Environmental & Social Management Framework

P152343: MONGOLIA-SECOND ENERGY SECTOR PROJECTJanuary 2017

SFG2750 V1 REV

1. INTRODUCTION.........................................................................32. PROJECT DESCRIPTION...............................................................33. WORLD BANK SAFEGUARD POLICIES TRIGGERED.........................54. POTENTIAL ENVIRONMENTAL AND SOCIAL IMPACTS....................65. MEASURES TO MANAGE ENVIRONMENTAL AND SOCIAL IMPACTS. .76. PROCEDURES FOR PREPARATION, REVIEW, CLEARANCE AND IMPLEMENTATION OF SUBPROJECT SAFEGUARD INSTRUMENTS........97. CAPACITY DEVELOPMENT.........................................................158. GRIEVANCE REDRESS MECHANISM............................................159. ESMF CONSULTATION AND DISCLOSURE....................................17ANNEX A 1: ............SAFEGUARD DUE DILLIGENCE TABLE COMPONENT 1

19ANNEX A 2: ...........SAFEGUARD DUE DILLIGENCE TABLE COMPONENT 2 (SOLAR) 20ANNEX B 1:.......................ENVIRONMENTAL CODES OF PRACTICE (ECOPs)

22ANNEX B 2:...........ENVIRONMENTAL MANAGEMENT PLAN FOR A SOLAR PHOTOVOLTAIC POWER FACILITY..................................................44ANNEX C RESETTLEMENT POLICY FRAMEWORK.............................55ANNEX D 1: .........................ESMF CONSULTATION DETAILS-Component 1 (Distribution)..............................................................................75ANNEX D-2: ..........ESMF CONSULTATION DETAILS-Component 2 (Solar)

80

ii

1. INTRODUCTION This Environmental and Social Management Framework (ESMF) is structured to guide the Project Management Office (PMO) under the Ministry for Energy and the implementing units (PIUs) of the two electricity distribution companies, Baganuur-Southeastern Region Electricity Distribution Network (BSEDN) and Erdenet-Bulgan Electricity Distribution Network (EBEDN) and the implementing unit (PIU) Western Energy System (WES) to perform safeguard due diligence in accordance with World Bank environmental and social safeguard policies. The World Bank Second Energy Sector Project (the “Project”) is structured with investments fully identified prior to loan approval and investments that are to be identified subsequent to loan approval. This ESMF is designed to guide BSEDN, EBEDN and WES in performing their safeguard obligations for all Project investments under component 1 identified subsequent to loan approval (see section 2.2 below).

2. PROJECT DESCRIPTION

2.1 Objective

The Project Objective is: to improve access to sustainable and reliable electricity services in selected regional distribution utilities and improve energy regulatory capacity in Mongolia. In addition, proposed PDO-level indicators include: (i) increased access to electricity supply; (ii) reduced system interruption frequency due to distribution faults; (iii) generation capacity of renewable energy constructed under the project; (iv) estimated GHG emission reduction; and; (v) tariff policy recommendations published.

2.2 Components

The Project will include three components as described below.

Component 1. “Rehabilitation of Distribution Networks”. The purpose of this component is to reduce system losses and improve reliability of and access to electricity services in selected parts of the distribution network through strengthening of power infrastructure. This component will have three sub-components: (1.1) Upgrade and Expansion of BSEDN, (1.2) Upgrade and Expansion of ESBDN; (1.3) Rehabilitation of switchgears in the National Power Transmission Grid (NPTG).

Component 2. “Solar Power Plant” will finance construction of a 10 MW solar PV power plant in the Western Energy System, as identified under Mongolia’s SREP Investment Plan. In addition, subsequent to loan approval and contingent upon available funds, additional solar PV power plants may be financed under this Project. Therefore, this ESMF is designed to provide guidance on additional safeguards procedures and documentation to meet the government and World Bank environmental and social regulations, policies and procedures

Component 3. “Capacity Building” will cover project management, technical assistance and training including regulatory aspects. The purpose of this component is to strengthen the capacity of the project management office (PMO) under the Ministry of Energy and the implementing units (PIUs) of the regional distribution companies and WES through provision of technical assistance, training and study tours. The component includes: (i) technical assistance for project implementation and special studies; (ii) training programs to improve the project management capabilities; and (iii) project management cost.

2.3 Target Area

Component 1 (Distribution)

3

BSEDN distributes and supplies electricity to a total of 43,704 customers in the Baganuur District close to Ulaanbaatar and in 56 soums (villages) of 7 aimags (districts). The vast majority of the customers are residential households with a small portion of SMEs and mines. EBDEN serves 65,400 customers spread over 108 soums in 11 aimags. A majority of residential customers live in ger areas, where most residents are poor.

Component 2 (Solar)No specific location has yet been designated. However, a decision made by MoE in agreement with World Bank that any solar facilities financed under this Project are to be located in the western region (especially Khovd and Uvs provines) of Mongolia. Siting considerations would likely place any facilities, inter alia: (a) near access to connect to the Mongolian power grid, (b) on State owned land, and (c) near a readily available water source. The locations will not include Bayan Ulgii or the northern Huvsgul provinces populated by the Kazakh and Tsartan ethnic minorities. Nor will they include areas populated by the Uyghurs, Uzbeks, Urianhais and Hotons (and Tuvinians/Tsataans), and the Evenk who speak a Tungusic language.

2.4 Anticipated Subproject Types

Component 1 (Distribution)Subprojects for which this ESMF will be used by BSEDN and EBEDN are generically similar to the subprojects which were identified prior to approval of the overall project by the World Bank Board. Specifically, the following subproject types are anticipated:

Replacement of 6-10/0.4 kv transformers: replacement of old, and installation of new transformers Construction of new 35/6-10 kv transformer substations Replacement of oil filled circuit breakers with new vacuum circuit breakers Installation of vacuum circuit breakers Replacement of old meters and installation of new meters Installation of new power distribution lines Replacement of old wooden poles and distribution line cables

Component 2 (Solar)The only subproject type to be considered under this Project component will be solar photovoltaic power production facilities.

The main elements of this ESMF will include the following aspects for safeguard evaluation of potential subprojects:

Subproject Due Diligence Risk Screening and Categorization (Impact Assessment) Safeguard Documentation Preparation

o Environmento Social

Consultation Legal/Contractual Obligations (Conditionality) Review, Approval and Disclosure Implementation Arrangements and Responsibilities

o Monitoring o Reporting

Capacity Development

4

o Training

3. WORLD BANK SAFEGUARD POLICIES TRIGGERED OP 4.01: Environmental Assessment1

This OP 4.01 is triggered as the project may cause some minor adverse environmental and social impacts associated with the movement of men, machines and materials (e.g. dust, noise, engine exhausts etc.). The project will involve rehabilitation and/or replacement of several substation transformers, or other electrical equipment some of which may contain or be contaminated with polychlorinated biphenyls (PCBs) and/or asbestos.

Cultural PropertiesThe project is not expected to have negative impacts on cultural property, including movable or immovable objects, sites, structures, groups of structures or natural features or landscapes with archaeological, paleontological, historical, architectural, religious, aesthetic or other cultural significance, since most anticipated investments for Component 1 will be rehabilitation or replacement of existing equipment (substations, OHLs support structures-wooden poles etc.). For Component 2, siting criteria and due diligence would reject any site at or near any site/structure of cultural value. However, since land clearing and excavation is likely to be involved, there is the possibility of accidental or “chance find” events.

Natural HabitatsThis project will not support or lead to the conversion of natural habitats. Most anticipated investments under Component 1 will be rehabilitation or replacement of existing equipment (substations, OHL support structures-wooden poles etc.). There may be investments in expanding existing substations or constructing new substations and/or distribution lines. Under Component 2 siting criteria and due diligence would reject any site at or near areas of high ecologic value or affect any wildlife migratory routes.

OP/BP 4.10 Indigenous PeoplesMongolia has an estimated 24 ethnic groups, which are either descendants of Mongolian nomadic tribes. The majority are the Khalkh who comprise over 90% of the population. Except for the Kazakh minority group residing in western Mongolia, all ethnic groups speak Mongolian dialects which are comprehensible to speakers of Khalkha and to each other. Only the Kazakhs rely upon a distinct spoken language. The majority of Mongolia’s ethnic minority groups share similar customs, traditions and systems of production as the Khalkh. With the exception of the predominantly Muslim and linguistically differentiated Kazakhs in western Mongolia, and traditionally nomadic reindeer herding Tsaatan peoples in the north, Mongolia’s ethnic groups are not considered to be economically, socially or legally marginalized or otherwise disadvantaged in a manner which would restrict their ability to participate in the project. Neither Components 1 nor 2 will include those areas populated by either the Kazakh (Bayan Ulgii) or Tsaatan (northern Khovsgul province) ethnic minorities, nor will it include areas populated by the Uyghurs, Uzbeks,

1For more details about WB guidelines and Policies, please visit Bank websites: http://web.worldbank.org/WBSITE/EXTERNAL/PROJECTS/EXTPOLICIES/EXTSAFEPOL/0,,menuPK:584441~pagePK:64168427~piPK:64168435~theSitePK:584435,00.html and http://www.ifc.org/ifcext/sustainability.nsf/Content/EHSGuidelines

5

Urianhais and Hotons (and Tuvinians), and the Evenk who speak a Tungusic language and is therefore not expected to trigger OP/BP 4.10 on Indigenous Peoples.

OP/BP 4.12 Involuntary ResettlementIt is expected that under this project no involuntary land acquisition, physical relocation of households or commercial entities due to construction work will occur. Under Component 1, It is anticipated that all works will be undertaken on the existing power distribution infrastructure, within the existing right of way or on government land. However, there may still be instances where land must be purchased through negotiated settlement or voluntary donation for small-scale works. Under Component 2, it is anticipated that any future sites will be on state land, that is not used formally or informally. As any sites and potential impacts on populations with both Component 1 and Component 2 have yet to be finalised a Resettlement Policy Framework (RPF) has been prepared and incorporated into this ESMF (see Annex C). The RPF discusses the steps to be taken when any land is involuntarily acquired, purchased under negotiated settlement or voluntarily donated (under component 1) for project activities.

4. POTENTIAL ENVIRONMENTAL AND SOCIAL IMPACTS

Component 1 (Distribution)Given the exact nature and location of subprojects will not be known at the time of appraisal any site specific potential impacts associated with any subproject while unlikely to be significant, are, strictly speaking unknown. Anticipated generic potential impacts that are likely to be of concern, based upon previous experiences, may include worker safety issues, hazardous (PCB) waste management and non-hazardous waste disposal, and generation of dust, noise, during subproject construction. For the most part, the potential impacts are anticipated to be localized, of limited duration and reversible and can be readily managed through proper design and good management practices.

Component 1 will contribute to social and economic development, which is currently energy constrained. All electricity consumers - institutional, industrial, commercial and domestic – will eventually benefit from more reliable energy supply than would be possible without this component. The component will also extend electrification to currently unserved micro, small and medium enterprises. Women and children will be particularly benefited by improved electricity services, critical for modern education, health and communications services, for relieving the drudgery of household tasks, and for facilitating small income-generating activities that help families. Potential negative impacts of involuntary resettlement are discussed in the Resettlement Policy Framework, Annex C.

Component 2 (Solar)Given the exact nature and location of subprojects will not be known at the time of appraisal the specific potential impacts associated with this components’ subprojects are unknown. Anticipated generic potential impacts that are likely to be of concern, based upon previous experiences, may include worker safety issues, hazardous waste management and non-hazardous waste disposal during subproject construction, generation of dust, noise, and disruption of traffic patterns. For the most part, the potential impacts are anticipated to be localized, of limited duration and reversible and can be readily managed through proper design and good management practices.

Anticipated social impacts will primarily be positive, associated with short term employment and local supply opportunities. In-migration of non-local construction workers is anticipated to be minor (less than 200 persons) given the temporary nature (6 months) of impacts associated with this component. No new connections are anticipated as part of the scope of the investment, nor is this anticipated to be induced as a result of future investments. Changes in consumer electricity prices, and potential improvements to reliability

6

are not anticipated given the current consistent and reliable use of Russian electricity and given consumers are already connected (in urban centres).

An Environmental and Social assessment (ESIA) has been conducted in November 2016, social impacts were evaluated to further understand positive and negative consequences for communities and recommend mitigation measures for solar plant development. Potential negative impacts of involuntary resettlement which could occur in the instance that state land is not available for a future sites are discussed in the Resettlement Policy Framework, Annex C.

5. MEASURES TO MANAGE ENVIRONMENTAL AND SOCIAL IMPACTS Most potential impacts on physical, biological and social environment could be mitigated through a set of general measures that are typically applied to most construction projects to minimize impacts such as noise dust, vibration, waste generation, traffic hindrance, public safety etc.

Component 1 (Distribution)A set of Environmental Codes of Practice (ECOPs) which describe specific requirements to be carried out by the contractor have been prepared for the types of subprojects anticipated. These ECOPs are provided in Annex B-1.

Scope and content of the ECOPs is as follows.Scope: Construction activities for small works governed by these ECOPs are those whose impacts are of limited extent, temporary and reversible and readily managed with good construction practices.

The typical mitigating measures have been identified for the following aspects:- Dust generation- Noise and vibration- Water pollution- Drainage and sedimentation- Solid wastes- Chemical or hazardous wastes/materials- Disruption of vegetative covers and ecological resources- Traffic management - Interruption of utility services- Public and worker safety- Communication with local communities- Chance find procedures

There may be site specific impacts that require measures during construction such as facilities near sensitive receptors (communities, hospitals, schools etc.), near surface waters (streams, bays, ponds, etc.). These specific measures are to be identified and follow relevant government technical regulations and incorporated into the ECOP as additional measures.

Relative to social impacts, a social assessment has been prepared by the borrower, in collaboration with the Bank Task team for the project in Q4 of 2016. This provides an overview of the beneficiary population profile and contributes socioeconomic information for incorporation into future subproject planning. Local consultants together with task team members conducted both primary and secondary data collection to determine local socio-economic and cultural issues that will inform the benefits, social impacts and risks of the

7

project as well as any necessary mitigations. The social assessment has been prepared as a stand-alone document.

Component 2 (Solar)A limited ESIA similar in scope to the ESIA prepared for the first solar project at Mayangad Soum (P 152343 MONGOLIA Second Energy Sector Project Component 2, ESIA [Solar] 2016) would be required. The generic EMP presented in Annex B-2 could be used as a basis for this ESIA

The typical mitigating measures have been identified for the following aspects:

Design- Ecological protection

Construction- Socio-economic impacts (community disturbances, public health and safety, worker in-migration)- Dust generation- Engine exhaust emissions- Noise and vibration- Altered surface runoff- Topsoil management- Vegetative waste management- Solid wastes (hazardous and non-hazardous)- Wastewater management- Worker safety- Chance find procedures- Protection of avian and terrestrial speciesOperation- Local employment and supply opportunities- Visual disruption- Panel washwater management- Hazardous wastes- Ecological protection

Decommissioning- Waste disposal- Land restoration

There may be site specific impacts that require measures during construction such as facilities near sensitive receptors (communities, hospitals, schools etc.), near surface waters (streams, bays, ponds, etc.). These specific measures are to be identified and follow relevant government technical regulations and incorporated into the EMP as additional measures.

No involuntary resettlement impacts, either physical or economic displacement are anticipated for Component 2. The chosen locations will prioritize the use of state land for any solar developments. However, in the event that the location affects households, such as the land use of nomadic heading families, these will be addressed as stated in the RPF (Annex C).

8

Relative to other social impacts (community disturbances, public health and safety, worker in-migration), these have been evaluated and mitigation measures included in the generic EMP, see Annex A. Any future solar plant developments will need to maintain documentation which includes an overview of the local population demographics, available services and infrastructure.

6. PROCEDURES FOR PREPARATION, REVIEW, CLEARANCE AND IMPLEMENTATION OF SUBPROJECT SAFEGUARD INSTRUMENTS

Component 1 (Distribution)During the project implementation phase BSEDN and EBEDN have arranged staff responsible and qualified to monitor and manage all project related social and environmental safeguards requirements. Since most of the investments are relatively small, for the sake of efficiency a “subproject” shall be considered to be a number of investments assembled together as a single procurement package.

Component 2 (Solar)During the project implementation WES has arranged for staff responsible and qualified to monitor and manage all project related social and environmental safeguards requirements.

6.1 Subproject Due Diligence

Government Permits for Environment and Social RequirementsComponent 1 (Distribution)BSEDN or EBEDN will complete the Table presented in Annex A-1 along with copies of any accompanying documentation demonstrating the validity of the entries in the Table (e.g. copies of permits, licenses, letters of approval etc.). The completed Table and associated documentation will be included in the Project file.

Component 2 (Solar)WES will complete the Table presented in Annex A-2 along with copies of any accompanying documentation demonstrating the validity of the entries in the Table (e.g. copies of permits, licenses, letters of approval etc.). The completed Table and associated documentation will be included in the Project file.

These Tables are to confirm that relevant Mongolian land use, environmental, social and occupational health and safety laws and regulations will be followed during the construction phase (EA approvals, permits, licenses etc. for trash etc. are/were secured).

Land Acquisition and ResettlementComponent 1 (Distribution)BSEDN/EBEDN will review the location of the proposed subproject. According to Annex C, If the proposed subproject site involves land acquisition and/or resettlement which cannot be avoided, then BSEDN, EBEDN will check with the PMO to determine if a due diligence review for the land had been previously done for other subprojects. If a due diligence review had been done for that land, it does not have to be repeated. If no due diligence review has been previously done for the land, BSEDN/ EBEDN will inform the PMO of their responsibility to perform one to continue processing the subproject. See Annex C15 for a checklist to be completed during due diligence review.

If the land is government owned, due diligence will ascertain that there is no dispute over the land and or informal use of the land or land based assets.

Component 2 (Solar)

9

The PMO will review the location of the proposed subproject and arrange for a due diligence review to determine the status of the land (i.e. state land/other); if anyone is living or using the land formally or informally; and if there are any outstanding complaints with regards to the land. See Annex C, Section C14 Tool 7 for a checklist to be completed during due diligence review.

In the event that land must be involuntarily acquired, or will displace users from the land, a resettlement plan will be required. Annex C, Section C6 outlines the steps to be undertaken.

For both Components if any free market purchase of land is needed for the proposed subproject, World Bank will require proof (i.e. documentation) that the land acquisition transaction occurred on the free market between a willing buyer and a willing seller in accordance with Mongolian Law; and that there are no outstanding complaints/liabilities in regards to the land: no resettlement action plan would be required.

6.2 Screening and Categorization (Impact Assessment)

All investments identified prior to project appraisal have, in accordance with World Bank Environmental Assessment policy (OP 4.01) already been assigned “Category B” (see below). Component 1 and Component 2 investments identified after Board approval, are most likely to be of a similar nature and therefore are also likely to be considered Category B. However, should a new type investment be considered after Board approval, BSEDN, EBEDN (Component 1) or WES (Component 2) should consult with the World Bank task team who will confer with the environmental and social safeguards specialists (World Bank - GSURR and GENR) regarding procedures to be followed and safeguard documentation required before proceeding with any such investment.

The World Bank Screening/Categorization system classifies projects into one of three categories: A, B, or C, depending on the type, location, sensitivity and scale of the project and the nature and magnitude of its potential impacts. General characteristics of projects in the different screening categories under the World Bank system are as follows:

Category A: A proposed project is classified as Category A if it is likely to have significant adverse environmental impacts that are sensitive, diverse, or unprecedented. These impacts may affect an area broader than the sites or facilities subject to physical works. A full EIA is needed in accordance with the specific requirements of the World Bank’s policy and procedures for Category A projects.

Category B: A proposed project is classified as Category B if it’s potential adverse environmental impacts on human populations or environmentally important areas-including wetlands, forests, grasslands, and other natural habitats-are less adverse than those of Category A projects. These impacts are site specific; few if any of them are irreversible; most have impacts that are primarily confined to the project site, and in most cases mitigation measures can be readily designed from standard procedures. The scope of the EA is much narrower than that of a Category A EA, usually an Environmental Management Plan (EMP) and/or ECOP would be sufficient.

Category C: A proposed project is classified as Category C if it is likely to have minimal or no adverse environmental impacts. Beyond screening, no further EA action or any environmental documentation is required.

6.3 Safeguard Document Preparation

Component 1 (Distribution)

10

BSEDN/EBEDN is responsible for preparation of all environment related safeguard documentation. The PMO will be responsible for all social safeguard documentation and will work in collaboration with BSEDN/EBEDN in the preparation of these documents.

EnvironmentFor environment, only Category B investments will be supported under the World Bank project.

Since the subproject environmental issues are only associated with construction and possibly land clearance, the simple ECOPs presented in Annex B -1 would be sufficient to meet World Bank requirements as environmental documentation for the subproject. BSEDN/EBEDN should review the generic ECOPs presented in Annex B 1 and delete/remove those issues/risks and associated mitigating measures that are not relevant to their specific subproject. Their revised specific ECOP would represent the subproject EA document.

Where there might be potential site specific issues, such as proximity to residential complexes or other sensitive receptors (e.g. schools, hospitals, nursing homes etc.), need for a worker camp, additions to the ECOP, should be included.

SocialThe PMO will include individuals charged with ensuring that screening for adverse impacts on land/livelihoods to assure the principles of the RPF (refer Annex C) are undertaken in concurrence with project planning processes.

For each sub-project, screening will be undertaken for land ownership and requirements for land and land-based asset acquisition requirements, to determine whether voluntary land donation (component 1 only) may be possible (refer Annex C) or whether a Resettlement Plan (RP) or Abbreviated Resettlement Plan (ARP), based on the involuntary Resettlement Policy Framework is required. For brevity, the term ‘RP’ will be used in this document to refer to whichever resettlement instrument is selected. The PMO will be responsible for preparing and implementing any necessary Resettlement Plans in collaboration with BSEDN/EBEDN.

Component 2 (Solar)The PMO is responsible for preparation of all environment related safeguard documentation and will prepare these together with WES. The PMO will be responsible for all social safeguard documentation and will work in collaboration with WES in the preparation of these documents.

EnvironmentFor environment, only Category B investments will be supported under the World Bank project.

Since subproject environmental issues are modest, of limited range, and basically reversible after project completion. A limited ESIA similar in scope to the ESIA prepared for the first solar project at Mayangad Soum (P 152343 MONGOLIA Second Energy Sector Project Component 2, ESIA [Solar] 2016) would be required. The generic EMP presented in Annex B-2 could be used as a basis for this ESIA as an integral part of World Bank environmental documentation requirements for the subproject. In preparing the ESIA, WES should review the generic EMP presented in Annex B-2 and delete/remove those issues/risks and associated mitigating measures that are not relevant to any specific proposed solar photovoltaic power facility. The revised specific EMP would be incorporated into the subproject ESIA document. Assessment of avifauna will be part of the limited ESIA to determine potential impacts of the project on migratory and ground-nesting avian species and to factor in potential impacts in the project design and EMP.

11

Where there might be potential site specific issues, such as proximity to residential complexes or other sensitive receptors (e.g. schools, hospitals, nursing homes etc.), need for a worker camp, construction of an access road etc., additions to the site-specific EMP, should be included.

SocialThe PMO will include individuals charged with ensuring that screening for adverse impacts on land/livelihoods to assure the principles of the RPF (refer Annex C) are undertaken in concurrence with project planning processes for any future site under component 2.

Due diligence will be conducted for any potential site for future solar plant investment. Land ownership and use will be reviewed. In the instance that involuntary land acquisition cannot be avoided, then a Resettlement Plan (RP) or Abbreviated Resettlement Plan (ARP), based on the involuntary Resettlement Policy Framework will be required (refer Annex C). The PMO will be responsible for preparing and implementing any necessary Resettlement Plan in collaboration with WES.

6.4 Consultation

Component 1 (Distribution)During preparation of the ECOPs for each subproject package, at least one public consultation must be carried out by BSEDN/EBEDN in a manner consistent with World Bank requirements in a form convenient to the local people (survey, meeting, signboard. etc.).

Component 2 (Solar)During preparation of an EMP for a solar photovoltaic facility, at least one public consultation must be carried out by WES in a manner consistent with World Bank requirements in a form convenient to the local people (survey, meeting, signboard. etc.).

Component 1 and Component 2Information on the main findings of the environmental impacts and proposed mitigating measures must be made available in the local language understandable for the majority of the affected people. Records of the public consultation should be attached to the final EMP/ECOP package and contain as a minimum the following information:

Manner in which notification of the consultation was announced: media(s) used, date(s), description or copy of the announcement demonstrating an adequate period for prior notification of consultation event, disclosure of documentation and the opportunity to provide feedback.

Date(s) consultation(s) was (were) held Location(s) consultation(s) was (were) held Who was invited

Name, Organization or Occupation, Telephone/Fax/e-mail number/address (home and/or office)

Who attendedName, Organization or Occupation, Telephone/Fax/e-mail number/address (home and/or office)

Meeting Program/Schedule What is to be presented and by whom Summary Meeting Minutes (Comments, Questions and Response by Presenters) List of decisions reached, and any actions agreed upon with schedules and deadlines and

responsibilities

12

Any major relevant issue identified at the public meeting should be included in the draft ECOPs (Component 1) or EMP (Component 2). The final version of the EMP/ECOPs with any input from the public consultation should include a clear statement that environmental concerns and suggestions for environmental improvements made by the public have been incorporated in the EMP/ECOPs. BSEDN/EBEDN (Component 1) or WES (Component 2) should include the final draft EMP/ECOPs in the subproject file.

Specific requirements for consultation for any Resettlement Plans prepared for subprojects is contained in Annex C, Section C10.

6.5 Review, Approval and Disclosure

Review and ApprovalComponent 1 (Distribution)The first two subproject ECOP documents of both BSEDN and EBEDN (four in total) should be sent to the World Bank Task Team Environment and Social Safeguard Specialists, for verification and a “no objection”.

Resettlement of households is not expected as subprojects have relatively small footprints and in most cases alternative sites can be found. However, should a future subproject require such relocation prior approval from the World Bank should be sought and a resettlement plan or an abbreviated resettlement plan prepared. This is anticipated to be an abbreviated RP given the size and nature of any impacts would be minor. In the instance that an RP is developed, the PMO will submit the RP for World Bank review and approval.

Component 2 (Solar)The first subproject EMP should be sent to the World Bank Task Team Environment and Social Safeguard Specialists for verification and a “no objection”.

Resettlement of households is not expected as any future solar plants are expected to be located on state land. However, should the subproject require involuntary resettlement prior approval from the World Bank should be sought and a resettlement plan or an abbreviated resettlement plan will be prepared in accordance with Annex C.

The PMO will submit the RP to World Bank review and approval. The World Bank will review and clear the RP.

DisclosureComponent 1 (Distribution)Before subproject implementation BSEDN/EBEDN will send English language versions of the final approved ECOPs to the World Bank Office in Ulaanbaatar for disclosure in the Infoshop. BSEDN/EBEDN will also disclose a Mongolian language version of the final approved ECOPs at a public location (e.g. government building, school, library etc.) near the project sites and/or on their website.

Component 2 (Solar)Before subproject implementation the PMO will send English language versions of the final approved EMP to the World Bank Office in Ulaanbaatar for disclosure in the Info shop. The PMO together with WES will also disclose a Mongolian language version of the final approved EMP at a public location (e.g. government building, school, library etc.) near the project sites and/or on their websites.

Component 1 and Component 2For any resettlement plans developed, the PMO, together with BSEDN/EBEDN or WES will disclose the draft and final versions to the affected persons and the general public in the project area both on its website, and in

13

hard copy in a language and location accessible to them. In this and any future projects undertaken in collaboration with the Bank, disclosure of the draft RP will be undertaken at least one month prior to Bank review. Disclosure of the final RP will occur following Bank acceptance. Refer Annex C, section C6 for further details.

6.6 Legal/ Contractual Obligations (Conditionality)

Component 1 (Distribution)BSEDN/EBEDN should include the ECOPs in any bid documents prepared and any contract(s) subsequently awarded should include copies of the ECOPs as well as specific language requiring the Construction Contractor to follow requirements specified in these referenced ECOPs.

BSEDN/ EBEDN should ensure that all bidding documents and contracts for Works contain provisions that require contractors to comply with the measures and requirements relevant to the contractor set forth in any RP prepared for individual subprojects (to the extent they concern impacts on affected people2 during construction).

Provisions should include that the contractor will provide BSEDN/EBEDN with a written notice of any unanticipated resettlement risks or impacts that arise during construction that were not considered in any RPs prepared for subprojects; and that the contractor must fully reinstate pathways, other local infrastructure, and agricultural land to at least their pre-project condition upon the completion of construction.

Component 2 (Solar)The PMO should include the EMP from the ESIA in any bid documents prepared and any contract(s) subsequently awarded should include copies of the EMP as well as specific language requiring the Construction Contractor to follow requirements specified in the referenced EMP.

The PMO should ensure that all bidding documents and contracts for Works contain provisions that require contractors to comply with the measures and requirements relevant to the contractor set forth in any RP prepared for a future solar plant site (to the extent they concern impacts on affected people 3 during construction).

Provisions should include requirements for the Construction Contractor to provide the PMO with a written notice of any unanticipated resettlement risks or impacts that arise during construction that were not considered in any RPs prepared for subprojects; and that the contractor must fully reinstate pathways, other local infrastructure, and agricultural land to at least their pre-project condition upon the completion of construction.

6.7 Implementation Arrangements & Responsibilities

Monitoring Component 1 (Distribution)BSEDN/EBEDN are responsible for environmental monitoring of the ECOP. In turn, during construction, the Construction Contractor would be responsible for the day-to-day monitoring of ECOP implementation. The PMO (in collaboration with BSEDN/EBEDN) will be responsible for monitoring the implementation of any RPs prepared under the project. Specific details for monitoring requirements for any RPs are contained in Annex C.

2 Please refer Annex C, section C.2 for a definition of Affected People. 3 Please refer Annex C, chapter AC.1 for a definition of Affected People.

14

Component 2 (Solar)WES is responsible for environmental monitoring of the EMP. In turn, during construction, the Construction Contractor would be responsible for the day-to-day monitoring of EMP implementation. The PMO (in collaboration with WES) will be responsible for monitoring the implementation of any RP prepared under the project. Specific details for monitoring requirements for RPs are contained in Annex C.

ReportingComponent 1 (Distribution)During construction, the Construction Contractor should, as part of normal reporting procedures, provide written confirmation to BSEDN/EBEDN that the ECOPs are being implemented in accordance with the schedules prescribed.

BSEDN/EBEDN in their normal reporting to the World Bank, should include a “safeguards” section which summarizes all their subproject ECOPs implementation activities, identifies any safeguard issues that developed, and how they are/or will be managed.

Component 2 (Solar)During construction, the Construction Contractor should, as part of normal reporting procedures, provide written confirmation to WES that the EMP is being implemented in accordance with the schedules prescribed.

The PMO in their normal reporting to the World Bank, should include a “safeguards” section which summarizes all EMP implementation activities, identifies any safeguard issues that developed, and how they are/or will be managed.

Component 1 and Component 2In the event that any RPs are prepared for subprojects including any future solar plant, each required RP will include detailed monitoring and progress reporting arrangements for the subproject (refer Annex C for further details).

7. CAPACITY DEVELOPMENT Component 1 (Distribution)Both BSEDN and EBEDN have each selected one technical person (responsible for health and safety issues) for World Bank environmental safeguard training and one person each for social safeguard training so that they are fully prepared to implement their responsibilities described under this ESMF. In October (4 th) 2016, they received an initial safeguards briefing from the World Bank Safeguards specialist. Additional training will be provided in Ulaanbaatar in the first half of 2017, by a safeguards specialist from the World Bank Office in Beijing.

Component 2 (Solar)Within WES, two Safeguards Officers (one environment and one social) will be appointed. The candidates for these two positions will be selected, based on their existing skills, interest and willingness to learn. They will receive capacity building training along with the PMO safeguard staff as mentioned in the above paragraph.

PMO, Component 1 and Component 2 In the preparatory stage, the PMO will appoint a Safeguards Officer (i.e. the Environment and Social Specialist) reporting to the Project Manager in the PMO, who will have the capacity and will be responsible for handling environmental and social requirements with equal diligence. This Officer will also undergo World Bank safeguard training, so that they can implement their responsibilities as per the ESMF and RPF (as described above). Particular attention will be given during the early stages to training on environmental and social due diligence (refer chapter 6.1 on subproject due diligence) for individual subprojects.

15

8. GRIEVANCE REDRESS MECHANISM BSEDN/EBEDN (Component 1) or WES (Component 2) shall coordinate with local authorities (leaders of local communes, leader of villages) for agreed schedules of construction activities at areas near sensitive places (such as hospitals, schools, libraries, etc.) or at sensitive times (e.g. holidays, weekends, religious festival days etc.). BSEDN/EBEDN (Component 1) or WES (Component 2) will inform local residents about construction and work schedules, interruption of services, traffic detour routes and provisional bus routes, blasting and demolition, as appropriate.

Notification boards shall be erected at all construction sites providing information about the project, as well as contact information about the site managers, environmental staff, health and safety staff, telephone numbers and other contact information so that any affected people can have the channel to voice their concerns and suggestions. The Construction Contractor should not create nuisances and disturbances in or near communities.

Copies of these ECOPs (Component 1) or EMP (Component 2) and of other relevant environmental and social safeguard documents shall be made available to local communities and to workers at the site upon commencement of the project. BSEDN/EBEDN (Component 1) or WES (Component 2) will provide a community relations contact from whom interested parties can receive information on site activities, project status and project implementation results.

Grievances could arise in relation to sub-projects physical impacts, associated with the upgrading of distribution infrastructure. These could possibly stem from environmental damage, disputes about land, assets or elements of livelihood, construction impacts or accidents. Irrespective of cause, the grievance mechanism will address affected people's concerns and complaints promptly, using a transparent process that is responsive, culturally appropriate, and readily accessible to all segments of the affected communities at no cost and without retribution.

The complaints process will offer remedies appropriate to the scale of the grievance. The process will be as follows:

Complaints or feedback that can be resolved by contractors or BSEDN/EBEDN (Component 1) or WES (Component 2) staff during normal working operations will be undertaken immediately. The complaint will be recorded, including details of the complaint (what, when, date(s), time(s) of day, gender, other observations), contact details of complainant, remedy/remedies, and date of close out. Complaints can be lodged with BSEDN/EBEDN (Component 1) or WES (Component 2) by phone, post, email, or in person with a Soum representative who will forward the complaint to BSEDN/EBEDN (Component 1) or WES (Component 2).

Other project-related complaints that cannot be resolved immediately, or by contractors or BSEDN/EBEDN (Component 1) or WES (Component 2) staff, will in the first instance be notified to the PMO Safeguard Officers for mediation within a specified short time, preferably not more than fifteen working days. The PMO’s Safeguards Officers will facilitate mediation hearings with the relevant body related to the grievance and complainant in open forum close to the place of residence of the affected person(s) or affected group. The complainant will be encouraged to be accompanied by supporters during the process.

If mediation is unsuccessful, or if the matter is substantive, at any time affected parties can file written or verbal grievances through the Mongolian Court system, in accordance with Mongolian laws and procedures.

At any time, if the project grievance redress mechanism is considered inadequate for addressing concerns then the World Bank Grievance Redress Service and the World Bank’s Inspection Panel are avenues for appeal.

16

Information on how to submit complaints to the World Bank’s corporate Grievance Redress Service (GRS), can be found at http://www.worldbank.org/GRS. Information on how to submit complaints to the World Bank Inspection Panel, can be found at www.inspectionpanel.org.

All complaints received will be recorded and sent through to the Safeguards Officer at the PMO, where they will consolidate complaints into a matrix recording the complainant’s details, date, cause of complaint, steps taken to resolve the issue, outcome and date, any further steps to be taken, date of ultimate resolution and number of days elapsed from first notification to final resolution. The matrix will be updated and included as part of regular reports to the Bank such that the World Bank Task team can monitor these on an ongoing basis. Analysis of causes of complaints will be undertaken to inform improvements in future sub-project design as appropriate.

Information about how to register a complaint will be given in all public communications (including notice boards) and consultations about the Project. Any RPs developed will extend the above process to ensure affected households can lodge grievances specific to the resettlement process and that appropriate capacity for resettlement related grievances is available at the local level.

9. ESMF CONSULTATION AND DISCLOSURE

Component 1 (Distribution)BSEDN/EBEDN have consulted with relevant stakeholders to discuss a draft ESMF prepared exclusively for Component 1. The consultation included the following:

Meetings with government stakeholders, such as the Ministry of Environment, Green Development and Tourism, the Ministry of Education, Culture and Science, the Administration of Land Affairs, Construction, Geodesy and Cartography to discuss this draft ESMF.

Public meetings involving communities, civil society organizations (i.e. Owners Associations, Entrepreneurs associations) and local NGOs in Baganuur and Erdernet cities.

At public meetings, copies of the draft Mongolian language ESMF was made available for ready reference. Presentations were made in simple language, providing maps and photos of the relevant equipment. Attendees were advised of the legal framework under which the project will operate, their rights and how to make comments or register complaints about the project. The presenter ensured there was sufficient discussion time. Comments and any resolutions adopted at the meetings are included in Annex D-1. These have been fed back to the technical team members and reflected in updates to this ESMF. We note the inclusion of items such as specifying work hours in the ECOPs (i.e. between 7am-6pm) and requirements for contractors regarding the collection and separation of recycling wastes.

Based upon the results of the consultation, BSEDN/EBEDN have finalized that ESMF.

A list of participants and a summary of meeting minutes from ESMF consultation and disclosure activities is included in Annex D-1. ESMF consultations in Baganuur included 48 individuals, and 30 in Erdernet. Consultations were advertised to the public through newspapers, posters and local radio.

Component 2 (Solar)The PMO and WES consulted relevant stakeholders to discuss a draft ESMF prepared exclusively for Component 2. The consultation included the following:

Meetings with government stakeholders, such as the Ministry of Environment, Green Development and Tourism, the Ministry of Education, Culture and Science, the Administration of Land Affairs, Construction, Geodesy and Cartography.

17

Meetings with relevant NGOs such as World Wildlife Fund, Wildlife Science and Conservation Centre of Mongolia.

Residents in Western Aimags, such as those potentially affected by group 1 subproject solar investments.

At consultation meetings, copies of this draft Mongolian language ESMF were made available for ready reference. Presentations were made in simple language, providing maps and photos of the relevant equipment and location. Attendees were advised of the legal framework under which the project will operate, their rights and how to make comments or register complaints about the project. Participant lists and a summary of the meeting minutes from consultations conducted on December 2nd 2016 are included in Annex D-2, 60 public participants attended the public consultations.

Based upon the results of the consultation, the PMO has finalized that ESMF.

At the recommendation of RSS, the ESMF for Component 1 was combined with the ESMF of Component 2 to obtained this current combined ESMF. This combined ESMF is to be included in the Project Operating Manual. Prior to appraisal. The PMO will disclose this Mongolian language ESMF on their website and send an English language version of this ESMF to the World Bank for public disclosure at the World Bank Office in Ulaanbaatar.

18

ANNEX A 1: SAFEGUARD DUE DILLIGENCE TABLE COMPONENT 1

IssueApproval Type

(Permit, License, Letter etc.) and Approving

Authority

Approval Date Documentation

AttachedReceived Expected

Environmental Assessment

MEGDTMonitoring and Evaluation

DepartmentNatural Habitats4 MEGDT

Department of Environment and Natural Resources

ManagementForestry3 MEGDT

Department of Forest Policy and Coordination

Waste Disposal-Non Hazardous (paper, packaging, wood,

plastics etc.)Waste Disposal-

Hazardous (spent solvents, used oil,

glues, etc.)PCB Management

Hazardous Materials Storage and Use

(paints, solvents, fuels, other combustibles

etc.)Fire Prevention

Worker Health and Safety

Cultural Resources3 Department of Cultural Properties Management

Whether the new building has a land use

certificate3

If land acquisition and/or resettlement is

involved

Aimag/ Soum Governors Office. Administration of

Land Affairs, Construction, Geodesy and Cartography.

4 Only required if new land is to be used and/or any excavations (Cultural Resources) is involved.

19

ANNEX A 2: SAFEGUARD DUE DILLIGENCE TABLE COMPONENT 2 (SOLAR)

IssueApproval Type

(Permit, License, Letter etc.) and

Approving Authority

Approval Date Documentation AttachedReceived Expected

Land ownership by the State

Request letter by PMO and Soum Governors

documentation regarding land transfer/ lease arrangement

Environmental Assessment

MEGDTMonitoring and

Evaluation DepartmentWater Supply Reliable well yield

data for groundwater at the

proposed project site. Should the due diligence efforts to collect this data be unsuccessful, field

studies to secure this information is

required as part of project design.

Water use permitNatural Habitats5 MEGDT

Department of Environment and Natural Resources

ManagementForestry3 MEGDT

Department of Forest Policy and

CoordinationWastewater discharge

permitWaste Disposal-Non Hazardous (paper, packaging, wood,

plastics etc.)Waste Disposal-

Hazardous (spent solvents, used oil, glues,

etc.)Hazardous Materials

5

20

Storage and Use (paints, solvents, fuels,

other combustibles etc.)

Worker Health and Safety

Cultural Resources Department of Cultural Properties

ManagementIf land acquisition

and/or resettlement is involved

Aimag/ Soum Governors Office.

Administration of Land Affairs, Construction,

Geodesy and Cartography.

21

ANNEX B 1: ENVIRONMENTAL CODES OF PRACTICE (ECOPs)

B1-1. Rehabilitation of 6-10/0.4 kv Transformers

ISSUES/RISKS MITIGATION MEASURES

Dust generation/ Air pollution(Installation of new

transformer)

The Contractor implement dust control measures to ensure that the generation of dust is minimized and is not perceived as a nuisance by local residents, maintain a safe working environment, such as: * watering dusty roads and construction sites; * exposed soil and material stockpiles shall be covered to protect against wind erosion.

Noise and vibration All construction vehicles must have mufflers in good condition to avoid excessive noise emissions and frightening any nearby livestock Conduct activities during normal working hours Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification. Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Chemical or hazardous materials and/or wastes (spent lubricants,

paints, adhesives, solvents)

Existing TransformerThe oil present in the transformer may contain polychlorinated biphenyls (PCBs). This oil should be sent to the PCB Test Laboratory in Ulaanbaatar.

If the oil contains PCB at unacceptable levels (>50 ppm), the transformer is to be sent to the PCB Processing Center in Ulaanbaatar for PCB removal from the oil.

If oil is free of PCBs (<50ppm), the transformer can still be used elsewhere in the power distribution system.

If there is evidence that the transformer has or is leaking and has PCB contaminated oil, the oil should be drained and treated at the PCB Processing Center and the faulty transformer either repaired or treated as “solid waste” (see below).

If there is any visual indication of soil contamination from the leak, that soil should be excavated, collected into heavy duty plastic containers. The MEGDT should be informed and should provide guidance for the handling of this waste (both for PCB contaminated soils and non PCB contaminated soils).

New Transformer (construction of support structure)Do not use toxic materials, including lead-based paints on any

22

structures: any coating materials for steel or concrete structures should be approved by the MEGDT.

Disruption of vegetative cover and ecological resources

(Installation of new transformer)

Any areas to be cleared should be minimized as much as possible. To the extent possible, existing roads/access routes to construction site should be used. If access roads must be established, they should be routed to cause minimal disruption to local habitats or any economic activity (e.g. agriculture or herders). The same access road used for construction/installation should be used for maintenance operations. In the event virgin vegetation is removed, The Contractor shall remove topsoil from all areas where topsoil will be impacted on by rehabilitation activities, including temporary activities such as storage and stockpiling of poles/structures etc. Any stripped topsoil shall be stockpiled in areas agreed with the BSEDEN/EBEDN for later use in re-vegetation and shall be adequately protected from loss by rain, wind etc.). Application of pesticides (herbicides) for vegetation clearing and/or maintenance is not permitted. Land clearance/maintenance should be either manual or mechanical or both. Disposal of vegetative cover should be to a government approved site.For the removal of virgin vegetation, BSEDN/EBEDN shall obtain an environmental clearance or permit issued by the MEGDT or local environmental authorities. When needed, the Construction Contractor shall erect temporary protective fencing to efficiently protect any trees before commencement of any works within the site. The Construction Contractor shall ensure that no hunting, trapping shooting, poisoning of fauna takes place by Contractor personnel. Cleared areas such as disposal areas, site facilities, workers’ camps, stockpiles areas, working platforms and any areas temporarily occupied during construction of the project works shall be restored by the Construction Contractor using landscaping, adequate drainage and vegetation. Soil contaminated with chemicals or hazardous substances shall be removed, transported and treated as hazardous waste. Disposal shall be based on documented guidance from the MEGDT

Solid waste At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities. Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN. Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof. No burning, on-site burying or dumping of solid waste shall occur. If burning is the only alternative, prior approvals should be obtained from the local environmental authority. The Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction materials, such as parts of building fabrication, boards, flooring and packaging materials for later

23

recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN. Waste materials that have no useful alternative shall be collected and stored temporarily at designation locations along the distribution line route. Disposal shall be based on documented guidance from the MEGDTIf there is evidence that the transformer has or is leaking and has oil free of PCBs, the faulty transformer can either be repaired or treated as waste material.Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses. When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities. Components that have remaining useful life are to be stored and/or used at other BSEDN/EBEDN sites as needed.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (To be included in procurement documents)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

Chance find procedures If the Construction Contractor discovers sites/artifacts of archeological, historical, significance, including graveyards and/or individual graves during excavation or construction, the Construction Contractor shall: Stop the construction activities in the area of the chance find immediately; Notify BSEDN/EBEDN officials who in turn will notify responsible authorities in charge of the Cultural Property Secure the site to prevent any damage or loss of removable objects. In cases of removable antiquities or sensitive remains, constant guarding

24

of the site shall be arranged until the responsible authorities take over; Delineate the discovered site or area Relevant authorities would be in charge of protecting and preserving the site before deciding on subsequent procedures. Decisions on how to proceed shall be taken by the responsible authorities. If the cultural sites and/or relics are of high value and site preservation is recommended by professionals and required by the cultural relics authority, BSEDN/EBEDN will make necessary design changes to accommodate the request and preserve the site; Decisions concerning the management of the finding shall be communicated in writing by relevant authorities; Construction works could resume only after written permission is granted from the responsible authorities concerning safeguard of the heritageAny worker removing such artifacts for personal use or gain, shall be dismissed and subjected to legal action.

25

B1-2: Replacement of Existing Substations with New Substations

ISSUES/RISKS MITIGATION MEASURE Site of new substation may involve conversion of critical

natural habitats or affects non-critical natural habitats6

Provide maps of proposed subproject area to Ministry of Environment, Green Development and Tourism(MEGDT), Director General for Environment and Natural Resource Management for approval

Site of new substation may involve destruction or

conversion of forests/forest ecosystems1

Provide maps of proposed subproject area to Ministry of Environment, Green Development and Tourism(MEGDT), Director General for Forests for approval

Site of new substation may adversely impact Mongolian

cultural resources1

Provide maps of proposed subproject area to Ministry of Education, Culture and Science, (MECS) Director General for cultural property management for approval

Dust generation/ Air pollution The Construction Contractor will implement dust control measures to ensure that the generation of dust is minimized and is not perceived as a nuisance by local residents, maintain a safe working environment, such as:

- watering dusty roads and construction sites; - covering of material stockpiles;- Exposed soil and material stockpiles shall be protected against

wind erosion. Noise and vibration All construction vehicles must have mufflers in good condition to

avoid excessive noise emissions Construction activities should be limited to legally permissible

times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification.

Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Water pollution If sanitary facilities are not currently available at the subproject sites, portable or constructed toilets must be provided for construction workers either on site and/or at any work camps (if such camps will be established). There should be no direct discharges of human sewage to any water body.

Do not wash cars, trucks or machinery in or near natural water bodies or drinking water sources.

Drainage and sedimentation The Contractor shall ensure any drainage system is always maintained cleared of mud and other obstructions.

Solid waste(non-hazardous)

At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities.

Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN.

Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof.

No burning, on-site burying or dumping of solid waste shall occur.

6 This is extremely unlikely, but is suggested as a precautionary measure

26

If burning is the only alternative, prior approvals should be obtained by the MEGTD or local environmental authorities.

The Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction materials, such as parts of building fabrication, boards, flooring and packaging materials for later recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN.

Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses.

When removed off site, solid waste or construction debris shall be disposed of only at sites recommended and approved by local waste management authorities or the Ministry of Environment, Green Development and Tourism (MEGDT)

Chemical or hazardous materials and/or wastes (spent

lubricants, paints, adhesives, solvents, equipment fluids

containing PCBs etc.)

Used lubricating oil and grease shall be removed from site and sold to a properly licensed recycling company. Used oil and lubricants, from the maintenance of any vehicles and machinery shall be stored in sealed drums or collected in holding tanks and removed from site and sold to a licensed oil recycling company or disposed at a government approved site. Do not use toxic materials, including lead-based paints on any structures: coating materials for steel or concrete structures.Asbestos materials are not to be used as either construction (roofs, interior or exterior walls etc.) or insulating materials (piping, ductwork, etc.) in any buildings.If any existing building contains asbestos materials, the Construction Contractor is responsible for having these materials removed with guidance from MEGTD

For components such as old transformers, circuit breakers, capacitors and other electric equipment, etc. which may contain PCBsBSEDN/EBEDN is to make arrangements to have the oils sent to the PCB Test Laboratory in Ulaanbaatar.

For those components free of any leaks:If the oil contains PCB at unacceptable levels (>50 ppm), arrangements are to be made by BSEDN/EBEDN to send the oil to the PCB Processing Center in Ulaanbaatar for PCB removal from the oil. The equipment may then be refilled with PCB free oil and used elsewhere in the distribution system

If oil is free of PCBs (<50ppm), the equipment can still be used elsewhere in the power distribution system.

For components which provide visual evidence of previous leaks or are leaking

If the oil contains PCB at unacceptable levels (>50 ppm), arrangements are to be made by BSEDN/EBEDN to send the oil to the PCB Processing Center in Ulaanbaatar for PCB removal from the

27

oil. The equipment may then either be repaired and refilled with PCB free oil and used elsewhere in the distribution system, or the equipment could be sold as scrap to operators officially licensed to conduct recycling/recovery

If oil is free of PCBs (<50ppm), the equipment can either be repaired and be used elsewhere in the power distribution system or sold as scrap to operators officially licensed to conduct recycling/recovery

Any soil or surface materials that exhibit visual evidence of contamination from oil leaks should be excavated to at least six inches beyond the line of visible contamination, then collected into heavy duty plastic containers. The MEGDT should be informed and should provide guidance for the handling of this waste (both for PCB contaminated soils and non PCB contaminated soils).

All new electrical equipment should be free of PCBs and this requirement should be specified in any bid documents.

Disruption of vegetative cover and ecological resources

Areas to be cleared should be minimized as much as possible. To the extent possible, existing roads should be used. If access

roads must be established, they should cause minimal disruption to local habitats. The same access road used for construction/installation should be used for maintenance operations

The Construction Contractor shall remove topsoil from all areas where topsoil will be impacted on by rehabilitation activities, including temporary activities such as storage and stockpiling. Any stripped topsoil shall be stockpiled in temporary areas agreed with BSEDN/EBEDN and be adequately protected from loss by rain, wind etc.

Application of pesticides (herbicides) for vegetation clearing and/or maintenance is not permitted. Land clearance/maintenance should be done either manually or mechanically or both.

For the removal of virgin vegetation, BSEDN/EBEDN shall obtain an environmental clearance or permit issued by the MEGDT or local environmental authorities.

When needed, the Construction Contractor shall erect temporary protective fencing to efficiently protect any trees before commencement of any works within the site.

Cleared areas such as disposal areas, site facilities, workers’ camps, stockpiles areas, working platforms and any areas temporarily occupied during construction of the project works shall be restored by the Construction Contractor using land Soil contaminated with chemicals or hazardous substances shall be removed, transported and treated as hazardous waste. Disposal shall be based on documented guidance from the MEGDT.

Traffic management Traffic control measures, during the construction phase of the project, the BSEDN/EBEDN Construction Contractor shall seek guidance from the Mongolian government traffic authorities if there is:

28

a) significant increases in vehicle trips b) a need to re-route traffic taking into account sensitive areas such as schools and hospitals. c) a need to install lighting at night for traffic circulation. The Construction Contractor shall place signs around the construction areas to facilitate traffic movement providing direction to various components of the works, and provide safety advice and warning. If materials are to be transported during rush hour, the local traffic department must be notified by the Contractor and if necessary, request their assistance. Before demolition/construction activities start, BSEDN/EBEDN shall carry out consultations with local government and community and with the traffic department.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of water/power at least 2 days in advance.

Any damages to existing utility systems of cable, telecommunications, water supply etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor. (To be included in Procurement documents

Restoration of affected areas Cleared areas such as disposal areas, site facilities, workers’ camps, stockpiles areas, working platforms and any areas temporarily occupied during construction of the project works shall be restored by the Construction Contractor using landscaping, adequate drainage and vegetation.

Soil contaminated with chemicals or hazardous substances shall be removed, transported and treated as hazardous waste. Disposal shall be based on documented guidance from the MEGTD

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

Chance find procedures If the Construction Contractor discovers sites/artifacts of archeological, historical, significance, including graveyards and/or individual graves during excavation or construction, the Construction Contractor shall:

29

Stop the construction activities in the area of the chance find immediately; Notify BSEDN/EBEDN officials who in turn will notify responsible authorities in charge of the Cultural Property Secure the site to prevent any damage or loss of removable objects. In cases of removable antiquities or sensitive remains, constant guarding of the site shall be arranged until the responsible authorities take over; Delineate the discovered site or area Relevant authorities would be in charge of protecting and preserving the site before deciding on subsequent procedures. Decisions on how to proceed shall be taken by the responsible authorities. If the cultural sites and/or relics are of high value and site preservation is recommended by professionals and required by the cultural relics authority, BSEDN/EBEDN will make necessary design changes to accommodate the request and preserve the site; Decisions concerning the management of the finding shall be communicated in writing by relevant authorities; Construction works could resume only after written permission is granted from the responsible authorities concerning safeguard of the heritageAny worker removing such artifacts for personal use or gain, shall be dismissed and subjected to legal action.

30

B1-3: Replacing Oil-filled Circuit BreakersISSUES/RISKS MITIGATION MEASURES

Noise and vibration All construction vehicles must have mufflers in good condition to avoid excessive noise emissions and frightening any nearby livestock Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification. Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Hazardous materials The oil present in the old circuit breakers may contain polychlorinated biphenyls (PCBs). This oil should be sent to the PCB Test Laboratory in Ulaanbaatar. If the oil contains PCB at unacceptable levels (>50 ppm), the circuit breaker is to be sent to the PCB Processing Center in Ulaanbaatar for PCB removal from the oil.

If oil is free of PCBs (<50ppm), the circuit breaker can still be used elsewhere in the power distribution system.If the circuit breaker leaks and has PCB contaminated oil, the oil should be drained and treated at the PCB Processing Center and the faulty circuit breaker either repaired or treated as “solid waste” (see below).

If the circuit breaker leaks and has oil free of PCBs, the faulty circuit breaker can either be repaired or treated as “solid waste” (see below).

Solid waste At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities. Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN. Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof. No burning, on-site burying or dumping of solid waste shall occur. If burning is the only alternative, prior approvals should be obtained from the local environmental authority. The Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction materials, such as parts of building fabrication, boards, flooring and packaging materials for later recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN. Waste materials that have no useful alternative (cable covering etc.) shall be collected and stored temporarily at designation locations along the distribution line route. Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses.

31

When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities. Components that have remaining useful life are to be stored and/or used at other BSEDN/EBEDN sites as needed.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (To be included in the Procurement documents)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

32

B1-4: Installation of Vacuum Circuit Breakers

ISSUES/RISKS MITIGATION MEASURESNoise and vibration All construction vehicles must have mufflers in good condition to avoid

excessive noise emissions and frightening any nearby livestock Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification. Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Solid waste At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities. Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN. Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof. No burning, on-site burying or dumping of solid waste shall occur. If burning is the only alternative, prior approvals should be obtained from the local environmental authority. The Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction materials, such as parts of building fabrication, boards, flooring and packaging materials for later recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN. Waste materials that have no useful alternative shall be collected and stored temporarily at designation locations along the distribution line route. Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses. When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities. Components that have remaining useful life are to be stored and/or used at other BSEDN/EBEDN sites as needed.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (To be included in Procurement documents)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety

33

condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

34

B1-5: Replacing Old Meters with Smart Meters and Installation of Smart Meters to New Customers

ISSUES/RISKS MITIGATION MEASURESNoise and vibration Construction activities should be limited to legally permissible times, or

to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification.

Solid waste At all places of work, the Contractor shall collect all waste materials (old meters, packaging, waste wire clippings etc.) generated and temporarily stored at sites designated and approved by BSEDN/EBEDN. No burning, on-site burying or dumping of solid waste shall occur. Meters that have remaining useful life are to be stored and/or used at other BSEDN/EBEDN sites as needed. Waste materials that have no useful alternative shall be collected, stored and sold to operators officially licensed to conduct recycling/recovery. Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses. When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of water/power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, water supply etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (TO BE INCLUDED IN THE PROCUREMENT DOCUMENTS)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

35

36

B1-6: Construction of New Distribution Lines

ISSUES/RISKS MITIGATION MEASURESRight of Way (ROW) involves conversion of critical natural

habitats or affects non-critical natural habitats

Provide maps of proposed subproject area to Ministry of Environment, Green Development and Tourism(MEGDT), Director General for Environment and Natural Resource Management for

approvalRight of Way (ROW) involves destruction or conversion of

forests/forest ecosystems

Provide maps of proposed subproject area to Ministry of Environment, Green Development and Tourism(MEGDT), Director

General for Forests for approvalRight of Way (ROW) adversely

impacts Mongolian cultural resources

Provide maps of proposed subproject area to Ministry of Education, Culture and Science, (MECS) Director General for Cultural Property

management for approvalDust generation/ Air pollution The Construction Contractor will implement dust control measures to

ensure that the generation of dust is minimized and is not perceived as a nuisance by local residents, maintain a safe working environment, such as: * watering dusty roads and construction sites; * exposed soil and material stockpiles shall be covered to protect against wind erosion.

Noise and vibration All construction vehicles must have mufflers in good condition to avoid excessive noise emissions and frightening any nearby livestock Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification. Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Water pollution Portable or constructed toilets must be provided for construction workers either on site and/or at any work camps (if such camps will be established). There should be no direct discharges of human sewage to any waterbody.

Do not wash cars, trucks or machinery in or near natural water sources.

Drainage and sedimentation The Contractor shall ensure any drainage system is always maintained cleared of mud and other obstructions.

Solid waste At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities. Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN. Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof.

37

No burning, on-site burying or dumping of solid waste shall occur. If burning is the only alternative, prior approvals should be obtained from the local environmental authority. The Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction materials, such as parts of building fabrication, boards, flooring and packaging materials for later recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN. Waste materials that have no useful alternative shall be collected and stored temporarily at designation locations along the distribution line route. Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses. When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities.

Chemical or hazardous materials and/or wastes (spent lubricants,

paints, adhesives, solvents)

Used oil and grease shall be removed from site and sold to a properly licensed recycling company. Used oil and lubricants, from the maintenance of any vehicles and machinery shall be stored in sealed drums or collected in holding tanks and removed from site and sold to a licensed oil recycling company or disposed at a government approved site. Do not use toxic materials, including lead-based paints on any structures: any coating materials for steel or concrete structures should be approved by the MEGDT.Hazardous wastes are to be stored with appropriate labeling at temporary facilities on-site or brought to a central facility that is well ventilated with impervious floors and locked when not in use. In the event materials are to be used containing chemicals not regulated in Mongolia, BSEDN/EBEDN should obtain approval for use from MEGTD.

Disruption of vegetative cover and ecological resources

Any areas to be cleared should be minimized as much as possible. To the extent possible, existing roads/access to proposed pole sites should be used. If access roads must be established, they should be routed to cause minimal disruption to local habitats or any economic activity (e.g. agriculture or herders). The same access road used for construction/installation should be used for maintenance operations. In the event virgin vegetation is removed, The Contractor shall remove topsoil from all areas where topsoil will be impacted on by construction activities, including temporary activities such as storage and stockpiling, of transmission line poles/structures etc. Any stripped topsoil shall be stockpiled in areas agreed with the BSEDEN/EBEDN for later use in re-vegetation and shall be adequately protected from loss by rain, wind etc.). Application of pesticides (herbicides) for vegetation clearing and/or maintenance is not permitted. Land clearance/maintenance should be

38

either manual or mechanical or both. Disposal of vegetative cover should be to a government approved site.For the removal of virgin vegetation, BSEDN/EBEDN shall obtain an environmental clearance or permit issued by the MEGDT or local environmental authorities. When needed, the Construction Contractor shall erect temporary protective fencing to efficiently protect any trees before commencement of any works within the site. The Construction Contractor shall ensure that no hunting, trapping shooting, poisoning of fauna takes place by Contractor personnel. Cleared areas such as disposal areas, site facilities, workers’ camps, stockpiles areas, working platforms and any areas temporarily occupied during construction of the project works shall be restored by the Construction Contractor using landscaping, adequate drainage and vegetation. Soil contaminated with chemicals or hazardous substances shall be removed, transported and treated as hazardous waste. Disposal shall be based on documented guidance from the MEGDT

Traffic management Traffic control measures, during the construction phase of the project, the BSEDN/EBEDN Construction Contractor shall seek guidance from the Mongolian government traffic authorities if there is: a) significant increases in vehicle trips b) a need to re-route traffic taking into account sensitive areas such as schools and hospitals. c) a need to install lighting at night for traffic circulation. The Construction Contractor shall place signs around the construction areas to facilitate traffic movement providing direction to various components of the works, and provide safety advice and warning. If materials are to be transported during rush hour, the local traffic department must be notified by the Contractor and if necessary, request their assistance. Before pole placement activities start, BSEDN/EBEDN shall carry out consultations with local government and community and with the traffic department.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of water/power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, water supply etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (TO BE INCLUDED IN THE PROCUREMENT DOCUMENTS)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols).

39

The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

Chance find procedures If the Construction Contractor discovers sites/artifacts of archeological, historical, significance, including graveyards and/or individual graves during excavation or construction, the Construction Contractor shall: Stop the construction activities in the area of the chance find immediately; Notify BSEDN/EBEDN officials who in turn will notify responsible authorities in charge of the Cultural Property Secure the site to prevent any damage or loss of removable objects. In cases of removable antiquities or sensitive remains, constant guarding of the site shall be arranged until the responsible authorities take over; Delineate the discovered site or area Relevant authorities would be in charge of protecting and preserving the site before deciding on subsequent procedures. Decisions on how to proceed shall be taken by the responsible authorities. If the cultural sites and/or relics are of high value and site preservation is recommended by professionals and required by the cultural relics authority, BSEDN/EBEDN will make necessary design changes to accommodate the request and preserve the site; Decisions concerning the management of the finding shall be communicated in writing by relevant authorities; Construction works could resume only after written permission is granted from the responsible authorities concerning safeguard of the heritageAny worker removing such artifacts for personal use or gain, shall be dismissed and subjected to legal action.

40

B1-7: Upgrading Existing Distribution LinesISSUES/RISKS MITIGATION MEASURES

Dust generation/ Air pollution The Contractor implement dust control measures to ensure that the generation of dust is minimized and is not perceived as a nuisance by local residents, maintain a safe working environment, such as: * watering dusty roads and construction sites; * exposed soil and material stockpiles shall be covered to protect against wind erosion.

Noise and vibration All construction vehicles must have mufflers in good condition to avoid excessive noise emissions and frightening any nearby livestock Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification. Any construction equipment deemed too noisy by the local environmental authority and/or if there are complaints from locally affected groups, the equipment shall be replaced.

Water pollution Portable or constructed toilets must be provided for construction workers either on site and/or at any work camps (if such camps will be established). There should be no direct discharges of human sewage to any waterbody.

Do not wash cars, trucks or machinery in or near natural water sources.

Drainage and sedimentation The Contractor shall ensure any drainage system is always maintained cleared of mud and other obstructions.

Solid waste At all places of work, the Contractor shall provide litter bins, containers and refuse collection facilities. Solid waste may be temporarily stored on site in a designated area approved by BSEDN/EBEDN. Waste storage containers shall be covered, tip-proof, weatherproof and scavenger proof. No burning, on-site burying or dumping of solid waste shall occur. If burning is the only alternative, prior approvals should be obtained from the local environmental authority. Since existing poles to be replaced may be impregnated with creosote, under no circumstance are these poles to be burned. If the discarded poles are provided to the public for construction purposes, recipients of the poles must be explicitly warned of the dangers associated with burning these poles. Creosote treated poles or pole sections that have deteriorated beyond any useful life for an alternative use, shall be collected and disposed of at a site recommended and approved by the Ministry of Environment, Green Development and Tourism (MEGDT)For other recyclable materials, the Contractor shall collect and separate on site (at specified, dedicated locations) recyclable wastes such as steel, aluminum and copper tailings, recyclable construction

41

materials, such as parts of building fabrication, boards, flooring and packaging materials for later recycling, for use as fill or selling off to licensed companies for recycling and rehabilitation on the consent of ESBDN/BSEDN. Waste materials that have no useful alternative (cable covering etc.) shall be collected and stored temporarily at designation locations along the distribution line route. Under no circumstances shall the contractor dispose of any material in environmentally sensitive areas, such as in areas of natural habitat or in watercourses. When removed off site, solid waste or construction debris shall be disposed of only at sites identified and officially designated by the local waste management authorities. Components that have remaining useful life are to be stored and/or used at other BSEDN/EBEDN sites as needed.

Chemical or hazardous materials and/or wastes (spent lubricants,

paints, adhesives, solvents)

Used oil and grease shall be removed from site and sold to a properly licensed recycling company. Used oil and lubricants, from the maintenance of any vehicles and machinery shall be stored in sealed drums or collected in holding tanks and removed from site and sold to a licensed oil recycling company or disposed at a government approved site. Do not use toxic materials, including lead-based paints on any structures: any coating materials for steel or concrete structures should be approved by the MEGDT.Hazardous wastes are to be stored with appropriate labeling at temporary facilities on-site or brought to a central facility that is well ventilated with impervious floors and locked when not in use. In the event materials are to be used containing chemicals not regulated in Mongolia, BSEDN/EBEDN should obtain approval for use from MEGTD.

Disruption of vegetative cover and ecological resources

Any areas to be cleared should be minimized as much as possible. To the extent possible, existing roads/access routes to pole sites should be used. If access roads must be established, they should be routed to cause minimal disruption to local habitats or any economic activity (e.g. agriculture or herders). The same access road used for construction/installation should be used for maintenance operations. In the event virgin vegetation is removed, The Contractor shall remove topsoil from all areas where topsoil will be impacted on by rehabilitation activities, including temporary activities such as storage and stockpiling, of transmission line poles/structures etc. Any stripped topsoil shall be stockpiled in areas agreed with the BSEDEN/EBEDN for later use in re-vegetation and shall be adequately protected from loss by rain, wind etc.). Application of pesticides (herbicides) for vegetation clearing and/or maintenance is not permitted. Land clearance/maintenance should be either manual or mechanical or both. Disposal of vegetative cover should be to a government approved site.For the removal of virgin vegetation, BSEDN/EBEDN shall obtain an environmental clearance or permit issued by the MEGDT or local

42

environmental authorities. When needed, the Construction Contractor shall erect temporary protective fencing to efficiently protect any trees before commencement of any works within the site. The Construction Contractor shall ensure that no hunting, trapping shooting, poisoning of fauna takes place by Contractor personnel. Cleared areas such as disposal areas, site facilities, workers’ camps, stockpiles areas, working platforms and any areas temporarily occupied during construction of the project works shall be restored by the Construction Contractor using landscaping, adequate drainage and vegetation. Soil contaminated with chemicals or hazardous substances shall be removed, transported and treated as hazardous waste. Disposal shall be based on documented guidance from the MEGDT

Traffic management Traffic control measures, during the construction phase of the project, the BSEDN/EBEDN Construction Contractor shall seek guidance from the Mongolian government traffic authorities if there is: a) significant increases in vehicle trips b) a need to re-route traffic taking into account sensitive areas such as schools and hospitals. c) a need to install lighting at night for traffic circulation. The Construction Contractor shall place signs around the construction areas to facilitate traffic movement providing direction to various components of the works, and provide safety advice and warning. If materials are to be transported during rush hour, the local traffic department must be notified by the Contractor and if necessary, request their assistance. Before pole replacement or rehabilitation activities start, BSEDN/EBEDN shall carry out consultations with local government and community and with the traffic department.

Interruption of utility services Provide information to affected households on working schedules as well as planned disruptions of water/power at least 2 days in advance. Any damages to existing utility systems of cable, telecommunications, water supply etc. shall be reported to authorities and repaired as soon as possible. Associated costs shall be the responsibility of the Contractor (TO BE INCLUDED IN THE PROCUREMENT DOCUMENTS)

Worker and public Safety Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance BSEDN/EBEDN protocols). The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas.

43

Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

Chance find procedures If the Construction Contractor discovers sites/artifacts of archeological, historical, significance, including graveyards and/or individual graves during excavation or construction, the Construction Contractor shall: Stop the construction activities in the area of the chance find immediately; Notify BSEDN/EBEDN officials who in turn will notify responsible authorities in charge of the Cultural Property Secure the site to prevent any damage or loss of removable objects. In cases of removable antiquities or sensitive remains, constant guarding of the site shall be arranged until the responsible authorities take over; Delineate the discovered site or area Relevant authorities would be in charge of protecting and preserving the site before deciding on subsequent procedures. Decisions on how to proceed shall be taken by the responsible authorities. If the cultural sites and/or relics are of high value and site preservation is recommended by professionals and required by the cultural relics authority, BSEDN/EBEDN will make necessary design changes to accommodate the request and preserve the site; Decisions concerning the management of the finding shall be communicated in writing by relevant authorities; Construction works could resume only after written permission is granted from the responsible authorities concerning safeguard of the heritageAny worker removing such artifacts for personal use or gain, shall be dismissed and subjected to legal action.

44

ANNEX B 2: ENVIRONMENTAL MANAGEMENT PLAN FOR A SOLAR PHOTOVOLTAIC POWER FACILITY

MITIGATION PLAN

IssueMitigatingMeasure

Cost of Mitigation(If Substantial)

Responsibility*

DesignWater resources availability Conduct a due diligence

effort to secure reliable well yield data, if unavailable

Undertake a program to collect this data

Minor World Bank

Solar panel technology selection

Based upon results of water resources availability efforts, choose: Conventional solar panel

design, if sufficient water resources are present

Dry self-cleaning panel design, if water resources are insufficient

To be confirmed Project Sponsor

Disturbance to nesting patterns of ground nesters and migratory bird flight patterns

Local bird expert will be engaged as part of the preparation of a limited ESIA to: survey proposed solar plant

site prior to construction and as necessary recommend micro-modifications to site location to avoid/minimize nesting areas

identify bird nesting periods and assist in designing construction schedule to avoid these periods

assure panel design elevation is sufficient to minimize disturbance to areas used for nesting

work with NGOs (e.g. IUCN, BirdLife International, Wildlife Science and Conservation Centre of Mongolia) to prepare an Avian monitoring program (AMP) for migratory birds and ground nesters during construction and operation phases.

determine migratory bird patterns to aid in decision

Minor Project Sponsor

45

regarding placement of transmission line above ground (with avian diverters) or underground

assure solar panel tilt for maximum solar efficiency is adequate to minimize bird collision risk

ConstructionSocio-economic impacts

Minor disturbances during construction (noise, dust, traffic).

In-migration for 6 months of non-local construction workforce.

Positive impacts associated with local employment and supply opportunities.

Notify community of construction schedules. Clearly designate the construction zone with signage and barriers, maintain safe driving limits.Manage air quality and noise impacts in conformance with the procedures described in this EMP.

Induction of non-local contractors and workers regarding code of conduct in community.

Priority employment of local workers wherever possible, both skilled and unskilled.

Non-local workers and contractors prioritisation of local services, such as accommodation and food service providers.

Minor Project Sponsor (Social

Safeguards Officer) and Contractor

Air quality Engine exhausts will produce emissions of carbon monoxide, nitrogen oxides and possibly dust and sulfur dioxide from poor quality diesel fuels.

Fugitive dust emissions may be generated from the movement of men, improperly stored construction materials, or movement of vehicles and equipment

Vehicles and equipment must comply with acceptable level of emissions NS 5014: 2009 / diesel engine vehicle- acceptable maximum level and measurement method / and MNS 5013: 2009 / petrol engine vehicle-acceptable maximum level and measurement methods/, standards review; and if all of these requirements are met, the machinery will be permitted to operate on site.

Choosing less windy days for construction works. Spray surfaces with water on dry windy days.Cover storage areas with dusty materialsCover trucks transporting dusty materials

Minor

Minor

Contractor

46

NoiseConstruction activities can generate noise which can be disruptive to behavioral patterns of local inhabitants and wildlife.

Maintenance should be performed regularly on all equipments and machinery. All construction vehicles must have mufflers in good condition to avoid excessive noise emissions

Equipment and devices must be turned/switched off when not in use.

Construction activities should be limited to legally permissible times, or to between 7:00 AM and 6:00PM, whichever is stricter. If work must be done outside these time limits: (a) permission must be obtained from the appropriate authorities and (b) local residents be given sufficient advanced notification.

MinorContractor

Alteration of runoff patternsLand clearing and modification to land surface contours can alter runoff patterns and introduce localized flooding

Maintain minimal changes to land contours, channel runoff to avoid roads and migratory pathways

Minor Contractor

Topsoil removalLand preparation may involve removal/storage of topsoil

Stripped topsoil for the construction should be covered to prevent erosion and used for rehabilitation of Vegetation coverage at the end of the construction.

Minor Contractor

Vegetative waste productionLand preparation may involve clearance and removal of existing vegetation

All land clearance should be implemented either manually and/or mechanically. No pesticides are to be used for land clearance.

Vegetative waste should not be burned, but collected and managed as non-hazardous solid waste.

Minor

Minor

Contractor

Construction Related Solid Wastes

Hazardous: used oils, lubricants, excess paints and or coating materials, adhesives require special handling and treatment

Toxic waste such as oil and lubricants, their plastic containers and used batteries should be categorized and sent to waste market.

Toxic-hazardous waste should be sorted into appropriate marked/labeled bags and containers for safe handling to

Minor

Minor

Contractor

47

Non-Hazardous:wastes from packaging, inert construction materials and possibly domestic wastes from worker camps require proper management

disposal.

Garbage bins should be placed on each construction site.

Packaging papers, foam, plastic, wood, metal and glass materials, clay, concrete, and paints should be categorized into separate containers/bags for transport to the waste market and/or central disposal site.

Minor

Minor

Wastewaters generated from cleaning equipment or possibly domestic wastewaters from sanitary facilities and worker camps will require proper management.

Maintenance and repair services to machineries are crucial actions to take on a regular basis to avoid sudden fuel or gas leakage.

Perform maintenance and repair services at a specific location with an impermeable surface and wastewater is collected for further treatment.

Domestic and sanitary wastewater either collected and disposed at local municipal treatment facilities or collected in septic tanks.

Minor

Minor

Minor

Contractor

Avifauna Define acceptable construction periods to avoid nesting activities

Identify and delineate on-site bird nesting areas to be avoided by construction crews and/or identify procedures for minimal disturbances

Minor Local bird expert and Contractor

Cultural resourcesDuring excavation activities, historical artifacts of cultural, religious or historical significance may be accidently uncovered

If the Construction Contractor discovers sites/artifacts of archeological, historical, significance, including graveyards and/or individual graves during excavation or construction, the Construction Contractor shall: Stop the construction activities in the area of the chance find immediately; Notify the project manager who in turn will notify responsible authorities in charge of the Cultural Property Secure the site to prevent any damage or loss of removable objects. In cases of removable

Minor Contractor

48

antiquities or sensitive remains, constant guarding of the site shall be arranged until the responsible authorities take over; Delineate the discovered site or area Relevant authorities would be in charge of protecting and preserving the site before deciding on subsequent procedures. Decisions on how to proceed shall be taken by the responsible authorities. If the cultural sites and/or relics are of high value and site preservation is recommended by professionals and required by the cultural relics authority, the project sponsor will make necessary design changes to accommodate the request and preserve the site; Decisions concerning the management of the finding shall be communicated in writing by relevant authorities; Construction works could resume only after written permission is granted from the responsible authorities concerning safeguard of the heritageAny worker removing such artifacts for personal use or gain, shall be dismissed and subjected to legal action.

Worker safetyConstruction activities will expose workers to hazardous conditions and materials that may affect their safety and health

Mongolia’s requirements for worker health and safety will be followed. (Refer to Mongolian Labour Law, (Part VII- Labour conditions, Health and Safety, Section 83-To provide the labour health and safety condition, Section 84- To ensure the occupational safety and hygiene requirements, 85- To compensate the damages caused by employees due to industrial accidents, poisoning and occupational diseases). In addition, worker health and safety will be followed in accordance with any project sponsor protocols).

Minor Contractor

49

The Construction Contractor shall provide safety measures such as installation of fences, barriers warning signs, lighting systems to prevent traffic accidents as well as other risk to people and sensitive areas. Alcohol use by workers during work hours is strictly prohibited. The employer shall provide instructions to workers for labour safety and health requirements every day before commencement of work. Use of personal protective equipment (PPE) by workers will be strictly enforced.

OperationSocio-economic impacts

Positive impacts associated with local employment, training and education opportunities.

Priority training and employment of women, for long term operations roles.

Priority hiring of local skilled workers, including additional training if needed to support the operations workforce.

Improvement of local knowledge, understanding and ownership of the solar plant through high school renewable energy education presentations and site tour.

Positive Project Sponsor (Social Safeguards

Officer)

Visual disruptionReflection of sunlight off solar modules can affect drivers’ visions and disrupt migratory bird flight patterns

Glaze solar panel and frame with anti-reflective coating, the glint and glare reflections to reduce safety hazard to drivers, use anti-reflective coated solar PV module.

Minor Project Sponsor

Groundwater availabilitySignificant drawdown of ground waters for panel washing could lower the groundwater table affecting water availability to other users

Panel washing wastewatersWastewaters from panel washing may contain pollutants and contaminate receiving waters

If design efforts indicate sufficient water resources are available, all necessary permits, approvals etc. for water withdrawal and use must be obtained prior to plant operation.

If conventional solar panel design is selected, water cleansing will only be necessary to remove dust deposits on the panels. Therefore, no cleansing agents (soap, detergents, special cleansing

Minor

Minor

Project Sponsor

50

agents) will be added to wash waters.

Wash water will be discharged untreated. However, land will be set aside for treatment facilities if wastewater quality analysis after the first two washings indicate treatment is needed.

If dry self-cleaning solar panel design is selected, there would be no wastewaters generated.

Hazardous wastesOil leaks from circuit breakers, inverters, and transformers during maintenance can contaminate soils

No PCBs are to be used in any electrical equipment.

Any contaminated soil is to be excavated, removed and collected by contractors licensed to handle these wastes.

Minor

Project Sponsor

EcologySelected site for both the solar photovoltaic panels and the route of the transmission line may interfere with migratory routes of birds, migration patterns of land based wildlife or grazing areas for domesticated livestock.

The entire solar voltaic facility is to be fenced, to prevent livestock grazing or migration of wildlife.

Overhead transmission lines are to be equipped with aviary diverters.

To be confirmed

Minor

Project Sponsor with advice from avian

specialists

DecommissioningWaste Disposal Recyclable materials are to be

collected separated and either reused at existing solar photovoltaic facilities or sold as scrap to companies licensed to manage these wastes

Non-recyclable materials must be deposited at government approved disposal sites.

Minor

Minor

Project Sponsor

Land surface restoration Land should be restored as closely as possible to the original contours and revegetated with native species similar or equivalent to species originally existing in the area.

Minor Project Sponsor

51

MONITORING PLANIssue What

parameter is to be monitored

Whereis the

parameter to be monitored

Howis the

parameter to be

monitored/ type of

monitoring equipment

Whenis the

parameter to be monitored-frequency of

measurement or continuous

CostWhat is the

cost of equipment or

contractor charges to

perform monitoring

Responsibility

ConstructionSocio-economicCommunity health & Safety

Induction& code of conduct

Local hiring & supply

Signage, barriers & safe speed limits. Completion of induction/ signing of code of conduct.

# of local workers hired# of local suppliers used

Construction site

Construction site

Visual observation. Induction/

code of conduct

documentation

Employment &

contracting documentati

on

Weekly

Monthly

Monthly

Minor Contractor & Project Sponsor

(Social Safeguards

officer)

Air QualityEngine

exhausts

Fugitive dust emissions

Compliance Certificate

Ambient dust

Prior to site entry

Construction site

Visual

Visual

First time prior to site entry

Daily during dry windy conditions

Minor

Minor

Project Sponsor

Project Sponsor

Noise Sound levels Construction site fenceline

Nearest population center

dB meter Weekly or if there are

complaints

Minor Project Sponsor

Alteration of runoff patterns

Site surface contours

Construction site

Visual Weekly, during site

preparation activities

Minor Project Sponsor

Topsoil removal

Topsoil storage covering

Topsoil storage site

Visual Weekly, during site

preparation activities

Minor Project Sponsor

Vegetative waste production

No pesticide use?

Disposal of waste (no

Construction site

Vegetative storage site

Visual

Visual Weekly, during site

Minor

Minor

Project Sponsor

52

burning)? preparation activities

Construction Related Solid Wastes

Hazardous

Non-hazardous

Sent to waste market or properly disposed?

Garbage bins provided or waste market and/or sent to central disposal site?

Construction site

Construction site

Visual

Visual

Weekly

Weekly

Minor

Minor

Project Sponsor

Project Sponsor

Wastewater Regular machinery maintenance?Dedicated repair location?Domestic wastewater to municipal sewage or septic system?

Construction site

Construction site

Sewage disposal site

Visual

Visual

Visual

Weekly

Start of construction

Start of construction

Minor

Minor

Minor

Project Sponsor

Project Sponsor

Project Sponsor

Cultural resources

Chance find procedures followed?

Discovery site Visual and discussions

When discovery is

made

Minor Project Sponsor

Worker safety

Mongolia’s requirements for worker health and safety followed?

Construction site

Visual and discussions

Weekly Minor Project Sponsor

Ground Nester birds

Disruption of nesting patterns

In accordance with AMP Local bird expert in

conjunction with local NGO

engaged by project sponsor

OperationSocio-economic

Induction & code of conduct for new hires

Local hiring

Completion of induction/ signing of code of conduct.

% of operations

Plant site Record keeping

Semi-annual Minor Project Sponsor (Social

Safeguards officer)

53

and training

Education

workforce locally hired# of women hired# of persons trained# of students receive site tour and presentation on renewables

Visual disruption

Solar panel and frame glazed with anti-reflective coating?

Delivery location

Visual Upon delivery of panels

Minor Project Sponsor

Groundwater availability

Panel washing wastewaters(If conventional solar panel design is selected)

Permits in order?

Only water (no soap or detergents

used)

Plant site

Water supply site

Visual

Visual

Prior to start of operation

Prior to start of operation

Minor

Minor

Project Sponsor

Project Sponsor

Hazardous wastes

All electrical equipment free of PCB

Contaminated soil managed by licensed

contractors?

Check bid document

A site of contamination

Visual

Visual

Upon delivery of equipment

At time of treatment

Minor

Depends on extent of

contamination

Project Sponsor

Project Sponsor

Ecology Plant site fenced

properly?

Fence properly

maintained?

Overhead transmission

lines equipped

with diverters?

Along plant fence line

Along plant fence line

Along entire length of

transmission line

Visual

Visual

Visual

Upon construction completion,

prior to operation

Semiannually

Upon construction completion,

prior to energizing,

then annually

Minor

Minor

Minor

Project Sponsor

Project Sponsor

Project Sponsor

54

Migratory and Ground Nester birds

Migratory: collision with solar panels and transmission line

Ground nester:Disruption of nesting patterns

In accordance with AMP Local bird expert in

conjunction with local NGO

engaged Project Sponsor

DecommissioningWaste

DisposalRecyclable materials properly

managed?

Non-recyclable materials

disposed at government

approved site?

At collection point

Disposal site

Visual

Visual

During and until decommissionin

g is complete

During and until decommissionin

g is complete

Minor

Minor

Project Sponsor

Project Sponsor

Land surface restoration

Plant site should be

restored as closely as

possible to the original

contours

Plant site revegetated with native

species similar or

equivalent to species originally existing in the area

At plant site

At plant site

Visual

Visual

After solar plant

equipment and facilities have been removed

After plant site land surface

contours, have been

reestablished

[to be confirmed]

[To be confirmed]

Project Sponsor

Recommend using a local

botanist expert

55

ANNEX C RESETTLEMENT POLICY FRAMEWORK

C 1. Introduction The exact location and nature of the investments, detailed design of the engineering works and precise siting of infrastructure works for the sub projects under component 1 has not been determined. Locations will be decided taking in to account engineering and other needs, as well as feedback from initial consultations with stakeholders and any Affected Persons (APs)7. The location of any future solar plant development (component 2) has also not as yet been determined and therefore a Resettlement Policy Framework (RPF) has been selected as the appropriate social safeguard instrument.

As this project is Category B for safeguards, it is not anticipated that there will be substantial resettlement requirements, and no physical displacement is envisaged. Component 2 is anticipated to be sited on state land and involuntary resettlement avoided. This RPF provides guidance in the instance that such state land is not available.

This RPF describes (i) the protocol for voluntary donation where impacts are small, do not affect livelihoods and no compensation is required for component 1 only; and (ii) the policies and procedures regarding involuntary impacts which lead to development of a Resettlement Plan (RP)/or Abbreviated Resettlement Plan (ARP), to be completed in the detailed planning stages of the sub-projects, prior to implementation of the civil works.

RPs will be developed in conformance with World Bank Operational Policy 4.12, Involuntary Resettlement, Annex A paragraphs 1-21. If resettlement affects fewer than 200 people, and impacts are minor, an ARP will be developed as per Operational Policy 4.12, Annex A paragraph 22. The RP or ARP will form part of the agreement between the Borrower and the World Bank. For brevity the term ‘RP will be used in this document to refer to whichever resettlement instrument is selected.

The PMO will include individuals charged with screening for adverse impacts on land or livelihoods and response according to the principles of this RPF will be undertaken in concurrence with project planning processes (see ESMF Chapter 6.2 Screening & Categorization and Annex C 15 for a screening tool) and in collaboration with the PIUs.

C 2. Objectives and Key Principles This RPF incorporates the requirements of Mongolian law and the World Bank’s Operational Policy 4.12, Involuntary Resettlement. The guiding principles for the RPF are that involuntary resettlement is to be avoided or minimised throughout the Project. Where avoidance is not possible, the policy objective is to minimise impacts. Ultimately, APs should be better off, or at least as well off, as before the project. All persons affected by the project are to be consulted throughout the project, have the opportunity to participate in planning, and to share in project benefits. The project should contribute to sustainable development.

These principles require a process of early identification of stakeholders, and in particular of APs; effective public disclosure of any known impacts; consultation and participation with all sectors of the community to avoid or mitigate negative impacts identified, and to ensure that no person or impact is overlooked; fair, transparent and timely intervention to support APs during implementation, resettlement and restoration of livelihoods; and commitment where possible to improve upon the status quo, particularly for those who may be vulnerable by reason of poverty, ethnicity, gender, age, disability, or social status.

7 World Bank Operational Policy 4.12 uses the terminology ‘displaced’ to mean social and/or economic as well as physical displacement of an affected person. In this document, to avoid confusion, the word ‘affected’ will be used to mean a person suffering any adverse impact.

56

If there is loss of land, and land-based assets, the aim will be to replace like for like, and if this is not possible, to compensate for lost land, assets and income, and meet the costs of relocation and restoration of livelihoods. Restoration includes not only physical assets, but also social and cultural assets. If there is a risk of disruption of these values, which are often disproportionally encountered by women, the APs will contribute to selection of mitigation and resettlement options to ensure policy objectives are met.

C 3. Key Principles of Resettlement Planning The following key principles are to be followed during resettlement planning and implementation:

Land acquisition should be avoided or minimized as far as possible. If unavoidable, sub-project designs and RPs should be conceived as development opportunities, so that displaced persons may benefit from the services and facilities created for, or by, project activities.

All displaced persons are entitled to compensation for project related loss of income, land and attached assets, or to alternative but equivalent forms of assistance in lieu of compensation. Lack of legal rights to the assets lost will not bar displaced persons from entitlement to such compensation or alternative forms of assistance.

Compensation rates as established in an RP refer to amounts to be paid in full to the eligible owner or user of the lost asset, without depreciation or deduction for any purpose.

When cultivated land is acquired, the project proponent/Bank borrower should seek to arrange land-for-land replacement if that is the preference of the displaced person.

Compensation for land, unharvested crops and attached assets should be paid prior to the time of impact.

Land donation is acceptable only when it is documented and fully consistent with the guidance on Voluntary Donation (see Chapter C 5) for component 1 investments only.

Displaced persons should be consulted during the process of RP preparation, so that their preferences regarding land acquisition and compensation arrangements are solicited and considered.

Information about the project, and the draft and final RPs are publicly disclosed in a manner accessible to displaced persons. They will be available on the Government’s and the Bank’s websites, and also available in hard copy from the relevant Government agency and the Utility.

The previous level of community services and access to resources will be maintained or improved after land acquisition. If individuals or a community has to be relocated, the same level of services as they formerly enjoyed should be restored or improved for both themselves and any new hosts.

The project proponent/Bank borrower is responsible for meeting costs associated with land acquisition and compensation. Any RPs prepared will include an estimated budget for all costs associated with land acquisition, including contingency arrangements.

Methods by which displaced persons can register complaints and pursue grievances will be established as necessary, and information regarding these grievance procedures will be provided to displaced persons and members of the public who may experience some inconvenience.

Open-market purchase of land must be voluntary, documented and free of rival claims or encumbrances.

C 4. Legal and Regulatory FrameworkAll provisions of this RPF are in accordance with the applicable Mongolian Laws (as listed below) and the World Bank’s Operational Policy 4.12, Involuntary Resettlement. The relevant stipulations of national law and World Bank policy are summarized in this section along with measures to bridge any gaps between the requirements.

The basic legislative framework for land acquisition and resettlement under the existing legal framework consists of the following:

The Constitution (1992) The Land Law (2006)

57

The Law on Allocation of Land to Mongolian Citizens for Ownership (2003) The Civil Code of Mongolia (2002) Government land valuation tariff (Cabinet Resolution 103, 2003) Law on State Registration of Property Allocation Rights and Other Related Rights (2003)

The Constitution of Mongolia states, inter alia, that “The State shall have the right to hold landowners responsible in connection with the manner the land is used, to exchange or take it over with compensation on the grounds of special public need, or confiscate the land if it is used in a manner adverse to the health of the population, the interests of environmental protection and national security” and “If the State and its bodies appropriate private property on the grounds of exclusive public need, they shall do so with due compensation and payment” respectively.

The Land Law regulates how to acquire land when possession titles expire. Non-titled occupants of land are considered illegal land users and can be evicted on the basis of Article 27.4 of the Land Law, which states that “possessing land without a valid license is prohibited”. The Law on Allocation of Land to Mongolian Citizens for Ownership contains provisions respecting expropriation of land under private ownership. Article 35 of the Law on Allocation of Land to Mongolian Citizens for Ownership stipulates the confiscation of land owned by a citizen when the Article 28 of the same law is infringed. The Government land valuation tariff (Cabinet Resolution 103) determines land valuation tariffs.

The Project may exchange or take over land owned by a citizen with compensation on the grounds of public need under Article 32 of the Law on Allocation of Land to Mongolian Citizens for Ownership which includes “to build roads, lines and networks and other objects of national scale” (32.1.3). A comparison of Mongolian Law and World Bank requirements, along with gaps between the two requirements is contained in Table C01 below.

Table C01: Comparison of Mongolian Law and World Bank Involuntary Resettlement Requirements

Topic Provisions of Mongolian Law World Bank RequirementsInvoluntary Resettlement

Invoking eminent domain is legally recognized when taking over land owned by a private citizen with compensation on the grounds of special needs when building a structure (Law on Allocation of Land to Private Citizens, Articles 32 and 37; Land Law, Articles 42 and 43). This law applies to the Project.

Eminent domain is generally recognized and subject to policy provisions aiming at avoiding and minimizing land acquisition and replacement of lost assets and rehabilitation of livelihoods. Affected entities to be at least as well-off as without project.

Negotiated Settlement / Open Market Purchase

The Civil Code of Mongolia is the legal basis for contractual agreements on the transfer of land from affected entities to the government (Chapter 15, Articles 1, 6, 7, 8, 109 and 112, among others).

Recognition of open-market purchase, where there is a willing buyer and a willing seller. If the seller has no option, than the requirements of OP 4.12 apply.

Eligible Affected Entities

Licensed owners, possessors and users of land can transfer their titles to other legal persons recognized under the Land Law (Articles 35 and 38) and the Law on Allocation of Land to Private Citizens (Article 27).Non-titled occupants of land as illegal possessors are not eligible to transfer the land occupied or receive compensation (Land Law, Article 27.4).The Civil Code recognizes the right of a long term non-owner occupant of ownerless immovable property (incl. land) to own it after 15 years, if registered in the Stateregister (104.2).

Titled affected entities are entitled tocompensation and rehabilitation for affected land and non-land assets at replacement cost. Those without legal title to affected land may be compensated for their structures and may qualify for other resettlement and rehabilitation assistance.

Compensation for land Compensation is a contractually agreed payment for land transferred to the government. Local practice applies the government land valuation tariff (Cabinet

OP 4.12 specifies either direct replacement of land or provision of full replacement cost, along with

58

Resolution 103, 2003), but negotiates with affected entities as well. Replacement land can be provided if an affected entity’s entire land or large part thereof is acquired.

rehabilitation measures, in order to restore livelihoods. Compensation should be paid prior to the time of impact.

Compensation for structures

Contractually agreed payment for transfer of structures located on land acquired. The value of structures is determined at market rates, with depreciation deducted from gross value of the structure.

For houses and other structures, compensation is at replacement cost. Which is the market cost of the materials to build a replacement structure with an area and quality similar or better than those of the affected structure, or to repair a partially affected structure, plus the cost of transporting building materials to the construction site, plus the cost of any labor and contractors’ fees, plus the cost of any registration and transfer taxes.

Joint property ownership

The Civil Code recognizes common property ownership and family property rights (Articles 108, and 125-128).Common property ownership requires permission of other owners to dispose of part of the property (108.4).Family property includes ‘other properties accrued since the marriage, notwithstanding in which name of spouses or family members the property is registered’(126.2.4). Disposal of immovable (incl. land) family property requires mutual agreement (128.1) and certified written permission from an adult family member (128.2).

No conflict with World Bank requirements, however joint signatures are encouraged.

Easement (property servitude)

Legal provision for easements, allowing the use of another person’s property is implemented under Article 33 of the Law on Allocation of Land to Mongolian Citizens for Ownership.

No conflict with World Bank requirements.

Rental of land or house

The Civil Code, Chapter 25 regulates the lease of property, including land and houses. If ownership is transferred the new owner incurs all rights and obligations of a lessor (Article 297). No provisions for lessee rights in case of land acquisition for a project, except that termination of a lease requires a 3 month notice (Article 294.3)

Temporary access can be obtained voluntarily through renting or leasing.Any involuntary temporary acquisition must be minimized and project plans must provide compensation for any involuntary temporary acquisition. Those people involuntarily bearing costs of temporary acquisition directly attributable to Bank projects are to be considered DPs.

Community and public resource losses

Affected community and public assets can be transferred through contractual agreement under the Civil Code.The cost of moving affected infrastructure is included in cost of civil works under the Project.

Common property resources or public structures and infrastructure affected by land acquisition are eligible for compensation.

Income and livelihood rehabilitation

No provisions in contractual agreements for transfer of property.

Displaced persons should be assisted in their efforts to improve their livelihoods and standards of living or at least to restore them, in real terms, to predisplacement levels or to levels prevailing prior to the beginning of project implementation, whichever is higher.

Relocation and transaction costs

The Mongolian Law on State Registration of Property Allocation Rights and Other Related Rights requires payment of registration duties and service fees for the registration of immovable property with the

Any administrative charges, title fees, or other legal transaction costs must be paid by the project or waived. The cost of any registration and transfer taxes,” whether

59

State Administrative Authority in charge of state registration of property rights (Article 9).All registration and other fees, as well as cost of relocation, are responsibility of parties to a contract and can be included in a contract.

for land in rural or urban areas or for houses or other structures, is included in the calculation of replacement cost. If impacts include physical relocation, then assistance is provided (such as moving allowances) during relocation.

Grievance procedure The Land Law refers disputes over land to the governors of administrative units and eventually the courts (Article 60). The Civil Code and Law on Allocation of Land to Private Citizens refers various types of disputes to the courts.

An appropriate and accessible grievance mechanism is established for displaced persons and their communities.

Resettlement Plan information disclosure and public consultation

No provision for public consultation and information disclosure. In practice, all cases involve a period of negotiation.

The draft resettlement instrument conforming to OP 4.12 is made available at a place accessible to displaced persons and local NGOs, in a form, manner, and language that are understandable to them. Displaced persons should be meaningfully consulted and should have opportunities to participate in planning and implementing resettlement programs.

Cut-off date Not applicable Normally, this cut-off date is the date the census begins. The cut-off date could also be the date the project area was delineated, prior to the census, provided that there has been an effective public dissemination of information on the area delineated, and systematic and continuous dissemination subsequent to the delineation to prevent further population influx.

Notification period for vacating property and commencement of civil works

Time period for vacating a property may be defined in contract.Civil works commence in parallel with acquisition of property, but without defined waiting period.

Cash compensation is normally paid before displacement or the initiation of civil works.

As presented in Table C01, there are several policy gaps between the Mongolian legal framework and the World Bank Operational Policy. According to Mongolian law or practice: (i) non-titled occupants of land (without ownership or possession license), including lessees of land and structures, are not eligible for compensation and rehabilitation entitlements; (ii) compensation for affected land is based on a government compensation tariff, not market rates, although there is room for negotiation with individual APs; (iii) a depreciation coefficient is applied in the valuation of affected structures; (iv) income and livelihood rehabilitation is not normally considered in local land acquisition practice; (v) transaction costs are not included in compensation payments; (vi) there are no project internal grievance procedures preceding dispute resolution by governors and the courts; (vii) public consultation and information disclosure is not practiced; (viii) an eligibility cut-off date is not declared; (ix) there is no limitation on commencement of civil works until after completion of all land acquisition procedures, and (x) there is no need to prepare an RP or to undertake monitoring and evaluation activities.

To bridge these gaps, this RPF provides entitlement provisions (see Chapter C15 Entitlements Matrix), which integrates both, while World Bank policy requirements prevail in cases of discrepancies. Any RPs prepared for this Project, will update the Entitlement Matrix (refer C15), to be specific to sub-project impacts. In addition, to bridge process related gaps (i.e. preparation of RPs, grievance redress, consultation and cut-off dates) the key principles of resettlement planning as outlined in Chapter C 3, will also apply to this project.

C 5. Voluntary Land Donation Arrangements and Documentation

60

There may be some few instances where the project seeks voluntary donation of land or purchases land through the open market for small scale civil works for component 1 investments. Voluntary land donation refers to a process by which an individual or communal owner agrees to provide land or property for project-related activities. In general, voluntary land contribution is undertaken without compensation. Voluntary contribution is an act of informed consent, made with the prior knowledge of other options available and their consequences, including the right not to contribute or transfer the land.

To meet World Bank safeguard policies, any donation of land or lease rights for the Project will be consistent with the following principles:

Donors should be currently connected to the grid, or be connected before or immediately after donating land.

Any potential donors should benefit directly from the project. The donation would be made for a specified purpose and term. If the land is not donated in

perpetuity, the donation agreement would specify what will happen to the land at term. The potential donor will be made aware that refusal is an option, and the right of refusal will be

specified in the donation document the donor will sign. The act of donation will be undertaken without coercion, manipulation, or any form of pressure on the

part of public or traditional authorities. This will be independently verified by the PMO or an independent third party such as a local NGO. Records of consultation with donors will require verification.

The donor may negotiate for compensation (in full or in part) or alternative forms of benefits as a condition for donation.

The proportion of land that may be donated cannot exceed 10 percent of the potential donor’s land area.

Donation of land cannot occur if it were to necessitate any involuntary household relocation. For community or collective land, donation can only occur with the consent of all individuals using or

occupying the land, or recognized in custom to have some claim. The PMO will confirm that the land to be donated is free of encumbrances or encroachment prior to

commencement of any work on the land. Any donated land that is not used for its agreed purpose by the project will be returned to the donor.

The intention of these conditions is that the new owner or tenant should be able to undertake any lawful transaction with respect to the land in question without legal impediment or delay. The responsible project implementation and land registration agencies will maintain a documented record of each instance of land donation, will make the documentation available for review in any grievances that may arise, and will make documentation available to the World Bank upon request for any project involving voluntary land donation undertaken in collaboration with the Bank. In addition, a template for voluntary consent is included in Chapter C15.

C 6. Preparing and Approving Resettlement PlansPreparation of RP/s will begin once it is determined that land acquisition is essential to complete any project activities, and screening processes (refer Chapter 6.2 of the EMSF on Screening and Categorization) establish the land area to be acquired. The PMO will prepare and implement the RP as follows:

Immediate consultations with relevant senior officials in government stakeholder Ministries and agencies to ensure a whole-of-government approach to the project.

Preparation of Project Information Bulletins (PIB) in Mongolian and English (see Chapter C15. Tool 7 for required content) describing the project parameters, anticipated impacts, resettlement assistance criteria, and cut-off date for entitlements.

Public disclosure about the project through release of the PIB in known impact areas.

61

Socioeconomic survey and census of affected persons and assets (See Chapter C15. Tool 2 Content of Census Surveys and Asset Inventories, Tool 3 Summary Census of Affected Persons Template, Tool 4 Summary Inventory of Affected Assets Template in Annex, Tool 5 Summary Schedule of Affected Land Template).

Ascertaining the severity of impact and whether compensation is required, preparation of voluntary land agreements where owners/users are willing, (see Protocol in Chapter C 5 and Sample Consent Template in C 15 Tool 1).

Preparation of an AP profile, asset inventory, a draft entitlement matrix (refined to specific sub-project impacts and consistent with the entitlement matrix in this RPF as presented in Chapter C15 – Tool 6) and budget for the RP covering involuntary impacts.

The Draft RP is prepared in conformance with World Bank Operational Policy 4.12, Involuntary Resettlement, Annex A paragraphs 1-21. An outline of the Resettlement Plan is provided in chapter C 15, tool 9.

Disclosure of the Draft RP information and an updated PIB. Finalization of the RP; borrower and World Bank Approval of the RP. Posting of the RP on the borrower and World Bank websites. Preparation of individual compensation and entitlement forms for each AP, specifying amounts, times

and places of payment. Restoration of any borrowed land; transfer of entitlements and acquittal by APs. Recording and periodic reporting to donors and financiers. Monitoring, with AP and community participation and publication of outcomes.

If any unforeseen impact is identified after approval, updates to the RP will be prepared, consulted and disclosed. Additional subcomponents of the Project may be covered if appropriate by an ARP informed by the same principles and process as this RPF.

The World Bank will review and clear any resettlement plan/s prepared.

C 7. Estimated Population Displacement Component 1

It is not anticipated that there will be any physical displacement or severe negative impacts resulting from any of the sub-projects in component 1. The improvements, such as line upgrades and rehabilitation of 6-10/ 0.4 KV substations are to take place within the existing network footprint and right of way. There may be temporary impacts from noise, dust and traffic disruption during these minor civil works which are addressed in Annex B.

Some new land may be required for rehabilitation of 35/ 6-10kv stations. Initially Government owned or leased land will be sought adjacent to the existing sites. In these instances, the PMO will confirm that land is indeed owned/leased by Government, the land is free of formal or informal settlements and that there are no outstanding complaints on the land. If Government land is unavailable, alternative sites will be selected which minimise impacts on livelihoods or social amenity.

Component 2Unused state land will be prioritised for any future solar investments, to avoid impacts on households. There may be temporary impacts from noise, dust and traffic disruption during construction works which are addressed in the ESMF Annex B.

Initially state or leased land will be sought for any future solar investments. In these instances, the PMO will confirm that land is indeed owned/leased by Government, the land is free of formal or informal settlements and that there are no outstanding complaints on the land. If Government land is unavailable, alternative sites will be selected which minimise impacts on livelihoods or social amenity. In the event that involuntary

62

resettlement is required, the process will follow that which is outlined in this RPF.

C 8. Eligibility CriteriaThe foreseeable categories of displaced persons relative to the project include:

Owners or users of any land and any land-based assets required that are not under Government ownership or lease.

Neighbors who may suffer temporary construction impacts.

Eligibility criteria apply to both affected persons and affected assets. Displaced persons may be classified in one of the following three groups: (a) those who have formal legal rights to land (including customary and traditional rights recognized under the laws of the country); (b) those who do not have formal legal rights to land at the time the census begins but have a claim to such land or assets provided that such claims are recognized under the laws of the country or become recognized through a process identified in the resettlement plan; and (c) those who have no recognizable legal right or claim to the land they are occupying.

Note: (1) The loss may be temporary or permanent; (2) the term resettlement assistance does not refer to compensation paid for loss of land to land owners, structures or crops etc. Resettlement assistance may include relocation expenses, or meeting costs of starting up new livelihood activities like preparing land in the new resettlement sites, etc.

Resettlement planning will ensure that affected persons have sufficient opportunity to replace assets they will lose, and to improve or at least restore their incomes and living standards. Furthermore, planning will ensure that there will be no discrimination against any affected person due to sex, social status, language or other criteria. To achieve these objectives, the PMO will ensure that all affected persons are identified, and that all affected persons are deemed eligible for appropriate mitigation measures in the RP.

Loss of non-land assets, whether temporary or permanent, will be recognized for project-induced impacts on: An individual’s business or income Any other assets or elements of livelihoods recognized in Mongolian law and in WB Operational Policy

that may be discovered during disclosure and consultation.

Persons demonstrating that they will suffer involuntary losses from any of these causes as at the cut-off date for entitlements will be regarded as eligible for resettlement. Losses from encroachments or activities commenced after the cut-off date for the respective projects will not be eligible.

C 9. Valuation Methodology“Replacement cost" is the method of valuation of assets that helps determine the amount sufficient to replace lost assets and cover transaction costs. In applying this method of valuation, depreciation of structures and assets should not be taken into account. For losses that cannot easily be valued or compensated for in monetary terms (e.g., access to public services, customers, and suppliers; or to fishing, grazing, or forest areas), attempts are made to establish access to equivalent and culturally acceptable resources and earning opportunities.

Assets and values affected will be fully identified during public consultations, for incorporation in any RP/s. The principles of replacing like for like, replacement cost for lost assets and income, and full restoration of livelihoods will be used in the RPs.

All affected assets will be compensated at replacement cost based on market value for comparable assets estimated by a valuation team. The valuation team will include such persons as: a resettlement specialist; property valuation specialists of the Property Relations Agency and Land Relations, Construction and Urban

63

Development Department (LRCUDD) of the Aimag/ Soum8; and a representative of affected entities, and agreed with affected persons. The formulation of the valuation team will also be discussed with the World Bank task team. The PMO will be responsible for follow-up and facilitation of the processes for estimation of the replacement values for land and non-land assets and losses. In the case of disagreements over the compensation rates during the negotiation process with APs, the PMO will be able to engage an independent private valuation specialist and re-assess the compensation rates offered to the APs and disclose the results to the APs.

The specific methods for various types of potential impacts associated with future subprojects are as follows:

Land. Affected land will be compensated at replacement value. The value will be determined by undertaking a land market survey with the objective of ascertaining prevailing market values (influenced by various factors such as location of land, advantages for business, connectivity, and classification/land use, type of soil, crops grown, available irrigation and other facilities, and other plus and minus points such as frontage to road, proximity to developed areas, regularity of shape, unevenness of land), or the applicable government compensation tariff, whichever is higher. An alternative option is the valuation of comparable replacement land.

Houses, structures, and buildings. They will be compensated at replacement value based on prevailing market rates for comparable types of structures free of depreciation, transaction costs and value of salvage materials, which can be used by the affected households for free.

Temporary business loss. Cash compensation equal to net income losses during interruption period to be included in contractual agreement, estimated based on tax receipts/other valid documents or, if these are not available, based on the average net income of typical road businesses in project areas.

Loss of trees. Cash compensation for trees based on volume of wood; for fruit trees based on the net annual income from the tree(s) for the number of years taken for replacement tree(s) to reach comparable production; and the cost for growing the replacement trees (e.g., seedling and growth management).

Loss of crops. Crops will be compensated at market rate of the harvested crop.

C 10. Implementation ProcessTo ensure fairness, a time-bound implementation schedule of all activities relating to land acquisition and payment of compensation will be included in any RPs prepared for subprojects. Payment of compensation should be completed at least one month prior to land acquisition to give the affected person time to adjust and prior to any civil works commencing. If there is a delay of one year or more between land or asset valuation and payment of compensation, compensation rates will be reviewed and adjusted if necessary for inflation or other cost factors. If the transaction is agreed but there is a justifiable delay in settlement, for example because it is difficult to locate an owner, the compensation amount may be held in a Government escrow account for disbursement as soon as practicable. Any interest accrued on the sum will be paid to, or apportioned amongst the legitimate claimants. This permits project work to proceed without disadvantage to the owner(s).

C 11. Involuntary Resettlement Consultation & Disclosure ArrangementsConsultation and participation on all aspects of the project is presented in Chapter 6 of the ESMF, this section discusses consultation/disclosure at it relates specifically to involuntary resettlement. During the resettlement

8 Mongolia is divided into 21 provinces, known as AImags. Each Aimag is then divided into several districts, known as Soums which are a second level of administrative subdivision.

64

planning stage key consultation actions include: meetings with key institutional and commercial informants; development and dissemination of the PIB; identification and socio-economic survey of APs; setting up an involuntary resettlement grievance mechanism; and disclosure of the draft RP with information about how to participate and seek redress. Any affected persons will be consulted directly regarding proposed land acquisition and other arrangements.

The main output of the planning stage is the agreed RP which will summarize the activities undertaken and the results of consultation, along with any future planned consultation activities to be undertaken. Other outputs include signed registers of attendance at public consultations, and summaries of discussions and decisions at all consultations.

The PMO, together with the PIUs will disclose the RP in draft and final stages to the affected persons and the general public in the project area both on its website, and in hard copy in a language and location accessible to them. In this and any future projects undertaken in collaboration with the Bank, disclosure of the draft RP will be undertaken at least one month prior to Bank review. Disclosure of the final RP will occur following Bank acceptance.

C 12. Grievance Procedures relating to Land AcquisitionGrievance procedures that will apply to the overall project are described in the ESMF Chapter 8 Grievance Redress Mechanism which is similarly applicable for any Resettlement Plans developed (see below). Sub-projects will be designed to avoid and minimize any need for private land so that major grievances are not anticipated and use of a local grievance mechanism already established for the project is favorable given any impacts are anticipated to be minor.

The complaints process will offer remedies appropriate to the scale of the grievance. The process will be as follows:

Complaints or feedback that can be resolved by contractors or BSEDN/EBEDN (Component 1) or WES (Component 2) staff during normal working operations will be undertaken immediately. The complaint will be recorded, including details of the complaint (what, when, date(s), time(s) of day, gender, other observations), contact details of complainant, remedy/remedies, and date of close out. Complaints can be lodged with BSEDN/EBEDN (Component 1) or WES (Component 2) by phone, post, email, or in person with a Soum representative who will forward the complaint to BSEDN/EBEDN (Component 1) or WES (Component 2).

Other project-related complaints that cannot be resolved immediately, or by contractors or BSEDN/EBEDN (Component 1) or WES (Component 2) staff, will in the first instance be notified to the PMO Safeguard Officers for mediation within a specified short time, preferably not more than fifteen working days. The PMO’s Safeguards Officers will facilitate mediation hearings with the relevant body related to the grievance and complainant in open forum close to the place of residence of the affected person(s) or affected group. The complainant will be encouraged to be accompanied by supporters during the process.

If mediation is unsuccessful, or if the matter is substantive, at any time affected parties can file written or verbal grievances through the Mongolian Court system, in accordance with Mongolian laws and procedures.

At any time, if the project grievance redress mechanism is considered inadequate for addressing concerns then the World Bank Grievance Redress Service and the World Bank’s Inspection Panel are avenues for appeal. Information on how to submit complaints to the World Bank’s corporate Grievance Redress Service (GRS), can be found at http://www.worldbank.org/GRS. Information on how to submit complaints to the World Bank Inspection Panel, can be found at www.inspectionpanel.org.

65

C 13. Funding ArrangementsThe project proponent/Bank borrower will bear responsibility for meeting the costs associated with land acquisition. Any RP/s prepared in accordance with this RPF require a budget with estimated costs for all aspects of RP implementation. While the process of making an inventory of affected land and assets should identify all affected persons, if there has been a mistake or an omission, persons who had a rightful claim at the time of commencement of the census survey but who are identified after resettlement planning are entitled to compensation even if insufficient mitigation funds have initially been allocated. To meet this and any other unanticipated costs that may arise, the RP budget will include a contingency provision of 10 percent of estimated total costs. Compensation rates included in the RP will provide the basis for calculating compensation amounts due. Compensation will be paid in full to the affected person or persons losing land or other assets or income prior to any civil works taking place.

Resettlement Plan budget items will include the following:

Administration costs: Safeguards Officers’ salary costs/consultancy fees if an external NGO/consultant is appointed. Office administration, use of equipment and supplies. Travel. Advertising and publications.

Resettlement costs: Cost of AP consultation meetings (Travel/ Mediation).

Compensation costs: Affected items including:

o Land. o Affected assets and livelihoods. o Relocation and reestablishment assistance.

Transaction costs (notary fees, cadastral map survey, service fees including property registration). Contingency for vulnerability and unforeseen costs at an additional ten per cent of the sum of above. Costs of scrutineer for entitlements disbursements.

No deductions from compensation will occur for any reason. The RP will put in place transparent procedures for the flow of compensation funds, from MoE to the affected persons, and for witnessing and recording of the transactions. Joint signatures of both husband and wife from each household are encouraged.

C 14 Monitoring Involuntary Resettlement Complete monitoring requirements for the ESMF are outlined in Chapter 6, this section relates to monitoring requirements to be included with RP/s. Monitoring is the responsibility of the borrower and can be divided into internal (or project administration) and external (or independent) monitoring. Monitoring of conformance with the RP/s during implementation will be carried out by the PMO, as well as by an external monitoring agency which may be a local consulting firm or NGO, or a qualified individual. Each RP will include indicators for both internal and external monitoring.

The PMO, in collaboration with the PIU will prepare periodic progress reports on the RP against any indicators specified in the borrower agreement with the World Bank, including for the period under review:

Any issues that have arisen necessitating change to the RP to meet policy objectives. Publicity about the resettlement process, including PIBs and any media coverage. Schedule of consultations with APs.

66

Signed roster of attendance at RP consultative meetings, photographs and any other evidence of participation.

Summary minutes of RP discussions and decisions. Record of grievances notified under the RP, process and outcomes. Copies of official records of any project-related changes to land use or transfer of land titles. Update of the Entitlements Matrix showing progress of recording voluntary land donations or transfers

and payments against entitlements under the RP. Financial summary of disbursements against entitlements.

67

C 15. Involuntary Resettlement Toolkit

Tool 1: Sample Consent Form (Voluntary Donation) Component 1 only

Date:

I/We: male household head female household head.

Resident/s of Soum in Aimag,

Declare that I/We/the group is voluntarily donating the use of (specify land, assets, location, size, type etc)

For the purpose of: (specify activity)

For the duration of: (specify commencement date and duration)

Of My/Our own free will, I/We are waiving My/Our right to compensation of any kind for the specified duration of the activity.

Signed:

Male household head Female household head

Witnessed:

Local Official

68

Tool 2: Content of Census Surveys and Asset InventoriesThe tables in the following sections provide models that can be followed or adapted to summarize results from census surveys of Affected Persons and consultations with key informants to determine affected assets. The census survey that provides inputs will be designed for the specific project circumstances. For both an ARAP and a full RAP it will typically include such data as:

Name of Head of Household Name of Spouse of Head of Household Location and contact details for household Occupation of Head of Household Occupation of Spouse of Head of Household Number of normally resident household members Language most commonly used in the household Media accessed by the household – radio, press, TV, internet Approximate annual household income (confidential, and used only to assess vulnerability) Number of household members that are aged or have some disability Area of land owned or controlled by the household Area of project affected land Legal description or status of project affected land owned or controlled by the household Current use of project affected land Land-based project-affected assets Other sources of livelihood affected by the project.

Additional data that may be required for a full RAP could include such information as: Area and style of house or other structure – permanent materials, semi-permanent, non-permanent. Water and sanitation facilities Distance of the house from nearest: Elementary school, Secondary school, Health facility, Public

transport, Market. Social organizations to which household members belong (church, youth group, women’s group, sports group etc.).

Household or census surveys should be kept brief and confidential; as a guideline they should not take more than 15 minutes to administer. The data gathered should be relevant to the project, gathered only for project purposes. Respondents will be informed of the purpose and use of the information they give, and assured of confidentiality.

Tool 3: Summary Census of Affected Persons (Template)

Aimag/ Soum

Land Acquisition Significantly Affected by Land Acquisition

Housing Affected Business Affected Vulnerable Persons

Other

Name OwnersHH:People:

UsersHH:People:

OwnersHH:People:

UsersHH:People:

Partially Affected

Owner HH:

People:

Tennant HHPeople: :

Require Relocation

Owner HH:

People:

Tennant HHPeople: :

Owners Workers Category

69

Tool 4: Summary Inventory of Affected Assets (Template)

Category Subcategory Volume/ Unit Unit Cost Local Currency USD

Land Private Land - ResidentialPrivate Land AgriculturalPrivate Land – OtherCommunity LandCrop (specify)Tree (specify)Other productive assets

Residential Structures Compensation

Private housingWater facilitiesAncillary structuresWalls, fences, gatesOther

Business structures compensation

Shops, food servicesOther servicesOther businesses

Tool 5: Summary Schedule of Affected Land (Template)

Aimag, Soum Total Land Acquisition (hectares)

Private Land Acquisition Number of Plots Affected

Other Land Acquisition Number of Plots Affected

Name Residential (Specify purpose)

Agricultural (Specify purpose)

Commercial

Other

Total

70

Tool 6: Entitlement MatrixTo bridge the gap between Mongolian Law and World Bank policy, this RPF provides entitlement provisions, which integrates both, while World Bank policy requirements prevail in cases of discrepancies. Any RPs prepared for this Project, will update the Entitlement Matrix provided below, to be specific to sub-project impacts.

Category of Impact Subcategory of Impact/ Specification

Population/ affected entity

Compensation or Mitigation Principle

LAND (residential/ commercial/public/ community)

Full loss of plot (=>50%)

Owner, possessor The AP may choose between the following alternatives: Land for land compensation through provision of replacement plot of comparable value and location as lost plot; Ownership license and State registration; OR Cash compensation at market rates or the government compensation tariff, whichever is higher, based on contractual agreement. All taxes, registration and transfer costs are waived or included in compensation price.

Legalizable occupant of land

Land for land compensation through provision of replacement plot of comparable value and location as lost plot;Ownership license and State registration.All taxes, registration and transfer costs are waived or included in compensation price.

User Replacement plot with use license. OR, if feasible and desired: Ownership license and State registration; all taxes, registration and transfer costs are waived or included in compensation price.

Lessee The AP may choose between the followingalternatives:Allocation of plot with ownership license and State registration; all taxes, registration and transfer costs are waived or included in compensation price.ORCash refund at rental fee rate and proportionate to duration of remaining lease period.

Partial loss of plot (<50%)

Owner, possessor Cash compensation at market rates or the government compensation tariff, whichever is higher, based on contractual agreement. All taxes are waived or included in compensation price.

Unlicensed occupant of land

Possession license and State registration for adjacent unlicensed land will be provided by government; all taxes, registration and transfer costs are waived.

User Continuation of use license on remaining land.

Lessee Cash refund at rental fee rate and proportionate to duration of remaining lease period.

STRUCTURES(residential/ commercial /public/ community

Full loss of structure and relocation

Owner, possessor, legalizabile owner of land

Cash compensation for replacement of lost structure at market rate determined through professional valuations by a certified valuer without deduction of depreciation, based on contractual agreement. No deduction for salvaged materials.

Alternation to structure

Owner, possessor, legalizable occupant of land

Cash compensation for lost part of structure and reconstruction of remaining structure at market rate without deduction of depreciation, based on contractual agreement.

Moving back of fences

Owner, possessor, legalizable occupant

The AP may choose between the following alternatives:Cash compensation for relocation of fence at market rate

71

of land without deduction of depreciation, based on contractual agreement.ORReplacement/reconstruction of the fence by the Project owner/contract.

Moving or relocation of ger

Owner, possessor, legalizabile occupant of land, lesee

Cash compensation for cost of taking down and raising of ger and for transport, as applicable; to be included in contractual agreement.

Temporary disturbance

Removal of fence, civil works on land outside ROW, restoration of land and fences

Owner, possessor, legalizable occupant of land

Cash compensation fee negotiated with AP. All taxes, registration and transfer costs are waived or included in compensation price.Access to land and residences.Fences will be moved by civil works contractor.No deduction for salvaged materials.

Businesses Any business loss due to land acquisition or construction activities by the project

All affected entities temporarily affected

Cash compensation equivalent to the loss, i.e. for the period of interruption of business based on tax receipts/other valid documents or, if these are not available, based on the average net income of typical local businesses in project areas.

All affected entities permanently affected.

Cash compensation equivalent to the loss, i.e. for the period of interruption of business based on tax receipts/other valid documents or, if these are not available, based on the average net income of typical local businesses in project areas. ANDCosts required for physical and financial reestablishment of business. If the business needs to be relocated, the following options will be provided to the DPs: (a) government will provide replacement land/shop space prior to relocation; or (b) if an acceptable plot of land/space cannot be agreed upon, net income loss of 1 year will be paid and, in consultation with the affected persons; the replacement land/shop space will be provided within 1 year of displacement.

Employment Any employment loss due to land acquisition or construction activities

All permanently laid-off employees of affected businesses

Compensation for loss of employment income for the period of interruption of employment.

All temporarily laid-off employees of affected businesses

Compensated with cash indemnity for 3 months wages for workers/employees that have been engaged for at least 1 year; otherwise entitlement is 1-month wage. AND Other labor benefits and retrenchment allowances according to the national labor law.

Relocation Transport/ transition costs

All APs to be relocated

Provision of allowances to cover transport costs on actual cost basis at current market rates; to be included in contractual agreement.Assistance to find an alternative plot or to find comparable house to rent, as applicable.

Vulnerable and/or severely affected APs9

Permanent loss of livelihood

All vulnerable APs Cash assistance up to a maximum of six months at guaranteed lowest living level and assistance in reconstitution of business or employment;

Loss of land All vulnerable and / or severely affected APs

Assistance with selecting a replacement plot and with preparation of contracts and administrative process of provisions of replacement plot.

Loss of structure All vulnerable and / or severely affected

Assistance with house relocation and other construction activities (new housing should meet minimum standard),

9 Vulnerable groups are distinct groups of people (poor, elderly, disabled and female headed households) who may suffer disproportionally from resettlement. Severely affected APs include those whose remaining landholdings are no longer fit for original purpose.

72

APs registration of property titles, relocation expenses, minimum housing guarantee.

Temporary disturbance

All vulnerable APs Preferential treatment to avoid, minimize or mitigate disturbance as quickly as possible.

Unidentified Losses Unanticipated impacts

All APs To be identified during project component implementation; measures will be formulated as appropriate according to World Bank policy and reported to World Bank prior to implementation

Tool 7: Project information Bulletin ContentsA Project Information Bulletin (PIB) will be issued for each sub-project where involuntary resettlement will be undertaken to give initial project information in English and Mongolian. It will be simple, jargon-free language aimed at the general public. It will be updated at least (i) to disclose the draft RP, (ii) to publicize the finalized RP, and (iii) to convey the results of end-of-project monitoring.

Media bulletins will be released at other intervals as required to inform the public about progress of works, any restrictions to normal access and operation of roads and airport facilities during implementation.

Content of the PIB in the resettlement planning phase will include: A whole-of-project description, and of the sub-components to be covered in the RP. The project rationale and expected benefits. A description of anticipated environmental, social and economic impacts, positive and negative. Reassurance that negative impacts will be compensated for. Eligibility criteria – persons and impacts that will be recognized in resettlement. Cut-off date for entitlements. A description of the type of impacts that would be recognized. A description of the proposed consultation process. Information about how to register as a potentially Affected Person. Information about the planned focus group meetings. An indication of the proposed process thereafter. Description of the proposed grievance system. Maps and other visuals when appropriate.

Content of subsequent bulletins will be influenced by initial consultations and the final form of the RP, grievance and monitoring processes.

73

Tool 8: Resettlement and Compensation ChecklistUse the following checklist to determine if land10 or assets will be involuntarily impacted, and if so, which safeguard tool to use:

1 If land is required, is the location of the required land known?

No Refer to the Resettlement Policy Framework

Yes Proceed to next screening question

2 Is the land required under Government ownership or lease?

Yes Ascertain that there is no dispute or informal use of the land or land based assets, and proceed to next screening question. If there are disputes, proceed to next screening question.

No Proceed to next screening question

3 Is the required land under a registered title?

Yes Ascertain that the title is not disputed; proceed through steps below.

No Identify all persons (men and women) with rights to occupy or use the land and any assets on it and proceed through steps below.

4 Will there be tree trimming, alternations to buildings (demolition or construction), removal of vegetation, etc. due to installation of project related components?

Yes Note and go to question 5

No Go to question 5

5 Are the land owners/users willing to donate the land and/or assets voluntarily for the public good?

Yes Follow voluntary donation procedures (refer Annex C. Chapter C5 ). Prepare voluntary land donation documents (refer Annex C, Chapter C15).

No Proceed to identify required form of resettlement plan (Questions 6 and 7).

6 Will physical displacement of affected persons11 be required?

Yes Prepare a Resettlement Plan in accordance with the RPF.

No Determine the scope and severity of impacts.

7 Will more than 200 people be affected, and/or will affected persons lose more than 10% of their livelihood assets?

Yes Prepare a Resettlement Plan in accordance with the RPF.

No Prepare an Abbreviated Resettlement Plan in accordance with the RPF.

10 ‘Land’ includes the ground and any assets on it, such as structures, trees or crops.11 An ‘affected person’ is anyone, irrespective of gender, titled, customary or informal land ownership or access status, who involuntarily loses land or any element of their livelihood, such as structures, trees, crops or income due to a project.

74

Tool 9 Resettlement Plan Contents

Resettlement Plan Abbreviated Resettlement PlanA resettlement plan in full, includes a statement of objectives, policies and principles, and typically covers the following:1. Project description;2. Project resettlement potential Impacts;3. Objectives;4. Socioeconomic baseline data, expectedconsequences:

Number of potentially affected people; Demographic and social economic profile; Income services and livelihood practices in the

subproject area.

5. Legal and institutional Framework: National legal requirements. World Bank Operational Policies and Procedures.

6. Eligibility criteria.7. Methodology for valuation of assets and potential loss of all other income opportunities and assets – including:

specific compensation rates and standards; detailed cost estimates.

8.Resettlement measures: Alternative income generation opportunities. Income restoration plans for specific subprojects.

9.Site selection, site preparation, and relocation.10.Housing, infrastructure, and social services.11. Environmental protection and management.12.Public participation, Consultation mechanisms.13.Grievance redress mechanism.14. Organizational responsibilities.15.Implementation process and schedule.16.Cost estimate and budget.17.Monitoring and evaluation of resettlement.

An abbreviated plan covers the following minimum elements:(a) a census survey of displaced persons and valuation of assets;(b) description of compensation and other resettlement assistance to be provided;(c) consultations with displaced people about acceptable alternatives;(d) institutional responsibility for implementation and procedures for grievance redress;(e) arrangements for monitoring and implementation; and(f) a timetable and budget.

75

ANNEX D 1: ESMF CONSULTATION DETAILS -Component 1 (Distribution)

ESMF CONSULTATION MEETING SUMMARY (BSEDN)

Date 2016.9.19Time 10:AMLocation Governors office of BaganuurParticipants 48 Participants. Local government, civil society, government ministry, local

residents

Meeting Purpose

-Introduction to ESP2 project, legal framework, along with potential environmental and social impacts associated with construction/civil works.

-Discussion of ESMF document Questions and discussion of ESP2 project.

Key Questions & Concerns raised by Participants Project start date and duration; Whether or not the households without electricity will be covered by the project and connected. Residents acquiring new plots as well as those interested in engaging in SMEs on their plots make

applications for connections to 220 and 380V. But they are not able to connect due to technical feasibility and financial shortage. Whether the residents will have such opportunity with the project implementation.

How to remove and dispose of harmful and harmless wastes from the construction/civil works, is there a specific waste disposal point? There is a disposal/landfill/ point for household wastes in the district. In case of harmful wastes, district is ready to collaborate and address it.

In case, the greenery and road and spaces are affected by the project implementation, how will it be addressed? /resettlements, rehabilitations etc/. These issues will not take place due to project measures.

In case, the historical and cultural heritages are to be affected, what measures will be taken? How will they be taken? Historical and cultural heritages are affected during the process of land adjustments in soum and district. A cultural heritage surveying should be done by the district on its jurisdiction.

Addresses of households, streets and khoroos where the project will be implemented are improper. Addressing must be made clear when the project design is developed and project implementation starts.

Information on smart meters to be installed by the project and on the difference between this and previous ones. Will there be any additional expenses to be incurred by the customers due to new metering device and line equipment by the project?

Issues related to connection cable, i.e., whether or not it will be supplied by the project or the responsibility of the customers, was raised and discussed. When households move or relocate, they take cables with them so there are shortages in the inventories of distribution lines. This should be considered.

Whether or not the customers will have an opportunity or a means to see and monitor their meter indicators and uses.

Whether or not there will be some things dependent on inspectors for the smart meters. Will the widespread electricity cut for the failure to pay electricity fees continue? The electricity cuts often happen at budgeted entities and this is related to imprudent budget planning and budget expenditures on non-functional items.

For Bor-Undur soum, water is extracted from Darkhan soum through a pump. However, when the electricity is cut, water provision stops. When a kindergarten electricity is cut, it is unable to prepare food for the

76

children. This and such issues are raised. When the local electricity lines and networks are constructed, expanded, handed over or used, there are

shortages of various electricity measurement tools, equipment and machines. Whether or not this issue will be addressed and whether or not will these be provided?

Local administration needs to pay attention to land allocations. Whether or not will there be new settlement areas? Electricity connection lines were brought to new settlement areas during the previous project but households didn’t relocate there so the line equipment remained ownerless and there were some looting incidences. When a land dispute happens during the project implementation, all work is stopped. Whether there are or are not duplicate allocations of plots. It was discussed that land disputes would be relatively low in the local areas.

Citizens have a concern that electricity fee will be increased due the drastic increases in the exchange rate and coal price. As the Baganuur mine provides UB city with coal for electricity generation, it was requested that the electricity price should not, at least, be increased (if not reduced) and this issue should be forwarded and addressed.

The electricity supply to new settlement areas will be addressed through city and district capital investment. As for the distribution company, it is not available to finance and construct new lines or sub-stations in the new settlement areas.

Whether or not the power performance rate can be estimated or calculated with the smart meters to be installed at the entities during the project implementation

Information or data collected through smart meters at the distribution companies. The information can be accessible online to the customers. They can access using customer codes provided by the distribution networks.

The completion and execution (information, photos etc.) of the project works must be handed over to the district for an input into their database. A comment for the inclusion of a representative from the district in the project works’ hand-over committee was raised.

How will the smart metering system and software be maintained after the project implementation? It will be addressed through the contract selection and contracting with the contractor. There will specific requirements in respective phases.

ESMF related items Nothing specific raised during the consultations relative to the ESMF document or changes needed.

77

ESMF CONSULTATION MEETING SUMMARY

Date 23rd of September 2016Time 11AMLocation Governors office of ErdenetParticipants 30 participants. Local government, civil society, government ministry, local

residents

Meeting Purpose

Introduction to ESP2 project, legal framework, along with potential environmental and social impacts associated with construction/civil works.

Discussion of ESMF document Questions and discussion of ESP2 project.

Key Questions & Concerns raised by Participants

Local government are interested in understanding the survey conducted to identify where new distribution lines should be extended.

Questions raised regarding waste disposal? Will waste be burned, or disposed similar to medical waste? In the medical waste facility or local landfill.

How transformer oil PCB will be addressed? There are areas with trees planted, will ESP2 affect newly planted trees? Will the distribution line cross these

tree areas? People requested that after the construction that rehabilitation must be carried out, as sometimes

contractors dig a hole but then leave without addressing it. General support given for the project and recognition that this project is important to the province.

ESMF related items Recommend putting in hours limiting noisy construction activities during the evening (i.e stop by 6pm).

78

Consultation Attendance: Baganuur September 19th 2016

Consultation Attendance: Erdernet September 23rd 2016

79

80

ANNEX D-2: ESMF CONSULTATION DETAILS-Component 2 (Solar)

Table D.1 ESMF Consultation Participant List December 2nd, Hovd

# Name Organisation

1 Даваадорж, Мянгад сумын Засаг дарга 2 Түмэнжаргал ЭХЯ-ны СБТГ-ын сэргээгдэх эрчим хүч

хариуцсан мэргэжилтэн 3 Д.Ганбаатар ЭХЯ-ны Дэлхийн банкны судалгааны багын

ахлах инженер4 Б.Батдэлгэр ЭХЯ-ны Дэлхийн банкны судалгааны багын

инженер5 Н.Алтангэрэл ББЭХС ТӨХК-ийн Ховд ЦТС ХХК-ийн ерөнхий

инженер6 Б.Энх-Амар ББЭХС ТӨХК-ийн Ховд салбарын ахлах инженер

7 О.Ойдов Ховд аймгийн Байгаль орчин хариуцсан мэргэжилтэн

8 Р.Цэцэгмаа, Б.Цэцэн Ховд аймгийн Газрын асуудал хариуцсан мэргэжилтэнүүд

9 Сэтгүүлч, Зураглаач,жолооч Орон нутгийн Жаргалан телевиз-3 хүн10 Инженерүүд-3, үйлчилгээний

ажилтан-2, жолооч-1ББЭХС ТӨХК-ийн Ховд ЦТС ХХК-ийн инженер техникийн ажилтанууд-6 хүн

# Name Organisation/ Citizen

1. С.Лхамхүү Ховд аймгийн Мянгад сумын иргэн

2. Нямболд Ховд аймгийн Мянгад сумын иргэн

3. Баянмөнх Ховд аймгийн Мянгад сумын иргэн

4. Чогсом Ховд аймгийн Мянгад сумын иргэн

5. Ч.Баттулга Ховд аймгийн Мянгад сумын иргэн

6. Ц.Энхтуяа Ховд аймгийн Мянгад сумын иргэн

7. Цагаач Ховд аймгийн Мянгад сумын иргэн Ахмадын хорооны дарга /95533111

8. Д.Бадам Ховд аймгийн Мянгад сумын иргэн

9. Ц.Батнасан Ховд аймгийн Мянгад сумын иргэн

10. М.Пүрэвхүү Ховд аймгийн Мянгад сумын иргэн

11 Г.Баттөмөр Ховд аймгийн Мянгад сумын иргэн

12 Б.Зул Ховд аймгийн Мянгад сумын иргэн

13 Ш.Даваахүү Ховд аймгийн Мянгад сумын иргэн

14 Б.Хишигдулам Ховд аймгийн Мянгад сумын иргэн

15 Д.Чинзориг Ховд аймгийн Мянгад сумын иргэн

81

16 Т.Балган Ховд аймгийн Мянгад сумын иргэн

17. Даваасүрэн Ховд аймгийн Мянгад сумын иргэн

18. Б.Энхтуяа Ховд аймгийн Мянгад сумын иргэн

19. Н.Мөнхтуул Ховд аймгийн Мянгад сумын иргэн

20. Эрдэнэбаатар Ховд аймгийн Мянгад сумын иргэн

21 Алтангадас Ховд аймгийн Мянгад сумын иргэн

22 Ж.Батбуян Ховд аймгийн Мянгад сумын иргэн

23 Нацагням Ховд аймгийн Мянгад сумын иргэн

24 Н.Нямцэцэг Ховд аймгийн Мянгад сумын иргэн

25 Ц.Отгонбаатар Ховд аймгийн Мянгад сумын иргэн

26 Н.Энхтуяа Ховд аймгийн Мянгад сумын иргэн

27. Батболд Ховд аймгийн Мянгад сумын иргэн

28. Д.Хишгээ Ховд аймгийн Мянгад сумын иргэн

29. Б.Мөнхзул Ховд аймгийн Мянгад сумын иргэн

30. Н.Дарьдулам Ховд аймгийн Мянгад сумын иргэн

31 Б.Нарантуяа Ховд аймгийн Мянгад сумын иргэн

32 Г.Лхагвасүрэн Ховд аймгийн Мянгад сумын иргэн

33 Д.Нэргүй Ховд аймгийн Мянгад сумын иргэн

34 Чулуунхүү Ховд аймгийн Мянгад сумын иргэн

35 Отгонзаяа Ховд аймгийн Мянгад сумын иргэн

36. Энхбат Ховд аймгийн Мянгад сумын иргэн

37. Оюун Ховд аймгийн Мянгад сумын иргэн

38. Нямхүү Ховд аймгийн Мянгад сумын иргэн

39. М.БАянжаргал Ховд аймгийн Мянгад сумын иргэн

40. Ж.Батсайхан Ховд аймгийн Мянгад сумын иргэн

41. Болдбаатар Ховд аймгийн Мянгад сумын иргэн

42. Даваасүрэн Ховд аймгийн Мянгад сумын иргэн

43 Галдан Ховд аймгийн Мянгад сумын иргэн

44 Б.Сайнбуян Ховд аймгийн Мянгад сумын иргэн

45 Б.Эрдэнэчимэг Ховд аймгийн Мянгад сумын иргэн

46. Ж.Бямбажав Ховд аймгийн Мянгад сумын иргэн

82

47. Б.Батхуяг Ховд аймгийн Мянгад сумын иргэн

48. Ш.Төрмөнх Ховд аймгийн Мянгад сумын иргэн

49. М.Ганболд Ховд аймгийн Мянгад сумын иргэн

50. Н.Мөнхтөр Ховд аймгийн Мянгад сумын иргэн

51. Энхтөр Ховд аймгийн Мянгад сумын иргэн

52 О.Мягмардаваа Ховд аймгийн Мянгад сумын иргэн

53 Д.Алтанцэцэг Ховд аймгийн Мянгад сумын иргэн

54 М.Цэвээндарь Ховд аймгийн Мянгад сумын иргэн

155 Ч.Мөнгөнхүү Ховд аймгийн Мянгад сумын иргэн

56. Б.Сарангэрэл Ховд аймгийн Мянгад сумын иргэн

57. Х.Түмэндэмбэрэл Ховд аймгийн Мянгад сумын иргэн

58. Э.Ууганзаяа Ховд аймгийн Мянгад сумын иргэн

59. Д.Баатарсүрэн Ховд аймгийн Мянгад сумын иргэн

60. А.Сайнжаргал Ховд аймгийн Мянгад сумын иргэн

61 К.Мереке Ховд аймгийн Мянгад сумын иргэн

62 Г.Отгонзаяа Ховд аймгийн Мянгад сумын иргэн

63 Г.Оролмаа Ховд аймгийн Мянгад сумын иргэн

64 Д.Одончимэг Ховд аймгийн Мянгад сумын иргэн

65 Д.Хашбаатар Ховд аймгийн Мянгад сумын иргэн

66. Б.Ганбол Ховд аймгийн Мянгад сумын иргэн

67. У.Пүрэвдорж Ховд аймгийн Мянгад сумын иргэн

Table D.2 ESMF CONSULTATION MEETING SUMMARY

Date 02 December 2016Time 12-15:00Location Mayangad Soum, Hovd ProvinceParticipants Ministerial stakeholders; Provincial government stakeholders; local government

stakeholders; Renewable Energy Specialists, Engineers from WES; Local Media/Television; local residents

Meeting Purpose

On December 2, 2016 discussion about the project planned to implement loan at the culture center of Myangad soum, Khovd province.To discuss about the ways to solve scope of environmental and social administrational works under “Solar plant” planned to build in Myangad soum of Khovd province and potentially elsewhere in Western Aimags.Exchange views with customers of electricity power.

83

Key Questions & Concerns raised by ParticipantsIntroduced delegates arrived in discussion meeting.

In order to hear opinions of local people about new construction and exchange views, made a presentation about 10MW capacity Solar power plant invested by World bank.Made a detailed presentation of the resolution on the funding of treated donor countries in renewable energy.

Local government informed notice about the wishes to issuance permission to build Solar power plant 20ha land located south side of the current garbage dump which is north side of 110/35/10kV Myangad substation in according to support of soum meeting and potentially elsewhere in Western aimags.

Outlined about the issued center land of the soum planned to implement the project is not belonged to water resource and reserve land, and not registered ownership.

Spoke about how to impact currently proposed 10MW substation in Khovd province by Western Region Energy System to energy supply of electricity power customers, and to be able to produce electricity power of the high cost of electricity imported from Russia on their own.

Presented how to improve problems of customers structure and current situation under project implementation, and also energy sustainable will improve and energy tariff will be stabilized.

Would be grateful if local people tell us what they think after presentation. Key discussion as follows:

Heard about Solar power plant construction in 20ha north side of our soum. Resident pointed that the Myangad soum territory has natural formation created lot dusting of delicate soil and added ground water and surface water sustains their lives. Furthermore questioned about how to coordinate those issues.

From province governor side supporting the project in according to documents given to you said Solar plant is environmentally safe, has no negative impact considered worldwide. However, need to do environmental detailed assessment. Moreover, in order to clean solar radiation collection boards certain water will be required. Therefore he said about the regulation to that water payment will be allocate into local budget.Said about that issued land’s 4-5 hectares belonged to garbage dump will cleaned to use.

Resident asked question about if it is necessary to get loan from abroad again for energy usage supply requirement when Mongolia has hard economic situation, and wondered also possibility to work under current infrastructure system.

Response: Mentioned this project investment will not belong to Mongolian loan, and added about has long-term with low interest rate condition. Moreover, half of the project consists of the possibility obtaining a grant loan.

Residnet said he is happy to know that solar resource will be near to soum center and asked if the plant will hire local people and number of permanent jobs.

Response: construction work will be performed by internal or international contracters and build construction and excavation work need temporary human resources from local people. Can I value your inquiry to understand that they are willing to include provisions on labor recruitment documents from local residents.Resdients The unanimous answer is YESResident thanked those people who is making the discussion to influence soum local development implementing the project. Called residents people for support to the construction of the project, not to interfere.

Residents are very interested into if it would be barrier to close the road when many livestock households of soum center are releasing grazing livestock pastures to the northern side, and if there is any opportunity to not increase electricity power tariff.Response: Animals are not grazing by through north side of the soum, garbage dump, therefore, won’t have barriers to close the road. But regarding the buried include funding for waste destruction point shall asked to project

84

implementers from local community.From north side of soum garbage dump, rubbish will blow away into substation land, furthermore, arise problem to bury destruction dump point.

Resident asked if nearby substation asked to take action on the green, tree planting lawn. Resdidents asked questions related to electricity power and received answers from related people.

Conclusions from public consultation1. Measures to take included in the document carefully to avoid dust emissions.2. Water consumption of solar plant should have pointed into environmental detailed assessment. 3. Ensure to prioritise the provision to provide jobs to local people in selection documents. 4. To organize destruct and bury current garbage dump by environment-friendly way.5. The planting trees and grassland on the north substation.

Because of Myangad substation’s current 2 transformers capacity overloaded to 60-80 percent, so install new 2 transformers with 2*16000 Mwa capacity and upgrade the related electricity equipment.

85