and
agreed action
plan for
resolution within
1 working day
As per the
agreed
action plan.
Low
Priority
Within 8 hours 12-18 hours Schedule for
resolution within
2 working days
As per the
agreed
action plan.
Query Within 12 hours 18-24 hours Response /
Schedule for
response with 3
working days
As per the
agreed
action plan.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
19
The SLA’s mentioned above are indicative and will be finalized on further discussion
with LESCO during the finalization of Agreement with implementer to be signed
separately after the issuance of work order.
5.1.14 Classification of Severity Levels
Following classifications will be used to identify and prioritize incoming support
requests:
Critical (Severity 0): The software is not functioning or is severely impaired. A
production server is down and is unable to restart or the problem resurfaces within
hours of a restart. A production server experiencing severe performance degradation
causing site to be unusable. Loss or corruption of data on a production server. A
major component or function has failed in production. Production is halted or
severely impacted by the problem. Immediate attention is necessary in Proposal to
reduce the problem priority to Severity 1 or lower.
High (Severity 1): The software is operational, but its functionality is seriously
affected. A production server is experiencing frequent failures which are addressed by
restarting the system. A production server is experiencing noticeable performance
degradation. A workaround is not possible or a workaround exists but is unacceptable
because of its impact on your business. If the problem results in project defect, that
defect will be fixed in next major release or patch and company will provide an
announcement when the patch or the release is available.
Low (Severity 2): This is the default classification. The software is useable, but
development or production is impacted. Development/production can continue for a
reasonable amount of time before the problem becomes critical. A workaround is
available and acceptable. If the problem results in product defect, that defect may be
fixed in a future release at the discretion of company.
Query (Severity 3): The software is useable, but you have a “how-to” question or
“would like to” submit an enhancement request for our product management team.
5.1.15 Infrastructure Requirements
The bidder shall propose the detail requirements (documentation only) with tentative
sizing of infrastructure and hardware i.e. server machines, storage etc by keep in view of
existing environment mentioned in section (4.3).
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
20
5.1.16 Special Conditions
Bid proposals should be separate for each LOT.
Proposals shall concisely address the Scope of Work specifications as they are
presented. Proposals not meeting our Scope of Work specifications may be rejected.
Bidder would be responsible for all the activities, except specific LESCO
responsibilities, required for successful rollout.
Bidder will submit along with technical bid, the proposed project organization
structure comprising of LESCO and bidder.
The bidder is required to define the project resources and clearly highlight the
responsibilities of LESCO.
Bidder will perform at-least two (2) trial test run before production and going live.
LECSO will approve the test and production environments before going live.
bidder shall provide the on-site support for maintenance period and production after
go-live for a period as per agreed b/w LESCO and bidder.
bidder to devise a strategy for minimizing the amount of downtime. It is currently
expected that 2 business days are maximum required for the go-live.
5.1.17 Price Summary
The bidder shall indicate the summary of price for all the main items separately in the
attached format appendix (B) as follows:
Required licenses
Implementation and Roll Out of Applications as per all the components of Scope
of Work
Post Production Support cost.
5.1.18 PAYMENT
A tentative Payment Plan is follow:
1. Payment for 100% of the licenses price will be made within four weeks after
project kick off and resource mobilization from the bidder at LESCO designated
office.
2. Implementation Cost will be made after the acceptance of deliverables as per the
following Schedule:
A. 20% after Acceptance of Requirement Specifications
B. 20% after submission of finalized system model and
implementation plan
C. 20% after Completion of User Acceptance Test
D. 25% Go live on agreed upon pilot sites (Here, Go-Live means 10
successful transactions with correct impacts on reports)
E. 15% after successful Rollout as per agreed upon Rollout Plan
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
21
i. The details of deliverables would be finalized in the agreement to be signed with
the successful bidder separately.
ii. Pilot sites will be decided after finalization of requirement specification and
system model
iii. After completion/signing off the deliverables as per above Payment Plan, bidder
will invoice which will be due for payment within 30 days of the date of filing the
payment application on production of following documents:
a) Bill in triplicate for the claimdue approved by the Director General (IT) LESCO
and pre-audited by office of Chief Financial Officer LESCO.
b) Deliverable acceptance certificate issued by Director General (IT) or his
authorized representative.
c) Confirmation of Director General (IT) about acceptance of Performance Bond in
case of the first claim.
d) Inspection/Acceptance Certificate issued by LESCO or his authorized
representative or otherwise as specified in Inspection clause 6.
e) GST amount will be deducted at the time of making payment as per FBR rules.
f) Professional Tax Paid Certificate by the firm.
g) The bidder in its invoices shall also give an undertaking that in case of omission
of any deductible amount, LESCO’s claim at any later stage (through pre-audit or
post audit) shall be acceptable to you.
h) While raising invoice for the material supplied or service delivered, the firm shall
vividly mention the account number as well as the name of the bank and branch
enabling Finance Director Office to release payment thereof accordingly.
i) Non-payment certificate.
5.1.19 INSPECTION/ACCEPTANCE
Inspection/Acceptance certificate shall be issued by DG (IT) or his authorized
representativeafter the completion of each phase of project as per agreed upon project plan.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
22
5.2 Asset Tagging
LESCO have around 120,000 transformers approximately as arrangement for
continuation of power supply. These transformers are installed &distributed in (191) Sub
Divisions of seven (7) operational Circles and on grid stations. Asset tags will be placed
on transformers only. All tags will be affixed to the asset in a conspicuous and convenient
location that is easily accessible for scanning and inventory purposes.
Quantity of Tags required: 120,000 approximately
Following specifications need to be considered
Asset tags should be durable for extreme outdoor (sunlight, raining etc) and
indoor conditions
Tags will be placed on Metallic surface
Temperature rages is -20C to 80C
Barcode tags that can be placed using welding or non removeable adhesive
material on transformers. Plate Size should be 2inch * 4 inch of stain less steel.
Barcode should be through and through
Quantity of Rugged Handheld Devices required: 300
Following specifications need to be considered
Androidsupported
With barcode scanner
Specifications needs to be compliance with IEC standards
Should be able to operate in extreme temperatures -20C – 50C
Integrated GPS & Wi-Fi are required
Should support 4G, 3G & EDGE
5.2.1 Special Conditions
Proposals should address the Scope of Work &specifications as presented in section
(5.2) of this document. Proposals not meeting our Scope of Work &specifications will
be rejected.
Bidder would be solely responsible for supply, installation, configuration,
functionally in operation and rollout at all locations where transformers are installed.
Estimated quantity of Asset Tags to be procured by LESCO is (120,000). LESCO
reserves the rights to deviate the quantity from -15% to +15% at the time of work
orderand during contract period.
Successful Bidder will be responsible to complete the task within 240 days of
issuance of work order. Work order for lot-2 will be issued late in comparison with
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
23
lot-1 and after requirement specification of lot-1. Initially about 1000 barcode plates
will be required for UAT of lot-1. Time period of 240 days will start after successful
user acceptance test.
Time period for supply of barcode plates and H.H devices will be mentioned in work
order separately.
Successful Bidder shall provide the services for whole solution after
installation/implementation for a warranty period (free of cost) of one yearand
support period (after warranty period) of initially one year extendable on yearly basis
with the consent of both the parties.
During installation, warranty and support period, the successful bidder will be
responsible for all charges i.e. replacement of tags, installation, logistics, travel &
labor charges, deployment, user trainings & maintenance of devices and OS.
SLA (Service Level Agreement) for devices will be signed afterissuance of work
order with the successful bidder and will be observed strictly during the course of
contract. The Successful bidder will also be responsible to provide the service
monitoring mechanism to ensure the quality service benchmarks to be decided in
SLA.
5.2.2 PAYMENT TERMS
Payment will be done as per the following schedule after acceptance of deliverables:
a. 100% Payment will be done for Handheld devices upon complete
consignment delivery
b. Tags payment will be made within 2 weeks upon receiving for the quantity
received
Payment (including Sales Tax) of one time cost will be made as presented in section (5.2)
of this document and would be processed for payment as per procedures of LESCO by
Chief Financial Officer LESCO on production of following documents;
i. Bill in triplicate with bank account number as well as the name of the bank
and branch duly approved by the Director General (IT) and pre-audited by the
Chief Financial Officer LESCO
ii. Delivery challan and GRN duly stamped and signed by the consignee
iii. Warranty Certificate
iv. Confirmation of Director General (IT) about acceptance of Performance Bond.
v. Inspection Certificate issued by Director General (IT) or their representatives.
vi. Non-Payment Certificate
vii. Professional Tax Paid Certificate by the firm.
viii. The bidder in its invoices shall also give an undertaking that in case of omission
of any deductible amount, LESCO’s claim at any later stage (through pre-audit or
post audit) shall be acceptable to you.
Remaining 20% will be paid after successful installation along with installation cost
Installation cost will be made within four Weeks . The selected agency will
submit a bill to Director General (IT) and would be processed for payment as per
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
24
procedures of LESCO by Chief Financial Officer LESCO on production of
following documents;
i. Bill in triplicate with bank account number as well as the name of the bank
and branch duly approved by the Director General (IT) and pre-audited by
the Chief Financial Officer LESCO
ii. Installation certificate by relevant SDO of LESCO or their
representatives.
iii. Non-Payment Certificate
8.3 The payment of Sales Tax (if applicable) or any other tax shall be made by Chief
Financial Officer LESCO on production of return cum payment challan. In case
of lump sum payment, the bidder shall also submit an affidavit on non-judicial
paper that the challan includes the amount of Rs. ___________ of Sales Tax for
supply of the mentioned services.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
25
6. BIDDERS SELECTION CRITERIA
1. The Bidder shall provide company's name and address, and the primary RFP contact's
name, phone number, e-mail address and fax number.
2. List of your customers using the service covered by this Bid similar in size, and
geographical presence.
Customer name and address
Customer employee size
Contact names and telephones (business and technical)
Brief description of the service provided
How long has Customer been using Bidder to provide services?
Describe the relevant aspects of your staffing:
Bidder’s organizational structure with a chart
List the name and location of primary individual(s) who would be responsible for
our account and provide brief biographies including titles, functions, academic
credentials, and relevant experience. Include the role of each consultant for this
assignment, the role of back-up personnel and how many clients are assigned to
each person named above?
The bidder must meet following criteria to be able to qualify for bidding:
The Bidder must have attained partnership with the principle
The Bidder must have at-least two successful implementations of
Integrated Asset Management System in its credit (Documentary Proof
Required)
The Bidders must have annual revenue more than 50 million in Financial
Year for each of last 3 years. (Financial Statement Required)
7. INSTRUCTIONS TO BIDDERS
1. The quoted price (in Pak Rupee) must be separated for each LOT, firm, final and
exclusive of all Government taxes/charges except licenses and support renewals.
Which will also be payable in Pak Rupee.
2. The bidders will submit bid bond 2% separated for each LOT in the form of Bank
Draft or CDR, WAPDA Bearer Bond/Non-Judicial Stamp Paper in favor of Chief
Executive Officer LESCO along with the financial bid. However, the bidder will
attach a certificate with technical bid that bid bond, without mentioning amount, has
been attached with financial bid. The bid security from any insurance company will
not be acceptable in any case and bid will be liable to rejection.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
26
3. The bidder should explain if any fault logging procedure/mechanism is already in
place. The firm must be able to define a guaranteed response time after acomplaint is
lodged.
4. Bids deviating above terms and conditions will be treated as non-responsive.
5. The bid will be declared technically responsive if scores 70% or more points of
technical facts. The technical factors are defined at Appendix-A
6. A single stage two parts procedure is opted in evaluation of the bids, with evaluation
of the technical bid being completed prior to any commercial bid being opened and
compared. The financial bids will be opened only of those firms who scores minimum
70% of technical points. The financial bids of the firms scoring less than 70% in
technical evaluation will be returned unopened.
8. CONSIGNEE
LESCO IT DIRECTORATE
NEW GHAZI GRID STATION
BURKI ROAD, LAHORE
9. SUBMISSION OF BID
Potential Bidder(s) must submit 02 separate copies of technical and financial bids marked as
“ORIGINAL” and “COPY”.
Bids may be submitted to the undersigned in SEALED ENVELOPS i.e. technical and
financial separately atthe address given below on 29-08-2016 at 11:00 am”. Technical
proposals of the bids submitted will be opened publicly on the same date at 11:30 am.
LESCO IT DIRECTORATE
NEW GHAZI GRID STATION
BURKI ROAD, LAHORE
10. LATE BID
Bidder will himself be responsible for ensuring that his bid is submitted in accordance with the
instructions stated herein. Any bid submitted after the deadline prescribed for submission of
the bids will not be considered even if it becomes late as a result of circumstances beyond the
bidder’s control.
11. RIGHTS RESERVED BY THE LESCO
i. If at any future point of time, it is found that the bidder had made a statement
which is factually incorrect, the LESCO reserves the right to debar the bidder
from bidding prospectively for a period to be decided by LESCO and take any
other action as may be deemed necessary.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
27
ii. LESCO reserves the right to accept or reject offers as per PPRA rules. The offer
received incomplete or not in accordance with the terms and
conditions/specifications as laid down in the tender document will not be
entertained. Bid offered is likely to be ignored if;
a. The tender is unsigned.
b. It is received after the time and date fixed for its receipt.
c. Offer is ambiguous or conditional.
iii. Further, LESCO shall have the right to cancel or amend the tender process at any
time without assigning any reason, prior to finalization of the bidding process.
Without thereby incurring any liability to the affected bidder or bidders. Reasons
for cancellation will be determined by LESCO at its sole discretion. However, any
amendment would be communicated to prospective bidders well in time.
iv. The decision of LESCO in all matters will be final and binding on all bidders
participating in this bid.
12. FAILURE AND TERMINATION
(A) If bidder fails to deliver the services in accordance with the agreed upon
timelines, the purchaser shall be entitled at his option either;
i) To recover from you liquidated damages levied at the rate of two percent (2%)
per month or a fraction thereof, subject to a maximum of ten percent (10%) of
the Contract Price, except;
a) Where un-delivered service/deliverable hold up the use of other
Services/deliverables, liquidated damages shall be levied on the total
value of the Contract.
b) The recovery of liquidated damages mentioned above can be effected
from any payment due to you from any unit of
LESCO/DISCOs/GENCOs/NTDC/WAPDA, or
ii) To purchase services from elsewhere without notice to you at your risk and
cost, the services not delivered, without canceling the contract in respect of
the consignment not yet due for delivery.
iii) To cancel the contract at your risk and cost;
In the event of action being taken under (ii) or (iii) above, you shall be liable for any
loss which the purchaser may suffer on the account; but you shall not be entitled to
any gain on repurchase made against the supply order.
(B) If during the course of execution of contract, you are black-listed by
DISCOs/GENCOs/NTDC/WAPDA/LESCO, or any other Electric Supply
Company, the purchaser may proceed with all or any of the actions detailed
below:
i) to allow the contract to run its course till completion in accordance
with the terms and conditions of Contract.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
28
ii) to stop further services with or without financial repercussions;
iii) to cancel the contract with or without reservation or rights.
NOTE:
While determining liquidated damages the purchaser shall not consider any of the
following circumstances, a cause under “FORCE MAJEURE” and shall not allow any
relaxation in the liquidated damages on the account:-
i) Delay on the part of the contractor in the arrangement of requirements under
its scope.
ii) Defect or failure occurring to any module/deliverable installed at the
contractor works during the currency of the contract.
The purchaser may proceed with all or any of the actions detailed below:
i) To allow the contract to run its course till completed in accordance with the
terms and conditions of Contract.
ii) To stop further services with or without financial repercussions;
iii) To cancel the contract with or without reservation or rights.
13. GENERAL INSTRUCTIONS FOR THE BIDDERS
The bidders are required to carefully note the following instructions, terms & conditions
etc:
i. A Bid not submitted in conformity with the specifications/terms & conditionsshall
not be considered by LESCO.
ii. Bidder firm has not been blacklisted by any Government/Semi Government
organization.
iii. LESCO reserve the right to modify the bidding documents at any time prior to the
deadline for submission of bids, on the request of the prospective bidders for any
clarification or at its own initiative, for any reason. This amendment shall
constitute part of the biding documents. In order to afford the prospective bidders
a reasonable time to take the amendments into account in preparing its bid,
LESCO may at its discretion extend the deadline.
iv. The bidder shall prepare Technical and Financial Bid separately, clearly marking
each as “TECHNICAL” and “FINANCIAL”. In case of any discrepancy between
the TECHNICAL and FINANCIAL, the TENCHNICAL proposal shall prevail.
The bidder shall seal the Technical proposal and the financial bids separately in
an INNER and an OUTER envelope, duly marking the envelopes as
“TECHNICAL” and “FINANCIAL”. Bid submitted in single envelope will be
disqualified.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
29
14. THE FINANCIAL BID SHALL COMPRISE OF THE FOLLOWING
The quoted price shall be inclusive of costs services at the designate rollout sites
in LESCO.
i. Conditional Bids/Rates offered in other currencies except Pak Rupees will not be
entertained/accepted.
ii. Successful bidders have to furnish 5 % of the value of implementation cost and
one year support as security in shape of Demand Draft or Bank Guarantee in favor
of the office entering into said maintenance contract valid for the contract period
starting from the date of signing contract. The same shall be released after expiry
of the contract.
iii. All proposal and price shall remain valid for a period of 120 days from the
closing date of the submission of the proposal. However, the responding
organization is encouraged to state a longer period of validity for the proposal.
iv. Bid submission / tender opening date & timings shall be observed strictly.
15. FORFEITURE OF SECURITY BOND/GUARANTEE (PERFORMANCE
BOND)
The contracting officer will have the right to forfeit the security Bond/Guarantee
(performance bond)
A) If the bidder:
(i) Fails to supply the goods/services within the time specified;
(ii) Commits any breach of contract;
B) For other reasons specified in the Purchase Order by the contracting officer for
forfeiting the security deposit.
If the forfeiture of the security deposit does not compensate the contracting officer for
losses suffered due to non-delivery or breach of contract for any other reasons, the
Contracting Officer will have a right to forfeit other security deposits or to recover the
same from any other security deposit made in favor of any other unit of
DISCOs/GENCOs/NTDC/LESCO or from any money due to the Contractor from any
unit of WAPDA/LESCO/DISCOs/GENCOs/NTDC.
16. COST OF BIDDING
The bidder shall bear all the costs associated with the preparation and submission of its
bid, and the purchaser will in no case be responsible or liable for those costs, regardless of
the conduct or outcome of the bidding process.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
30
17. CLARIFICATION OF BIDDING DOCUMENT
A prospective bidder requiring any clarification of the bidding document may notify
the purchaser in writing at the purchaser address indicated in the bid date sheet. The
purchaser will respond in writing at three days.
18. LANGUAGE OF BID
The bid prepared by the bidder shall be written in the English, supporting documents and
printed literature furnished by bidder may be in another language provided they are
accompanied by accurate translation in English, for purpose of interpretation of the bid.
19. BID PRICES
In accordance to the Bid Prices format attached as appendix (B)
20. BID SECURITY
i. The bidder shall furnish, as part of its bid, a bid security in the amount specified.
ii. The bid security is required to protect the purchaser against the risk of
bidder’sconduct, which would warrant the security’s forfeiture.
iii. The bid security may be forfeited
If a bidder;
a) Withdraws its bid during the period of bid validity specified by the bidder on
the bid form, or
b) Does not accept the correction of error or in case of a purchaser bidder, if the
bidder fails
c) To sign the contract in accordance with the clause of contract or
d) To furnish performance security in accordance with clause of contract after
issuance of LOI
21. PRELIMINARY EXAMINATION
i. The purchaser will examine the bid to determine whether they are complete, whether
any computational errors have been made, whether required sureties have been
furnished, whether the documents have been properly signed and whether the bids are
generally in order.
ii. Arithmetical error will be rectified on the following basis, if there is a discrepancy
between the unit price and the total price that is obtained by multiplying the unit price
and quantity, the unit price shall prevail and the total price shall be corrected. If there
is a discrepancy between words and figures, the amount in words will prevail, if the
suppliers not accept the correction of the errors, its bid will be rejected and its bid
security may be forfeited.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
31
22. FORCE MAJEURE
i. Notwithstanding the provision of GCC Clauses, the supplier shall not be liable for
forfeiture of its performance security, liquidated damages, or termination for default if
and to the extent that it’s delay in performance or other failure to perform its
obligations under the contract is the result of events of Force Majeure.
ii. For purpose of this clause “Force Majeure” means an event beyond the control of the
supplier and not involving the supplier’s fault or negligence and no restricted to act of
the purchaser, epidemics, quarantine restrictions and freight embargoes.
iii. If a Force Majeure situation arises, the supplier shall continue to perform its
obligations under the contract as far as is reasonably practical and shall seek all
reasonable alternative means for performance not prevented by the Force Majeure
event.
23. THE TECHNICAL BID SHALL COMPRISE OF THE FOLLOWING
i. The bid not in accordance with the terms and conditions mentioned in the bidding
document will be rejected by LESCO as disqualified.
i. The Proposed bid shall contain no interlineations, or over-writing except as
necessary to correct errors made by the Bidder, themselves. The person signing the
proposal shall initial any such correction.
ii. The inner and outer envelopes shall be;
a. Addressed to the following address.
i. Director General (IT) LESCO, Ghazi Grid Station, Barki Road,
Lahore Tender No.__/2015-16 and the words “DO NOT OPEN
BEFORE (Opening time) on (Opening Date) “shall by written on
them.
b. In addition to above, the inner envelope shall indicate the name and address
of the Bidder to enable the bid to be returned unopened incase it is declared
“Late”.
iii. Every bid shall be scrutinized by LESCO to see that it meets the criteria as laid
down in the bidding documents, prior to the detailed evaluation of the same. A
substantially responsive bid is one which:
a. Is accompanied by the certificate of acceptable securities with the
financial bid;
b. Meets the major technical criteria specified in the schedule;
c. Offers clear price i.e. the bid do not offer an escapable price quotation;
d. Is otherwise complete and generally in order;
e. Conforms to all the terms, conditions and specifications of the bidding
documents;
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
32
iv. The acceptability of a bid shall be determined on the basis of the contents of the
bid itself. However, LESCO reserves the right to seek any extrinsic evidence if
needed.
v. A bid found substantially in accordance with the bidding documents shall be
checked by LESCO for any arithmetic errors. If any discrepancy is found between
the unit rate and the total price resulting from multiplying the unit rate by the
quantity, the unit rate as quoted will prevail and the total price shall stand
corrected. Unless in the opinion of LESCO there is an obvious gross
misplacement of the decimal point in the unit rate, in such a case the total price as
quoted will prevail and the unit rate will be corrected, and where there is a
discrepancy in the total price quoted in the price schedule vis-à-vis addition of
each item, the total of the itemized prices will govern.
vi. Any pressure by a bidder to influence LESCO in its decision making shall result
in the rejection of its bid.
vii. LESCO will determine to its satisfaction whether the bidder has offered prices
consistent with the current prevailing market prices.
24. DOCUMENTS / SAMPLES / CERTIFICATES TO BE SUBMITTED ALONG
WITH THE BID
i. Bid security of an amount not less than 2% of the total value for each LOT
separately of tender issued by a scheduled bank of Pakistan only (or as applicable
if specified in the special condition above). The bid money is to be attached with
financial bid and only certificate will be attached with technical bid that bid
money is attached with financial bid.
ii. Certificate that the services offered is in accordance with the tender specifications
amended to-date.
iii. List of any deviations or reservations from the bid specifications.
iv. Copy of letter of current renewal of registration with WAPDA/DISCOs if
applicable
v. Technical data as required in the specification and literature in English giving out
salient feature of the quoted items.
vi. Deposit receipt of tender fee in original.
25. LAWS GOVERNING THE CONTRACT
i. The contract shall be governed by the Laws of Pakistan as amended from time to
time
ii. Subject to the above conditions, a binding contract has been concluded with the
issuance of this letter and that the provisions of this contract shall be binding on
you, on your assigns, executors, administrators and all those who have any
interest pecuniary or otherwise in your concern.
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
33
Imtiaz Ahmad Butt
Director General (IT)
132-KV Ghazi Grid Station
Barki Road, Lahore
Ph: 92-42-36636815, Fax: 92-42-36636814
Email: [email protected]
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
34
26. GLOSSARY
ERP Enterprise Resource Planning
IAMS Integrated Asset Management System
EBS E-Business Suite
RFP Request for Proposal
IT Information Technology
FAT Final Acceptance Test
PAT Preliminary Acceptance Testing
PEP Performance Evaluation Period
SPE System Performance Evaluation
NA Not Applicable
QA Quality Assurance
AIM Application Implementation Methodology
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
35
27. APPENDIX (A): TECHNICAL EVALUTION CRITERIA (LOT 1/ LOT 2)
Sr. # Factors Points
1.
Company Profile
1. Office Location
Main Office Located at Lahore= 04Points
Branch office at Lahore = 02 Points
2. Age of Company
Existence of Company Over ten (10) Years = 04 Points
Existence of Company less than ten (10) years = 02 Points
3. Financial strength
Last Three year Audited Report of the Company = 02 Points
10
2.
Relation with Principal
Platinum level or equivalent= 05 Points
Gold level or equivalent = 03 Points
05
3.
Implementation Experience
Number of relevant projects in public/private sector where (Only one
project by one client will be considered. ).
Attach List of Clients public/private having minimum
financial worth of 50 million with Appropriate
References(Completion Certificate should attach in the proposal)
o Each Project = 5 Points
15
4
Technical Staff Number of relevant technical staff (Employment prove must be attached)
S.
No.
Name Designation Total
Experience
Experience with
present employer
o Each experienced IAMS professional = 1 Point
o Each Certified IAMS professional = 2 points
20
6.
Project Management Staff
Certified Project Management Professional (PMP)
o Each Professional= 2 Points
04
7. Technical positive compliance against the requirements of the
Scope of work & Implementation Methodology. 6
Total 60
Minimum 42 Points are required for the bidder to qualify for the bidding
process.
28. APPENDIX (B): BID PRICES FORMAT (LOT 1)
NOTE:
i. Assumption: Initially license is valid for one year.
ii. Implementation cost will also be included
a. Cost of Implementation services including one year warranty period.
b. Principle support/license renewal cost of implementation period (if proposed project plan exceeds one year)
c. Principle support renewal cost of warranty period.
iii. The rates will be exclusive of all applicable taxes
iv. Currency conversion rate (for License only) is applicable according to State Bank of Pakistan declared rates and
variation payable policy.
SR# Application details
Cost
License
(One time cost)
Implementation
cost
Annual Support
Trainings Cost (if any) License
renewal Support
1
TOTAL
Lahore Electric Supply Company Ltd.
Tender (Request for Proposal)
37
29. APPENDIX (B): BID PRICES FORMAT (LOT 2)
Nature of Cost Particulars
Estimated
Quantity
Per Unit Cost Installation Cost Total Cost
One time Cost
Asset Tags including installation
as mentioned section (5.2) of this
document
120,000
Handheld Devices 400
Reoccurring Cost Per Annum (For support period) Note:
1) Price offered shall be Firm during the currency of the Contract Period.