Upload
others
View
0
Download
0
Embed Size (px)
Citation preview
UNITED STATES DISTRICT DISTRICT OF MAINE
United States of America,
Plaintiff, ;
v. ; t t
Anson, Inc. ]
Arkwright, Inc. ; Arlon, Inc. (Laminates Division of ] Keene Corporation) ]
Axton Cross Company, Inc. j Boston Whaler, Inc. (Rockland) j Cincinnati Milacron-Heald Corporation ) Clean Harbors, Inc. ) Colgate-Palmolive Company )
(Etonic, Inc./Charles A. Eaton Co.) )
Commercial Disposal Company, Inc. ) Davidson Rubber Company, Inc. ) Digital Equipment Corporation ) Eastern Fine Paper, Inc. ) Ekco Group, Inc. (Centronics )
Data Computer Corporation) )
Ellis Paperboard Products, Inc. ) Emhart Industries, Inc. )
(Fellows Corporation) ) Fenwal, Inc. ) Flexcon Company, Inc. ) Fonda Cup & Container Group )
(Paper Corp. of America) ) Forster Manufacturing Company, Inc. ) General Electric Company )
Great Falls Products Co. ) Haartz Corp. (Haartz Auto ) Fabric Company) )
Hazen Paper Company ) IMC Magnetics Corporation ) New Hampshire Division )
International Packings Corporation ) Irving Tanning Company ) Jet-Line Services, Inc. ) Jones & Vining, Inc. ) Laidlaw Environmental Services )
(Northeast), Inc. (Northeast Solvents)) Maine Department of Transportation ) Maine Pearl Essence )
(EM Industries, Inc.) ) Mearl Corporation )
92Jlf:,'l6 FMl»:33
BY =
SDMS DocID 262365
CIVIL ACTION NO.
Nashua Corporation ) NEPTCO, Inc. (New England Printed )
Tape Company) )
Newport Plastics Corporation )
Nike Incorporated - Blue Ribbon Sports )
O.K.P. Inc. (Kyanize Paints, Inc.) ) Philips Elmet Corporation )
Pioneer Plastics Corporation )
Prime Tanning Company, Inc. )
Pro Corporation, The ) Sabre Yachts ) Saco Defense, Inc. ) Sanborn's Motor Express, Inc. )
Service Chemical Co. ) Stanley-Bostitch Inc. )
Security )
Heel Company )
Steego Corporation (Steego/Farrar-Brown ) Auto Parts) )
Thompson Tool Company, K W )
Troy Mills, Inc. ) Union Industries, Inc. )
Upaco Division of ) Worthen Industries, Inc. )
Vermont Tap & Die (Vermont American ) Corporation) )
Vernon Plastics Co. - Division of ) Borden Industries )
Vulcan Corporation ) Waterlac Industries, Inc. ) Watts Fluid-Air, Inc. (Division of )
Robert Shaw Controls Company) )
Wes, Inc. (Maine Coastal Services) ) Wilner Wood Products Co. ) Xidex Corporation Anacorp. Inc.) )
)
Defendants.
State of Maine, ) )
Plaintiff, ) )
v. ) )
Anson, Inc. )
Arkwright, Inc. )
Arlon, Inc. (Laminates Division of )
Keene Corporation) )
Axton Cross Company, Inc. )
Boston Whaler, Inc. (Rockland) )
Cincinnati Milacron-Heald Corporation )
Clean Harbors, Inc. )
Colgate-Palmolive Company ) (Etonic, Inc./Charles A. Eaton Co.) )
Commercial Disposal Company, Inc. )
Davidson Rubber Company, Inc. )
Digital Equipment Corporation )
Eastern Fine Paper, Inc. )
Ekco Group, Inc. (Centronics )
Data Computer Corporation) )
Ellis Paperboard Products, Inc. )
Emhart Industries, Inc. )
(Fellows Corporation) )
Fenwal, Inc. )
Flexcon Company, Inc. ) CIVIL ACTION Fonda Cup & Container Group ) No.
(Paper Corp. of America) ) Forster Manufacturing Company, Inc. )
General Electric Company ) Great Falls Products Co. ) Haartz Corp. (Haartz Auto )
Fabric Company) )
Hazen Paper Company ) IMC Magnetics Corporation )
New Hampshire Division )
International Packings Corporation ) Irving Tanning Company )
Jet-Line Services, Inc. )
Jones & vining, Inc. ) Laidlaw Environmental Services )
(Northeast), Inc. (Northeast Solvents)) Maine Department of Transportation ) Maine Pearl Essence )
(EM Industries, Inc.) )
Mearl Corporation ) Nashua Corporation ) NEPTCO, Inc. (New England Printed ) Tape Company) )
Newport: Plastics Corporation ) Nike Incorporated - Blue Ribbon Sports )
O.K.P. Inc. (Kyanize Paints, Inc.) )
Philips Elmet Corporation )
Pioneer Plastics Corporation )
Prime Tanning Company, Inc. ) Pro Corporation, The ) Sabre Yachts ) Saco Defense, Inc. ) Sanborn's Motor Express, Inc. )
Service Chemical Co. )
Stanley-Bostitch Inc. )
Secur ity )
Heel Company )
Steego Corporation (Steego/Farrar-Brown )
Auto Parts) )
Thompson Tool Company, K W )
Troy Mills, Inc. )
Union Industries, Inc. )
Upaco Division of )
Worthen Industries, Inc. )
Vermont Tap & Die (Vermont American )
Corporation) )
Vernon Plastics Co. - Division of ) Borden Industries )
Vulcan Corporation )
Waterlac Industries, Inc. )
Watts Fluid-Air, Inc. (Division of ) Robert Shaw Controls Company) )
Wes, Inc. (Maine Coastal Services) ) Wilner Wood Products Co. ) Xidex Corporation Anacorp. Inc.) )
)
Defendants. )
CONSENT DECREE
Page
I. BACKGROUND 1
II. JURISDICTION 4
III. PARTIES BOUNp 5
IV. DEFINITIONS 6
V. GENERAL PROVISIONS 13
VI* PERFORMANCE OF THE WORK BY SETTLING DEFENDANTS 16
VII. U.S. EPA PERIODIC REVIEW TO ASSURE PROTECTION OF HUMAN HEALTH AND ENVIRONMENT .... 26
VIII. ADDITIONAL WORK 26
IX. QUALITY ASSURANCE; SAMPLING 28
X. ACCESS AND INSTITUTIONAL CONTROLS 30
XI. REPORTING REQUIREMENTS 33
XII. SUBMISSIONS REQUIRING AGENCY APPROVAL 36
XIII. REMEDIAL PROJECT MANAGER/PROJECT COORDINATORS . . 38
XIV. ASSURANCE OF ABILITY TO COMPLETE WORK? 40
XV. TRUST FUND 42
XVI. CERTIFICATION OF COMPLETION OF WORK 44
XVII. ENDANGERMENT AND FUTURE RESPONSE 46
XVIII. REIMBURSEMENT OF RESPONSE COSTS 47
XIX. INDEMNIFICATION AND INSURANCE 50
XX. FORCE MAJEURE 52
XXI. DISPUTE RESOLUTION 55
XXII. STIPULATED PENALTIES 60
XXIII. COVENANTS NOT TO SUE BY PLAINTIFFS 64
XXIV. EFFECT OF SETTLEMENT; CONTRIBUTION PROTECTION. . . 70
Page
XXV. COVENANTS BY SETTLING DEFENDANT? 71
XXVI. ACCESS TO INFORMATION 71
XXVII. RETENTION OF RECORDS 73
XXVIII. NOTICES AND SUBMISSIONS 74
XXIX. EFFECTIVE DATE 75
XXX. RETENTION OF JURISDICTION 76
XXXI. TERMINATION 76
XXXII. MODIFICATION 77
XXXIII. COMMUNITY RELATIONS 78
XXXIV. LODGING AND OPPORTUNITY FOR PUBLIC COMMENT .... 78
XXXV. SIGNATORIES 79
LIST OF APPENDICES
I. RECORD OF DECISION fRODl
II. STATEMENT OF WORK
III. SITE MAP
IV. SETTLING DEFENDANTS
I. BACKGROUND
The United States of America ("United States"), on behalf of
the Administrator of the United States Environmental Protection
Agency ("EPA"), and the State of Maine (the "State") filed
complaint[s] in this matter pursuant to the Comprehensive
Environmental Response, Compensation, and Liability Act, 42
U.S.C. §§ 9606, 9607, as amended, and applicable Maine law;
The United States in its complaint seeks: (1) reimbursement
of costs incurred by EPA and the Department of Justice for
response actions at the Union Chemical Company, Inc. Superfund
Site in South Hope, Maine (the "Site"), together with accrued
interest; (2) performance of studies and response work by the
Defendants at the Site in conformity with the Record of Decision
(as defined below) and the National Contingency Plan, 40 C.F.R.
Part 300, as amended ("NCP"); (3) declaration of Defendants'
liability for further response costs; and (4) such other relief
as the Court finds appropriate.
In accordance with Section 121(f) of CERCLA, 42 U.S.C. §
9621(f), EPA notified the State of Maine on January 7, 1991 of
negotiations with the potentially responsible parties ("PRPs")
for the Site regarding the scope of the remedial design and
remedial actions for the Site, and EPA has provided the State
with an opportunity to participate in such negotiations and be a
party to this Consent Decree;
The State of Maine has also filed a complaint against the
Defendants alleging that the Defendants are liable to the State
under Section 107 of CERCLA, 42 U.S.C. § 9607 and 38 M.R.S.A. §
1367 for: (1) reimbursement of costs incurred or to be incurred
by the State in connection with the Site; (2) declaration of
Defendants' liability for further response costs; (3) natural
resource damages; and (4) such other relief as the Court finds
appropriate.
In accordance with Section 122(j) of CERCLA, 42 U.S.C. §
9622(j), EPA on January 10, 1991 notified the Federal Natural
Resource Trustees of negotiations with the PRPs regarding the
scope of the remedial design and remedial action at the Site, and
has encouraged the participation of the Trustees in such
negotiations;
Pursuant to Section 105 Of CERCLA, 42 U.S.C, § 9605, EPA
proposed the Union Chemical Company, Inc. Site in South Hope,
Maine for inclusion on the National Priorities List, which is set
forth at 40 C.F.R. Part 300, Appendix B, in April, 1985. The
Site was later reproposed for inclusion on the National
Priorities List in June, 1988. Pursuant to Section 105 of
CERCLA, 42 U.S.C. § 9605, the Site was placed on the National
Priorities List on October 4, 1989, by publication in the Federal
Register, 54 Fed. Reg. 41000;
In 1988, in response to a release or a substantial threat of
a release of a hazardous substance at or from the Site, certain
potentially responsible parties commenced a Remedial
Investigation and Feasibility Study ("Rl/FS") for the Site
pursuant to 40 C.F.R. § 300.68 (1985) and 40 C.F.R. § 300.400
(1990), under the oversight of EPA and the State;
EPA issued a Remedial Investigation/Feasibility study Report
dated June 1990;
On July 5, 1990, pursuant to Section 117 of CERCLA, 42
U.S.C. § 9617, EPA published notice of the issuance of the FS and
of the proposed plan for remedial action and provided opportunity
for public comment on the proposed plan for remedial action;
Certain persons, including certain Defendants, have provided
comments on EPA's proposed plan for remedial action, and to such
comments EPA has provided a summary of responses;
The decision by EPA on the selected remedy is embodied in
the Record of Decision ("ROD"), executed on December 27, 1990, to
which the State has given its concurrence. The ROD includes a
discussion of the reasons EPA selected the remedy and an
explanation of any significant changes in the selected remedy
from that proposed;
Pursuant to Section 117(b) and (d) of CERCLA, 42 U.S.C. §
9617 (b) and (d), EPA provided public notice on January 3, 1991 of
its adoption of the final remedial action plan embodied in the
form of the ROD, including notice of the ROD'S availability to
the public;
EPA, the State, and Defendants agree that the remedy
selected in the ROD as adopted by EPA and embodied herein is
protective of the public health and the environment and is
consistent with CERCIA and the National Contingency Plan ("NCPM);
The United States and the State and certain Defendants named
in the Complaint desire to settle their alleged liability for
this matter. Based on the information currently available to EPA
and the State, EPA and the State believe that the Work will be
done properly and conducted promptly by the Settling Defendants.
The Parties have entered into this Consent Decree at arms'
length and in good faith, and the Settling Defendants do not
thereby admit to any facts alleged in the complaint[s] or in this
Consent Decree or to any liability arising out of or associated
with the transactions or occurrences alleged in the complaint[s].
The Parties recognize, and the Court by entering this
Consent Decree finds, that implementation of this Consent Decree
will expedite the cleanup of the Site, will avoid prolonged and
complicated litigation between the Parties, and that entry of
this Consent Decree is therefore fair, reasonable and in the
public interest;
NOW, THEREFORE, it is hereby Ordered, Adjudged, and Decreed:
II.
JURISDICTION
1. This Court has jurisdiction over the subject matter of
these actions pursuant to the following: 28 U.S.C. §§ 1331 and
1345; 42 U.S.C. §§ 9606, 9607, and 9613(b); 42 U.S.C. § 6973; and
pendent jurisdiction over the claims asserted by the State
arising under the laws of Maine. This Court also has personal
jurisdiction over the Defendants. Venue in this District is
proper under 42 U.S.C. § 9613(b). For purposes of this Consent
Decree and the underlying complaint[s], Defendants waive all
objections and defenses that they nay have to personal
jurisdiction and to jurisdiction of the Court or to venue in this
District. The complaint[s] state claims against Defendants upon
which relief may be granted. Defendants shall not challenge this
Court's jurisdiction to enter and enforce this Consent Decree.
III.
PARTIES BOUND
2. This Consent Decree applies to and is binding upon the
Settling Defendants and their directors, officers, employees,
agents, successors, assigns, trustees, heirs and contractors, the
United States on behalf of EPA, and the State of Maine on behalf
of DEP. Any change in ownership or corporate status of a
Settling Defendant, including any transfer of property, shall in
no way alter such Settling Defendant's responsibility under this
Decree. Settling Defendants shall provide a copy of this
Consent Decree to any contractor(s) and subcontractor(s) hired to
perform the Work required by this Consent Decree and shall
condition all contracts and subcontracts entered into hereunder
upon performance of the Work in conformity with the terms of this
Consent Decree. Settling Defendants shall nonetheless be
required to perform the Work in accordance with this Consent
Decree. With regard to the Work undertaken pursuant to this
Consent Decree, each of the Settling Defendants' contractors and
subcontractors shall be deemed to be related by contract to the
Settling Defendants for the purposes of Section 107(b)(3) of
CERCLA, 42 U.S.C. § 9607(b)(3). Thus, as to acts or omissions of
contractors, the Settling Defendants shall not assert a defense
to a claim made by Plaintiffs based upon CERCLA Section
107(b)(3), 42 U.S.C. § 9607(b)(3).
IV.
DEFINITIONS
3. Unless noted to the contrary, the terms of this Consent
Decree shall have the meaning assigned to those terms by the
Comprehensive Environmental Response, Compensation, and Liability
Act of 1980, as amended, 42 U.S.C. §§ 9601 et seq. and its
implementing regulations and the Solid Waste Disposal Act, as
amended, 42 U.S.C. § 6901 et seq. Whenever the terms listed
below are used in this Consent Decree and the Appendices attached
hereto, the following definitions shall apply:
"Additional Work" shall mean all activities required by
Section VIII herein.
"CERCLA" shall mean the Comprehensive Environmental
Response, Compensation, and Liability Act of 1980, as amended, 42
U.S.C. §§ 9601 et seq.
"Contractor" shall mean the company or companies retained by
the Settling Defendants to undertake and complete the Work
required by this Consent Decree. Each contractor and
\ subcontractor shall be qualified to do those portions of the Work
for which it is retained.
"Day" shall mean a calendar day unless expressly stated to
be a working day. "Working day" shall mean a day other than a
Saturday, Sunday, or federal legal holiday. In computing any
period of time under this Consent Decree, where the last day
would fall on a Saturday, Sunday, or federal legal holiday, the
period shall run until the end of the next working day.
"Defendants" shall mean the Settling Defendants.
"DEP" shall mean the Maine Department of Environmental
Protection and any successor departments or agencies of the
State.
"DEP's Past Response Costs" shall mean all of the State's
costs, including but not limited to, payroll costs, contractor
costs, travel costs, laboratory costs, and interest and indirect
costs, that DEP has incurred with respect to the site prior to
the lodging of the Consent Decree. To the extent that the State
costs relate to work performed by outside contractors, "DEP's
Past Response Costs" shall include work performed prior to the
lodging of the Consent Decree regardless of whether the State has
been billed for such work prior to lodging.
"DEP's Future Response Costs" shall mean all costs related
to this Consent Decree which are recoverable under 38 M.R.S.A. §
1367 and which the State incurs in overseeing the Work,
including, but not limited to, payroll costs, contractor costs,
travel costs, laboratory costs, community relations costs, the
costs incurred pursuant to Section X [Access and Institutional
Controls], the costs incurred pursuant to Section XVII
[Endangerment and Future Response] and, to the extent provided by
38 M.R.S.A. S 1367, the costs of reviewing or commenting on
plans, reports or other items pursuant to this Consent Decree,
verifying the Work, or otherwise implementing or enforcing this
Consent Decree. DEP's Future Response Costs shall only include
costs incurred for work performed by or on behalf of the State
after the lodging of the Consent Decree.
"EPA" shall mean the United States Environmental Protection
Agency and any successor departments or agencies of the United
States.
"EPA's Future Response Costs" shall mean all costs relating
to this Site incurred by the United States after October 31, 1990
and costs incurred by the United States relating to this Consent
Decree which are not inconsistent with the NCP including, but not
limited to, direct and indirect costs that the United States
incurs in overseeing the Work, including, but not limited to,
payroll costs, contractor costs, travel costs, laboratory costs,
community relations costs, and the costs of reviewing or
developing plans, reports or other items pursuant to this Consent
Decree, verifying the Work, or otherwise implementing or
enforcing this Consent Decree; but specifically excluding,
however, those costs which Settling Defendants agree to pay
pursuant to Sections X and XVII herein and those costs for which
8
EPA retains a right of action pursuant to Sections VII and XXIII
herein.
"EPA's Past Response Costs" shall mean all costs, including
but not limited to, payroll costs, contractor costs, travel
costs, laboratory costs, and interest and indirect costs, that
the United States has incurred with respect to the Site prior to
October 31, 1990.
"Facility" shall have the meaning provided in Section 101(9)
of CERCLA, 42 U.S.C. § 9601(9).
"Hazardous Substance" shall have the meaning provided in
Section 101(14) of CERCLA, 42 U.S.C. § 9601(14).
"Institutional Controls" shall mean the deed restrictions
(other than the filing of the Consent Decree required under
Paragraph 7) and other appropriate requirements and controls
developed: (1) to prevent further migration of contaminated
groundwater at the Site and off the Site; (2) to restrict the use
of groundwater at the Site prior to the attainment of the
Performance Standards; (3) to limit human or animal exposure to
Waste Material; and (4) to ensure non-interference with the
performance of the Work.
"National Contingency Plan" or "NCP" shall mean the
National Contingency Plan promulgated pursuant to Section 105 of
CERCLA, 42 U.S.C. § 9605, codified at 40 C.F.R. Part 300,
including any amendments thereto.
"Operation and Maintenance" or "0 4 M" shall mean all
activities required under the Operation and Maintenance Plans
approved by EPA or developed by Plaintiffs pursuant to this
Consent Decree and the Statement of Work.
"Paragraph" shall mean a portion of this Consent Decree
identified by an arabic numeral.
"Parties" shall mean the United States, the State of Maine
and the Settling Defendants.
"Performance Standards" shall mean those cleanup standards,
cleanup levels, treatment standards, institutional controls and
other substantive requirements, criteria, or limitations set
forth in this Consent Decree, the ROD or in the SOW.
"Plaintiffs" shall mean the United States and its
department and agencies, and the State of Maine and its agencies
and departments, excluding the Maine Department of
Transportation.
"Record of Decision" or "ROD" shall mean the EPA Record of
Decision relating to the Site signed on December 27, 1990 by the
Regional Administrator, EPA Region I, and all attachments
thereto. The ROD is attached as Appendix I hereto.
"Remedial Action" shall mean all activities required by this
Consent Decree, except for Remedial Design and Operation and
Maintenance, but including Additional Work required under Section
VIII hereof, to be undertaken by the Settling Defendants.
"Remedial Action Work Plan(s)" shall mean the document(s)
submitted by Settling Defendants for implementation of Remedial
Action activities required under this Consent Decree and the
10
of Work (SOW), and any modifications tfiereto in
accordance with the Consent Decree and SOW.
"Remedial Design" shall mean those activities to be
undertaken by the Settling Defendants to develop the final plans
and specifications for the Remedial Action pursuant to the
Remedial Design Work Plan(s).
"Remedial Design Work Plan(s)" shall mean the document(s)
submitted by the Settling Defendants for implementation of
Remedial Design activities required under this Consent Decree and
the SOW, and any modifications thereto in accordance with this
Consent Decree and the SOW.
"Section" shall mean a portion of this Consent Decree
identified by a roman numeral and including one or more
paragraphs.
"Settling Defendants" shall mean those Defendants who are
listed in Appendix IV, and who both sign this Consent Decree, and
make payments required under Section XVIII, Paragraphs 49 and 50
of this Consent Decree.
"Site" shall mean the former Union Chemical Company
facility located in South Hope, Maine where disposal of Waste
Material was conducted, and in addition, those places where Waste
Material emanating from the Union Chemical Company facility has
come to be located. The Site is shown generally on the map
attached as Appendix III to this Consent Decree. The Site
includes approximately 12.5 acres of land along Route 17 formerly
owned by Union Chemical Company, Inc.
11
%fate" shall mean the State of Maine.
"Statement of Work" or "SOW" shall mean the statement of
work for implementation of the remedial design, remedial action,
and operation and maintenance of the remedial action at the site,
as set forth in Appendix II hereto and any modifications thereto
in accordance with this Consent Decree.
"Supervising Contractor" shall mean the contractor retained
by the Settling Defendants to carry out the Work under this
Consent Decree, and approved by EPA under Paragraphs 10 and 11.
"RCRA" (Resource Conservation and Recovery Act) shall mean
the Solid Waste Disposal Act, as amended, 42 U.S.C. §§ 6901 et
seq.
"United States" shall mean the United States of America,
including the United States Environmental Protection Agency.
"Waste Material" shall mean (1) any substance meeting the
definition provided in Section 101(14) of CERCLA, 42 U.S.C. §
9601(14); (2) any "pollutant or contaminant" under Section
101(33) of CERCLA, 42 U.S.C. § 9601(33); (3) any "hazardous
waste" under Section 1004(5) of RCRA, 42 U.S.C. § 6903(5); and
(4) any "hazardous substance" under 38 M.R.S.A. § 1362.
"Work" shall mean all activities Settling Defendants are
required to performed under this Consent Decree, including, but
not limited to, Remedial Design, Remedial Action, Operation and
Maintenance, and any Additional Work required to be undertaken
pursuant to Section VIII, except those required by Section XXVII
(Retention of Records).
12
V.
GENERAL PROVISIONS
4. Purposes of this Consent Decree
The purposes of this Consent Decree are to protect
public health, welfare and the environment from releases or
threatened releases of Waste Material at and from the Site by the
investigation, development, design and implementation of remedial
and monitoring programs by the Settling Defendants, and, to the
extent set forth herein, to reimburse Past and Future Response
Costs incurred by EPA and DEP.
5. Commitments by Settling Defendants
a. Settling Defendants agree jointly and severally to
finance and perform all Work at the Site in accordance with this
Consent Decree, including the Remedial Design, Remedial Action
and Operation and Maintenance activities set forth in Section VI
and in the SOW, and to reimburse the United States and the State
for Past and Future Response Costs and civil penalties to the
extent set forth in this Consent Decree.
b. In the event of the insolvency or other inability
of any one or more Settling Defendant to implement the
requirements of this Consent Decree, the remaining Settling
Defendants agree to complete all such requirements.
c. The Work set forth in Section VI and the SOW shall
be completed in accordance with the standards, specifications and
13
^ within the time periods as prescribed in Section VI and in the
SOW.
d. Settling Defendants shall assume any and all
liability arising from or relating to their acts or omissions in
the performance of the Work or their failure to perform fully or
to complete the requirements of this Consent Decree.
e. The Settling Defendants agree that with respect to
any action brought under CERCLA in the United States District
Court for matters related to this Consent Decree they will notify
the United States and the State within thirty (30) days of: the
initiation of such suit, first notice of trial, settlement, and
entry of judgment.
f. In any subsequent administrative or judicial
proceeding initiated by the United States (or the State) for
injunctive relief or other appropriate relief relating to the
Site, Settling Defendant(s) shall not assert, and may not
maintain, any defense or claim based upon the principles of
waiver or claim-splitting or otherwise based upon any contention
that the claims raised by the United States (or the State) in the
subsequent proceeding were or should have been brought in the
instant case; provided, however, that nothing in this paragraph
affects the enforceability of the covenants not to sue set forth
in Section XXIII.
6. permits
a. All Work undertaken by the Settling Defendants
pursuant to this Consent Decree shall be undertaken in accordance
14
with the requirements of all applicable or relevant and
appropriate public health and environmental requirements, as
required by Section 121(d) of CERCLA and the NCP. The United
States and the State have determined that the obligations and
procedures authorized under this Consent Decree are consistent
with the NCP.
b. Except as provided in Section 121 (e) of CERCLA and
the NCP, no permit shall be required for any portion of the Work
conducted entirely on the Site. Where any portion of the Work
off the Site requires a federal or state permit or approval under
CERCLA and the NCP, Settling Defendants shall timely submit
applications and take all other actions necessary to obtain all
such permits or approvals.
c. All hazardous waste, as defined under Section
1004(5) of RCRA, 42 U.S.C. § 6903(5), which is generated,
treated, handled or disposed of in the performance of the Work
shall be managed by the Settling Defendants in accordance with
the NCP, including but not limited to the RCRA requirements
relating to use and signing of manifests.
d. Settling Defendants shall include in all contracts
or subcontracts entered into for Work required under this Consent
Decree provisions stating that such contractors or
subcontractors, including their agents and employees, shall
perform all activities required by such contracts or subcontracts
in compliance with all applicable laws and regulations.
15
l
11, if \ ^ *** b. As described with particularity iiTTliie SOW, the
major components of the Remedial Action for the Site are as
follows: (1) for unsaturated soils and selected saturated soils
which are contaminated above the Performance standards,
excavation and on-site low-temperature soil aeration treatment,
or an equivalent thermal desorption (aeration) treatment
technology approved by EPA (unless otherwise directed by EPA
pursuant to Paragraph 9.b.); (2) for extraction of contaminated
groundwater, vacuum-enhanced groundwater extraction, or separate
groundwater and soil vapor extraction (or combinations thereof)
approved by EPA; (3) on-site treatment (UV light/oxidation, or an
equivalent groundwater treatment/destruction technology approved
by EPA) of contaminated groundwater; (4) discharge of treated
groundwater to Quiggle Brook; (5) decontamination and demolition
of facilities at the Site; and (6) monitoring of soils beyond the
boundary of the former Union Chemical Company property.
9. a. In order to expedite the design of the Remedial
Action at the Site, Settling Defendants agree to commence and
perform the Remedial Design activities as described herein and in
the sow as a contractual obligation effective upon the receipt of
notice of the lodging of this Consent Decree with the Court.
Settling Defendants shall perform such Remedial Design activities
regardless of whether this Consent Decree is entered by the
Court.
b. (i) Upon receipt of written notification by EPA
that the EPA Regional Administrator, Region I, has signed this
17
the State, in writing, of the name, title, and qualifications of
the Supervising Contractor to be used in carrying out the
Remedial Design activities to be performed pursuant to this
Consent Decree. Settling Defendants shall also notify EPA and
the State of the names of any other contractors and/or
subcontractors proposed to be used in carrying out the Remedial
Design activities within twenty (20) days after the submission of
each approved Pre-Design and RD Work Plan. Selection of any such
contractor and subcontractor shall be subject to disapproval by
EPA. EPA will, if practicable, notify the Settling Defendants in
writing of its disapproval within fourteen (14) days of receipt
of the notice. If EPA disapproves of the selection of any
contractor or subcontractor, the Settling Defendants shall submit
a list of contractors or subcontractors, including their
qualifications, to EPA and the State within 21 days of receipt of
the disapproval of the contractor or subcontractor previously
selected. EPA will, if practicable, within 21 days of receipt of
the list, provide written notice of the names of contractors or
subcontractors that the Plaintiffs disapprove. The Settling
Defendants may at their election select any one not disapproved
on the list. After selection of a contractor or subcontractor,
Settling Defendants shall notify EPA and the State of the name of
such contractor or subcontractor within 14 days following receipt
of notice.
11. All Remedial Action and Operation and Maintenance
activities to be performed by the Settling Defendants pursuant to
19
this Consent Decree shall be under the direction and supervision
of a qualified contractor. Consistent with the time periods and
procedures established in the SOW, the Settling Defendants shall
notify EPA and the State in writing of the name, title and
qualifications of the Supervising Contractor(s) and the names of
any other.principal contractors and/or subcontractors proposed to
be used in carrying out the Remedial Action activities and/or the
Operation and Maintenance activities to be performed pursuant to
this Consent Decree. Selection of any such contractor and/or
subcontractor shall be subject to disapproval by the Plaintiffs
in accordance with the provisions of Paragraph 10.
12. Appendix II to this Consent Decree provides a Statement
of Work (SOW) for the completion of the Work required at the
Site. This Statement of Work is incorporated into and made an
enforceable part of this Consent Decree.
13. The following Work shall be performed by Settling
Defendants:
a. Consistent with the time periods specified in the
SOW, Settling Defendants shall submit for review, modification
and/or approval by EPA, after a reasonable opportunity for review
and comment by the State, work plan(s) for the Pre-Design and
Remedial Design at the Site [Pre-Design Work Plan(s) and RD Work
Plan(s), respectively]. These Work Plan(s) shall be developed in
conformance with the ROD, the SOW, EPA Superfund Remedial Design
and Remedial Action Guidance, and any additional guidance
20
documents provided by EPA to the Settling Defendants within a
reasonable tine frame before the due date(s) for the submissions.
b. The Pre-Design and RD Work Plan(s) shall include
the documents specified in the SOW, and shall contain schedules
which are consistent with the time limits identified in the SOW
for design of the Remedial Action.
c. Settling Defendants shall implement the Work
detailed in the Pre-Design and RD Work Plan(s) upon their
approval or modification by EPA pursuant to the procedures in
Section XII. Unless otherwise directed by EPA, the Settling
Defendants shall not commence field activities until approval by
EPA of these Work Plan(s). Upon such approval, these Work
Plan(s) and any submissions required thereunder or this Consent
Decree shall be deemed incorporated into and made an enforceable
part of this Consent Decree. All Remedial Design activities
shall be conducted in accordance with the National Contingency
Plan, EPA Superfund Remedial Design and Remedial Action
Guidance, any additional guidance documents provided by EPA to
the Settling Defendants within a reasonable time frame before the
activity is to be performed, and the requirements of this Consent
Decree, including the standards, specifications and schedule
contained in the SOW and these Work Plan(s).
d. Consistent with the time periods specified in the
SOW, Settling Defendants shall submit for review, modification
and/or approval by EPA, after a reasonable opportunity for review
and comment by the State, work plan(s) for the Remedial Action
21
and Operation and Maintenance at the Site [RA Work Plan(s) and 0
& M Plan(s)). These Work Plan(s) shall be developed in
conformance with the ROD, the SOW, EPA Superfund Remedial Design
and Remedial Action Guidance, and any additional guidance
documents provided by EPA to the Settling Defendants within a
reasonable time frame before the due date(s) for the submissions.
e. The RA Work Plan(s) and O 4 M Plan(s) shall include
the documents specified in the SOW, and shall contain schedules
which are consistent with the time limits identified in the SOW
for implementation of the Remedial Action and Operation and
Maintenance.
f. Settling Defendants shall implement the Work
detailed in the RA Work Plan(s) upon approval or modification of
the RA Work Plan(s) by EPA pursuant to the procedures in Section
XII. Upon approval by EPA, the RA Work Plan(s) and any
submissions required thereunder or this Consent Decree shall be
deemed incorporated into and made an enforceable part of this
Consent Decree. All Remedial Action activities shall be
conducted in accordance with the National Contingency Plan, EPA
Superfund Remedial Design and Remedial Action Guidance, any
additional guidance documents provided by EPA to the Settling
Defendants within a reasonable time frame before the activity is
to be performed, and the requirements of this Consent Decree,
including the standards, specifications and schedule contained in
the SOW and tha RA Work Plan(s). Settling Defendants shall
implement the Work detailed in the O & M Plan(s) upon approval or
22
modification of the 0 4 M Plan(s) by EPA pursuant to the
procedures in Section XII. Upon approval by EPA, the 0 4 M
Plan(s) and any submissions required thereunder or this Consent
Decree shall be deemed incorporated into and made an enforceable
part of this Consent Decree. All Operation and Maintenance
activities shall be conducted in accordance with the National
Contingency Plan, EPA Superfund Remedial Design and Remedial
Action Guidance, any additional guidance provided by EPA, and the
requirements of this Consent Decree, including the standards,
specifications and schedules contained in the SOW and the O & M
Plan(s).
g. Upon entry of this Consent Decree, all obligations
concerning Remedial Design are subject to enforcement pursuant to
this Consent Decree, including but not limited to stipulated
penalties, retroactive to the date of the lodging of this Consent
Decree.
h. Settling Defendants shall submit to EPA four (4)
bound copies and one (1) unbound copy of each Work Plan and any
other submission required under this Consent Decree or the SOW
(including schedules). Settling Defendants shall submit to the
State three (3) bound copies and one (1) unbound copy of each
Work Plan and any other submission required under this Consent
Decree or the SOW (including schedules).
14. The Parties acknowledge and agree that neither the sow
nor any of the Pre-Design, RD or RA Work Plan(s) or the 0 4 M
Plan(s) constitute a warranty or representation of any kind by
23
Plaintiffs that the SOW or such Work Plan(s) or Plan(s) will
achieve the Performance Standards set forth in the ROD, the SOW
and in Paragraph 15 below, and shall not foreclose Plaintiffs
from seeking performance of all terms and conditions of this
Consent Decree, including achieving the Performance Standards.
15. The Work performed by Settling Defendants pursuant to
this Consent Decree must achieve the following Performance
Standards:
a. Cleanup levels for contaminants in groundwater are;
bis(2-ethylhexyl)phthalate 4 ppb
carbon tetrachloride 5 ppb
chloroform (as total trihalomethanes) 100 ppb
1,1-dichloroethane (1,1-DCA) 5 ppb
1,2-dichloroethane (1,2-DCA) 5 ppb
1,2-dichloroethylene-cis (cis,1,2,DCE) 70 ppb
1,1-dichloroethylene (1,1-DCE) 7 ppb
ethylbenzene 700 ppb
methylene chloride 5 ppb
methyl ethyl ketone (2-butanone) 170 ppb
tetrachloroethylene (PCE) 5 ppb
toluene 2,000 ppb
1,2-dichloroethylene-trans (trans-l,2-DCE) 100 ppb
1,1,1,-trichloroethane (1,1,1-TCA) 200 ppb
trichloroethylene (TCE) 5 ppb
vinyl chloride 2 ppb
xylenes (total) 10,000 ppb
24
b. Cleanup levels for contaminants in the on-site
unsaturated soils and in selected saturated soils, as specified
in the SOW, are:
1,1-dichloroethylene (1,1-DCE) 0.1 ppm
trichloroethylene (TCE) o.i ppm
tetrachloroethylene (PCE) 0.1 ppm
xylenes (total) 100 ppm
c. For effluent from the groundwater treatment plant,
Federal Ambient Water Quality Criteria and Federal Maximum
Contaminant Levels for various pollutants;
d. For emissions from the groundwater treatment plant,
National Ambient Air Quality Standards for particulates and
ozone;
e. For emissions from the vacuum extraction system,
National Emission Standards for Hazardous Air Pollutants for
vinyl chloride;
f. For demolition of the facilities, National Emission
Standards for Hazardous Air Pollutants for asbestos;
g. For treatment of contaminated soils, Land Disposal
Restrictions for treatment of F001 through F005 wastes, at 40 CFR
268.41; and
h. Other standards identified as ARARs in the ROD are
hereby incorporated by reference and must be attained, as if set
forth fully herein.
25
VII.
U.S. EPA PERIODIC REVIEW TO ASSURE PROTECTION OF HUMAN HEALTH AND ENVIRONMENT
16. To the extent required by Section 121(c) of CERCLA, 42
U.S.C. § 9621(c), and any applicable regulations, EPA shall
review the remedial action at the Site at least every five (5)
years after initiation of the remedial action to assure that
human health and the environment are being protected by the
remedial action being implemented. EPA reserves the right to
seek to recover from the Settling Defendants the costs of
studies, investigations, or other response actions determined
necessary by EPA, in order to conduct the review of the site
required by Section 121(c) of CERCLA.
17. As provided by Sections 113(k) and 117 of CERCLA, 42
U.S.C. §§ 9613(k) and 9617, and the National Contingency Plan,
Settling Defendants will have an opportunity to submit comments
for the record on any proposed subsequent response action.
Settling Defendants shall be provided with an opportunity to
confer with EPA on any Additional Work proposed by EPA during the
5-year review process. Selection of any subsequent response
action shall be based on the administrative record.
VIII.
ADDITIONAL WORK
18. In the event that EPA, after reasonable opportunity for
review and comment by the State, or the Settling Defendants
determine that Additional Work, including Additional Work
26
identified during the CERCLA Section 121(c) review process, is
necessary to meet the Performance Standards described in Section
VI above, or to carry out the remedy in the ROD or the SOW,
notification of such Additional Work will be provided to the EPA
Remedial Project Manager and all Project Coordinators designated
pursuant to this Decree.
19. Any Additional Work that Settling Defendants determine
is necessary to meet the Performance Standards, or to carry out
the remedy in the ROD or the SOW, shall be subject to approval by
EPA, after reasonable opportunity for review and comment by the
State, and, if authorized by EPA, shall be completed by Settling
Defendants in accordance with the plans, specifications, and
schedules approved or established by EPA pursuant to Section XII
(Submissions Requiring Agency Approval).
20. Any Additional Work determined to be necessary by
Settling Defendants and approved by EPA, or determined to be
necessary by EPA to meet the Performance Standards or to carry
out the remedy in the ROD or the SOW, shall be completed by
Settling Defendants in accordance with the standards,
specifications, and schedules approved or established by EPA,
after reasonable opportunity for review and comment by the State.
21. Unless otherwise stated by EPA, within sixty (60) days
of receipt of notice by EPA that Additional Work is necessary, or
otherwise agreed to by the Parties, the Settling Defendants shall
submit for approval by EPA, after reasonable opportunity for
review and comment by the State, a work plan for the Additional
27
Work. The work plan shall conform to the requirements of this
Consent Decree, the National Contingency Plan, Superfund Remedial
Design and Remedial Action Guidance, and any additional guidance
documents provided by EPA to the Settling Defendants within a
reasonable time frame before the due date of the submission.
Upon approval pursuant to the procedures set forth in Section
XII, Settling Defendants shall implement the work plan for
Additional Work in accordance with the schedule contained
therein.
IX.
QUALITY ASSURANCE; SAMPLING
22. Throughout the performance of the Work, Settling
Defendants shall use quality assurance, quality control, and
chain of custody procedures in accordance with the SOW, EPA's
"Interim Guidelines and Specifications For Preparing Quality
Assurance Project Plans" (QAM-005/80), Data Quality Objective
Guidances (EPA/540/G-87/003 and 004); "EPA NEIC Policies and
Procedures Manual," May 1978, revised November 1984 (EPA/330/9
78 -001 -R) ; and subsequent amendments to such guidelines upon
notification to Settling Defendants of such amendments by EPA.
Settling Defendants shall assure that EPA and State personnel or
their authorized representatives are allowed access to any
laboratory utilized by Settling Defendants in implementing this
Consent Decree. In addition, Settling Defendants shall have a
28
designated laboratory analyze a reasonable number of samples
submitted by EPA for quality assurance monitoring.
23. Settling Defendants shall make available to EPA and the
State the validated results of all sampling and/or tests or other
verified data generated by Settling Defendants with respect to
the implementation of this Consent Decree, and shall submit these
results with the progress reports as described in Section XI of
this Consent Decree.
24. At the request of EPA or the State, Settling Defendants
shall allow split or duplicate samples to be taken by EPA, the
State, and/or their authorized representatives, of any samples
collected by Settling Defendants pursuant to the implementation
of this Consent Decree. Settling Defendants shall notify EPA and
the State not less than twenty-eight (28) days in advance of any
sample collection activity, which requirement may be waived by
EPA, after reasonable opportunity for review and comment by the
state. In addition, EPA and the State shall have the right to
take any additional samples that EPA or the State deem necessary.
EPA and the State shall, if practicable, allow split or duplicate
samples to be taken by the Settling Defendants, or their
authorized representatives, of a reasonable number of samples
collected by EPA or the State. Upon request, EPA and the State
agree to make the validated results of such split, duplicate or
additional sampling available to Settling Defendants within a
reasonable time frame. EPA and the State will, if practicable,
give the Settling Defendants at least five (5) days notice of any
29
sample collection activity to be conducted by them; but failure
of EPA or the State to do so shall not affect their respective
inspection or sampling authorities or their oversight of Settling
Defendants' performance of the Work.
25. Notwithstanding any provision of this Consent Decree,
the United States shall retain all of its information gathering,
inspection and enforcement authorities and rights under CERCLA,
RCRA and any other applicable statutes or regulations, except
that nothing in this paragraph shall affect the covenants not to
sue in Section XXIII of this Consent Decree.
X.
ACCESS AND INSTITUTIONAL CONTROLS
26. From the receipt of notice of the lodging of this
Consent Decree, the United States and its representatives,
including but not limited to EPA and the State, their employees,
agents, authorized representatives, and contractors, shall have
access at all times to the Site and any property to which access
is required for the implementation of this Consent Decree, to the
extent access to the property is controlled by or available to
Settling Defendants, for the purposes of conducting any activity
authorized by or related to this Consent Decree, including, but
not limited to:
a. Monitoring the Work or any other activities taking
place on such property;
30
b. Verifying any data or information submitted to the
United States or the State;
c. Conducting investigations relating to
contamination at or near the Site;
d. Obtaining samples;
e. Assessing the need for or planning and
implementing additional response actions at or near the Site;
f. Inspecting and copying records, operating logs,
contracts, or other documents required to assess Settling
Defendants' compliance with this Consent Decree; and
g. Assessing Settling Defendants' compliance with
this Consent Decree.
27. a. The State acknowledges that it is the receiver of
the former Union Chemical Company property and hereby grants
access to the Settling Defendants to carry out the Work and the
Additional Work, and to the United States and its employees,
agents, authorized representatives, and contractors. To the
extent that entry or access is required onto other property to
conduct the Work or Additional Work, Settling Defendants shall
use best efforts to secure from such persons owning or
controlling such other property access for Settling Defendants,
the United States, including EPA, the State, and their employees,
agents and authorized representatives, contractors or consultants
as necessary to effectuate implementation of this Consent Decree.
For purposes of this paragraph "best efforts" includes, but is
31
not limited to, seeking judicial assistance and the payment of
reasonable sums of money in consideration of access.
b. Settling Defendants shall use their best efforts to
establish and maintain the necessary Institutional Controls as
set forth in the SOW, and in accordance with the time frames set
forth in the SOW. For purposes of this subparagraph "best
efforts" includes, but is not limited to, seeking judicial
assistance and the payment of reasonable sums of money in
consideration of Institutional Controls.
c. (i). If access is not obtained within forty-five
(45) days of the date of the lodging of this Consent Decree, or
within forty-five (45) days of the date EPA determines in writing
to Settling Defendants that additional access beyond that
previously secured is necessary, Settling Defendants shall
promptly notify the United States and the State in writing. EPA
and the State may thereafter, consistent with their authorities,
assist Settling Defendants in obtaining access.
(ii). If the Institutional Controls required by Part
E.l.a.(ii)(a) of the SOW are not obtained within 180 days of
receipt of written notice that the EPA Regional Administrator,
Region I, has signed this Consent Decree, Settling Defendants
shall promptly notify the United States and the State in writing.
If the Institutional Controls required by Part E.l.a.(i) and Part
E.l.a.(ii)(b) of the SOW are not obtained within 180 days of
receipt of notice of the lodging of this Consent Decree, Settling
Defendants shall promptly notify the United States and the State
32
in writing. If EPA, after reasonable opportunity for review and
comment by the State, determines in writing to Settling
Defendants that additional Institutional Controls beyond those
previously secured are necessary and Settling Defendants have not
secured such further Institutional Controls within 180 days of
EPA's written determination, then Settling Defendants shall
notify EPA and the State in writing. Following receipt of any
written notice by Settling Defendants pursuant to this
subparagraph, EPA and the State may thereafter, consistent with
their authorities, assist Settling Defendants in obtaining the
necessary Institutional Controls.
(iii). Settling Defendants shall, in accordance with
Section XVIII herein, reimburse the United States for all costs
not inconsistent with the NCP incurred by it in obtaining access
and Institutional Controls necessary for performance of the Work
or Additional Work.
28. Notwithstanding any provision of this Consent Decree,
the United States and the State retain all of their access
authorities and access rights under CERCIA, RCRA and any other
applicable statutes or regulations.
XI.
REPORTING REQUIREMENTS
29. In addition to any other requirement of this Consent
Decree, Settling Defendants shall submit to EPA and the State
written progress reports as required in the SOW which: (a)
describe the actions which have been taken toward achieving
33
compliance with this Consent Decree during the reporting period;
(b) include all validated results of sampling and tests and all
other verified data received by or generated by Settling
Defendants during the course of the Work in the previous
reporting period; (c) include all work plans, plans, deliverables
and procedures that were completed under the Pre-Design, RD or RA
Work Plan(s) during the previous reporting period; (d) describe
all actions, data and plans which are scheduled for the next
reporting period and provide other information relating to the
progress of construction that is necessary to assess compliance
under this Consent Decree, including but not limited to, at the
Settling Defendants' option, critical path diagrams, Gantt charts
or Pert charts; (e) include information regarding percentage of
completion, unresolved delays encountered or anticipated that may
affect the future schedule for implementation of the Work, and a
description of efforts made to mitigate those delays or
anticipated delays; (f) include any modifications to the work
plans or other schedules that Settling Defendants have proposed
or that been approved by EPA; and (g) describe all activities
undertaken in support of the Community Relations Support Plan
during the previous reporting period and those to be undertaken
in the next reporting period. These progress reports are to be
submitted to EPA and the State following receipt of notice of
the lodging of this Consent Decree pursuant to the schedule set
forth in the SOW. If requested by EPA or the State, Settling
34
Defendants shall also provide briefings for EPA and the State to
discuss the progress of the Work upon seven (7) days' notice.
30. Upon the occurrence of any event during performance of
the Work which Settling Defendants are required to report
pursuant to Section 103 of CERCLA, 42 U.S.C. § 9603 and/or
Section 304 of the Emergency Planning and Community Right-To-Know
Act (EPCRA), 42 U.S.C. § 11004, Settling Defendants shall
promptly orally notify the EPA Remedial Project Manager ("RPM");
the EPA Geographic Section Chief designated pursuant to Section
XIII (in event of the unavailability of the EPA RPM); or, in the
event that neither the EPA RPM nor the EPA Geographic Section
Chief is available, the Emergency Response Unit, Region I, the
United States Environmental Protection Agency; and the State
Project Coordinator. These reporting requirements are in
addition to the reporting required by Section 103 of CERCLA and
Section 304 of EPCRA. Within twenty (20) days of the onset of
such an event, Settling Defendants shall furnish to Plaintiffs a
written report setting forth the events which occurred and the
measures taken, and to be taken, in response thereto. Within
thirty (30) days of the conclusion of such an event, Settling
Defendants shall submit a report setting forth all actions taken
to respond thereto. Settling Defendants shall submit each year,
within thirty (30) days of the anniversary of the entry of the
Consent Decree, a report (which may be contained in a progress
report submitted pursuant to Paragraph 29) to the Plaintiffs
setting forth the status of response actions at the Site, which
35
shall, at a minimum, include a statement of major milestones
accomplished in the preceding year, a statement of tasks
remaining to be accomplished, and a schedule for implementation
of the remaining Work.
31. All reports and other documents submitted by Settling
Defendants to EPA and the State (other than the progress reports
referred to above) shall be signed by the Settling Defendants'
Project coordinator.
XII.
SUBMISSIONS REQUIRING AGENCY APPROVAL
32. After review of any plan, report or other item which is
required to be submitted for approval pursuant to this Consent
Decree, EPA, after reasonable opportunity for review and comment
by the State, shall, in writing, either: (1) approve the
submission in whole or in part; (2) approve the submission upon
specified conditions; (3) modify the submission to cure the
deficiencies; (4) direct that the Settling Defendants modify the
submission; (5) disapprove the submission in whole or in part,
notifying Settling Defendants of deficiencies; or (6) any
combination of the above.
33. In the event of approval, approval upon specified
conditions, or modification by EPA, Settling Defendants shall
proceed to take any action required by the plan, report, or other
item, as approved or modified, subject to Settling Defendants'
36
rights under the dispute resolution procedures set forth in
Section XXI.
34. a. Upon receipt of a written notice of disapproval,
or a written notice requiring a modification, Settling Defendants
shall, within thirty (30) days thereafter (unless EPA, after
reasonable opportunity for review and comment by the state,
specifies more or less time), correct the deficiencies and
resubmit the plan, report, or other item for approval. After
receiving the resubmittal, EPA, after reasonable opportunity for
review and comment by the State, will exercise one of the options
in Paragraph 32. Notwithstanding a written notice of disapproval
or written notice requiring a modification, Settling Defendants
shall proceed to take any action required by any separable, non-
deficient portion of the submission approved or modified under
Paragraph 32, in accordance with the schedules established by
EPA, unless otherwise directed by EPA, after reasonable
opportunity for review and comment by the State. Implementation
of separable, non-deficient portions of the submission shall not
relieve Settling Defendants of their liability for stipulated
penalties under Section XXII.
b. Disapproval of a submission for the first time
shall not alone constitute the basis of a violation of this
Consent Decree, provided that the submission was made in good
faith and in a timely manner. If, upon the resubmission, the
plan, i-eport, or item is neither approved nor approved upon
specified conditions by EPA, after reasonable opportunity for
37
review and comment by the State, Settling Defendants shall be
deemed to be in violation of this Consent Decree. The provisions
of Section XXI (Dispute Resolution) and Section XXII (Stipulated
Penalties) shall govern the implementation of the Work and
accrual and payment of any stipulated penalties during Dispute
Resolution.
35. All plans, reports and other items required to be
submitted to EPA under this Consent Decree shall, upon approval
by EPA, be deemed to be incorporated in and an enforceable part
of this Consent Decree. In the event that EPA approves a portion
of a plan, report or other item required to be submitted to EPA
under this Consent Decree, the approved portion shall be deemed
to be incorporated in and an enforceable part of this Consent
Decree.
XIII.
REMEDIAL PROJECT MANAGER/PROJECT COORDINATORS
36. Within ten (10) days of the receipt of notice of the
lodging of this Consent Decree, the Settling Defendants shall
notify EPA and the State, in writing, of the name, address and
telephone number of the Settling Defendants' Project Coordinator
and an Alternate Project Coordinator. The Settling Defendants'
Project Coordinator shall be subject to approval by EPA, after
reasonable opportunity for review and comment by the State, and
shall have the technical expertise sufficient to oversee
adequately all aspects of the Work. The Settling Defendants'
38
Project Coordinator shall not be acting as an attorney for any of
the Settling Defendants in this matter. He or she nay assign )
other representatives, including other contractors, to serve as a
Site representative for oversight of performance of daily
operations during remedial activities. Within ten (10) days of
lodging of this Consent Decree/ EPA will designate, in writing,
a Remedial Project Manager (RPM) for administration of its
responsibilities, for oversight of the day-to-day activities
conducted under this Consent Decree, and for receipt of all
written matter required by this Consent Decree. In addition, EPA
will designate, in writing, a Geographic Section Chief. The
State will designate a State Project Coordinator within the same
ten (10) day period. If any Party decides to change its
designated Project Coordinator or RPM, the name, address, and
telephone number of the successor shall be given to the other
Parties within five (5) working days before the change is to be
effective, unless impracticable, but in no event later than the
actual day the change is made.
37. Plaintiffs may designate other representatives,
including EPA and state employees, and federal and state
contractors and consultants, to observe and monitor the progress
of any activity undertaken pursuant to this Consent Decree.
EPA's RPM shall have the authority lawfully vested in an RPM and
On-Scene Coordinator (OSC) by the National Contingency Plan, 40
C.F.R. Part 300. In addition, the EPA RPM shall have authority
consistent with the National Contingency Plan, to halt, conduct,
39
or direct any work required by this Consent Decree, and to take
any necessary response action when he or she determines that
conditions at the Site nay present an endangerment to public
health or welfare or the environment.
XIV.
38. within sixty (60) days of receipt of notice of the
lodging of this Consent Decree, Settling Defendants shall
demonstrate their ability to complete the Work and to pay all
claims that arise from the performance of the Work by obtaining
and maintaining financial security, equalling the total estimated
cost of the Work, in one of the following forms:
a. A surety bond guaranteeing performance of the Work;
b. One or more irrevocable letters of credit;
c. A trust fund, as provided in Section XV of this
Consent Decree;
d. A guarantee to perform the Work by a one or more
parent corporations, sibling corporations, subsidiaries, or by
one or more unrelated corporations which have a substantial
business relationship with at least one of the Settling
Defendants;
e. A demonstration that one or more of the Settling
Defendants satisfies the requirements of 40 C.F.R. Part
264.143(f); or
40
f. Internal financial information regarding Settling
Defendants' net worth, cash flow, total liabilities, and current
rating for most recent bond issuances sufficient to demonstrate
to EPA's satisfaction that one or more Settling Defendants have
the financial ability to complete the Work.
39. If the Settling Defendants seek to demonstrate the
ability to complete the Work through a guarantee by a third
party, Settling Defendants shall demonstrate that the guarantor
satisfies the requirements of 40 C.F.R. Part 264.143(f). If
Settling Defendants seek to demonstrate their ability to complete
the Work pursuant to Paragraph 38.d. through 38.f., they shall
resubmit sworn statements conveying the information required by
40 C.F.R. Part 264.143(f) annually, on the anniversary of the
effective date of this Consent Decree.
40. In the event that EPA, after reasonable opportunity for
review and comment by the State, determines at any time that such
financial assurances are inadequate, Settling Defendants shall,
within sixty (60) days of receipt of written notice of EPA's
determination, obtain and present for approval to EPA, after
reasonable opportunity for review and comment by the State, one
of the other forms of financial assurance listed in Paragraph 38.
Settling Defendants' inability to demonstrate financial ability
to complete the Work and pay all claims that arise from the
performance of the Work shall not excuse performance of any
activities required under this Consent Decree.
41
XV.
TRUST FUND
41. a. Within thirty (30) days of the Settling Defendants'
receipt of notice of the lodging of this Consent Decree, Settling
Defendants shall present to EPA and the State for approval a
fully executed trust agreement (the "RD/RA Trust Agreement"}
establishing the Union Chemical Site Remedial Design/Remedial
Action Trust Fund (the "RD/RA Trust Fund") and shall notify EPA
and the State of the identity and qualifications of the
Trustee(s). The RD/RA Trust Agreement shall confer upon the
Trustee all powers and authorities necessary to finance the
obligations of the Settling Defendants under this Consent Decree.
Money paid into the RD/RA Trust Fund by Settling Defendants shall
be used solely to pay proper and necessary expenses pursuant to
this Consent Decree, including expenses of administering the
RD/RA Trust. The RD/RA Trust Fund may not be used to pay
stipulated penalties that may be required to be paid pursuant to
Section XXII and shall not be used to pay attorneys' fees or
other litigation costs of the Settling Defendants.
b. Notwithstanding anything in the RD/RA Trust
Agreement, Settling Defendants shall be jointly and severally
liable for compliance with this Consent Decree. Settling
Defendants shall provide EPA and the State with written notice at
least twenty (20) days in advance of any proposed change in the
RD/RA Trust Agreement or of the Trustee. EPA and the State,
through their approval of the terms and conditions of the RD/RA
42
Trust Agreement or otherwise, do not guarantee the monetary
sufficiency of the RD/RA Trust Fund nor the legal sufficiency of
the RD/RA Trust Agreement.
42. The Parties understand that Plaintiffs may enter into
an Administrative Order By Consent, EPA Docket No. 1-91-1067,
(the "Administrative Order by Consent"), pursuant to Sections
122(g)(4) of CERCLA and 38 M.R.S.A. § 1365, with certain PRPs who
have been denominated as de minimis PRPs for the Union Chemical
Company Site. The Administrative Order by Consent provides that
a portion of the monies paid into the Union Chemical Site De
Minimis Trust Fund may be used by the Settling Defendants for
performance of the Work. However, Settling Defendants agree that
no portion of the monies paid into the Union Chemical De Minimis
Trust Fund shall be used to reimburse the United States for EPA's
Past Response Costs.
43. The RD/RA Trust Agreement shall provide that the «
Trustee shall, within sixty (60) days of his appointment and
within thirty days of each anniversary date of the RD/RA Trust
and until EPA issues the Certification of Completion of the Work,
submit to Settling Defendants, EPA, and the State financial
reports, which shall include the amount of money currently in the
RD/RA Trust Fund and in the Union Chemical Site De Minimis Trust
Fund and setting forth cash flow projections showing the level of
funds that will be necessary to pay for the obligations of
Settling Defendants under this Consent Decree for the next year.
If the amount of money in the RD/RA Trust Fund and the Union
43
Chemical Site De Mininis Trust Fund is less than the amount
projected in the Trustee's report to be needed for the next year,
Settling Defendants shall, within thirty (30) days of issuance of
the Trustee's report, deposit into the RD/RA Trust Fund amounts
sufficient to bring the level of the RD/RA Trust Fund up to that
projected amount.
44. If any Settling Defendant fails to pay within thirty
(30) days into the RD/RA Trust Fund the additional amounts
required under Paragraph 43, the other remaining Settling
Defendants shall make the necessary payments within thirty (30)
days thereafter. The failure of any Settling Defendant to make
payments into the RD/RA Trust Fund shall not excuse timely
completion of any obligation under this Consent Decree. Settling
Defendants shall in any event make payments to the RD/RA Trust
Fund when and to the extent necessary to ensure the uninterrupted
progress and timely completion of the Work.
XVI.
CERTIFICATION OF COMPLETION OF WORK
45. Within ninety (90) days after Settling Defendants
conclude that the Work (including 0 & M) has been fully
performed, Settling Defendants shall so notify the United States,
EPA, and the State and shall schedule and conduct a pre
certification inspection to be attended by Settling Defendants,
EPA and the State. Such inspection shall be followed within
thirty (30) days by a written report signed by the Settling
44
Defendants' Project Coordinator and by a registered professional
engineer certifying that the Work has been completed in full
satisfaction of the pertinent requirements of this Consent
Decree. If EPA determines, after reasonable opportunity for
review and comment by the State, that the Work or any portion
thereof has not been completed in accordance with this Consent
Decree, EPA shall notify Settling Defendants in writing of the
activities that must be done to complete the Work, and shall
require Settling Defendants to submit a schedule pursuant to
Section XII to EPA for approval, after reasonable opportunity for
review and comment by the State, for the performance of such
activities. Settling Defendants shall perform all activities
described in the notice in accordance with the specifications and
schedules approved by EPA, subject to their right to invoke the
dispute resolution procedures in Section XXI.
46. If EPA, after a reasonable opportunity for review and
comment by the State concludes, following the initial or any
subsequent notification of completion of Work by Settling
Defendants that the Work has been fully performed in accordance
with this Consent Decree, EPA shall so certify in writing to
Settling Defendants. This certification shall constitute the
"Certification of Completion of Work" for purposes of this
Consent Decree, including Section XXIII ( Covenants Not to Sue by
Plaintiffs).
45
XVII.
EKDANGERMENT AND FUTURE RESPONSE
47. When Settling Defendants learn or should have learned
of an event or occurrence during and related to Settling
Defendants' performance of the Work that causes or threatens a
release of Waste Material on, at, or from the Site, or that may
present an endangerment to public health or welfare or the
environment, Settling Defendants shall immediately take all
appropriate action to prevent, abate, or Minimize such release or
endangerment, and shall immediately notify the EPA RPM, the EPA
Emergency Response Unit, Region I, the State Project Coordinator
and the Maine State Police. Settling Defendants shall take such
action in accordance with all applicable provisions of the Health
and Safety Plan(s) developed pursuant to the SOW and approved by
EPA. The Settling Defendants shall develop and submit a response
plan to EPA within ten (10) days or as soon thereafter as is
practicable. The provisions of Section XII apply to the
submission of such response plan, except that the time period for
resubmission after disapproval shall be fourteen (14) days rather
than the thirty (30) days, unless extended by EPA. In the event
that Settling Defendants fail to take appropriate response action
as required by this Section and EPA and/or the State take such
action instead, Settling Defendants shall reimburse all costs of
the response action which are not inconsistent with the NCP or
which are recoverable under state law. Payment of such response
costs shall be made in the manner described in Paragraph 49 of
46
Section XVIII, within thirty (30) days of Settling Defendants'
receipt of demand for payment. Nothing herein shall require
Settling Defendants to carry out any response actions or
reimburse EPA or the State for any response actions if the
requirements of 42 U.S.C. § 9607(b) are met and the harm caused
by an event or occurrence as defined in this Paragraph 47 is
divisible from the harm existing at the Site.
48. Nothing in the preceding paragraph shall be deemed to
limit the power and authority of the United States, the State, or
this Court to take, direct, or order all appropriate action to
protect public health, welfare, or the environment or to prevent,
abate, or minimize an actual or threatened release of Waste
Material on, at, or from the Site.
XVIII.
REIMBURSEMENT OF RESPONSE COSTS
49. a. Within thirty (30) days of receipt of notice of the
entry of this Consent Decree, Settling Defendants shall, jointly
and severally, pay to EPA $2,800,ooo in the form of a certified
check made payable to "EPA Hazardous Substances Superfund," and
referencing the Union Chemical Superfund Site, CERCLA Number 65,
and DOJ Case Number 90-11-2-643, in reimbursement of EPA's Past
Response Costs and EPA's Future Response Costs. The certified
check shall be forwarded to EPA Region I, Attn: Superfund
Accounting, P.O. Box 360197M, Pittsburgh, PA 15251. Copies of
the check and transmittal letter shall be sent to EPA's RPM and
47
to the Regional Hearing Clerk, EPA Region I, J.F.K. Federal
Building, Boston, MA 02203.
b. If Settling Defendants are required to make
payments to EPA pursuant to Paragraphs 27.c.(iii) or 47, EPA
shall send the Settling Defendants a bill requiring payment.
EPA's demand for payment shall include an accounting consisting
of a detailed cost summary by category of costs and a brief
narrative describing the activities performed. Payment shall be
made in the manner described in Paragraph 49.a. above, within
thirty (30) days of Settling Defendants' receipt of each bill
requiring payment.
50. a. Within thirty (30) days of the receipt of notice of
entry of this Consent Decree, Settling Defendants shall, jointly
and severally, pay to the State $125,000 in the form of a
certified check made payable to the Maine DEP Uncontrolled
Hazardous Substance Fund, in reimbursement of DEP's Past Response
Costs and for any claim for damages to natural resources
resulting from Site activity. The certified check shall be
forwarded to the Director, Division of Site Investigation and
Remediation, Bureau of Hazardous Materials and Solid Waste
Control, State House, Station 17, Augusta, ME 04333, Attention:
Union Chemical Project Coordinator. Copies of the check and any
transmittal letter(s) shall be sent to the State's Project
Coordinator.
b. Settling Defendants shall, jointly and severally,
reimburse the State for DEP's Future Response Costs. DEP shall
48
send to the Settling Defendants a bill requiring payment, on an
annual basis. DEP's demand for payment shall include an
accounting consisting of a detailed cost summary by category of
costs and a brief narrative describing the activities performed.
Payment shall be made in the manner described in Paragraph 50.a.
above, within thirty (30) days of Settling Defendants' receipt of
each bill requiring payment.
c. Notwithstanding anything in this Consent Decree to
the contrary, in the event that Settling Defendants elect to
conduct studies for in-situ vapor extraction as set forth in
Paragraph 9.b. herein, the Settling Defendants shall reimburse
the State for all costs of reviewing and evaluating said studies
which are recoverable under 38 M.R.S.A. § 1367, up to a total
cost of $8,000. The submission of bills for payment and the
making of payments shall be governed by the procedures set forth
in Paragraph 50.a.
51. In the event that the payments required by Paragraphs
49 and 50 are not made timely, Settling Defendants shall pay
interest on the unpaid balance at the rate established by the
Department of the Treasury pursuant to Section 107(a) of CERCLA,
42 U.S.C. § 9607(a). The interest shall begin to accrue 30 days
after the effective date of this Consent Decree. In addition,
Settling Defendants shall, jointly and severally, pay a six
percent (6%) per annum penalty charge, if Settling Defendants
have not paid the full amount within ninety (90) days after the
payment is due. Payments made under this paragraph shall be in
49
addition to such other remedies or sanctions available to
Plaintiffs by virtue of Settling Defendants' failure to make
timely payments under this Section.
XIX.
INDEMNIFICATION AND INSURANCE
52. The United States and the State do not assume any
liability by entering into this agreement or by virtue of any
designation of Settling Defendants as EPA's authorized
representatives, if such occurs, under Section 104(e) of CERCLA.
53. Settling Defendants shall indemnify and save and hold
harmless the United States, the State, and their officials,
agents, employees, contractors, and representatives from any and
all claims or causes of action or other costs incurred by the
United States or the State including, but not limited to
attorneys fees and other expenses of litigation and settlement
arising from or on account of acts or omissions of Settling
Defendants, their officers, employees, agents, contractors,
subcontractors, and any persons acting on their behalf or under
their control, in carrying out activities pursuant to this
consent Decree, including any claims arising from any designation
of the Settling Defendants as EPA's authorized representatives
under Section 104(e) of CERCLA. Provided, however, that the
Settling Defendants shall not be required to indemnify the United
States or the State and their officials, agents, employees,
contractors and representatives for any costs or damages
resulting from actions performed in an non-negligent manner at
50
the express direction of the United States, which actions
Settling Defendants have not themselves proposed. Neither the
United States nor the State shall be held out as a party to any
contract entered into by or on behalf of Settling Defendants in
carrying out activities pursuant to this Consent Decree. Neither
Settling Defendants nor any such contractor shall be considered
an agent of the United States or the State.
54. Settling Defendants waive any claims or causes of
actions against and shall indemnify and hold harmless the United
States or the State, and their officials, agents, employees,
contractors, subcontractors and representatives for damages or
reimbursement, or set-off of any payments made or to be made to
the United States or the State, arising from or on account of any
contract, agreement, or arrangement between any one or more of
Settling Defendants and any person for performance of work on or
relating to the Site, including claims on account of construction
delays.
55. Prior to commencing any on-site work required under
this Consent Decree, Settling Defendants shall secure, and shall
maintain, or shall have their contractors maintain for the
duration of this Consent Decree comprehensive general liability
and automobile insurance with limits of $5 million, combined
single limit, naming as insured the United States and the State.
In addition, for the duration of this Consent Decree, Settling
Defendants shall satisfy, or shall ensure that their contractors
or subcontractors satisfy, all applicable laws and regulations
51
regarding the provision of workers' compensation insurance for
all persons performing work on behalf of Settling Defendants in
furtherance of this Consent Decree. Prior to commencement of any
on-site work under this Consent Decree, Settling Defendants shall
provide to EPA and the State certificates of such insurance and a
copy of each insurance policy. Settling Defendants shall, upon
the request of EPA or the State, resubmit such certificates and
copies of policies each year on the anniversary of the effective
date of this Consent Decree. If Settling Defendants demonstrate
by evidence satisfactory to EPA and the state that any contractor
or subcontractor maintains insurance equivalent to that described
above, or insurance covering the same risks but in a lesser
amount, then with respect to that contractor or subcontractor
Settling Defendants need provide only that portion of the
insurance described above which is not maintained by the
contractor or subcontractor.
XX.
FORCE MAJEURE
56. "Force Majeure" is defined for the purposes of this
Consent Decree as an event arising from causes beyond the control
of Settling Defendants and of any entity controlled by Settling
Defendants, including their contractors and subcontractors, which
delays or prevents the performance of any obligation under this
Consent Decree despite Settling Defendants' best efforts to avoid
the delay. The requirement that the Settling Defendants exercise
"best efforts to avoid the delay" includes using best efforts to
52
___. ._ f
anticipate any potential Force Majeure event and best efforts to
address the effects of any potential Force Majeure event (i) as
it is occurring and (ii) following the potential Force Majeure
event, such that the delay is minimized to the greatest extent
possible. "Force Majeure" does not include unanticipated or
increased costs, changed financial circumstances, or non-
attainment of the Performance Standards and requirements set
forth in Section VI hereof or in the SOW.
57. When circumstances occur which may reasonably indicate
to Settling Defendants that a delay may occur or prevent the
attainment of any obligation of the Consent Decree (other than
the attainment of the groundwater or soil Performance Standards),
whether or not caused by a Force Majeure event, Settling
Defendants shall orally notify the EPA RPM and the State Project
Coordinator of the circumstances within forty-eight (48) hours
after Settling Defendants first knew or should have known of such
circumstances. If the EPA RPM is unavailable, Settling
Defendants shall notify the Director of the Waste Management
Division, EPA Region I. Within ten (10) working days thereafter,
Settling Defendants shall supply to Plaintiffs in writing the