Upload
others
View
0
Download
0
Embed Size (px)
Citation preview
1
Sarah Cremin
From: Ray Mitchell <[email protected]>Sent: 07 February 2019 13:00To: Patrick Fannin; Public Accounts CommitteeCc: [email protected]; '[email protected]'
([email protected])Subject: FW: CHP&P Steering Group minutesAttachments: CHPP 170526 Programme Project Steering Group (notes 260517 for
circulation).pdf; CHPP 170829 Programme Project Steering Group.pdf; CHPP 171020 Steering Group Meeting FINAL Minutes.pdf; CHPP 171122 Steering Group Meeting Minutes v0.4.pdf; CHPP 180125 Steering Group Meeting Draft Minutes v2.0.pdf; CHPP 180226 Steering Group Meeting Minutes V2.0.pdf; CHPP 180326 Steering Group Meeting Minutes V4.0.pdf; CHPP 180423 Steering Group Meeting #8 Minutes V1.0.pdf; CHPP 180531 Steering Group Meeting final.pdf; CHPP 180625 Steering Group Meeting issued.pdf; CHPP 180827 Steering Group Meeting v2 final.pdf; CHPP 180924 Steering Group Meeting v02 final.pdf; CHPP 181022 Steering Group Meeting #13 final.pdf; CHPP 181210 Steering Group Meeting #14 final.pdf; CHPP 170526 Programme Project Steering Group (notes 260517 for circulation).pdf
Dear Pat, I understand that the PAC have requested the minutes of the Childrens Hospital Programme and Project Steering Group (CHP&P). Please find attached copies of the minutes as requested for the information of the Committee. (Just for clarity these are the minutes that Dep. Kelly had requested and received separately). With kind regards, Ray Mitchell HSE Parliamentary Affairs Division 01 6352531
Children's Hospital Programme and Project (CHP&P) Steering Group Meeting
26th May 2017 at 9.30am
Room 2.21, Dr Steevens Hospital
Attended by:
Liam Woods, National Director of Acute Hospitals, HSE (Interim Chair) (LW)
Helen Byrne, Head of Planning & Performance, Acute Hospitals, HSE (HB)
Eilish Hardiman, Group CEO, CHG (EH)
Aine Carroll, Director Clinical Strategy & Programmes, HSE (AC)
Stephan Mulvany, Chief Financial Officer, HSE (SM)
Jane Carolan, National Director of Health Business Services, HSE (JCa)
Joe Ryan, Acting Head, Programme for Health Services Improvement (JR)
Greg Dempsey, Assistant Secretary Finance, DOH (GD)
Tracey Conroy, Assistant Secretary Acute Hospitals Policy, DOH (TC)
Fionnuala Duffy, Principal Officer, Acute Hospitals Policy, DOH (FD)
John Pollock, Project Director, NPHDB (JP)
Apologies:
Rosarii Mannion, National Director of Human Resources, HSE (RM)
Richard Corbridge, Chief Information Officer, HSE (RC)
Muiris O’Connor, Assistant Secretary R&D and Health Analytics, DOH (MO’C)
1 – Introductions and Welcome
The meeting was chaired by Liam Woods. John Connaghan (JCo) to chair the meetings following
appointment on 1st August 2017.
2 – Decision Making Framework / Steering Group Terms of Reference and Membership
Terms of Reference were discussed and agreed.
Action: Amendments to be submitted prior to the next meeting. Memo to the Government agreed
key elements of approved decision by Government and outline to be shared with steering group.
The Children’s Hospital Group, Development Board Project Team and HSE National Directors to
provide relevant reports to the CHP&P Steering Group. These will be subject to discussion and
decision making at future meetings.
3 – Children’s Hospital Programme
(a) Children’s Hospital Programme Dashboard
Children’s Hospital Programme dashboard was tabled and discussed. Interdependencies outlined
between capital project, national Model of Care for Paeds, national EHR project and workforce plan
for CHG.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
2
The Paediatric Model of Care needs an implementation plan and it was noted that there are
implications for other divisions also.
Action: EH to lead for the Acute Division initially and will also require financial input.
Action: Paper required to inform on the financial implications of implementation.
Draft Heads of Bill for the CHG to become a legal entity is expected to go to Cabinet at the end of
June.
Future Operating Model under development in order to set-out how the Children’s Hospital with
two satellites will operate from 2021 onwards.
Action: Milestones and timelines of the project and programme will be key discussion items at all
future meetings.
It was noted that SAP-HR implementation in the CHG needs to be added to the milestones.
High Level Risks discussed – issues around resourcing, decision making between this Steering Group
and the CHP+P Board, from ICT perspective the national roll-out of MedLIS and National EHR are
risks.
(b) 2017 Funding Deficit Children’s Hospital Programme / Estimates Process 2018
For 2017, the integration programme has a deficit of €4.6m and this is impacting on its
implementation. The shortfall was originally €8.6m however the CHG have re-profiled some of the
work scheduled for 2017 to 2018. The impact of the deficit will start next month.
The reconfiguration of outpatient and urgent care services and expected opening of the Connolly
satellite in 2018 will require recruitment of difficult to fill posts to start mid-late 2017.
Action: JP to provide 3 year and dependency estimates.
Action: The CHG need to clearly set-out the costs associated with ICT/integration programme in the
estimates for 2018.
Action: EH to progress paper on difficult to fill posts with RM.
(c) Children’s Hospital Programme ICT Dependencies
ICT have 17 projects across the CHG for the Paeds Outpatient and urgent care centres at Tallaght
and Connolly. These are integration projects on-going across hospitals and a due diligence process is
underway to support commencement of the new legal entity. There is an executive arrangement in
place with St. James’s Hospital on shared campus infrastructure and associated services.
Action: Report at next meeting on the Value Engineering Report.
Discussion on need for an Integrated PMO approach to map the interdependencies between the
capital project, implementation of the National Model of Care for Paeds, National EHR, workforce
and Integration Programme. LW/JP/JR/EH to revert with proposal for Integrated PMO.
Action: Project Management Office to be integrated and EH to develop a straw-man.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
3
The decision with regard to MES is outstanding as it is unclear who the stakeholders are and who will
be signing-off on it.
Action: GD to follow-up and ascertain who in DPER to engage with to progress.
Action: SM to submit Crowe Horwath report to DOH and circulate to members of this Group.
In relation to the ICT Business Case - MedLIS – programme delivery date for national roll-out is
challenging. SM concurs and project under intensive oversight by HSE, progress with programme to
be monitored closely.
(d) Paediatric Outpatient & Urgent Care Centre Resourcing (Connolly)
Paper on Workforce Plan to open paediatric outpatient and urgent care centre at Connolly included
with papers. Connolly requires approval to progress the start of recruitment of difficult to fill posts
in last quarter 2017. There are a total of 31 post identified in 2017 in this category. There is a long
lead in time to get the staff in place.
Action: EH to progress paper with RM for DoH consideration. Approval is required to progress.
National Model of Care for Paediatrics: There is to be a follow up meeting with the Paediatric Clinical
Programme Leads and EH. Resource requirements need to be set out for implementation. Aine
Carroll and Liam Woods to discuss. It is intended that a group will be set up to oversee the Model of
Care implementation with input from all relevant divisions
Action: DOH to lead on discussion with DPER on the implications of the Model of Care.
5 – Children’s Hospital Project
(a) Construction Contracts Update
Decision made by the Government on 26th April. The commercial and contract engagements are to
commence in the next week.
Action: Indemnity for the NHDB needs to be addressed. Construction contracts are expected to be
signed in early June. GD to follow-up re indemnity.
JP to revert with updated Programme on contract signing.
Fire Cert – There has been a condition attached into the building regarding sprinklers. The NPHDB
are appealing these conditions with An Bord Pleanala as it would increase costs. An appeal will be
lodged and notification of the outcome expected towards year end.
(b) Tallaght Hospital ICT Server Room
Paper included with agenda outlining urgent requirement to resolve €2m HSE funding for Phase 1
works to move ICT server at Tallaght Hospital. Satellite build is due to commence in August and
solution on server move required.
Action: JCa to follow up with RC to progress solution.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
4
6 – Agreed Meetings Schedule
To be decided upon after the Governance Board set their meeting dates. It was considered
preferable to meet monthly for the forthcoming months and then move to every 6 weeks. It was
also suggested that these meetings take place before the Board meetings.
Children's Hospital Programme and Project (CHP&P)
Steering Group Meeting
29th August 2017 at 1.15pm
Boardroom, Hawkins House, Dublin 2
Attended by: John Connaghan (JCo), Deputy Director General, HSE (Chair) Liam Woods (LW), National Director of Acute Hospitals, HSE (Interim Chair) Tracey Conroy (TC), Assistant Secretary Acute Hospitals Policy, DOH Eilish Hardiman (EH), Group CEO, CHG Aine Carroll (AC), Director Clinical Strategy & Programmes, HSE Stephan Mulvany (SM), Chief Financial Officer, HSE Jane Carolan (JCa), National Director of Health Business Services, HSE Greg Dempsey (GD), Assistant Secretary Finance, DOH John Pollock (JP), Project Director, NPHDB Helen Byrne (HB), Head of Planning & Performance, Acute Hospitals, HSE Muiris O’Connor (MO’C), Assistant Secretary R&D and Health Analytics, DOH Audrey Doyle (AD), General Manager, Office of the National Director of HR, HSE Siobhan Keenan (SK), Acute Hospitals Policy, DOH Roisin Mulqueen (RMu), Acute Hospital Division, HSE Deirdre Love (DL), Acute Hospital Division, HSE Apologies: Joe Ryan (JR), Acting Head, Programme for Health Services Improvement Rosarii Mannion (RMa), National Director of Human Resources, HSE Fionnuala Duffy (FD), Principal Officer, Acute Hospitals Policy, DOH Richard Corbridge (RC), Chief Information Officer, HSE
1 – Introductions & Welcome The meeting was chaired by John Connaghan (JCo).
2 – Minutes/Matters Arising Action: Update required from Rosarii Mannion (RMa) re paper submitted by Eilísh Hardiman (EH) on approval for difficult to fill posts, for opening first facility. Action: Integrated PMO to be in place by the next meeting (Joe Ryan, JR). Action: Reporting Framework required for CHP&P Board (Tracey Conroy, TC).
3 – Children’s Hospital Programme Dashboard EH provided an update on the major milestones for the Children’s Hospital Programme for the next year – overall programme is in amber status due to DG Letter to Chairman on 2017 funding deficit and lack of clarity on progression of National EHR. The publication of the Heads of Bill (29/08/2017) was noted. Action: HSE feedback on Heads of Bill to go to Liam Woods (LW). It was noted that pre-commencement analysis and review of the 3 hospitals mergers (due diligence/risk assessment) is in progress and will require engagement with Liam Woods.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
2
Workforce - Difficulty in filling a number of posts was noted (e.g. ICT Infrastructure Lead at Assistant
National Director grade – currently embarking on 3rd attempt to fill the role – due to highly competitive market. )
- Issues of the sustainability of an over-reliance on External ICT support were also discussed. - Approval to recruit required asap. - Paper submitted with meeting documentation regarding the permanent filling of executive
posts for the CHG being progressed due to commencement of entity. It was noted that there is a funding deficit of €3m to year end in relation to the Children’s Hospital Integration Programme. EH/LW and SM to meet. The greatest dependency is on the National Electronic Healthcare Record (EHR) - Pre-procurement work on specification progressing with assurance required on EHR
programme. - MedLis timeline is a risk within the healthcare system. Action: Monthly report on MedLis required. Update report on EHR requested from RC Key Dependencies of the Children’s Hospital Programme - National EHR – the New Children’s Hospital will be the first to roll-out EHR in the acute sector. - Funding – Proposals have been submitted for 2018 estimates. - Legislation enacted in Q4 2017 to allow commencement and transition of the three hospitals
into a single entity. Draft General Scheme published – opportunity to review draft for the 2 next weeks.
- Workforce – Approval required in recruiting staff for opening Paediatric OutPatient and Urgent Care Centre at Connolly.
Staff engagement – EH advised that the Joint Information and Consultation Forum was presented to in Q2 2017. EH advised that meeting with National Leads arranged for October 2017 and briefings arranged for the three hospitals. Clarity has been sought in relation to Senior Management roles / variations to roles. It was noted that there are supports available to staff (e.g. Occupational Health) and an Organisational Development plan re people and change. Expectations in market rates are impinging the ability to recruit appropriately experienced/qualified staff, in particular ICT senior positions.
4 – 2017 Funding Deficit Children’s Hospital Programme/Update of Estimates 2018 It was noted that the 2018 estimates have been submitted, which have been escalated to DPER as a priority. Action: Meeting to be scheduled between LW, EH and Stephen Mulvany (SM) to discuss 2017 funding deficit. Closed.
5 – Workforce: Approvals for Commencement Executive Roles Paper circulated with Agenda by EH. Executive posts are currently filled on a temporary basis with exception of CFO post, approval sought for these to be filled on a permanent basis – through external advertisement. EH to progress required Business Cases for these executive posts without previous approval.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
3
The proposal is to develop a cross city arrangement structure over a two year period that will involve the re-alignment of hospital executive posts in a phased manner. Action: EH to commence approvals process with HSE and Dept. of Health for unapproved posts.
6 – Update of Programme for Capital Projects Report circulated by John Pollock (JP). - JP advised the group that the construction contract for the National Children’s Hospital (NCH;
Phase A) with BAM was signed last month. A 52 month construction period is anticipated plus 2 months contingency. The start date is anticipated to be 2nd October 2017, with completion due by the end of Q1 2022. There will be a 6 month commissioning period thereafter with the expectation of being operational by the end of Q3 2022. It was noted that there are 2 phases for the NCH – Phase A basement level (15-18 months) and Phase B above ground works.
- The contract for the 2 satellite centres (Phase B) is due to be signed 30/08/17. Estimated completion of Connolly centre is end of May 2019, with a 2 month commissioning period – due to be operational by the end of July 2019. Estimated completion of Tallaght centre is end of April 2020, with a 2 month commissioning period – due to be operational by the end of June 2020.
Action: SM/JCo requested an update at every meeting regarding the expected vs current programme of the construction project, with funding streams and interdependencies to be included. EH and JP will provide until the PMO is assigned. There is a plan in place for the relocation of Server at Tallaght. As this is an important dependency it was agreed that the plan required a written update on progress for the Steering Group Meetings. Action: RC to nominate an alternative representative to make provision for update on issues at meetings. Action: TC requested a report of slippages since April ahead of the Governance Board meeting on 14th September. A query was raised in relation to the future reporting agenda. The importance of making plans and implementing Primary Care Teams in the Communities around the vicinities of the current hospital sites was noted. Dashboard report circulated by JP which gave an update on construction Health & Safety, Tallaght server relocation and completion of Aspegillus works at Connolly. Action: Update required from Richard Corbridge (RC) for the Governance Board meeting on 14th September in relation to Tallaght server relocation. Action: Alternative ICT representative required. It was noted that settlements have been agreed for the residents of O’Reilly Avenue. Main construction to commence on 2nd October – 5 day working week with planning permission to work a half day on Saturdays if required as contingency arrangement. The NCH construction programme project has been benchmarked against similar projects in the UK and compares favourably (month/1,000 sq.m). Construction of Phase A of the project to be tracked as a KPI.
DRAFT NOTES_Children's Hospital Programme & Project Steering Group Meeting
4
It was noted that the project incorporates a Frozen Design Layout and changes only considered through the identification of commensurate savings elsewhere. JP raised a concern regarding costs – it was noted that there is an aligned programme issue between mechanical/electrical work and main contractor as well as fire certificate/sprinklers additional requirements – to be reported to the group on a regular basis. Guaranteed Maximum Price (GMP) to be agreed with BAM at the end of the GMP process and will be known within the next 7-9 months. It was advised that €65m for Managed Equipment Services (MES) has been identified, €20m approx. for standard capital. A Steering Group has been established – JP, HSE, Dept. – in relation to approvals. It was noted the MES is a first for Ireland and will be challenging in relation to approvals process. A query was raised in relation to the cut-off date regarding a decision to proceed with MES option – JP to revert. The Business Case needs to be accurate with regard to how we measure value.
7 – ICT Dependencies Action: Update required from RC regarding Tallaght alignment server alignment between National EHR and the Children’s Hospital opening. Muiris O’Connor (MO’C) advised that there is an opportunity of securing funding for National EHR though Sláinte Care implementation. It was noted that contingency planning undertaken in this key dependency.
8 – Implementation of Paediatric National Model of Care Aine Carroll (AC) advised the group that a sub-group met recently – 0.5 wte project management post in place. TC noted that an implementation plan is required as soon as possible detailing how the Implementation of the Acute Hospital’s Model of Care including how it will integrate with Primary Care. LW stressed the import of dependency on the role out of the Model of Care on a national basis in particular that services in Galway, Limerick and Cork need to be developed in line with the national programme also. Immediate requirements to develop the implementation action plan have been submitted to the 2018 estimates process.
Action: AC to update next meeting with estimated timescale to develop the implementation plan.
9 – Agreed Meeting Schedule It was agreed that the meetings would take place on a monthly basis. Integrated PMO to schedule meetings between now and the end of Spring 2018.
10 – AOB Dublin 8 Health and Innovation Corridor
- Multi-stakeholder group (Children’s Hospital, Coombe, St. James’s, IDA and Dublin City Council) re urban regeneration to include health and innovation corridor due to meet on 5th September – update to be provided at the Governance Board meeting on 14th September.
Philanthropy
- Philanthropy campaign required, follow up meeting with three hospital Foundations being planned for October 2017.
- No funding acquired for the Research Building
Children’s Hospital Group Programme & Project Steering Group
Page 1 of 5 [
Meeting Children’s Hospital Programme & Project (CHP&P) Steering Group Meeting #3
Date 10.00-12.00, 20th October 2017
Location Boardroom, Dargan Building, Heuston South Quarter, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
Eilish Hardiman (EH) Group CEO, CHG
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Greg Dempsey (GD) Assistant Secretary Finance, DOH
Jane Carolan (JCA) National Director of Health Business Services, HSE
John Pollock (JP) Project Director, NPHDB
Liam Woods (LW) National Director of Acute Hospitals, HSE – dial in
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
Rosarii Mannion (RM) National Director of Human Resources, HSE
Additional Attendees
Deirdre Faherty (DF) Office of the National Director, Acute Hospitals, HSE
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Róisín Mulqueen (RM) Programme / Project Manager, Acute Hospitals, HSE – dial in
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group, HSE
Apologies
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Joe Ryan (JR) Acting Head, Programme for Health Services Improvement, HSE
Stephen Mulvany (SM) Chief Financial Officer, HSE
Richard Corbridge (RC) Chief Information Officer, HSE
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, DOH
Key Discussion Points
1. Introduction
Agreed external assessment of governance of Steering Group, to be arranged by JR. Action
Agreed EH to liaise with JR regarding specification of this external assessment.
2. Minutes and Matters Arising
Agreed changes to minutes of previous Steering Group, proposed by MO’C and FD.
Agreed changes to format and introduction of action log, proposed by JGC and EH.
Discussed feedback on Heads of Bill. LW confirmed that the General Scheme text had been considered
by HSE Corporate and there was minimal feedback on the text provided to DOH.
3. Items Arising from CHP&P Board
a) EHR Programme:
JCA noted programme status red as key approvals (business case, funding and staff) are overdue.
MO’C noted challenges with all-encompassing, multi-annual business case and confirmed move to
modular approach; developing smaller business case, more specific to children’s hospital but part of a
national roll out.
Children’s Hospital Group Programme & Project Steering Group
Page 2 of 5 [
Discussed funding; limited funding available in 2018 but requirements are modest; requirements will
increase significantly from 2019 onwards.
Discussed cash flow over coming years; an exercise was done on this in April 2017 but probably needs
revision to be more modest; there will be more clarity on pricing when tenders are received.
Agreed MO’C and JCA to prepare (i) detailed timeline on plan for EHR business case and procurement
approval until March 2018 and (ii) overview of project management processes and governance for
discussion at the next meeting. Action
b) Managed Equipping Solutions:
GD confirmed next HTSS Steering Group meeting scheduled for 26th October 2017.
Agreed update on MES will be agenda item at next Steering Group. Agenda Item
Discussed MES Sourcing Strategy document, which proposes breaking MES business case in three lots.
EH confirmed Managed Lab Service (MLS) is not being pursued; included to demonstrate options.
Agreed need for engagement with DPER and NDFA for feedback on approach. Action
Agreed need for HSE support to cost traditional equipment compared to MES approach. Action
Agreed JCA to follow up with JP to discuss potential support from Elaine Maye. Action
c) Model of Care for Paediatrics Implementation Plan:
GT provided overview of MOC implementation plan.
- Identified 3 aspects of the MOC: acute services, healthy children, and community services.
- Confirmed fully costed, prioritised plan is due May 2018, in time for the estimates process.
- Noted this depends on internal and external resources being in place in 2017.
- Noted LW and AC engaging with JR in relation to these resources.
- MO’C noted he leads a Health Research Board, which may offer funding opportunities for relevant
medium-term work on the MOC implementation plan, which would warrant international awareness.
Discussed resource implications of MOC implementation, approx. €290m (staffing costs).
- Confirmed relevant resource implications were noted only in children’s hospital business case.
- Clarified any additional revenue funding required to build up a workforce for the new children’s hospital
and to implement the new MOC in the hospital would need to be considered as part of the annual
estimates discussions.
- Significant discussion about the reality of the annual funding mechanism that applies in the Irish health
system, and how it differs from experience abroad. Acknowledged implementing a capital project of this
scale without revenue funding agreed is a major risk.
- Agreed JGC and GD to have follow-up conversation relating to this concern.
Discussed governance of MOC implementation plan.
- Agreed MOC implementation plan will be standing agenda item in this forum. Agenda Item
- GT noted the Programme Sponsors, AC and LW, have agreed that the governance for the MOC implementation plan design is through the Service Delivery Board.
- Discussed potential for divergent decisions or duplication of work with two forums; need for clear remits.
- Agreed GT to prepare short paper on governance for CHP&P Board, with EH contributing. Action
d) Format for Reporting to CHP&P Board:
Agreed FD, SO’B and Siobhan Kennan to develop proposal to bring to JGC. Action
4. Update from NPHDB Capital Project
JP presented NPHDB reporting and capital cost update.
JP noted some emerging challenges, with estimated capital cost currently exceeding funding available.
JP noted this is a working estimate; it will be January-March 2018 before there is certainty.
Children’s Hospital Group Programme & Project Steering Group
Page 3 of 5 [
JP noted the figures presented take into account existing value engineering mitigation measures.
JP highlighted €20m allocated to additional fire safety; An Bord Pléanala decision on this is due
November 2017.
JP confirmed there will be reasonable certainty about the size of the funding deficit by end March 2018.
JP added that the agreed Guaranteed Maximum Price (GMP) will require Government / HSE approval by
early July 2018.
Discussed four possible options for addressing capital cost funding deficit including:
i) Descoping capital project: JP noted QS already exploring descoping options at a high level.
ii) Reallocating capital from wider HSE Capital Plan: JCA flagged difficulty due to contract constraints.
iii) Mitigating deficit through philanthropic funding: EH noted current commitment is to raise €20m.
iv) Engaging with DPER for additional funding.
Agreed EH to prepare a case on projected philanthropy funding by March 2018. Action
The use of funding raised by third parties warrants further discussion with DPER at a later date.
Agreed JP and EH to prepare short report for CHP&P Board that describes the emerging risks and
commits to looking at immediate ways to mitigate the deficit and, in parallel, exploring
backstop/contingency options in the event a sizeable deficit cannot be reasonably avoided. Action
5. Update from Children’s Hospital Programme
FD noted that timeline of March 2018 for legal enactment has been agreed with the Minister.
EH noted legal commencement date of 1st July 2018 has been supported by the executives and is being
recommended to the three Hospital Boards.
Discussion around other factors that will affect the actual commencement date. Need to ensure relevant
stakeholders are satisfied that any proposed commencement date is feasible, achievable and practical. In
this context, agreed EH to discuss commencement date with LW and SM. Action
EH noted three foundations have agreed to become a single philanthropic and fundraising foundation.
6. Standing Update on Children’s Hospital Programme Funding
Agreed EH to discuss funding with LW and SM. Action
EH noted funding does not match what was approved in the business case. All revenue requirements,
including for the integration programme, are considered as part of the annual estimates discussions.
EH noted likely resulting scenario for 2018 integration spend is that ICT implementation will be prioritised
over change management and clinical integration.
7. Standing Update on HR
RM confirmed priority posts for 2018 have been approved by HR to commence recruitment process,
which can take 12-18 months to recruit.
RM noted that workforce capacity in general is an issue.
EH confirmed proceeding with recruitment, with known risk that funding is not yet confirmed.
HB added that the posts are not reflected in 2018 estimates.
EH notes the priority posts have a total cost of €11m, with some in 2018 and most in 2019.
Agreed this is a critical risk, as the opening of the satellite centres depends on this recruitment.
Agreed EH to discuss with LW and SM as part of the wider conversation on funding.
RM noted good engagement with unions, but this will continue to be a challenge and a priority.
MO’C raised concern about overreliance on external ICT support.
Agreed EH to prepare proposal on ICT staffing to demonstrate internal-external balance. Action
Agreed RM to present on change management of change model at next Steering Group meeting. Action
8. Tallaght ICT Server Relocation
Raised concern about lack of clarity over who is leading on implementation, Tallaght or OoCIO in HSE.
Agreed JCA to clarify ownership of this activity directly with Tallaght Hospital. Action
Children’s Hospital Group Programme & Project Steering Group
Page 4 of 5 [
Children’s Hospital Group Programme & Project Steering Group
Page 5 of 5 [
Action Log
Ref Action Owner Due
1 (i) Prepare detailed timeline on EHR until March 2018.
(ii) Prepare overview of PM processes and governance. MO’C / JCA 20/11/18
2
Convene HTSS Steering Group, including CHGB, and agree next
steps for completion of MES business case (business case due
February 2018; business case approvals due April 2018), including
meetings with NDFA & DPER to agree involvement, inputs, and
scope of programme.
GD 20/11/18
3 Confirm HSE resources and costings for traditional equipment
procurement for Public Sector Benchmark comparator. JCA 20/11/18
4 Discuss potential support from Elaine Maye for MES. JP / JCA 20/11/18
5 Paper on MOC implementation plan governance for CHP&P Board. GT / EH 20/11/18
6 Develop proposal for format of report to CHP&P Board. FD / SO’B 20/11/18
7 Estimate how much philanthropic funding could potentially generated
for the period until March 2018. EH 20/11/18
8 Paper on projected capital deficit for CHP&P Board. JP / EH 20/11/18
9 Follow up meeting in relation to commencement date, funding and
approval to recruit. EH / LW / SM 20/11/18
10 Proposal on ICT staffing to improve internal-external balance. EH 20/11/18
11 Update on change model at next Steering Group meeting. RM 20/11/18
12 Clarify ownership of Tallaght ICT server relocation. JCA 20/11/18
13 Proposal on external assessment of governance of Steering Group.
EH to contribute input into specification. JR 20/11/18
Children’s Hospital Group Programme & Project Steering Group
V0.4 Page 1 of 5 [
Meeting Children’s Hospital Programme & Project (CHP&P) Steering Group Meeting #4
Date 10.00-11.30, 22nd
November 2017
Location Boardroom, Dargan Building, Heuston South Quarter, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Eilish Hardiman (EH) Group CEO, Children’s Hospital Group (CHG)
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Greg Dempsey (GD) Assistant Secretary Finance, DOH
John Pollock (JP) Project Director, National Paediatric Hospital Development Board (NPHDB)
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, DOH
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
John Smith (JS) Assistant National Director, Health Business Services (HBS), HSE
Róisín Mulqueen (RMU) Programme / Project Manager, Acute Hospitals, HSE – dial in
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group, HSE
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS) / Acting CIO, HSE
Joe Ryan (JR) Acting Head, Programme for Health Services Improvement (PHSI), HSE
Stephen Mulvany (SM) Chief Financial Officer, HSE
Liam Woods (LW) National Director of Acute Hospitals, HSE
Key Discussion Points
1. Minutes and Actions
Agreed changes to minutes from previous session; to circulate for approval with minutes for this session.
Discussed how funding for capital projects will be approved in future:
- JGC raised the issue of having separate processes for capital and revenue funding approvals.
- JGC queried if the DOH is aware of any intention in Government to change this approach.
- GD acknowledged it is a well-known problem that particularly impacts health.
- GD confirmed DOH has raised with DPER on numerous occasions.
- GD suggested could raise again if desired; agreed that this would be left to GD’s discretion.
- GD noted that business case approval for a capital project is a separate process from capital and revenue
funding approvals, and does require information on all associated costs.
- TC added for the national children’s hospital the DOH made a great effort to fully appraise Government on
future revenue implications during the decision on capital funding; information on Model of Care revenue
implications was not available at the time.
- JGC acknowledged this issue is beyond the scope of this forum alone and asked GD to give consideration
as to how to engage with Government on it.
Discussed governance of implementation of the Integrated Care Programme for Children: - Noted draft paper on this for CHP&P Board was received from Grace Turner and reviewed by JGC.
- AC explained the Integrated Care Programme for Children will report to the Service Delivery Board (SDB),
under PHSI governance; this is the most appropriate arrangement as it is mostly operational work.
- AC explained a significant amount of work is involved in the Integrated Care Programme for Children and
resource requirements have been identified but not allocated. AC is raising this internally in HSE. Action
- AC confirmed the programme is highly relevant to this forum and will remain a topic of discussion.
Children’s Hospital Group Programme & Project Steering Group
V0.4 Page 2 of 5 [
- EH noted the governance arrangement is satisfactory provided it is clear where decisions are made, and
that interdependencies with the Children’s Hospital Programme continue to be discussed in this forum.
- TC asked that the final paper for CHP&P Board identifies a single person responsible for the programme.
- JGC proposed briefing all Steering Group members on the PHSI governance structure. Action
- JGC proposed briefing the Service Delivery Board to ensure it is fully aware of the interdependencies
between the Integrated Care Programme for Children and the Children’s Hospital Programme. AC agreed
to discuss with SM (Chair of Service Delivery Board). Action
Discussed reporting from CHP&P Steering Group to CHP&P Board: - Noted draft report format developed with input from JGC, SO’B, FD and Siobhan Kennan (DOH).
- Agreed to finalise and secure Secretary General approval before next CHP&P Board meeting. Action
Discussed progress on the proposed Commencement Date:
- EH confirmed CHG Board recommended the proposed commencement date, 1st July 2018, for approval
on the condition that certain criteria are met.
- EH noted a high-level preliminary report identifying potential issues with the proposed commencement
date (e.g. regulatory or fiduciary issues) is due for completion in December 2017. EH noted only one issue
has emerged so far – technical accounting standards relating to pensions. EH to raise with SM and LW.
- GD noted he is part of a DPER sub-group trying to resolve the same issue relating to pensions. Agreed
EH to arrange for Valerie Plant to circulate a paper to GD, JGC, LW and SM on the implications of this
issue for the entity on commencement. Action
- TC noted it is positive that the 3 hospitals support the proposed commencement date, indicating their
ability and willingness to be ready by 1st July 2018. TC clarified that the finalisation of the commencement
date depends on other factors; DOH need assurances for relevant stakeholders relating to all potential
issues, and need to complete an options appraisal comparing mid-year and start-of-year commencement
dates before making a recommendation on the final commencement date to the Minister.
- JGC queried how long an options appraisal would take. TC responded a matter of weeks.
- EH raised credibility challenges associated with moving from the proposed commencement date.
Discussed progress on approval to recruit roles with long lead times:
- EH noted cost of 2018 roles with long lead times have been revised down from €1m to €0.6m.
- EH worked with the Consultant Applications Advisory Committee (CAAC) on a proposal relating to this for
discussion at their December session.
- EH noted a letter of comfort regarding funding is required from the DOH and HSE for CAAC approval. EH
agreed to share a business case to support this to FD and LW this week. Action
- RMA noted the need for a proviso that funding will be available at point of offer.
Discussed concern raised by JP at last Steering Group meeting about relocation of Tallaght ICT server:
- SO’B noted JCA and PMO for the OoCIO confirmed this work is on track.
- JP flagged a potential disconnect between the project status being reported by OoCIO and Tallaght.
- JS agreed to follow up with JCA. Note: Following the Steering Group meeting, this matter was resolved by
JCA and JP; it was concluded that the project is indeed on track.
- Agreed further clarity required on ultimate responsibility for the server relocation. Note: Following the
Steering Group meeting, JCA confirmed this is David Wall, Director of ICT for Tallaght Hospital.
Discussed business case on ICT staffing:
- EH clarified definitive business case identified capital, consultancy support and future staff under ICT.
- EH noted CHP is looking to recruit future staff ahead of plan to reduce reliance on external support.
- MO’C noted an impression there is a heavy dependency on external consultants. EH confirmed the ICT
staffing paper being developed will give assurances that there is a balanced mix of resources.
- EH noted a challenge recruiting internal staff due to very competitive market and suggested the need to
go beyond recommended public sector pay rates. MO’C agreed to work with EH to make a case for this.
- Agreed the ICT staffing paper to be presented at the next Steering Group, 25th January 2018. EH and
MO’C to meet separately to review the paper in advance of this. Action
Children’s Hospital Group Programme & Project Steering Group
V0.4 Page 3 of 5 [
- RMA advised recruiting over Christmas period has been an effective strategy for National HR and offered
resources to support early recruitment communications for the Children’s Hospital Programme during the
period. Action
2. Update on Electronic Healthcare Record (EHR)
MO’C noted a timeline for EHR has been developed and agreed to circulate. Action
MO’C reiterated that approval for EHR will no longer be sought as a single business case for c. €800m.
MO’C clarified the EHR vision is still national; the modular approach to the business case and tenders,
commencing with implementation in the new children’s hospital, is being used for practical purposes.
MO’C clarified the aspect of EHR most relevant to the new children’s hospital is Acute EHR, which relates
to all hospitals.
MO’C clarified the initial tender will be framed as a national roll out of Acute EHR, but will only be for
implementation in the new children’s hospital.
EH asked if there will be a separate tender for each individual hospital. EH raised a concern about this, as
the success of the new children’s hospital is dependent on the nationwide implementation of the Model of
Care, which requires all hospitals to have EHR to enable access to the same records.
JGC queried if this creates a problem in terms of value for money.
MO’C noted these details will be considered as part of the business case development.
EH suggested it would be beneficial to have a Children’s Hospital Group representative on the EHR
project. MO’C agreed to involve a Children’s Hospital Group representative in framing the business case
and tender. HB added it would be beneficial to have a MN-CMS representative. MO’C agreed in principle.
MO’C noted he will initiate preparatory discussions with the Office of Government CIO.
MO’C emphasised it is unknown whether the business case will get approval within timescales required.
Agreed separate meeting to discuss EHR before the CHP&P Board meeting. Action
3. Update on Managed Equipping Solution (MES)
GD noted some good progress establishing governance and Terms of Reference (TOR) for the
Equipment Procurement Strategy Board and Equipment Procurement Project Team; a key decision is that
its remit will now include considering the alternative procurement options and making a recommendation
for a preferred procurement methodology.
Agreed GD to set out update on MES progress in a paper. Action
JP raised a concern about the timeline for the MES business case. JP noted that he met with Elaine Maye
(EM) – HBS, previously involved in public-private partnership (PPP) – who presented a different view of
the scope of work involved in the business case and advised the current timeline for completing the
business case is unrealistic.
JP emphasised the need to engage DPER and the National Development Finance Agency (NDFA) to
understand what they want to see in the business case, to ensure it fully meets their needs.
GD noted that the first step is to get NDFA to commit to fulfil this role and NDFA advised they would
require the TOR in advance of this.
GD offered clarity about what DPER will want to see in the business case; DPER want the business case
done as if for PPP and will want to compare MES to traditional equipping and assess which offers better
value for money.
JP and EH raised a concern that DPER needs specific equipment requirements upfront as part of the
business case approval process, whereas they require flexibility until the competitive dialogue stage of
procurement, due to the interdependencies between EHR and equipment / health technology needs.
GD confirmed DPER will need relatively certainty about the list of equipment required; this is necessary in
any case for the Equipment Procurement Project Team to compare MES and traditional equipping.
JGC asked EH and JP to set out user requirements to establish common understanding of needs. Action
GD committed to reconvene the Equipment Procurement Strategy Board as soon as possible. Action
RMU referenced similarity to previous NAS experience and agreed to follow up on lessons learned. Action
Children’s Hospital Group Programme & Project Steering Group
V0.4 Page 4 of 5 [
4. Update on Funding
EH agreed to circulate business case on Director of Philanthropy this week. Action
JP confirmed An Bord Pleanála (ABP) decision – fire sprinklers must be fitted throughout the hospital.
JP noted that the independent expert and the inspector appointed by ABP ruled in favour of the NPHDB.
JP confirmed the decision has a cost implication of approx. €20m, making the current estimated gap
between total capital cost and funding available approx. €60m.
MO’C requested clarity on total cost of sprinklers, and the percentage increase in costs due to this
decision. Agreed this information can be included in the paper for the CHP&P Board.
JP explained he is working with EH to develop a back stop / contingency and will present a paper to the
CHP&P Board; JP and EH will brief JGC on this in advance of the CHP&P Board meeting. Action
JP noted this has identified capital items for descoping. GD noted that this potential mitigation is welcome.
5. Update on the Capital Build
JP raised risk around capital programme funding for 2018; €120m is being made available, which is €40m
lower than expected. JP noted this has been discussed with Jim Curran (JCU), HBS.
GD suggested this is due to different understandings of the initial commitment.
GD noted he understands the €120m is based on the contractual commitment.
JP noted that approx. €150m was set out in the definitive business case.
JP stated that JCA has acknowledged the 2018 programme funding gap.
Agreed for JCA, JCU, JP, GD and JS to meet and come to a resolution before year end. Action
6. Update on Proposal for External Governance Assessment
TC noted concern relating to scope of the assessment, as governance is mandated.
Deferred detailed discussion. Note: Since the Steering Group meeting JGC has clarified that his request
for a review of “Governance” applies only to the CHP&P Steering Group and is required to assure him that
the process of business carried out in the Steering Group is sound, and that information flows, decision
making and resources for project management satisfy appropriate business standards.
7. Update on Human Resources (HR)
RMA noted the revised Change Model was reviewed at the Enabling Board and further work is required.
RMA agreed a full update on the Change Model will be provided at the next Steering Group meeting.
EH proposed RMA meets with Phil Welsh, Director of Strategic HR, Organisational Development and
Change Management in the Children’s Hospital Group, in relation to union engagement. Action
EH noted a national workforce plan for children’s nursing in Ireland is underway and due to report April
2018 – this will provide an extensive analysis of demand and supply, and make recommendations.
EH noted there is a risk around recruitment of health and social care professionals.
8. AOB
Agreed to develop overarching critical path; EH and JP to brief JGC before CHP&P Board meeting. Action
Noted next Steering Group meeting is 25th January 2018. Agreed to extend future meetings to 2 hours.
Children’s Hospital Group Programme & Project Steering Group
V0.4 Page 5 of 5 [
Action Log
Ref Action Owner Due
Carry Forward (amendments to actions made as appropriate)
1 Circulate EHR timeline to Steering Group members.
Prepare overview of PM processes and governance for EHR.*
MO’C /
JCA 01/12/17
2 Finalise paper on Model of Care governance for CHP&P Board. AC 01/12/17
3 Finalise format of report to CHP&P Board with Sec Gen approval.* FD / SO’B 01/12/17
4 Circulate business case on Director for Philanthropy. EH 24/11/17
5 Estimate potential philanthropic funding between now and March 2018.* EH 17/01/17
6 Finalise paper on projected capital deficit for CHP&P Board and brief JGC. JP / EH 08/12/17
7 Provide briefing on ICT staffing paper at next Steering Group.* EH 17/01/18
8 Provide update on change model at next Steering Group.* RM 17/01/18
9 Update on external assessment of governance at next Steering Group.* JGC / JR 17/01/18
New Actions
10 Update on resources for MoC implementation plan at next Steering Group. AC 25/01/18
11 Circulate paper on PHSI governance structure to Steering Group. JR 17/01/18
12
Ensure Service Delivery Board briefed on its governance of the Integrated
Care Programme for Children, and the interdependencies with the
Children’s Hospital Programme.
AC 01/12/17
13 Provide paper on impact of pensions issue for the entity on commencement. EH 08/12/17
14 Provide business case to support request for letter of comfort regarding
funding from DOH and HSE to support CAAC approval for recruitment. EH 24/11/17
15 Follow up on potential for Christmas communications campaign to generate
early momentum for new children’s hospital recruitment. EH / RMA 01/12/17
16 Follow up meeting in relation to EHR before CHP&P Board meeting. JCA / MOC 08/12/17
17 Prepare update paper on MES progress.* GD 08/12/17
18 Set out user requirements for MES.* EH / JP 08/12/17
19 Reconvene project board for MES as soon as possible. GD 22/12/17
20 Follow up on lessons learned from NAS relating to MES.* RMU 17/01/18
21 Follow up meeting on annual capital programme funding for 2018. JCA / JP 22/12/17
22 Follow up with Phil Welsh for insights on union engagement. RMA 22/12/17
23 Develop overarching critical path and brief JGC. EH / JP 08/12/17
* Please submit relevant pre-reading materials to SO’B by Tuesday, 17
th January 2018.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 1 of 5 [
Meeting Children’s Hospital Programme & Project Steering Group Meeting #5
Date 15:00-17:00, 25th January 2018
Location Boardroom, Children’s Hospital Group, Herberton, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
John G. Connaghan (JGC), Deputy Director General - Chief Operations Officer, HSE
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, DOH
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Eilísh Hardiman (EH) Group CEO, CHG
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
John Pollock (JP) Project Director, NPHDB
Liam Woods (LW) National Director of Acute Hospitals, HSE
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Paul de Freine (PD) Chief Architectural Adviser, HBS, HSE
Roisin Mulqueen (RM), Project Manager, Acute Hospitals, HSE
Noreen Noonan (NN), ICT Programme Manager, OoCIO, HSE
Frank O’Leary, Assistant National Director, Human Resources, HSE
Joe Ryan (JR) Programme Director Value Improvement Programme & GDPR, HSE
Fran Thompson (FT) Programme Director for Strategic e-Health Programme, HSE*
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group, HSE
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS) / Interim CIO, HSE
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Colm Desmond (CD) Director of Finance, DOH
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Stephen Mulvany (SM) Chief Financial Officer, HSE
Key Discussion Points
1. Minutes
JGC requested final feedback on minutes from previous sessions to be submitted by email to SO’B.
2. Actions
JGC raised Action 14 from Steering Group #4. TC and FD confirmed letter of comfort regarding funding to
support CAAC approval for recruitment is pending Ministerial sign-off and expected shortly without issue.
JGC raised Action 22 from Steering Group #4. EH confirmed this is ongoing. JGC proposed action closed.
SO’B confirmed all other actions are on track or being discussed during other agenda items.
3. Standing Update on Electronic Healthcare Record (EHR)
FT noted concerns regarding timelines for MedLIS and NIMIS.
FT noted emerging challenge with Tallaght Data Centre relocation; Tallaght Hospital concerned speed of
data restore function is insufficient. FT provided assurances this should not impact timelines.
JP requested OoCIO update timeline for Tallaght Data Centre relocation completion to June 2018. Action
FT noted minor delay in Definitive Business Case for Acute EHR, noting it should not impact timelines.
MO’C agreed to proceed to engage DPER. FT to reissue EHR revenue forecasts ahead of this. Action
EH queried if some Acute EHR approval steps can be done in parallel. MO’C agreed to raise with DPER.
FT presented document describing risks associated with EHR, highlighting lack of slack in timeline.
FT described significant risk of delay due to legal challenge once a preferred vendor is appointed.
FT confirmed an internal audit of the procurement process will be undertaken in anticipation of this.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 2 of 5 [
JGC requested visibility of how the audit will be done and updates at key points. Action
FT highlighted risk of delay due to negotiation process, based on experience with large vendors.
FT escalated need for EHR programme staffing; €757k requirement (50% clinical / 50% technical staff).
TC agreed to convene meeting with relevant stakeholders to discuss in detail and agree solution. Action
FT explained revenue costs of EHR were included in strategic business case for EHR but not funded.
FT noted DPER may seek assurances from DOH / HSE that revenue side of EHR is addressed.
JGC noted 3 aspects of revenue costs: people costs, ongoing running costs and double-running costs.
EH agreed to map combined revenue costs against available resources to identify gaps. Action
JGC noted there is some probability that the Acute EHR system maywill probably not be introduced ready
for introduction sufficiently in advance ofbefore the new children’s hospital building.
EH agreed to refresh contingency and backstop plans and bring summary view to Steering Group. Action
MO’C agreed to follow up on formation of DPER peer review panel for EHR approval process. Action
4. Standing Update on Equipping / Healthcare Technology
TC confirmed CD contacted NDFA. Agreed CD to provide clear timescale to confirm NDFA role. Action
JP presented paper on user requirements for MES, Competitive Dialogue and linkage with PPP.
JP presented paper summarising work completed to develop business case for Equipping / Healthcare
Technology.
JP noted NDFA is needed to work on risk transfer with NPH for the Business Case process.
Agreed need for further meeting with DOH on MES. Action
5. Standing Update on Capital Funding
JP noted backstop plan no.1 was rejected by all stakeholders and presented backstop plan no.2.
JP noted €20m additional funding will be sought from DOH for cost of additional fire sprinklers.
PD queried €2m saving from deferred procurement for ICU beds; HBS understanding was that original
budget did not allow equipment for these ICU beds, which will not be operational until further into future.
EH confirmed they were in original budget and decision will not impact number of ICU beds on opening.
PD raised concern that capital saving from MES is double counting. TC confirmed this is no longer an
option.
JP noted there will be a review with CHG to maximise how to drive value from existing assets.
EH confirmed this will be in conjunction with HBS Estates. See Action 29/3 from CHP&P Board.
JGC queried process for the €47m capital funding from commercial sources for the basement carpark.
JP confirmed, as set out in the Business Case, this requires HSE to cashflow the basement construction,
until NPH can raise commercial capital funding from carpark operators/funders on opening of the hospital.
All parties noted this is agreed in principle. Agreed to formalise with written agreement. Action
LW noted potential issue if timing spanned year end. PD added same concern for philanthropic funding.
LW clarified any discrepancy (surplus or shortfall) between the upfront capital funding of €47m provided
by the HSE and the money raised in the market will be borne by HSE, so there is a financial risk involved.
JP noted €13m shortfall in NPH capital funding for 2018. JGC noted same and asked for regular updates.
JGC queried process for capital funding from DES and HEA. FD confirmed meeting scheduled with DES
to discuss and update will be provided at next Steering Group. Action
PD raised emerging challenge around Ronald McDonald House Charity (RMHC) Family Accommodation.
RMHC initially planned to provide all capital funding. RMHC now propose to fund €8m upfront and ask
HSE to provide €7-7.5m lending for capital expenditure. PD explained it could take many years for this to
be repaid by RMHC.
Agreed SM and JCA to meet to agree HSE position on this unplanned capital requirement. Action
Agreed TC and CD to meet to clarify if using funding from HSE Capital Plan for this purpose would breach
the capital spending maximum agreed with DPER. Action
Agreed PD to prepare briefing paper on the issue prior to both meetings taking place. Action
Children’s Hospital Programme & Project Steering Group
V1.0 Page 3 of 5 [
6. Standing Update on Capital Project
JP noted that key items have already been discussed.
7. Standing Update on Integration
EH noted legislation timeline updated by DOH and released to CHP.
EH noted CHP&P Board agreed process for naming entity.
TC noted this process needs Ministerial approval, but no issues are anticipated.
8. Standing Update on Legislation
TC noted HSE observations received and responses issued.
JGC noted some further HSE observations due. Agreed strict deadline of end 26th January.
TC noted aiming to circulate next week.
9. Update on National Paediatric Model of Care
Discussion deferred. JGC noted focused session taking place on 29th January with key stakeholders.
10. Update on ICT Staffing
Discussion deferred. EH confirmed work is ongoing and update will be provided at next session.
11. Update on External Governance Assessment
JR confirmed desktop review and most stakeholder interviews are completed.
JR confirmed the assessment will be completed and presented at February / March Steering Group.
EH raises concern regarding ICT / EHR governance. JR noted this will be considered as part of separate
work with SO’B to look at key interdependencies.
12. Standing Update on HR
FO’L confirmed work has concluded on the revised Change Model.
FO’L confirmed the framework for recruitment and retention has gone to HSE Leadership for review.
13. AOB
EH noted lessons learned report from Australia site visits. Agreed as agenda item for next meeting. Action
Action Log
Arising from CHP&P Steering Group
Ref Action Owner Due
Carry Forward
1 Prepare overview of PM processes and governance for EHR. JCA 15/02/18
2 Provide update on change model at next Steering Group.* RMA 15/02/18
3 Confirm resources secured for MoC implementation plan. AC 09/02/18
4 Confirm letter received from DOH to support CAAC approval for recruitment. EH 09/02/18
New Actions
5 Update timeline for Tallaght Data Centre relocation to reflect June end date. FT 09/02/18
6 Proceed with further engagement with DPER regarding Acute EHR. FT to reissue
EHR revenue forecasts to provide a basis for these discussions. MO’C 15/02/18
7 Provide paper for next Steering Group describing how the internal procurement
process audit for EHR will be done.* FT 15/02/18
8
Convene meeting with stakeholders (DOH; HSE - OoCIO, Acutes; CHP - ICT,
Chief Clinical Information Officer) to discuss resource requirements for EHR
programme and agree solution.
TC 15/02/18
9 Provide paper for next Steering Group mapping elements of Acute EHR revenue
costs year-on-year against available resources to identify gaps.* EH 15/02/18
Children’s Hospital Programme & Project Steering Group
V1.0 Page 4 of 5 [
Ref Action Owner Due
10 Present refreshed contingency plan and backstop plan for Acute EHR at next
Steering Group.* EH 15/02/18
11 Provide progress update on formation of DPER peer review panels. MO’C 15/02/18
12 Provide definitive timescale to confirm NDFA role.* CD 15/02/18
13 Convene meeting between DOH & HSE on Equipping / Healthcare Technology. CD 09/02/18
14 Prepare written agreement between HSE (HBS Estates and Finance) and NPH
building board regarding arrangements for cashflow for construction of carpark.*
JP /
JCA 15/02/18
15 Provide update at next Steering Group regarding process for capital funding from
DES and HEA. FD 26/02/18
16 Prepare briefing paper on emerging issue regarding funding for Ronald McDonald
Family Accommodation, to inform meetings on same. PD 09/02/18
17 Agree HSE position on Ronald McDonald Family Accommodation proposal. SM /
JCA 15/02/18
18
Provide clarification if the use of funding from the HSE Capital Plan to cover
unforeseen capital expenditure for Ronald McDonald Family Accommodation
would breach the agreed DPER capital spending maximum.
TC /
CD 23/02/18
19 Present lessons learned from Australia site visits at next Steering Group. EH 26/02/18
*Pre-reading materials for next Steering Group meeting (26
th February) due before 12pm on 16
th February.
Arising from CHP&P Board
Ref Action Owner Due
Action
10/2
EH to look at the feasibility of both establishing the new entity on a statutory basis and transferring to the new entity the three hospitals at the same time and establishing the new entity on a statutory basis in advance of the transfer to the new entity of the three hospitals and submit to DoH.
EH March
Action 11/2
EH to circulate a formal business case for a Director of Philanthropy to CHP&P Steering Group for consideration by the Steering Group prior to submission by JC to DoH.
EH March
Action 15/2
JC to submit a full brief for Board meeting No 4. (capital shortfall) JC March
Action 18/2
JC to report to the Board on progress made on the proposed governance structures at Board meeting No 4. (Model of Care)
JC March
Action 23/3
Subject to approval by Minister, EH and Secretariat to progress arrangements for the naming process
EH / SK TBC
Action 24/3
Legislation update - Secretariat to address any outstanding issues with the CHG and with the OPC.
SK ASAP
Action 25/3
DoH to bring clarity to the role of the NDFA to enable JP to conclude the MES business case within required timeframe.
CD ASAP
Action 27/3
NPHDB Board to note that the €20m in contingency funds is to be assigned to known cost increases as identified by the CHP&P Board (ref action 13/2) (JP).
JP ASAP
Action 28/3
JP to submit business case to DoH for €20m for sprinklers as an out of scope additional project cost (Ref action 12/2). Due prior to CHP&P Board meeting on 14
th March so it can be considered.
JP March
Action 29/3
Alternative funding contribution options to be explored further including philanthropy, options on securing existing funds of the three children’s hospitals’ Foundations for this project; initiate/continue review of existing children’s hospitals’ assets and how to drive best value from them, including a value and disposal strategy for OLCHC and possible use of Temple Street (EH and HSE) - to be brought to the CHP&P Steering Group. Due prior to CHP&P Board meeting on 14
th March so it can be considered.
EH / JCA March
Children’s Hospital Programme & Project Steering Group
V1.0 Page 5 of 5 [
Children’s Hospital Programme & Project Steering Group
V1.0 Page 1 of 4 [
Meeting Children’s Hospital Programme & Project Steering Group Meeting #6
Date 15:30-17:30, 26th February 2018
Location Green Room, Dr. Steevens’ Hospital, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, DOH
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Eilísh Hardiman (EH) Group CEO, CHG
Stephen Mulvany (SM) Chief Financial Officer, HSE
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
John Pollock (JP) Project Director, NPHDB
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Jim Curran (JCU) Head of Estates, HBS, HSE
Colm Desmond (CD) Director of Finance, DOH
Mags Giffney (MG) Integrated PMO for CHP&P Steering Group (CHP&P SG), HSE
Noreen Noonan (NN), ICT Programme Manager, OoCIO, HSE
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group (CHP&P SG), HSE
Frank O’Leary, Assistant National Director, Human Resources, HSE
Joe Ryan (JR) Programme Director Value Improvement Programme & GDPR, HSE
Fran Thompson (FT) Programme Director for Strategic e-Health Programme, HSE
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS) / Interim CIO, HSE
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Liam Woods (LW) National Director of Acute Hospitals, HSE
Key Discussion Points
1. Minutes & Actions
• JGC noted no feedback on minutes from previous meetings. JGC confirmed these are approved.
• JGC asked that feedback on minutes is submitted promptly by email following meeting.
2. Lessons Learned Review of Australia Site Visits
• EH presented lessons learned from CHG team’s Australian Hospital Tour – see pre-reading presentation.
• EH noted Lady Cilento is closest comparison; it will have an integrated hospital and community network.
• EH noted previous CEO of Lady Cilento is on CHG Board, supporting strong knowledge exchange.
• EH concluded key risks are interdependency on ICT and the complex change management, integration
and people issues.
• MO’C queried NPH construction costs and how they compare to international best practice.
• JP and EH confirm cost per square metre is more accurate metric than price per bed and is relatively low.
• TC confirms benchmarking of construction costs was reviewed in detail as part of DBC approval process.
3. Standing Update on EHR
• TC confirmed €760k ICT revenue funding shortfall for 2018 was resolved at pre-meeting. TC confirmed
this was done without placing additional strain on national HSE services, in response to query by SM.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 2 of 4 [
• Discussed delay in Acute EHR business case:
- FT confirmed 3-4 week delay due to issues with quality of work by Deloitte.
- JGC agreed to escalate with letter of concern to Deloitte. FT to draft. Action
- EH requested updated week-by-week plan to September 2018, reflecting new timeline. Action
- MO’C noted feedback from DPER that approvals process (presented by FT in Steering Group #5) does
not need to be strictly sequential, as previously understood; this could mitigate some delay.
• Discussed meeting between DPER, DoH and OoCIO on 15th February 2018:
- FT and MO’C noted overall the meeting was positive.
- FT noted DPER gave early indication of risks, some of which go beyond ICT risk.
- EH noted some risks that arose relate specifically to the integration and operation of the new children’s
hospital, as well as, Acute EHR rollout, and as such requested a CHG or Acute Hospitals representative is
part of this team going forward.
- MO’C noted work is underway with Government CIO Barry Lowry to map out approval process in detail.
• Discussed governance of National EHR programme, which includes Acute EHR programme: - FT and MO’C noted DPER emphasised importance of EHR governance arrangements.
- FT noted the current TOR for the EHR Steering Group was issued to SO’B last week.
- FT noted the EHR governance is currently being revised and strengthened, following meeting with DPER.
For discussion at next CHP&P Steering Group meeting. Action
- JGC noted EHR programme has transitioned to new phase and a review of governance is timely.
- EH agreed to feed into this process for CHG as business owner of first roll out of Acute EHR project.
- TC requested update prior to meeting with DPER on draft Children’s Health Ireland Bill on 1st March.
• EH presented on ICT resources for the CHP including existing, ICT programme and future resources. –
see pre-reading presentation. SM enquired if comparability undertaken of future resources against
requirements for a Digital Hospital. HSE reviewed this with Gartner (IT Advisors) as part of the Definitive
Business Case review.
-
- EH confirmed the 50:50 internal-external resource mix as set out in DBC is being achieved.
- MO’C asked EH for further detail on the conceptual transition plan (outlined on pg. 5) and further detail on
balance of internal-external resources in terms of cost. Specific meeting on this to be arranged. Action
- EH noted challenge attracting qualified ICT resources – public service not competitive with IT market.
• Discussed Acute EHR contingency and backstop plans.
- EH agreed to update to contingency plan to reflect current timelines. Action
- JGC requested combined paper on contingency and backstop plans.
- EH suggested backstop plan no longer viable as project has advanced to point where it is no longer valid.
- Agreed to detailed discussion at next CHP&P Steering Group meeting. Action
4. Standing Update on Equipping / Healthcare Technology
• CD confirmed NDFA was engaged in early February 2018; initial response received last week.
• CD agreed to convene Equipment Procurement Strategy Board next week to discuss further. Action
• EH noted work on risk evaluation and transfer progressing and would benefit from NDFA input.
• CD noted contingency plan is to procure an alternative advisor, in response to query by JGC.
• JP explained NDFA are the preferred advisor as DPER is familiar with and trust their approach and an
alternative advisor may cause delays due to duration of procurement and because DPER would be
unfamiliar with their approach; there will also be a cost impact of external procurement.
• JP confirmed draft MES business case for imaging will be issued to progress discussion. Action
• JGC suggested query into DPER may help. SM suggested also asking DPER next preferred advisor.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 3 of 4 [
5. Standing Update on Capital Funding
• JP outlined Sprinkler Funding Business Case – see pre-reading paper. FD noted comments for follow up.
• SM queried progress on value engineering target. JP confirmed target is €62m and is currently on track.
• JP confirmed capital budget overrun currently projected at €35m (after €20m additional funding for
sprinklers, €6m additional savings relating to equipment, and before use of €20m contingency reserve).
• EH noted discussions about alternative funding sources underway. JGC requested paper by April, to
resolve before Memo to Government in May 2018. JGC requested update for noting for CHP&P Board
meeting on 14th March. Action
• Discussed funding arrangements for car park:
- JCU explained HSE will cashflow €47m for its construction, with money to be returned for 2022.
- JCU confirmed €47m is allowed for in the HSE capital plan, as part of annual allocation to NPHDB.
- JCU explained funding for repayment will be raised in market by leasing rights to cark park yields.
- JCU confirmed any gap between €47m and what is raised in market is borne by the HSE.
- SM queried if €47m is allocated to general spending or new children’s hospital once repaid; JCU
responded that this is not specified.
- SM noted payment of €47m in a single instalment will be a challenging term in a commercial agreement.
- JGC queried the likelihood of having a commercial agreement signed prior to 2022 and noted risk.
- JCU agreed to respond to letter from JP on this matter, being explicit about the nature of the agreement,
who bears the risk, and how the €47m is provided for in the HSE capital plan. Action
- EH agreed to circulate existing briefing paper on Q&A relating to car park funding arrangements. Action
• Discussed other funding arrangements:
- JCU noted similar arrangements exist in relation to DES / HEA and philanthropic funding.
- EH noted €20m philanthropic funding allocated to the build.
- JCU noted €5m philanthropic funding needs to materialise by 2021 to cover capital spending.
- SM queried if there are parts of the build associated with the €20m philanthropic funding that can be
deferred or descoped if the funding does not materialise; JP agreed to revert. Action
- TC noted need to bottom out appropriate arrangements prior to Memo to Government in May 2018.
• Discussed funding for Ronald McDonald House Charity (RMHC) Family Accommodation:
- JCU confirmed HSE currently own site and would also own asset from opening, and lease to RMHC.
- JCU confirmed the gap is approx. €7m and there is no allocation for this in the HSE capital plan.
- JCU noted no contract currently in place, but construction would ideally take place between 2020-2022.
- SM suggested possibility other organisations could provide funding, due to nature of the project.
6. Standing Update on Capital Project
• JP shared drone footage of progress on construction sites. Advancement of the capital build welcomed.
7. Standing Update on National Paediatric Model of Care
• AC noted revised PID to go to HSE Leadership by end of this week. Action
• AC noted decision on project resources due by end this week. Action
• EH noted the elements of MoC critical for new children’s hospital (i.e. Phase 1) are now agreed. Action
• TC noted importance of clarity around MoC implementation plan for Memo to Government in May 2018.
• JGC proposed, accordingly, that the MoC implementation plan needs to be complete by end April 2018.
• JGC noted the MoC implementation plan will go to HSE Leadership for approval; if timing does not permit
prior discussion at a CHP&P Steering Group meeting, it will be circulated to members for consideration.
• SO’B queried if capital and equipment requirements need to be considered for Memo to Government.
• AC noted these are out of scope of the MoC implementation plan, which is restricted to resources.
• TC and FD agreed to consider offline in conjunction with DOH Capital Unit in context of national paediatric
capital requirements to facilitate MOC implementation. as part of
• JGC requested weekly progress update on MoC is circulated to CHP&P Steering Group. Action
Children’s Hospital Programme & Project Steering Group
V1.0 Page 4 of 4 [
8. Standing Update on Integration
• TC confirmed any outstanding issues with OPC regarding legislation expected to be resolved this week.
• EH noted any further delay will impact on Connolly OPD & UCC opening date.
• EH confirmed urgent posts approved by CAAC and acknowledged work from colleagues in this regard.
9. Update on ICT Staffing
• Discussed under 2. Standing Update on EHR.
10. Standing Update on HR
• JGC agreed discussion deferred until next CHP&P Steering Group meeting.
11. Update on Governance Review
• JGC noted as priority item for discussion at next CHP&P Steering Group meeting.
12. AOB
• JGC asked for feedback on frequency of CHP&P Steering Group meetings.
• General agreement monthly CHP&P Steering Group meetings are appropriately frequent.
• General agreement that more frequent and targeted sub-meetings would be beneficial.
• JGC agreed with this proposal, provided key decisions and actions arising are communicated to and
managed through the CHP&P Steering Group.
Children’s Hospital Programme & Project Steering Group
V4.0 Page 1 of 5 [
Meeting Children’s Hospital Programme & Project Steering Group Meeting #7
Date 15:30-17:30, 26th March 2018
Location Boardroom, Children’s Hospital Group, Herberton, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE – dial-in
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, Department of Health (DOH)
Colm Desmond (CD) Director of Finance, DOH
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Eilísh Hardiman (EH) Group CEO, Children’s Hospital Group (CHG)
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
John Pollock (JP) Project Director, National Paediatric Hospital (NPH) Development Board
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Jim Curran (JCU) Head of Estates, HBS, HSE
Paul de Freine (PD) Chief Architectural Adviser, HBS, HSE
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group (CHP&P SG), HSE
Joe Ryan (JR) Programme Director Value Improvement Programme & GDPR, HSE
Fran Thompson (FT) Programme Director for Strategic e-Health Programme, HSE
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS) / Interim CIO, HSE
Liam Woods (LW) National Director of Acute Hospitals, HSE
Stephen Mulvany (SM) Chief Financial Officer, HSE
Key Discussion Points
1. Minutes & Actions
JGC noted feedback on minutes received from FD and confirmed approved.
2. Update on Governance Review
JGC noted purpose was to seek best practice advice regarding how we operate as a forum.
JGC noted governance of the CHP&P Board, CHG Board and NPH Board were out of scope.
JR presented overview; general agreement on value of exercise and key recommendations.
Discussed recommendation for interim mechanisms for communication between CHP&P Steering Group
and current hospital boards. EH and TC noted engagement is currently between CHG Board and hospital
executives, and this is effective. Agreed JR to update language in final version of governance review.
Discussed sensitivity of information shared at CHP&P Steering Group, and the importance of document
confidentiality and control. Acknowledged there has been no issue to date regarding information security,
but agreed it is an important risk. Agreed JR to reflect in final version of governance review.
Discussed need for additional members of CHP&P Steering Group. Agreed proposed CHO representative
should have broader remit, i.e. community, social inclusion and disability. EH and AC proposed Anne
O’Connor, National Director for Community Operations, HSE as the appropriate representative.
TC noted governance arrangements of CHP&P Steering Group were approved by government and the
Secretary General should be appraised of proposed changes to membership. JGC acknowledged same,
noting approval for additional membership will be sought from CHP&P Board. Action
Discussed recommendation regarding memoranda of understanding and clarified these are intended
between the CHP and divisions of the HSE where critical dependencies exist. JR noted this practice has
worked well previously for Tusla. Agreed JR to clarify in final version of governance review.
Agreed JR to prepare final version, which JGC will present to CHP&P Board for information. Action
Children’s Hospital Programme & Project Steering Group
V4.0 Page 2 of 5 [
Agreed JR and SO’B to proceed with implementing selected straightforward and high priority
recommendations, as identified by JGC, drawing on Steering Group members for input as required.
Agreed governance review will be an agenda item in CHP&P Steering Group meeting in May 2018, to
track progress of implementation of recommendations.
3. Standing Update on EHR
National EHR Governance
FT presented updated EHR governance, which is due for review by HSE Leadership on 29th March 2018.
All relevant stakeholders present agreed general satisfaction with strengthened EHR governance.
MO’C noted the proposed governance was shared with DPER in draft for information.
FT agreed to remove term “co-chair” in draft presented at HSE Leadership meeting on 29th March 2018.
EH asked for work to be undertaken by the CHP to clarify how issues arising from the CHP are escalated
to EHR Steering Group and CHP&P Steering Group, developing a RACI matrix for different scenarios. JR
agreed to support. Action
National Acute EHR Approval
FT confirmed final National Acute EHR business case is complete and approved by EHR Steering Group,
subject to conditions raised by CHG members.
MO’C confirmed he will review final version and share with DPER.
FT noted work has started developing statement of requirements (SOR) and procurement documentation.
FT noted progress in relation to the formation of the DPER peer review panel has been limited.
Medical Devices Integration
FT raised issue around medical devices integration. This was never part of the National EHR proposal but
is required for a HIMSS level 6 hospital. The cost is not included in the National Acute EHR business case
(inclusion being sought by CHG) or the CHG ICT business case.
FT explained this will create an additional cost, but it can be minimised if procurement of new medical
devices stipulates they are IHE compliant. FT noted, however, potential complexity and cost involved if
legacy medical devices are not IHE compliant.
JGC noted any additional cost arising from this challenge was not included in the definitive business case
approved by DPER, and exceeding the prescribed budget is problematic. JGC asked for clarity about the
financial risk associated with this challenge and a resolution prior to memo to government.
AC agreed to consider this issue in more detail at the next EHR Steering Group meeting on 19th April
2018. AC to decide what work is required prior to this meeting to enable a successful resolution. Action
CHG Acute EHR Contingency Plan
EH agreed to update CHG Acute EHR contingency plan. Action
4. Standing Update on National Paediatric Model of Care (MoC)
AC agreed to circulate 1-page update submitted to CHP&P Board to Steering Group members. Action
JGC confirmed work will now focus on elements of the MoC critical to the new children’s hospital.
HB confirmed Dean Sullivan, Deputy Director General Strategy and Planning, HSE, is now leading the
MoC governance and has asked her to become involved.
HB noted need to clarify interdependencies with Women and Infants Programme.
HB noted MoC work will consider what needs to be implemented in short, medium and long-term.
EH confirmed site visits are scheduled with key regional paediatric units to identify local requirements for
the implementation of the model of care.
TC noted the Memo to Government will provide an opportunity to update Government on the progress on
MOC implementation and associated costings AC agreed and confirmed on track for costings to be
complete by end April 2018 to align with this timeline.
TC asked for clarification about how capital implications of implementing the MoC in the regional and local
paediatric services will be considered.
Children’s Hospital Programme & Project Steering Group
V4.0 Page 3 of 5 [
AC confirmed they are out of scope of the MoC costings, except for transport / retrieval.
PDF asked to what extent are capital requirements already captured by individual capital plans.
HB provided anecdotal evidence, noting different locations have considered them to varying degrees.
Agreed need to demonstrate that hospital capital plans are aligned to the capital requirements to facilitate
the implementation of those elements of the MoC critical to the new children’s hospital, so that this can be
reflected in the memo to government. Action
5. Standing Update on Integration
EH confirmed implementation of Clinical Directorate structure is being progressed. EH confirmed cross
hospital CDs will be executively accountable for quality care, access, people and finances. EH confirmed
CDs will report to her directly.
EH provided update on central referrals pilot – on track for general paediatrics to start using single PAS by
October 2018, with an office in Temple Street to redistribute central referrals. There is a data governance
issue because the three locations will not be part of a single entity by this point. JR agreed to follow up
with EH to provide lessons learned from similar example. Action
EH noted IR issue arising as Tallaght payroll moves to national shared services. EH explained Fórsa are
trying to engage with CHG on this as a local issue, but it is part of a national rollout, so CHG is liaising
with RM and directing queries to national HR.
EH raised challenge around MedLIS – the rollout has been re-planned and CHG sites are no longer in
Phase 1. EH sought clarity about when Phase 2 will be scheduled. Action
6. Standing Update on Pre-CAR and Action Plan
EH noted the Pre-CAR report will be completed by end March 2018 and a detailed action plan will follow
in April 2018, outlining steps to address issues or risks identified, accountable owners, and deadlines.
EH confirmed both the Pre-CAR report and detailed action plan will be submitted to CHP&P Board.
EH asked that Pre-CAR and progress against the action plan remains a standing item at this forum, in line
with request from CHP&P Board.
7. Standing Update on Capital Funding
Sprinklers Funding Business Case:
JP noted TC and FD are satisfied with business case for sprinklers funding and will proceed to seek
funding approval.
Capital Backstop Plan:
JP presented capital backstop plan no.3. JP explained the current estimated budget shortfall is €35m -
€20m to be offset by NPH contingency, on instruction from CHP&P Board, against advice from JP; €9m to
be offset by once-off funds raised from dissolution of existing hospital foundations; €6m to be offset by
philanthropic funding.
JP explained the intention, as discussed at CHP&P Board, in assigning the NPH contingency to known
costs at such an early stage in the capital project is for it to be re-filled as other funding sources are
received. JP noted this involves significant risk as some funding sources may fall short of expectations
and the holder of this risk would need to be confirmed.
JGC flagged considerable risk associated with relying on philanthropic funding, particularly when it is due
towards the late stages of the capital project.
EH confirmed philanthropy business case is on track for completion in April. It will cover governance and
management arrangements for philanthropic funding and will estimate how much will be raised and by
when.
TC emphasised need for the philanthropy business case to be comprehensive, to support the memo to
government.
Phasing of Capital Allocation:
JP referred to letter and table submitted by Jim Curran, outlining the timing of capital funding.
Children’s Hospital Programme & Project Steering Group
V4.0 Page 4 of 5 [
JP flagged this does not align with NPH cashflow as set out in the Business Case and will not align with
current projected cashflow being prepared by NPH.
JP noted potential shortfalls of €60m in 2019 and €50m in 2020.
JGC asked if the expected gaps could change. JP confirmed they may decrease or potentially increase,
depending on GMP agreement with the contractors.
JP agreed to prepare a briefing paper on the current anticipated cashflow gap by year. PDF requested
involvement in this. JP agreed to review the paper with NPH Board next week and share with Jim Curran
and relevant Steering Group members following this. CD and TC agreed to meet to review the paper on
receipt. Action
Car Park Funding:
JP noted NPH and CHG just completed a 1-week survey in Crumlin hospital of visitor and parent car
parking demand; this will be used to further develop and validate the revenue model.
JP noted the Minister for Health ordered a national review of hospital car parking charges on 16th March,
to be carried out by John Hennessy, National Director Acute Strategy & Planning, HSE.
JGC noted he has requested SM review the car park business case but will put this on hold until after
John Hennessy has completed the review. Action
EH to brief John Hennessy on the issue of car parking charges in relation to the new children’s hospital
and facilitate an introduction with JP. Action
Ronald McDonald House Charity (RMHC) Funding:
PDF confirmed the draft legal agreements relating to RMHC Family Accommodation will be issued and
discussed with stakeholders in the near future.
SO’B queried if an explicit decision has been made about whether the HSE will provide funding to RMHC.
Note: no decision recorded at CHP&P Steering Group – see minutes from 26th
February 2018.
JGC queried who is intended to sign the legal agreements. PDF confirms HSE and RMHC.
JP queried who holds the risk of a shortfall in capital funding for the project. JGC recommends SM’s paper
on financial risk will provide clarity. Note: SM’s paper identifies NPH as the ultimate risk owner.
Agreed SM to finalise paper on financial risk associated with the new children’s hospital and issue to CD
for consideration. Action
Education Funding:
FD confirmed work is underway for a decision ahead of the memo to government.
FD confirmed the QS in DoE / HEA understands the rationale for the pro rata costs as presented by NPH.
FD explained DoH will seek funding from DoE / HEA to cover actual pro rata costs, while noting the
definitive business case for the new children’s hospital only assumed receipt of a portion of these costs.
Guaranteed Maximum Price (GMP) Approval
JP confirmed end June 2018 as current expected timeline for GMP agreement with contractor (original
target May 2018).
JP noted GMP agreements with main contractor are currently unsatisfactory and this issue has been
escalated.
TC noted the timeline for the memo to government is dependent on readiness of GMP agreement. If GMP
approval slips further, there is a risk the memo to government could be delayed until after government
summer recess, which would likely have implications for the overall new children’s hospital timelines.
8. Standing Update on Capital Project
JP confirmed construction is progressing well across all 3 sites.
9. Standing Update on Equipping / Healthcare Technology
CD confirmed work is continuing to secure a meeting with NDFA in early April 2018.
CD noted DPER have been consulted informally and indicated support for NDFA involvement.
Children’s Hospital Programme & Project Steering Group
V4.0 Page 5 of 5 [
JGC noted deadline for approval of the MES imaging business case is April 2018 and asked if there is an
alternative option if NDFA engagement is not viable. CD confirmed that the Equipping Board has not
considered who else it would approach.
JP noted if the approval of the MES imaging business case goes beyond a certain point, there will no
longer be sufficient time for MES procurement, and a decision will need to be made to revert to traditional
equipping. JGC asked for clarity about when this point is. Action
10. Standing Update on HR
RM noted an increase in IR activity is expected, and national HR and CHG will need to work closely.
11. AOB
JGC emphasised the need for full attendance by CHP&P Steering Group members, given the importance
and scale of the project, and the stage at which it is. JGC called for all CHP&P Steering Group members
to prioritise attendance of CHP&P Steering Group meetings.
JGC suggested, given the scale and important of the project, someone should be assigned to document it
as a case study. EH and RM noted ideas already exploring this option.
JGC noted need for an integrated critical path setting out key activities, dependencies and timelines.
Agreed JR and SO’B to develop this with input from relevant stakeholders for CHP&P Steering Group
meeting in May. Action
Children’s Hospital Programme & Project Steering Group
V1.0 Page 1 of 5 [
Meeting Children’s Hospital Programme & Project Steering Group Meeting #8
Date 15:30-17:30, 23rd
April 2018
Location HSE, PHSI Programme Room, Parkgate Street, Dublin 8
Chair John G. Connaghan (JGC) Deputy Director General – Chief Operations Officer, HSE
Attendees
Steering Group Members
John G. Connaghan (JGC), Deputy Director General - Chief Operations Officer, HSE
Tracey Conroy (TCO) Assistant Secretary Acute Hospitals Policy, DOH
Martin Curley, (MC) Chief Information Officer, HSE
Colm Desmond (CD) Director of Finance, DOH
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Eilísh Hardiman (EH) Group CEO, CHG
Stephen Mulvany (SM) Chief Financial Officer, HSE
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
John Pollock (JP) Project Director, NPHDB
Liam Woods (LW) National Director of Acute Hospitals, HSE
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Tim Carey (TCA) Assistant National Director, Clinical Strategy & Programmes, HSE
Margaret Giffney (MG) Integrated PMO for CHP&P Steering Group, HSE
Frank O’Leary (FO’L) Assistant National Director, Human Resources, HSE
Joe Ryan (JR) Programme Director Value Improvement Programme & GDPR, HSE
Fran Thompson (FT) Programme Director for Strategic e-Health Programme, HSE
Sadhbh O’Brien (SO’B) Integrated PMO for CHP&P Steering Group, HSE
John Smith (JS) Assistant National Director, Health Business Services (HBS), HSE
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS), HSE
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Key Discussion Points
1. Minutes and Matters Arising
JGC confirmed minutes from CHP&P Steering Group in March approved.
Discussed CHP&P Steering Group governance review, presented at CHP&P Steering Group in March:
JR noted the scope of the governance review was limited to the CHP&P Steering Group, not the CHG or
NPH Boards.
JR circulated key recommendations for immediate action. JGC asked JR to assign owners to key
recommendations and proceed to implement. Action
EH noted it was previously agreed the additional CHO representative would have a wider remit of national
community services – agreed JR to update in CHP&P governance review accordingly.
Agreed additional Health & Wellbeing representative is not required immediately – to be explored later.
TCO flagged concern about attendance of CHP&P Steering Group members.
JGC noted he will raise any proposed changes to CHP&P Steering Group membership with Jim Breslin,
Secretary General of the DoH, in his capacity as Chair of the CHP&P Board.
2. Standing update on Integration
EH presented the integration paper submitted – progress is proceeding with no exceptions.
EH explained the integration paper submitted is organised by the releases that the Children’s Hospital
Programme PMO is using to structure its work: Commencement, Central Referrals Pilot, Connolly
Outpatient and Urgent Care Centre (OPDUCC), Tallaght OPDUCC, New Children’s Hospital.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 2 of 5 [
EH confirmed the integration paper submitted aligns with the work breakdown structure outlined in the
Children’s Hospital Investment Case (20th February 2017). However, the paper submitted focuses only on
the most immediate and urgent elements of work.
TCO noted circulation of draft Bill to government is imminent. TCO explained discussion about a phased
commencement is underway. TCO confirmed this will be concluded before next CHP&P Steering Group.
JGC asked when the new model of clinical directorship will be in place. EH confirmed next year and noted
the single entity would need to be established to enable it. EH noted plans allow for a shadow period.
EH described risks outlined in Children’s Hospital Programme report. In particular, EH flagged that getting
hospital resources backfilled and released by hospitals is taking longer than planned. JGC asked about
mitigation strategies. EH noted possibility of exploring external resources for a limited period of time.
EH described issues outlined in Children’s Hospital Programme report. In particular, EH flagged challenge
of getting hospitals to prioritise ICT requirements for Connolly OPDUCC over existing individual hospital
ICT plans – CHG and OoCIO are actively engaging with hospitals in this regard.
3. Standing Update on Pre-CAR
EH confirmed the Pre-CAR report was brought to CHG Board and updated following feedback. EH agreed
to formally issue to selected CHP&P Steering Group members. Action
EH explained the recommendations of the Pre-CAR report are being addressed by a Pre-CAR action
plan, already circulated to selected CHP&P Steering Group members. EH confirmed there are currently
no escalations to the CHP&P Steering Group– all actions are being progressed.
4. Standing Update on HR
FO’L confirmed no HR items for escalation at this point.
EH explained unions have agreed in principle for consultants in new posts in the OPDUCCs to work
outside 8am-8pm and expect to be engaged on remuneration. EH noted this is a national issue so CHG
have escalated to National HR via RM.
EH noted CHG require clarity about remuneration before first consultant contracts are signed in Q4 2018.
LW noted renegotiation of consultant contract, if required, would have universal applicability and would be
considerable work.
EH noted the possibility of ring-fenced resolution for paediatric consultants is being considered.
JGC requested short paper from FO’L on this item describing implications. Action
EH noted she has escalated to RM the need for smoother CAAC process going forward.
EH noted she has escalated to RM the need for engagement with the unions at a national level on the roll-
out of a national Pay and Staff Records system in the CHG.
JS queried if change in commencement date impacts payroll go-live for 200 staff in Tallaght in January
2019. EH confirmed the go-live date stands.
CHG seeking HSE HR engagement & national direction on HSCPs executive leadership arrangement.
5. Standing Update on Capital Funding
Guaranteed Maximum Price (GMP) Approval
JP noted GMP approval by end June is significantly at risk.
JP flagged pricing discrepancies between NPH quantity surveyors and BAM/M&E Contractors.
JP explained that pricing discrepancies that cannot be agreed will go to the agreed independent expert to
adjudicate, which will take time.
JP confirmed that BAM agree that the overall programme completion date is still achievable, provided
some critical path activities in Phase B contract are brought into Phase A contract to continue work on site
without delays.
TCO recognised need to invest time in concluding the process of GMP approval to ensure best value for
money, however raised concern about the potential impact on the overall programme completion date.
TCO asked at what point would slippage in GMP approval impact on the overall completion date. JP
explained this is difficult to assess without an integrated programme being agreed with BAM/M&E
Contractors, but tentatively suggested autumn this year.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 3 of 5 [
JGC asked about the financial risk involved. JP explained it is too early to estimate at this point. JP
agreed to provide clarity about the timeline and financial risk by June. Action
TCO noted the slippage in the GMP approval will delay the memo for Phase B construction decision to
government and suggested the possibility of an interim memo for information to government in summer to
provide an update on overall progress.
Integrated Critical Path
JGC asked for progress update on an integrated critical path for the new children’s hospital 2022.
JR and SO’B confirmed work is ongoing and it will be completed by mid-May, in advance of the next
CHP&P Board meeting.
JR and EH agreed ultimate ownership of the integrated critical path is with the CHG programme director.
Contractor Pay Entitlements
JP explained that the contractor has made a claim following Government enactment of a Sectoral
Employment Order (SEO) to increase construction industry minimum pay rights and entitlements,
following a Labour Court recommendation. JP confirmed NPH has rejected the claim under contract.
Nevertheless, JP explained it is an industry-wide issue and some contractor is likely to take legal action,
the ruling of which will impact NPH. JP explained it needs to be closed as part of wider Government
approach. JP agreed to estimate the financial risk and the likelihood of the risk based on the contract
terms for the next CHP&P Steering Group meeting. Action
Carpark Charges
LW noted John Hennessy, National Director Acute Strategy and Planning, HSE, estimated 6-8 weeks for
the national review of car park charges.
JGC noted the recommendations of the review could impact the viability of the carpark business case.
SM noted the more aggressive the charging model included in the business case, the greater the risk is
that the national review of car park charges will impact its financial viability. JP confirmed the charging
model used in the business case is based on St. James’ Hospital existing parking charges to ensure an
aligned campus approach.
Education Funding
FD confirmed a follow up meeting between the Department of Health, HSE, NPH, Department of
Education and the Higher Education Authority is taking place 2nd
May to discuss the extent and timing of
their capital contribution.
Philanthropic Funding
EH confirmed the paper on philanthropic funding is on track for completion by end April and will be
presented at the next CHP&P Steering Group meeting. EH noted it will need to be reviewed in advance by
the CHG Board and the Hospital Foundation Boards.
Funding Risk
SM presented a paper providing overview of supplementary items associated with the new children’s
hospital and the related financial risks, outlining the size of the risk, the risk manager and the risk owner.
RMHC Family Accommodation
JGC asked for clarification as to whether the proposed HSE funding for the RMHC family accommodation
would be taken from the HSE capital budget. SM confirmed this would be the only option, noting that the
Exchequer capital budget is already significantly under pressure.
CD noted discussion would be required with the Department of Health prior to any decision on the use of
Exchequer capital budget.
CD asked if the HSE will subsidise operational costs. SM confirmed it will not.
JGC noted upfront capital funding is preferable to funding running costs in perpetuity.
JS confirmed the HSE will own the RMHC family accommodation building and already own the land.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 4 of 5 [
Cashflow Analysis
JP described cashflow gaps presented in letter (11th April) responding to Jim Curran (limited circulation).
SM noted efforts to manage cashflow will need to be within the programme; HSE does not have sufficient
cash available.
JGC asked if capital spend could be reprofiled towards later years when surplus cashflow is available. JP
explained this would prolong programme duration, delay programme completion date and increase overall
programme costs.
SM suggested possibility of securing supplementary funding – e.g. €47m for carpark, €20m for sprinklers
– earlier than planned and using to offset anticipated cashflow gaps.
CD noted this degree of cashflow differences between HSE and NPH is unexpected. CD agreed to
convene sub-committee to resolve before next CHP&P Steering Group meeting, consisting of CD, TCO,
JP, SM (optional) and Jim Curran. Action
6. Standing Update on Capital Project
JP and EH flagged issue with capacity of Connolly adult hospital laboratory to service the Connolly
satellite, as initially planned, due to increased activity levels absorbing capacity. Negotiations are in
progress with General Manager of Connolly hospital and a solution is required in next few weeks. Agreed
to examine at the next CHP&P Steering Group in more detail if a solution cannot be reached. EH noted
this is the highest priority issue for the Connolly OPDUCC.
JP noted status of dependency on use of HBS framework to support equipment procurement for satellites
is now on track, following approval by HBS.
7. Update on National Paediatric Model of Care (MoC)
TCA confirmed the resource costing for the elements of the MoC critical to enable the new children’s
hospital is complete. It will be presented to the MoC Steering Group, led by Dean Sullivan, Chief Strategy
and Planning Officer, HSE, on 26th April. It will then be presented to HSE Leadership for approval and,
following this, the CHP&P Steering Group for observation.
TCA noted for clarity the MoC work to date does not consider prioritisation for implementation.
HB noted the full implementation plan will probably be a 10-year roll out.
FT asked if there are ICT implications that need to be considered.
TCA confirmed ICT, equipment and capital implications are out of scope, except for transport.
EH also noted change and project management costs for implementation have not been included.
Some concern noted that these elements have not been considered.
TCO requested visibility of MoC costing document before it is presented to HSE Leadership.
JGC asked TCA to liaise with DS to arrange a briefing session before the MoC costing is submitted to
HSE Leadership, to provide an opportunity for relevant members of the CHP&P Steering Group to provide
observations and discuss concerns raised. Action
MO’C suggested it would be useful for the MoC to be embedded in Sláintecare. HB confirmed this is so.
8. Standing Update on EHR & ICT
Acute EHR Business Case
MO’C confirmed substantial progress on the Acute EHR business case.
MC, JGC and EH also acknowledged work of FT and team to progress the Acute EHR business case.
MO’C confirmed DoH observations have been incorporated into the Acute EHR business case.
MO’C confirmed Acute EHR business case was shared with DPER on 23rd
April for information.
MO’C confirmed DPER peer review group has been set up and will meet on 30th April.
MO’C confirmed overall timeline is currently back on track.
FT agreed to issue copy of Acute EHR business case to JGC following meeting.
FT noted next critical step is Statement of Requirements (SOR), which needs to be approved by 10th July.
MO’C noted the Acute EHR business case already provides a high-level outline of SOR.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 5 of 5 [
CHG Acute EHR Contingency Plan
JGC deferred the discussion on the draft CHG Acute EHR Contingency Plan until the next CHP&P
Steering Group meeting to allow members time to review and submit queries. Action
Medical Devices Integration
FT confirmed from national EHR perspective, OoCIO will go to market requiring vendors to have a
standards-based approach to integration.
FT explained CHG can set requirement for compatible devices when procuring new equipment which will
address most medical devices integration.
FT noted the concern is with legacy devices. SM noted the problem of legacy devices should become less
as large devices in individual sites become aged and are replaced. SM suggested assessing the presence
of legacy devices when evaluating site readiness during the national Acute EHR roll out. SM suggested
OoCIO consult with Ger Flynn, National Clinical Head of Medical Devices, HSE, in due course to examine
this in detail.
MO’C confirmed interoperability is assured from the national Acute EHR perspective.
Agreed the medical devices integration issue is closed.
MedLIS
EH noted CHG received communication that MedLIS is not on track for new children’s hospital in 2022.
SM advised MedLIS is significantly behind and a revised plan should be complete in 3-4 weeks.
EH noted it would be a significant issue if CHG had to move to a contingency for the main hospital.
Agreed to make this an agenda item at the next CHP&P Steering Group meeting. Action
NIMIS
EH noted some operational challenges with NIMIS which pose difficulty for Connolly opening.
EH asked if it is possible for scope of Temple Street to include Crumlin. SM advised this is not possible.
Agreed to provide update on this at next CHP&P Steering Group meeting. Action
9. Standing Update on Equipping / Healthcare Technology
CD confirmed meeting with NDFA took place 19th April. CD noted NDFA were interested in governance,
scale and technical aspects of the programme but gave no indication of willingness to be involved.
JP and EH confirmed the MES timeline has been re-evaluated; the cut-off point for DPER approval is
September 2018; beyond this MES is no longer viable because of the time it takes to procure.
JGC asked what drives the September 2018 cut-off point. JP explained a tender notice needs to be
issued in September 2018 in order to start competitive dialogue in January 2019; this will run for 18
months and then a preferred vendor will be appointed; the vendor will require 12 months to build
equipment in order to provide in time for contractor timelines.
CD commented that the September 2018 cut-off point is very challenging and suggested external advisors
should be explored, recognising that the NDFA would be preferred by DPER. CD agreed to try get an
indication from NDFA about willingness to be involved within the next week.
FD noted the capital funding allowance for possible MES equipping in the last memo to government was
€65m. FD asked whether this is still accurate. JP confirmed it needs updating; 250,000 approx. equipment
items have been identified in detailed design from C-Sheets and these need to be estimated using
existing HBS pricing, proposed to include with memo for information to government in summer. Action
Children’s Hospital Programme & Project Steering Group
V1.0 Page 1 of 4 [
Meeting Children’s Hospital Programme & Project Steering Group Meeting #9
Date 15:00-17:00, 31st May 2018
Location Department of Health, Hawkins House, Hawkins Street, Dublin 2
Chair Dean Sullivan (DS) Deputy Director General, HSE
Attendees
Steering Group Members
Tracey Conroy (TC) Assistant Secretary Acute Hospitals Policy, DOH
Martin Curley, (MC) Chief Information Officer, HSE
Colm Desmond (CD) Assistant Secretary, Finance & Evaluation, DOH
Fionnuala Duffy (FD) Principal Officer, Acute Hospitals Policy, DOH
Eilísh Hardiman (EH) Group CEO, CHG
Stephen Mulvany (SM) Chief Financial Officer, HSE
Muiris O’Connor (MO’C) Assistant Secretary R & D and Health Analytics, DOH
John Pollock (JP) Project Director, NPHDB
Dean Sullivan (DS) Deputy Director General, HSE
Additional Attendees
Helen Byrne (HB) Assistant National Director, Acute Hospital Division, HSE
Dara Carroll (DC) Integrated PMO for CHP&P Steering Group, HSE
Margaret Giffney, (MG) Integrated PMO for CHP&P Steering Group, HSE
John Smith (JS), National Director Health Business Services HSE
Fran Thompson (FT) Programme Director for Strategic e-Health Programme, HSE
Lynda Sisson, (LS) Consultant and Accredited Specialist in Occupational Medicine
Apologies
Jane Carolan (JCA) National Director of Health Business Services (HBS) / Interim CIO, HSE
Áine Carroll (AC) National Director Clinical Strategy & Programmes, HSE
Rosarii Mannion (RMA) National Director of Human Resources, HSE
Liam Woods (LW) National Director of Acute Hospitals, HSE
Joe Ryan (JR) Programme Director Value Improvement Programme & GDPR, HSE
Key Discussion Points
1. Minutes and Matters Arising
DC to reflect comments to the previous minutes. Final document to be circulated by 1st June 2018.
DS introduced himself as the new Chair, CHP&P SG and outlined his brief as Chair. DS noted thanks to
Sadhbh OBrien for her input and support to the steering group as she has moved on to a new position
and welcomed DC.
2. Standing update on Integration
The integration paper submitted is organised by the releases that the Children’s Hospital Programme
PMO is using to structure its work: Commencement, Central Referrals Pilot, Connolly Paediatric
Outpatient and Urgent Care Centre, Tallaght Paediatric Outpatient and Urgent Care Centre, new
children's hospitals with prominent attention to the first opening facility, Connolly Hospital.
EH outlined progress is proceeding, with no exceptions.
EH noted that a meeting was held with DOH Sec Gen 25th May and Chair of CHG Board to discuss the
legislation.
EH noted that the Sec Gen will meet with the Chairs of Temple Street, Crumlin, Tallaght, and Children’s
Hospital Group Board on 8th June to address queries and outstanding issues related to the
commencement of the legislation.
EH noted the Integration Programme has been signed off by the Children’s Hospital Group. A Work
Breakdown Structure has been prepared for the allocated €85m and this programme is reported on
through its PMO against releases.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 2 of 4 [
EH noted that the Critical Pathway had been completed, which included the detail around the various
interdependencies.
DS requested that, in order to facilitate a streamlined Steering Group meeting update, an Integration
Plan, with clear deliverables (2018 to 2022) be prepared, against which positive assurances would be
provided by CHG at the Steering Group meetings going forward.
TC noted that the DoH would welcome such a formalised plan.
FD noted that the Children’s Hospital Programme Investment Case (last version Feb 2017) could be
updated, with a refreshed profile of expenditure and deliverables (for next 5 years).
It was agreed that an Integration Plan (2018-2022) with key milestones within the current critical path and
expected resources be prepared and circulated by CHG prior to the next Steering Group meeting.
ACTION
3. Standing Update on EHR & ICT (MedLIS, NIMIS, etc.)
Acute EHR
MC outlined that progress has been made for Acute EHR Business Case Review with very constructive
engagement at second peer review.
DS welcomed this progress, queried what risk mitigation plan is in place for EHR.
FT stated that the business case for EHR is on track with the new children’s hospital being the first
deployment. The Peer Review is progressing and DPER needs to formally approve the Business Case. A
first draft Statement of Requirement by Aug is being prepared and Noel Carbury CHG EHR Project
Manager as assigned to lead this for the HSE.
FT confirmed mid to end of August for 1st Drafts of SOR, with resources being added to catch up c. 3
week delay.
It was agreed that start Sept 2018 remained the critical path date and FT states confidence that this date
was achievable.
MC noted ongoing discourse around governance, with some feedback coming through the Peer review process. DS and MC agreed to meet wk 4
th June to discuss EHR and associated contingency. ACTION
TC noted DPER seeking assurance around governance and accountability. An update of Governance and
Accountability will also be required at the next CHP&P board meeting on 20th June 2018.
MC, MO’C and DS to meet around Governance, and Assurance wk 4thJune. ACTION.
Further to query by MC, it was agreed that the roll out of National EHR will not be paediatric specific and
will encompass the adult EHR, but that the NCH will be the 1st site in which it will be implemented.
EH noted that clinical engagement involving adult community is vital and is being led by Noel Carbery
throughout July and August ’18. FT noted that some delay was due to engagement outside of paediatrics.
LW has written to hospital groups for nominees to ensure the acute system functional requirements are
met.
DS concluded by noting that EHR was complex and challenging, with associated risks, however, based
on discussion, will succeed if procurement is initiated in Sept ’18.
PAS
FT outlined that the iSoft solution set for PAS is functioning for CUH.
EH advised that a single PAS to be operational in Crumlin, Tallaght paediatrics and Temple Street, but
agreement required with the adult service in Tallaght on key interfaces. This risk is currently being
actively manged by CHG.
DS asked that MC, FT and EH to form a working group to review issues in relation to PAS and NIMIS.
Any material risk to be brought before this steering group. ACTION
DS noted that the risk is being actively managed. No further discussion required at steering group.
SM outlined the MedLis and NIMIS update paper, Medlis replanning is going well, resourcing national
project team in relation to Phase A sites; Cavan General, Beaumont, St James’s and Mater.
Confirmation of nch implementation after 1st roll out NIMIS allows for localised workflow configured at
hospital level. Paper is prepared for discussion at meeting week 4th June around CHG radiology working
group.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 3 of 4 [
Interoperability project plan needed from FT/MC for Connolly facility. ACTION
EH noted the need for the converged network implementation and testing 15 months before NCH
opening.
4. Standing Update on Pre-CAR
EH noted that the final report and Action Plan is complete and has been circulated to selected steering
group members and to the CHP&P Board in advance of their June meeting. The Action Plan contains 29
items, resolution on some items may not be until 2019. The CHG Executive is taking a lead role on
progressing the actions.
EH noted that Key milestone as the Establishment of Legal Entity, with a Commencement date Jan ’19.
EH noted that a high-level symposium is scheduled for 4th July for Governance of the hospital Boards and
CHGB.
TC noted Sec Gen preferred approach for a phased commencement of legislation commencement. A
meeting between Sec Gen and Chair of CHG Board took place on 25th May. Agreement on best
approach for legislation with the three hospital boards and CHG is required prior to submission of the Bill
to government in early July ’18 seeking permission to publish.
EH noted the importance of maintaining the 1st January 2019 as the date for commencement. Matters
such as staff recruitment and equipment handover require adherence to this date.
5. Standing Update on HR
LS advised there were no HR items for escalation at this time, staff engagement progress is ongoing.
DS requested a workforce plan to be presented to the next meeting outlining the ramp-up arrangements
for staffing to opening of NCH in 2022. ACTION
MO’C noted concern around the nursing intake in third level education as the current flow will not
generate the required 300 new paediatric nurses in 2022. EH noted that the National Children’s Nursing
Workforce Plan (final draft) will be ready 1st June 2018 - which is to address the future supply of paediatric
nurses. Similar challenges exist in relation to junior doctors and AHP’s. EH noted ongoing interface with
D.E.S.
EH highlighted the importance of the Model of Care in completing the staffing plan.
DS noted the nursing capacity is to increase by 20% year on year. SM noted NDP (HSE) require a budget
increase from DoH for this purpose.
TC noted clarity required around MoC and staffing recruitment deadlines in order to plan for adequate
numbers of graduates for 2022.
DS requested a paper for the next SG meeting from LS on increased training requirements. ACTION
SM noted that retaining graduates is a key challenge and we require innovative ways of retention before
they move away overseas.
EH advised that innovative methods were being explored in relation to affordable accommodation for key
workers. CHG and NPHDB are working on proposals in this regard. EH to outline progress in a paper to
Steering Group meeting in August ‘18. ACTION
6. Standing Update on Capital Funding
JP reported progress in relation to the Guaranteed Maximum Price (GMP) programme. All design
packages issued by QS to contractors for final measure of quantities and pricing. An independent expert
will deliver binding decision on disputed construction costs. Deadline end-June will not be met for
concluding GMP process. End of June NPH will have a strong sense of where we stand in overall terms
for Capital Construction Cost. July and August to work through identified issues, make any changes to
contract documents and firm up on GMP. September NPH QS to produce a Final GMP Report. NPHDB
Board will then meet to approve and to allow Dept to bring a memo to government in October for decision.
TC advised to go to government for decision before the 2019 Estimates process, September would be
better than October.
SM requested an approximate figure be adjudicated on by mid-July (before estimates process closed) to
allow DPER and Government to maximise position.
Children’s Hospital Programme & Project Steering Group
V1.0 Page 4 of 4 [
EH outlined the philanthropy challenges being faced with the merger of three separate foundations into a
single entity contingent on Legal Commencement January 2019. EH to provide a philanthropy review for
August SG meeting. ACTION
7. Standing Update on Capital Project
JP reported that work at the Connolly Hospital site is progressing well and is on track for 2019
completion. Report due in relation to solution for shared Connolly Laboratory is due on 1st June. Tallaght
decant and crèche buildings are on track for completion in July 2019.
EH advised discussions about specific aspects with Universities are commencing but no firm commitment
about 3rd
Level education.
FD advised there is no government commitment to fund the RMHC family accommodation unit, so there is
a €7 capital shortfall. SM noted that RMHC is putting resources into all operating costs as well as €8m
capital costs. SM to provide update paper (prepared by Paul de Freine / Tony Kelly, HSE Estates) for next
meeting. ACTION
CD noted HSE could use current funding for capital purposes up to certain minor agreed limits.
It was agreed that family accommodation was critical and how to pay for it needs resolution. CD/DS to
discuss. ACTION
8. Update on Paediatric Model of Care (PMoC)
A draft paper has been produced for HSE Leadership which will come to CHP&P Steering Group meeting
on 25th June ’18.
9. Standing Update on Equipping / Healthcare Technology
CD outlined progress on CBA and the business case. Document identifying 3 equipment strands to go to
DPER by July ‘18. Single equipment business case will be issued to Steering Group by August ’18, then
to DPER by August/September. This will be reflected in the Memo for Government.
SM queried whether the funding (€65m) was categorised as revenue or capital, this has to be confirmed
ACTION.
DS requested key procurements and key milestones for July ’18 SG meeting. CD, SM (HSE) to
progress. ACTION
10. AOB
FD asked if the CHP expenditure document is relevant to this meeting. We need to plan around
integration and costs.
SM requested that EH attach a definition to Revenue Expenditure Update. ACTION
EH noted the Children’s Hospital Acute EHR Contingency Plan document was included as a request from
the last meeting.
Mo’C requested we capture documents in today’s pack that were not formally tabled or discussed today.
These included CHG Acute EHR Contingency Plan,the NIMIS Impact Paper and some financial papers.
Meeting Close
Next meeting Monday 25th
June 3.30pm, Green Room, Dr Steeven’s Hospital, Dublin 8