View
212
Download
0
Category
Preview:
Citation preview
Kanamadi Associates
PROPOSED INTERIOR WORK
FOR
BANK OF INDIA
AT
BRANCH OFFICE, MADIKERI.
DATE OF ISSUE: - 17.07.2015 TO 23.07.2015
TENDER SUBMISSION ON: - 23.07.2015 AT 3.00 P.M.
TENDER OPENING: - 23.07.2015 AT 3.30 P.M
COMPLETION PERIOD
3 weeks
BANK OF INDIA
Zonal office, Bangalore
Bank of India Building, K.G.Road, Bangalore
560 009, Ph: 080 22959419
Architects
KANAMADI AND ASSOCIATES
#58, First Floor, 6th Cross S.P.Extn., 11th Cross, Malleshwaram, Bangalore -560 003
Ph: 080 23347210, Email: kanamadiassociates@gmail.com
Kanamadi Associates
TENDER FOR PROPOSED INTERIOR WORK FOR BANK OF INDIA
BRANCH OFFICE AT MADIKERI.
Documents issued to: 16.07.2015
Date of submission: 23.07.2015
Place of submission; Zonal Manager
BANK OF INDIA
BANK OF INDIA BUILDING
Zonal office, K.G.Road
Bangalore 560001.
ARCHITECTS: KANAMADI & ASSOCIATES.
ARCHITECTS AND ENGINEERS,
#58, FIRST FLOOR,
11TH CROSS, VYALIKAVAL,
MALLESHWARAM
BANGALORE- 560 003.
PH: 080-2334 7210.
Kanamadi Associates
APPENDIX TO GENERAL CONDITIONS OF CONTRACT
1. Earnest Money Deposit (EMD): Rs.7, 500.00
2. Initial Security Deposit (ISD): 2% of contract value
3. Period of Completion: 3 weeks
4. Defect Liability Period: 6 months after completion as Recorded in the completion
Certificate / final bill
5. Agreed Liquidated Damages: 1% of Contract amount per Week of delay
subjected to a Maximum of 10% of contract Value.
6. Period of Final Measurements: 7 days after completion as Recorded in the
Completion Certificate.
7. Minimum value of work to be Executed for issue of interim Certificates for
making payment: After completion of entire work
8. Retention money from each bill: 5% of gross value of each Interim bill.
9. Total retention money Including earnest money And initial security deposit:
5% of the contract value
10. Release of security deposit: after the defect liability period Which after virtual
Completion Is six months
11. Period for honoring certificate: working days from date of for Making payment
Certificate of Payment for interim bills & 15 Working days for final Certificate.
12. Tender Fees: Rs.1000.00
WITNESS:
DATE: SIGNATURE OF THE CONTRACTOR WITH DATE
Kanamadi Associates
TENDER FORM
PROJECT: PROPOSED INTERIOR WORK FOR BANK OF INDIA BRANCH OFFICE
AT MADIKERI.
Dear Sirs,
I/We the undersigned have carefully gone through and clearly understood after visiting the site and
the Tender Drawings and Tender Documents comprising of the tender from, Notice to Contractors,
Specifications and Schedule of probable Quantities prepared by your Architects
M/s. KANAMADI AND ASSOCIATES. Architects, and Interior Designers, Bangalore.
I/We do hereby undertake to execute and complete the whole or part of the work (as desired by
you) at the respective rates which I/We have quoted for the respective items of the Probable Bill of
Quantities and at which rate the items specified amount of Rs. _____________________
In the event of this Tender being accepted I/We agree to enter into an agreement as and when
required and execute the contract according to your form of Agreement, after the receipt of work
order, in default thereof.
I/We further agree to complete the work covered in the said Schedule of Quantities within
______________ from the date of issue of the work order to commence the work.
I/We agree not to employ Sub-Contractors other than those that may be specifically approved by
your Architects for this contract work.
I/We agree to pay the Government, General and Sales Tax (State and Central), Excise and Octopi
duties, insurance and all other taxes including works contract tax etc., as prevailing from time to
time, on such items for which the same are leviable, and to get the work, workers, employers (of
contractor, Architect and Employer) engaged on the work at site and all materials and machinery
collected and kept / operated at site for execution of the work shall be insured comprehensive
insurance including fire / accidents / rain / floods / riots / CAR policy (Contractor s all risk insurance
policy) shall cover the period from date of start of work to date of actual completion of work. In
case pat work is taken over by the employer before final completion of the whole work, such parts
may not be covered by the insurance from the date of taking over the part of work by the
Employer. Draft Insurance deed will be got vetted by the Architect, before obtaining the same. All
the rates quoted by me / us are inclusive of the same in full and nothing extra shall be claimed
anytime on account of any of these.
The contractor shall be responsible for the co-ordination of the work of other contractors / sub-
contractors etc., the respective contractors shall work harmoniously and afford reasonable facility
to each other as circumstances required.
Kanamadi Associates
The employer reserves to himself the right of altering drawings and nature of work, adding to or
omitting any item of work from the contract or having portion of the same carried out through other
agencies without prejudice to this contract.
All disputes and differences of any kind whatever arising out for in connection with the contract or
the carrying out of the works (whether during the progress of the works or after their completion
and whether before or after the determination, abandonment or breach of the contract) shall be
determined and referred to arbitration as per the relevant clause of the conditions of the contract.
The provisions of the arbitration act 1940 or any statutory modification or reenactment thereof and
of the rules made there under for the time being in force shall apply to any arbitration proceedings
under this clause.
Further all disputes arising out of or in any way connected with this agreement shall be deemed to
have arisen in Bangalore and only courts in Bangalore shall have jurisdiction to entertain and
determine the same.
I/We agree to pay Income tax, to be deducted at source, on the Gross value of the work done, and
the rates quoted by me / we are inclusive of same.
I/We agree to pay works contract tax, to be deducted at source, at the rates prevailing from time to
time as per State Government rules as amended and rates quoted by me / us as inclusive of the
same.
The several part of this contract have been read by us and fully understood by us.
Yours faithfully,
Contractors Signature
Address: Date:
Kanamadi Associates
NOTICE TO CONTRACTOR
ADDRESS:
_____________________________________
_____________________________________
_____________________________________
_____________________________________
_____________________________________
PROJECT:
PROPOSED INTERIOR WORK FOR BANK OF INDIA BRANCH
OFFICE AT MADIKERI.
Dear Sirs,
1. On behalf of our clients, M/s. Bank of India, Zonal Office, K.G. Road, Bangalore. We are
pleasured in inviting you to tender for the aforesaid work
. 2. Sealed tenders in the prescribed form, in a sealed envelope should be addressed to The
ZONAL Manager, Bank of India, Bangalore
3. Tender will be opened at
Time: 15.30 Hrs
Date: 23.07.2015
Place: The ZONAL Manager, KG Road, Bangalore. In the presence of
the Architects or Tenderers or their authorized representatives should they
choose to present. No tender will be received after the expiry of the time
notified for receiving tenders under any circumstances whatsoever.
4. The tendered must obtain for himself, on his own responsibility and at his own expenses,
all the information which may be necessary for the purpose of filling this tender and for
entering into a Contract for the execution of the same and must examine the drawings and
inspect the site of the work and acquaint himself with all local conditions and matters
pertaining thereto.
5. Each of the tender documents page is required to be signed by the person or persons
submitting the tender in token of his. Their having acquainted himself / themselves with the
General Conditions etc., as laid down. Any tender with any of the documents not so signed
will be rejected.
6. The tender documents must be filled in English and all the entries must be made by hand
and written in ink. If any of the documents are missing or unsigned, the tender shall be
considered invalid.
Kanamadi Associates
7. If the differences are found between the rates given by the contractor in worked and
figures or in the amount worked out by him, the following procedure shall be followed.
a. Where there is a difference between the rates in figures and words, the rates which
correspond to the amounts worked out by the contractor shall be taken as correct.
b. Where the amount of an item is not worked out by the contractor or it does not
correspond with the rates written either in figures or in words, ten the rate quoted by
the contractor in words shall be taken as correct.
c. Where the rate quoted by the contractor in figures and in words tallies but the amount
is not worked out correctly, the rate quoted by the contractor shall be taken as correct
and not the amount.
d. Where there is any discrepancy between the original, duplicate copies, the entries in
the original shall be taken as correct.
8. A schedule of probable quantities in respect of each work and specifications accompany
these special conditions. The schedule of quantities is liable to alteration by omission,
deductions or additions at the discretion of the Architects with the consent of the employer.
9. Statutory Regulations: The whole of the work is to be complied with, as per the
requirements and the bylaws of the relevant statutory authorities, including Contract Lab
our (Regulation and Abolition) Act, 1970.
10. Total Security Deposit: The retention of 5% of the value of the work done will be
deducted from every running bill. On the Architect s certifying the completion of the work,
after the defects liability period which is 6months as the case may be.
11. All compensation or other sums of money payable by the Contractors to the Employer,
under the terms of this contract, may be deducted from the retention amount.
12. The Contractor shall arrange for the procurement of all the materials at site as required
and directed, and store them in their godown at the site of construction, and also bear all
the expenses incurred in connection there with, including payment of all taxes.
13. The rate quoted by the Contractor shall include all eventualities, such as heavy rain,
sudden floods, accidents, fire, riots etc., which may cause damage to the executed work or
which may totally wash out the work. Until the completion certificate is issued to the
Contractors, neither the Architect nor the Employer will be responsible for such damage or
wash out of the construction work.
14. Time is the essence of the contract. The work should be completed within 3 weeks, after
the work order issued to the Contractor to commence the work. The successful Contractor
will have to give a CPM / PERT chart of various activities of work to be done so that the
work gets completed within the stipulated time. The chart shall be submitted within 2 days
from the date of acceptance of the tender.
Kanamadi Associates
15. Intending tenderer shall pay as Earnest Money a sum of Rupees Nine Thousand Five
Hundred as mentioned in the Appendix to General Conditions of Contract in the form of
Demand draft drawn in favour of Bank of India, Bangalore. Earnest Money will be
returned to the tenders if his / their tender is not accepted is not accepted but without any
interest. Tenders without Earnest Money shall not be considered at all. Under no
circumstances, Earnest Money Deposit will be accepted in form of cheques, fixed deposit
receipts of bank or insurance guarantees.
16. The successful tender shall, in addition to the Earnest Money Deposit a further sum equal
as mention in Appendix to General Conditions of Contract including EMD amount, as
Security Deposit by Demand Draft in favour of Bank of India at the time of signing the
contract for the execution and fulfillment of the contractor. This sum will carry no interest.
17. The contractor fails to complete the work by the Scheduled date of completion or within
any sanctioned extended time, he will have to pay liquidated damages at the rate of 1% of
contract amount of each week of delay the work remains incomplete beyond the
completion (original / extended date), subject to maximum of 10% of the contract value
(without extra items).
18. The quantities contained in the Schedule are only approximate. The work actually carried
out and done will be measured from time to time, for which payment will be made subject
to the terms and conditions of Contract.
19. The unit prices shall be deemed to be fixed prices. In case of extra items, the rates will be
either derived from the tender taxes if not the rates of extra items shall be derived from the
market rates based on the analysis of rates.
20. Removal of Improper work :The Employer shall during the progress of the work have
power to order in writing from time to time the removal from the work within such
reasonable time or times as may be specified in order of any materials in which in the
opinion of the Employer / Architects are not in accordance with specification or
instructions, the substitution or proper re-execution of any work executed with materials or
workmanship not in accordance with the drawings and specifications or instructions. In
case the contractor refuses to comply with the order the Employer with the order the
Employer shall have the power to employ and pay other agencies to carry out the work
and all expenses consequent thereon or incidental thereto as certified by the Employer /
Architects shall be borne by the Contractor or may be deducted from any money due to or
that may become due to the contractor. No certificate which may be given by the
architects shall relieve the Contractor from his liability in respect of unsound work or bad
materials.
21. Final Payment: The final bill shall be accompanied by the certificate of completion from
the Architects. Payments of final bill shall be made after deduction of retention money as
Kanamadi Associates
specified which sum shall be refunded after completion of Defect Liability Period after
receiving the Employers / Architects certificate that the Contractor has rectified all defects
to the satisfaction of the Employer / Architects. The acceptance of payment to final bill by
the Contractor would indicate that he will have no further claim in respect of the work
executed.
22. Our Employer M/s. Bank of India, do not bind themselves to accept the lowest or any
tender and reserve to themselves the right to accept or reject any or all tenders, either in
whole or in part, without assigning any reason whatsoever for doing so.
INSTRUCTIONS TO TENDERERS:
All the rates shall be filled up in figures as well as words without fail.
The rates and amount against each item of work shall be filled up by only in tender papers issued
to the tendered
The Earnest Money Deposit shall accompany the tenders for the specified amount.
The competent person shall duly sign the tenders.
No paper or sheet shall be detached from the tender document issued to the tendered.
All the drawings shall be returned along with the tenders.
The tenders shall be liable for rejection if any of the above said requirements are not complied
with.
The Contractor shall arrange water and power for construction. In case the Bank agrees to provide
water, the electricity charges towards pumping of water will have to be borne by the contractor.
The client does not bind itself to accept the lowest or any tender and reserves to itself the right to
accept or reject any or all the tenders, either or in whole or in part without assigning any reason for
doing so.
A schedule of probable quantities in respect of each work and specifications accompany these
specials conditions. The schedule of quantities is liable to alteration by omission, deductions or
additions at the discretion of the Architects with the consent of the employer.
All items or work described in the schedule of quantities are to be deemed and paid as complete
works in all respects and details including preparatory and finishing woks involved, directly, related
to and reasonably detectable from the drawings, specifications and schedule of quantities and no
further extra charges will be allowed in this connection. In case of lump-sum charges in the tender
in respect of any item of works, the payment of such items of work will be made for actual work
done on the basis of lump-sum charges as will be assessed to be payable by the Employer /
Architects.
Kanamadi Associates
The tenderer must include in their tender prices quoted for all duties royalties, cess and sale tax or
any other taxes or local charges if applicable.
No extra claim on this account will in any case be entertained.
If the employer has supplied any materials or goods to the contractor, the cost of any such
materials or goods will be progressively deducted from the amount due to the Contractor in
accordance with the quantities consumed in the work.
The Employer shall during the progress of the work have power to order in writing from time to
time the removal from the work within such reasonable time or times as may be specified in the
order of any materials in which in the opinion of the Employer / Architects are not in accordance
with specification or instructions, the substitution or proper re-execution of any work executed with
materials or workmanship not in accordance with the drawings and specifications or instructions. In
case the contractor refuses to comply with the order the Employer shall have the power to employ
and pay other agencies to carry out the work and all expenses consequent thereon or incidental
thereto as certified by the Employer / Architects shall be borne by the Contractor or may be
deducted from any money due to or that may become due to the contractor. No certificate, which
may be given by the architects, shall relieve the Contractor from his liability in respect of unsound
work or bad materials.
The contractor from approved laboratory and test result submitted to the employers for approval
should be tested all materials. Only those materials approved by the employers to be used at
works. The cost for testing shall be borne by the contractor only.
The Contractor will be made payments towards steel based on the actual quantities of steel used
at site including laps mentioned in the drawings to the exact lengths.
The contractor must co-operate and co-ordinate the work with work of all other contractors
appointed by the employer so that the work shall proceed with the least possible delay and to the
satisfaction of the Architects. The contractor co-ordination with other contractors appointed by the
employer is essential to maintain smooth progress of work and any delays, which in the opinion of
the Architects / Employer is due to non-co-ordination and inefficient management of the contractor
will not be entertained for any extension of time.
No escalation of cost of materials due to any reasons will be entertained.
The contractor will observe all statutory and legal requirements as required by the central and
state governments as applied to the work. He shall fully indemnify the employer against any loss of
property, life etc.
Contractors shall indemnify the employer and architect against any accident on site and
immediately outside causing injuries / death to any workers / visitors / third party claims under any
of the statutory bodies. All insurance certificates to be provided by the contractor.
Kanamadi Associates
PF / Insurance / Taxes of contractor workers are the contractors full responsibility.
This tender is accepted in whole or in part, I/We hereby agree to abide by and fulfill all the terms
and conditions annexed hereto. Further, I/We bind ourselves to execute the contract and
commence the work within the time specified failing which I/We agree that my/our Earnest Money
shall be retained by the Employers. Further I/We undertake to deposit the full amount of the
security deposit specified in the above memorandum. I/We also agree to the retention money
being deducted from my/our bills in accordance with the conditions of contract.
It is clearly understood that the Employer / Architects reserve the right to reject any tender,
including the lowest, without assigning any reasons whatsoever for such rejection
A schedule of probable quantities in respect of each work and specifications accompany these
tender documents. The Schedules of probable quantities are liable to alterations, omissions,
deductions or additions to any extent at the discretion of the Architects / Employer. Each schedule
of quantities should contain not only the rates but also the value of each item of work entered in a
separate column and all the items should be totaled in order to show the aggregate value of the
entire tender. Rates should be quoted both in figures and words. However, rates quoted in words
will be taken as final for calculation purpose.
The tenderer must obtain for himself on his own responsibilities and at his own expenses all the
information which may be necessary for the purpose of making a tender and for entering into a
contract and must examine the drawings and must consider and inspect the site of the work and
acquaint himself with all local conditions, means of access to the work, nature of the work and all
matters pertaining thereto.
The quoted rates in the tender shall include all charges for scaffolding, water and electricity,
consumption charges, hire for any tools and plants, shed for materials, marking out and clearing of
site. The rate quoted shall be deemed to be for the finished work to be measured at site. The rates
shall also be firm and shall not be subjected to change, variation, Lab our conditions, fluctuations
in railway freights or any conditions whatsoever. Tenderers must include in their rates sales tax,
excise duty, Octopi, works contract tax and any other tax and duty or other levy levied by the
central government or any state Government or local authority, if applicable. No claim whatsoever
in respect of sales tax, excise duty, Octopi, works contract tax or other taxes shall be entertained
by the employer.
The calculations made by the tenderer should be based upon probable quantities of the several
items of work which are furnished for the tenderers convenience in the schedule of probable
quantities. But it must be clearly understood that the contract is not a lump sum contract that
neither the probable quantities or the value of the individual items nor the value of the entire tender
will form part of the contract and that the employer does not in any way assure the tenderer or
guarantee that the said probable quantities are correct.
Kanamadi Associates
The calculations made by the tenderers should be based upon probable quantities of the several
items of work which are furnished for the tenderer s convenience in the schedule of probable
quantities. But it must be clearly understood that the contract is not a lump sum contract that
neither the probable quantities nor the value of the individual items nor the value of the entire
tender will form part of the contract and that the employer does not in any way assure the tenderer
or guarantee tat the said probable quantities are correct.
The calculations made by the tenderers should be based upon probable quantities of the several
items of work which are furnished for the tenderer s convenience in the schedule of probable
quantities. But it must be clearly understood that the contract is not a lump sum contract that
neither the probable quantities nor the value of the individual items nor the value of the entire
tender will form part of the contract and that the employer does not in any way assure the tenderer
or guarantee that the said probable quantities are correct.
The Employer / Architect will be free to take away any item / items from the schedule / bill of
quantities in part or the whole schedule itself and the tenderer shall not have any claims for this.
The tenderer shall extend his / their full co-operation to other agencies working at the same site.
The final bill of tenderer will be based on the actual executed quantities of each item and they shall
not have any extra claims, for less / more quantities compared to tendered quantities.
The rates quoted by the tenderer shall remain firm during the execution of this contract and also
during the extended time beyond the completion period, till the premises are handed over to the
employer. No escalation in rates whatsoever on this account the employer will consider.
The employer / Architect reserve the right to award this work to a single tenderer or split it two or
more tenders.
At any time during the progress of the work, any item/s being manufactured at the tenderer s
workshop may be inspected by the Architect / Employer. The contractor shall make all necessary
arrangements for such visits at their own cost.
SCOPE OF WORK:
The contractor shall carry out and complete the work in every respect in accordance with this
contract and with the directions of and to the satisfaction of the Architects / Employer. The
Architects may in consultation with the Employer from time to time further drawings and/or written
instructions details, directions, and explanations which are hereafter collectively referred to as
ARCHITECTS / EMPLOYERS INSTRUCTIONS in regard to :
a) The variation or modification of the design quality o quantity of works, or the addition or
omission or substitution of any work.
b) Any discrepancy in the drawings or between the schedule of quantities and/or drawings
and/or specifications.
c) The removal from the site of any materials brought thereon by the contractor and the
substitution of any other materials therefore.
Kanamadi Associates
d) The removal and/or re-execution of any works executed by the contractor.
e) The dismissal from the works of any persons employed thereupon.
f) The opening up for inspection of any work covered up.
g) The amending and making good of any defects.
The contractor shall forthwith comply with and duly execute any work comprised in such Architects
/ Employer s instructions provided always that verbal instructions, directions and explanations
given to the contractor or his representatives upon the works, by the Architects shall if involving a
variation, be confirmed in writing by the contractor to the Architects and the Employer within seven
days, and if not dissented from in writing within further seven days by the Architects such shall be
deemed to be Architect s instructions within the scope of the contract.
CONTRACTOR TO PROVIDE EVERYTHING NECESSARY:
The contractor shall supply, fix and maintain at his cost during the execution of any works, all the
necessary centering, scaffolding, staging, planking, timbering, strutting, shoring, pumping, fencing,
watching and lighting up nights as well as by day, required not only for the proper execution and
protection of the public and the safety of any adjacent road, buildings, streets, cellars, vaults,
pavements, walls, houses and all other erections, matters or things. The contractor shall take
down and remove any or all such centering, scaffolding, staging, planking, timbering, strutting,
shoring, etc., as occasion shall requires or when ordered to do so and shall fully reinstate and
make good all matters and things disturbed during the execution of the works, to the satisfaction of
the Architects / Employer.
The contractor shall be responsible to register themselves under the Contract Lab our
(Regulations and Abolition) Act 1970 and rules there under and they shall comply with and
carryout all the provisions and obligations under the said act and rules and furnish all information
to Employer as may be required by it and shall also indemnify the Employer against any penalties /
claims arising from any default on their part.
The contractor shall observe that his work shall not cause any nuisance to the public in
general and to the neighboring occupants in particular.
CONTRACTOR RESPONSIBLE FOR SETTING OUT WORKS & FOR RECTIFYING BAD
WORKS:
The contractor shall set out the works and shall be responsible for the true and perfect setting of
the same and for the correctness of the positions, levels, dimensions and alignment of all parts
thereof. If at any time any error in this respect shall appear during the progress of the works, the
contractor shall at his own expense rectify such error to the satisfaction of the Architect.
MATERIALS AND WORKMANSHIP TO CONFIRM TO DESCRIPTION:
All materials and workmanship shall be of the respective kinds described in the schedule of
quantities and/or specifications and in accordance with the Architects instructions and the
Kanamadi Associates
contractor shall upon the request of the Architect or employer, furnish them with all invoices,
accounts, receipts and other vouchers, accounts to prove that the materials comply therewith. The
contractors shall at his own cost arrange for and/or carryout any test of any materials which the
architects may require.
REMOVAL OF IMPROPER WORK:
The Architects shall during the progress of the works have power to order in writing from time to
time or times as may be specified in the order, of any materials which in the opinion of the
Architects are not in accordance with the specifications or instructions and the contractors shall
forthwith carryout such order at his own cost. The case of default on the part of the contractor to
carry out such order the employer shall have the power to employ and pay other persons to carry
out the same, and all expenses consequent or incidental thereto as certified by the Architects shall
be borne by the contractor, or may be deducted by the employer from any moneys due or that may
be become due to the contractor.
DEFECTS LIABILITY PERIOD
Any defects, shrinkage, settlement or other faults which may appear within the defects liability
period stated in the schedule hereto within 12 months after the virtual completion of the work
arising in the opinion of the architects from materials or workmanship / not in accordance with the
contract, shall upon the directions in writing of the architects, and within such reasonable times as
shall be specified therein, be amended and made good by the contractor at his own cost and in
case of default the employer may employ and pay other persons to amend and make good such
defects, shrinkage, settlements or other faults and all damages, loss and expenses consequent
thereon or incidental thereto shall be made good and borne by the contractor and such damages
loss and expenses shall be recoverable from him by the employer or may be deducted by the
employer upon the architects certificate in writing form any moneys due or that may become due to
the contractor.
COMPLETION CERTIFICATE
The works shall not be considered as completed until the architects have certified in writing that
they have been virtually completed and the defects liability period shall commence from the date of
such certificate.
OTHER PERSONS ENGAGED BY EMPLOYER
The employer with the concurrence of the architects reserves the right to use the premises and
any portion of the site for the execution of any work not included in this contract which he may
desire to have carried out by other persons, and contractor is to allow all reasonable facilities for
the execution of such work but is not required to provide any plant or materials for the execution of
such work except by special arrangement with the employer; such works shall be carried out in
such manner as not to impede the progress of the works included in the contract.
Kanamadi Associates
21) LIABILITY FOR ACCIDENTS AND DAMAGE AND INSURANCE
i) The contractor shall during the execution of the work properly cover up and protect any
part of the work liable to injury by exposure to the weather, and shall take every
reasonable precaution against accident or injury to the work from any cause.
ii) All contractors equipment shall be at the sole risk of the contractor.
iii) The contractor will insure all his personnel and his part of the work
Against any personnel injury which may be sustained by them as a result of fire / accident
at the time of execution of the work.
The contractor shall be responsible for workmen s compensation insurance and all other statutory
requirements in regard to the personnel in the contractor s employment.
CLEARANCE OF SITE:
The contractor shall have to remove all Melba from the site of work, dirt and dust, from floors and
wood work and white wash or color wash, distemper or paint splashes from doors, windows, glass
panels, etc., before handing over the building to the employer. The work shall not be treated as
complete in all respects unless there requirements are fulfilled by him. In the event of the
contractor failing to do so the Architects and the Employer shall have the right to get the site
cleared, dust and dirt removed and doors and windows etc., cleared of splashes etc., at the
contractor s risk and cost without prejudice to the right of Architects or employer to take action to
recover damages under clause 23 of the contract.
SITE ESTABLISHMENTS:
The contractor shall provide all huts, stores, tarpaulins and other covers for all the accommodation
of his staff, workmen and materials likely to deteriorate in the open shall be stored under suitable
cover.
Kanamadi Associates
ANNEXURE
B
List of Approved Materials
Sl.
No.
Materials
Approved Manufacturers/ Suppliers
1. Paint ICI Dulux / Asian Paints / Berger
2. Wood preservative Bison by British Paints / Termiseal by PCI.
3. Plywood Century Ply, Green ply, Anchor Ply,
4. False ceiling Armstrong, Indian Gypsum Board, New age
5. Laminates As per drawings
6. Screws GKW / Nettle fold
7. Adhesive Fevicol SH
8. Locks Godrej
9. Night Latch Godrej
10. Aluminum Door frame Jindal
11. Glass Modi / Asahi / Saint Gobain
12. Aluminum Cladding Eurobond / Altobond / Alukbond
13. Key board drawer EBCO
14. Telescopic CPU Stand EBCO
15. Cable Organizers
(Wire Manager)
EBCO
16. Vitrified Tiles EURO / RAK / Kajariya
NOTE: Plywood mentioned in the drawings as well as in bill of quantities
Should be MR Grade only.
LIST OF APPROVED MAKE OF MATERIALS
Salwood: Well seasoned free from sap, knots, and cracks and As Per Approved sample.
Teakwood: Best quality teakwood well seasoned as per approved Sample.
Commercial Ply / Marine: Century Ply, Green ply, Anchor Ply,
Plain Particle Board / MDF: Nova pan, Nuwud, Bombay Bumah, Bhutan Board.
Flush Shutters: Karnataka Forest Industries, Uni ply Green ply.
Lamination: All lamination shall be 1.0mm thick of Merino lam, Virgo, Green lam, Formica and Sundeck, Allum, sheets, Alu Bond make.
Veneer: Timex, Uniply, UNO, Kilachandra, and Birla, Jacksons, Green ply or approved make
Kanamadi Associates
Glass: All glass shall be flat glass of IAC Triveni, Gujarat Guardian, Indo-Asahi, and Saint.Gobain.
Paints: ICI, Asian, Berger, Jenson & Nicholson
PVC Floors: PVC floors to be of premier Vinyl, Armstrong, LG in the forms and shall be of 2mm thick.
Gypsum board false ceiling: shall be of India Gypsum
Adhesives: Shall be Fevicol / Vemicol
Screws: All screws shall be machine made
Melamine polish: shall be of Asian company matt finish
Venetian Blinds: Vertical or Horizontal of Vista Leveler or Luxaflex / Trac / Aerolex including all fixtures and fastenings
Sliding channel (telescopic): shall be of Earl
Bihari, glydo efficient gadgets, powder coated Aluminum channel
Mort ice Locks: Shall be of Godrej, Ebco, Golden
Multi locks: shall be at Godrej, Ebco
Tower bolts: all lower bolts of various sizes shall be of good quality powder coated medium gauge as per approved sample
Ball catches: shall be of Mukund or equivalent of approved quality
Ceiling Tiles: Armstrong makes / approved quality
Brief Specifications of Major Items;
1. Counters
Clerical counters.
Size: Height 2 6 Width 2 6 Length 4 6 to 5 6 .
Material: Marine ply IS 303 of 19mm thickness, for top And Supports, 12mm for drawers and front apron.
Finish: Area Visible to customers shall be laminated by 1.0mm laminates on top and 1mm on sides, Remaining Area to be polished.
Hardware: Earl Bihari, Godrej, Efficient Gadget.
Cash Counters.
Size: Height 2 6 Width 2 6 Length 4 6 to 5 6 .
Material: Marine ply IS 303 of 19mm thickness, for top and
Kanamadi Associates
Supports, 12mm for drawers and front apron.
Finish: Area Visible to customers shall be laminated by
1.0mm laminates on top and 1mm on sides, remaining Area to be polished.
Hardware: Earl Bihari, Godrej, Efficient Gadget.
2. Partitions.
Full Height
Frame: 2 x2 sal wood or equivalent B grade locally available Wood treated anti termite minimum 2 0 c/c.
Beading; ½ Teak wood.
Glass: 8mm thick
Moulding: ½ x 1-1/4
teak wood.
Finish: 1.0mm thick laminate of approved colour And Make.
2.1. Low height for workstations.
Frame: 2 x2 Sal wood or equivalent B grade locally
available Wood treated anti termite minimum 2 0 c/c.
Frame: 4 x2 Teak wood
Glass: 12 mm thick
Moulding: 1 x 1 teak wood
Finish: French polish.
Hardware: 1 x2 brush finish stainless steel handles.
Floor springs: Dorma
Beading: Round shaped out of 1 teak wood
Finish: 1.0mm thick laminate of approved colour and make
and Polish on beading.
3. Doors
3.1 Main Door
Frame: 4 x2 Teak wood
Glass: 12 mm thick
Moulding: 1 x 1 teak wood
Kanamadi Associates
Finish: French polish.
Hardware: 1 x2 brush finish stainless steel handles.
Floor springs; Dorm
3.2 For cabins having glazed partitions.
Door Frame: 4 x2-1/2 Teak wood
Shutter frame: 2 x2 Sal wood @ minimum 1 6 c/c
Glass: 8 mm thick above 3 0 height
Panel: 6mm thick marine ply (IS 303). On both sides Up to
3 0 Height.
Moulding: 1 x 1 teak wood
Beading: ½ thick
Finish: 1.5 thick laminate on both sides on ply and French
Polish.
Hardware: 1 x1 brush finish stainless steel handles.
Door closers: Dorma/ Eve rite/ Efficient Gadgets.
3.3 For cabins having solid partitions
Door Frame:4 x2-1/2 Teak wood
Shutter frame:2 x2 Sal wood @ minimum 1 6 c/c
Panel: 6mm thick marine ply (IS 303). On both sides
Moulding:1 x 1 teak wood
Beading: ½ thick
Finish: 1.5 thick laminate on both sides on ply
and Polish on beading, Moulding, and ply wood Area in record room, pantry etc.
Hardware: 1 x1 brush finish stainless steel handles 9 Tower bolts, and heavy-duty hinges,
Godrej/Vijayan makes handles.
Kanamadi Associates
BANK OF INDIA
PREMISES DEPARTMENT
HEAD OFFICE
BRAND IMAGE refurnishing standardization-2011 Guidelines for uniform pattern in
Branch / Office premises
i) Guidelines for general layout:
The consultants appointed for any furbishing project as per the prevailing laid down
guidelines will prepare the layout plan of the branch premises in consultation with
corporate services / A&S dept. besides the information technology department and
security department of Zonal Office and Branch manager as per the requirement of the
branch.
Following features are required to be incorporated in the layout plan.
a) Diamond customer lounge / Relationship Manager
In the branches having more than 500 Diamond customers, a Diamond customer lounge
(D.C. lounge) along with relationship manager (R.M.) is required to provide. It preferable to
have the D.C. Lounge along with R.M s cabin adjacent to the branch manager s cabin. The
modules having indicative sizes of the diamond customer lounge along with the
relationship managers cabin and branch managers cabin and diamond customers lounge
along with RMs cabin are shown in the drawings No. (16) and (3) respectively for your
guidance.
The entry to R.M s cabin shall be through D.C. Lounge and if the manager s cabin is
adjoining to the D.C. Lounge, one entry to D.C. Lounge from the manager s cabin shall
also be provided.
Maximum area to be earmarked for the branch manager / relationship manages and
diamond customer s lounge shall be 150 sq.ft, 75 sq.ft. Respectively.
b) Suitable space shall be earmarked for the customers for seating (Max. area
250 sq.ft.
and Max number of seating
20 nos.) if it is not possible to have seating arrangement at
one location, it may be suitably scattered.
c) Provision for drinking water (water dispenser) may be provided in Customer area.
d) Demarcation on the floor (preferably in yellow colour) say 3 from the cash counters, shall
be drawn for the restricting customers from crowing in front of the cash counters. Also
stainless steel chain link in between two cash counters may be provided in customer s
area.
e) All statutory notices / instructions are to be displayed on the single board which shall be
placed at prominent location in the customer s area. The background of board shall be
blue (matching with blue colour laminate no. 1) with white letters.
f) Provision for an officer for authorization purpose should be kept near cash counters.
Kanamadi Associates
g) Lunch room for staff: Lunch room may be earmarked for staff with the seating for
maximum 20% of staff strength of the branch depending upon the availability of space in
the branch.
h) In CBS branches, no server room is required. As the web-server is being provided in
manger s cabin, therefore the router may be provided at suitable location in manager s
cabin in consultation with Zonal I.T. dept. and data cables may be converted with wooden
boxing finished with laminate no. 3. Suitable arrangement for ventilator (exhaust fan) and
also for air-circulation (wall fan) may be provided for avoiding heating in consultation with
zonal I.T. Department.
i) The UPS room shall be located in such a way that it has proper ventilation.
j) Preferably the electrical conduits should be concealed so as to have neat and clean
ambience.
k) In the Branches headed by the by. General Manager or Asst. General Manager, only
cubicles shall be provided to the Chief Managers posted in the branch.
ii) Guidelines for Designs & Specifications
The designs and specifications of the following items have been standardized and these
should not be deviated. The designs and specifications of the items which are not covered
hereunder including electrical and other civil works shall be continued to be provided by
the project consultant. We are enclosing photographs showing broad concept of the Front
office counters, cash counters, partitions and tables. However, the colour scheme as
mentioned in simple of laminates / specifications / drawing should be followed.
I) Cash Counter
ii) Front office counter
iii) Partitions
iv) Tables
v) Side and back credenza
vi) Storage units
vii) Entrance door
viii) Façade of entrance door
ix) Flooring
x) False ceiling
i) Cash Counter :
The design of cash counter has been given in drawing as far as possible. The length of
cash counters (frontage) shall be as per the drawing. A suitable passage behind the cash
counters may be provided as per the branch requirement with single door. However, minor
variation in the length of counters depending on the site conditions may be approved by
the Zonal Manager. Blue colour laminate No. 1 boxing as per standard design are to be
provided at both the extreme ends of the cash counter area to define the cash counters as
shown in the photograph.
Kanamadi Associates
ii) Front office counter
The design of front office counter has been given in drawing no As far as possible, the
length of front office counters (frontage) shall be as per the drawing. However, minor
variation in the length of counters depending on the site conditions may be approved by
the zonal managers.
In case of cash counters, the blue colour boxing is provided at the extreme ends of the
cash counters. However, in the case of front office counters, location of the blue colour
boxing varies with number of counters. The different modules for 3 counters / 4 counters /
5 counters are shown in the drawing no. (15). same pattern shall be repeated if the
number of counters are more than 5 nos. e.g. if the counters are six, then module of 3
counters as per the drawing will be repeated.
iii) Partitions
The designs of various partitions are given in drawings as under:
i) Partly glazed (7 7 height) partitions for cash counter
ii) Partly glazed full height partition (relationship manager Cabin / D.D. Lounge) iii) Partly
glazed full height partition (managers cabin)
iv) Door for cash cabins
v) Managers cabin door
vi) Partly glazed low height partitions
vii) Full eight solid partitions
iv) Tables
The design of various tables is shown in drawings. The size if the various tables as under:
Chief Mangers Table: 6 -0 x 2 6
AGM Table : 7 0 x 3 0
DGM Table: 8 -0 x 3 -0
(There are 2 designs for mangers table, one with the left side projection and the other with
the right side projection. The design of the tables shall be decided by the consultant as per
the layout of manager s cabin)
Officer Table: 5 -0 x 2 6
(Include relationship manager)
Staff Table (including daftri) 4 6 x 2.6
v) Side and Back credenza
The side black credenza is as per the drawing. It shall be provided for managers table and
officer s table. The back credenza provided .
vi) Storage units:
The design of full height and low height (4 high) storage units are as per drawing
respectively. However the use of wooden storage units should be restricted to the
minimum.
Kanamadi Associates
vii) Entrance door
The entrance door is given in Drawing All other security department s instructions
contained in IOM No. SD: LKS: 58:5647 dated 28.11.2006 (copy enclosed) in respect of
main entrance to be complied with.
viii) Façade of entrance door
The design of the entrance façade is given in drawing. The width of vertical and horizontal
boxing of the Aluminum cladding may vary as per site conditions. However its width should
not exceed the measurements shown in the drawing.
ix) Flooring:
The colour of the flooring should strictly be as per the model and make specified in the
Annexure A and Annexure B.
iii) Guidelines for co lour scheme:
Colour scheme should not be deviated. We are enclosing the samples of the laminates to
be used wherever specified and these should not be changed. The colour scheme is
should be followed strictly as mentioned in the drawing and no deviation is permitted in
this regard. All wooden beedings / moldings / lip pings etc. should be finished strictly as
per the colour specified in the respective drawing.
The miscellaneous like centre table, side table, notice board, writing shelf / desk etc. shall
be designed by the project consultant as per the site requirement. However the laminates
to be used should be as per the colour of the laminate enclosed.
The fabric of chairs/sofas (in diamond customer lounge) shall be in blue colour.
The wall should be painted in white and one wall preferably near the cash counter should
be painted in yellow as shown in the photograph. The shade and make shall be as per the
Annexure A and B. Gypsum board false ceiling shall be painted using plastic emulsion
paint. However, the walls / ceiling in the non-customer area shall be painted in white oil
bound distemper paint.
iv) Guidelines for false ceiling:
All the branches in metro and urban centers shall be provided with false ceiling. The false
ceiling is not required to be provided in branches located in rural areas. If necessary, the
false ceiling may be provided in branches in semi-urban centers. The false ceiling should
be provided in non-customer area. The false ceiling mainly will be consisting of 2 0 x 2 0
grid system. However to avoid partial grid (less than 2 0 x 2 0 ) at the ends, a band of
uniform size Gypsum board false ceiling may be provided along the periphery. The size of
gypsum board band may be decided by the project consultant after preparing the false
ceiling plan.
v) Guidelines for flooring:
Kanamadi Associates
All the branches in metro and urban centers shall be provided with vitrified tile flooring. If
necessary, vitrified tile flooring may be provided in branches at semi-urban centre. Vitrified
tile flooring should not be provided in non-customer area. Wherever alternate / new
premises are acquired on lease, it must be ensured that vitrified tile flooring in metro /
urban centers and ceramic tile flooring in semi-urban centers should be provided by the
landlord(s) at their cost.
vi) General guidelines
We are enclosing Annexure A and B containing detailed specification to be incorporated
in bill of quantities and approved makes of materials respectively for tender purpose.
BANK OF INDIA INTER-OFFICE MEMORANDUM
From: To: The General Manager The Zonal Manager Head Office All Zones Security Department
SD/LKS/58/5647 Dated:
THE SECURITY ARRANGEMENTS REPLACEMENT OF CHAI AND LOCK
INSTALLED ON COLLAPSIBLE GATE AT THE MAIN ENTRANCE AT THE
BRANCHES IN METRO AND URBAN CENTRES
We have been advised by the Govt. of India, Ministry of Finance to consider replacing the chain and lock installed at the collapsible gates on the main entrance to facilitate easy and hurdle free access to customers inside the branch premises. This instruction of the government refers to customers complaining about the difficulty they face especially the woman and elderly people in entering the public sector bank. Whereas a private bank located next door in the same area does not have this kind of restriction.
2. The matter has been discussed at top management level and it has been decided as under: a) All the metropolitan and urban centre branches the chain and lock installed on the
collapsible gate at the main entrance will be removed. b) Collapsible gates will remain but they will be widely opened for easy access to
Customers c) If the branch is air conditioned, a glass door (if not already installed should be
installed with a door closer so that if remains closed at all the times. d) In non-air conditioned branches the collapsible gate will be kept opened at the
distance of 4 feet to allow free access to customers. e) Wherever space permits a turnstile door will be installed, design of which will be
sent to you soon from the head office. f) All rural / semi urban centers branches will continue to have the chain and
lock installed on collapsible door, however if two chains are installed the lower one will be removed
3. You are requested to advise to branches for immediate compliance. 4. Please acknowledge.
(GENERAL MANAGER)
CONSULTANTS
KANAMADI & ASSOCIATES
ARCHITECTS AND ENGINEERS
MALLESHWARAM, BANGALORE 56003
PROPOSED INTERIOR WORK OF BANK OF INDIA, BRANCH OFFICE AT MADIKERI
Sl.No. Description of the work Unit Qty. Rate Amount
1 BANKING COUNTER
Providing and fixing in position front office counter, 2'6" wide,
bill of quantity
PROPOSED INTERIOR WORK OF BANK OF INDIA, BRANCH OFFICE AT MADIKERI
Providing and fixing in position front office counter, 2'6" wide,
comprising of the following complete in all respects :1. Working top made with 25mm thick BWP plywood finished.
Outside edge of the working top shall be provided with 1 1/4" x 1" TW
moulding finished with melamine polish. Inside edge will be provided
with 1/2" x 1" TW beadin patti with melamine finish.2. Vertical facia (apron) made with 18mm thick BWP plywood finished
with 1 mm thick aminate with 1mm thick groove at the joint of
laminates of two different shades.3. Vertical drop (horizontal band) shall be provided on the facia below3. Vertical drop (horizontal band) shall be provided on the facia belowthe working top made with 18mm thick BWP plywood finished with1mm thick laminate with provision for concealed light, 1mm thickgroove shall be provided at the joint of two different shades oflaminate.4. Glazed partition above working top to be provided with 12mm thickclear glass, cut to the standard shape, fixed to partition as per fixingdetails and to boxing with concealed SS finished D-bracket as shownin the drawing. The exposed edges of the glass shall be finished withmirror polish.5. 3'-10" high boxing (10"x10") made with 19mm thick plywood5. 3'-10" high boxing (10"x10") made with 19mm thick plywood
finished with 1mm thick laminate including providing and fixing 6mm
thick square frosted glass at a height 3'-2" above finished floor level.6. 1'-9" high boxing (5"x5"), made with 12mm thick plywood finished
1mm thick laminate.7. Vertical supports made with 19mm thick plywood finished withwhite enamel paint.8. Telescopic CPU stand/ready made keyboard tray shall be provided
of approved model and make.9. Footrest made with TW membe of size 4"x11 1/2" finished with9. Footrest made with TW membe of size 4"x11 1/2" finished withfrench polish.10. Drawer units as per drawing shall be provided with multipurpose
Godrej Locks in each drawer. Facia of drawer unit shall be finished
with 1mm thick laminate and all other sides shall be finished with
white enamel paint. The drawers shall be provided with handles (SS
finish) and channels as per specified brands.11. Boxing as per drawing made with q3mm thick BWP plywoodfinished with synthetic enamel paint shall be provided below the tabletop for electrical conduiting and at the bottom for the LAN cabling /top for electrical conduiting and at the bottom for the LAN cabling /telephone wire conduiting.The item shall include all necessary hardware and fittings in SSfinish, lipping to all edges and making provision only for electricalfitting behind the front vertical drop and also in the 10" x 10" boxingas shown in the drawing. Necessary beadings with melamine polishfor fixing the glass are to be provided. Rft 12.00
2 CASH COUNTER
Providing and fixing in position cash counter, 2'9" wide, as per
drawing comprising of the following :drawing comprising of the following :1. Working top made with 25mm thickBWP plywood finished with1.5mm thick laminate. Outside edge of the working top shall beprovided with 1 1/4" x 1" TW moulding finished with melamine polish,inside edge will be provided with 1/2" x 1" TW beading patti withmelamine polish.2. Vertical facia (apron) made with 19mm thick BWP plywood finishedwith 1.5 mm thick laminate with 1mm thick groove at the joint oflaminates of two different shades.
3. Vertical drop (horizontal band) shall be provided on the facia below
the working top made with 19mm thick plywood finished with 1mm
thick laminate with provision for concealed light, 1mm thick groove
shall be provided at the joint of two different shades of laminate.shall be provided at the joint of two different shades of laminate.4. Glazed partition of 1'-4" height above working top provided with
12mm thick toughened and frosted glass besides non transparent
firm from inside fixed to partition as per fixing details and to boxing
with concealed SS finished D-brackets as shown in the drawing. The
exposed edges of the glass shall be finished in mirror polish. 5. Transaction top shall be provided with 12mm thick toughenedglass (partly glazed, partly frosted) fixed horizontally with concealedSS D-bracket. Both exposed edges (inside and outside) shall bemoulded and finished in mirror polish.moulded and finished in mirror polish.6. Glazed partition having height 1'-0" above the transaction (in facia)
shall be provided with 12mm thick glass (clear) with cut out of 8"x4"
as per drawing. The edges of cut out and the top edge of glass are to
be mirror polished and to be fixed to partition as per fixing details and
to boxing with concealed SS finished D-brackets as shown in the
drawing. The exposed edges shall be finished with mirror polish.7. 7"-7" high boxing (10"x10") made with 19mm thick plywood as perdrawing with 1'-6" horizontal extension at the top including providingand fixing 6mm thick square frosted glass at a height of 5'-11" aboveand fixing 6mm thick square frosted glass at a height of 5'-11" abovefinished floor level.8. 1'-9" high boxing (5"x5"), made with 12mm thick plywood finished
with 1mm thick laminate.9. Telescopic CPU stand/ready made keyboard tray shall be provided
of approved model and make.10. Footrest made with TW member of size 4"x1.5" finished with
french polish. 11. Drawer units as per drawing shall be provided with multipurpose
Godrej locks in each drawer. Facia of drawer unit shall be finished
with 1mm thick laminate and all other sides shall be finished with
white enamel paint. The drawers shall be provided with handles (SS
finish) and channels as per specified brands.12. Boxing as per drawing made with q3mm thick polywood finishedwith synthetic enamel paint shall be provided below the table top forelectrical conduiting and at the bottom of the LAN cabling / telephonewire conduiting.The item shall include all necessary hardware and fittings in SSfinish, lipping to all edges and making provision only for electricalfitting behind the front vertical drop and also in the 10" x 10" boxingfitting behind the front vertical drop and also in the 10" x 10" boxingas shown in the drawing. Necessary beadings with melamine polishfor fixing the glass are to be provided.13. Boxing as per drawing made with 12mm thick plywood finishedwith synthetic enamel paint shall be provided below the table top forelectrical conduiting and at the bottom for the LAN cabling /Telephone wire conduiting.The item shall include all necessary hardware and fittings in SS
finish, lipping to all edges and making provision only for electrical
fitting behind the front vertical drop and also in the 10" x 10" boxing
as shown in the drawing. Necessary beadings with melamine polish
for fixing the glass are to be provided. Rft 6.00
3 SOLID FULL HEIGHT PARTION
Providing and fixing in position solid full height partition in frame workincluding door in 2'x2' grid (vertically and horizontally) comprising of1"x1.5" TW section with 6mm thick BWP plywood on both sidesfinished with 6mm thick plywood on both sides finished with 1.5mmthick laminates of approved make and colour as shown in drawing.Item to include 2'x2" TW member for door frame. All exposed TWsurfaces to be finsihed in melamine polish of matching laminatesurfaces to be finsihed in melamine polish of matching laminatecolour as directed, including all necessary SS finish fittings/hardware, door closers, Godrej locks and wood preservative paintetc., as directed, complete in all respects.Note : In case of false ceiling, the vertical TW members to be fisedwith pucca ceiling but the area of partition payable will be below thefalse ceiling only. Sft 240.00
4 PARTLY GLAZED FULL HEIGHT PARTITION4 PARTLY GLAZED FULL HEIGHT PARTITION
Providing and fixing in position partly glazed full height partition work
as shown in the drawing, including door, in framework at 2'x2' grid
(horizontally & vertically) comprising of 2"x1.5" TW section, as per
framework shown in the drawings with 6mm plywood on both sides
finished with 1mm thick laminate of approved sade and colour as
shown in drawings. Item to include 8mm thick glass with etching and
frosting as per design and 2'x2' TW member for door sides and glass
sides and TW door frame to take 8mm thick glass with etching andsides and TW door frame to take 8mm thick glass with etching and
frosting.All exposed TW surfaces to be finished with melamine polish
of matching laminate colour as directed, including all necessary SS
finish fittings / hardware, door closers, Godrej locks and wood
preservative paint etc., as per list of approved materials and as
directed, complete in all respects.(Note : In case of false ceiling, the
vertical TW members to be fised with pucca ceiling bit the area of
partition payable will be below the false ceiling only. sft 200.00partition payable will be below the false ceiling only. sft 200.00
5 PARTLYALUMINIUM PARTION FOR CASH CABINSProviding and fixing in position 7"x7" high, partly aluminium grill
partition for Cash Cabins as per drawings, including door, in frame
work at 2'x2' grid (horizontal & vertically) comprising of 2" x 1.5" TW
section and/or as per framework shown in drawings with 6mm
plywood on both sides, finished with 1mm thick lamina te of approved
shade and colour as shown in drawing. as per design and 2'x2' TW
member for door sides and glass sides and TW door frame to take
aluminium grill aluminium grill The door will be provided with TW louvres finished with melamine
polish of matching laminate colour. The doors are also to be provided
with Godrej night latch. Two wooden trays are also to be provided as
per drawing. Necessary cutouts are to be provided in the glass and
the edges of the glass cutouts are to be finished in mirror polish.All exposed TW surfaces to be finished with melamine polish ofmatching laminate colour as directed, including all necessary SSfinish fittings / hardware, door closers, Godrej locks and woodpreservative paint etc., as per list of approved materials and aspreservative paint etc., as per list of approved materials and asdirected, complete in all respects. sft 250.00
6 12 MM THIK GLASS PARTITION
Providing and fixing in position fully glazed full height partition (2'5"thick) in framework with TW vertical members @ 2' c/c and 3horizontal members at equal distance comprising of 2'x1.5" TWsection with 6mm plywood on boths ides finished with 1mm thicklaminates of approved make and shade as shown in drawing. Item toinclude 12mm thick glass (clear / frosted) to be fixed as shown indrawing. The exposed edges of the glass to be finished in mirrorpolish. TW runner should be melamine polished in matching colour oflaminate etc., complete in all respects. sft 100.00
7 PARTLY GLAZED LOW HEIGHT PARTITION
Providing and fixing in position partly glazed low height partition (2'5"thick) in framework with TW vertical members @ 2' c/c and 3horizontal members at equal distance comprising of 2'x1.5" TWsection with 6mm plywood on boths ides finished with 1mm thick
laminates of approved make and shade as shown in drawing. Item to
include 12mm thick glass (clear / frosted) to be fixed as shown in
drawing. The exposed edges of the glass to be finished in mirror
polish. TW runner should be melamine polished in matching colour of
laminate etc., complete in all respects. sft 135.00
8 MANAGER TABLE WITH SIDE CREDENZA
Providing and fixing in position Manager's Tables of size 6'0" x 2'6"
including side storage (credenza) by using 25mm thickBWP plywood
for top and 19mm thick plywood for all other horizontal and vertical
members. Telescopic CPU stand / readymade keyboard tray shall be
provided, of approved model and make. Footrest made with TW
member of size 4"x1.5" finished with French polish.Side storage
(credenza) shall be provided as per drawing. Facia of side storage(credenza) shall be provided as per drawing. Facia of side storage
shall be finished with 1mm thick malinates as shown in the drawing
and all other sides shall be finished with white enamel paint. The side
storage shall be povided with handles (SS finish) and channels as
approved. All exposed plywood surfaces to be finished with 1.5mm
thick laminate of approved made and shade, and all exposed edges
of table top & plyveticles to have 1"x.25" TW lipping. All exposed TW
sections to be melamined and internal surfaces to have white enamel
paint as directed. Item to include plywood boxing, all necessary
hardware and fittings in SS finish, lipping to all edges etc., complete
in all respects. Nos 1.00
9 OFFICERS TABLE WITH SIDE CREDENZA Providing and fixing in position Staff Table of size 5.0" x 2'6" as per
drawing by using 25mm thick plywood for top and 19mm thick BWP
plywood for all other horizontal and vertical members. Telescopic
CPU stand / readymade keyboard tray shall be provided.Drawer units as per drawing shall be provided with multipurpose
Godrej locks in each drawer. Facia of drawer unit shall be finishedGodrej locks in each drawer. Facia of drawer unit shall be finished
with 1.0mm thick laminate and all other sides shall be finished with
white enamel paint. The drawers will be provided with handles (SS
finish) and channels as approved.All exposed plywood surfaces to be finished with 1mm thick laminate
of approved make & shade, and al exposed edges of table top & ply
veticals to have 1"x0.25" TW lipping. All exposed TW sections to be
melamined and internal surfaces to have white enamel paint as
directed. The item to include plywood boxing, all necessary hardwaredirected. The item to include plywood boxing, all necessary hardware
fittings in SS finish, lipping to all edges etc., complete in all respects. Nos 4.00
10 SIDE CARDENZAProviding and fixing in position Low Height Storage (2'6"high) as
shown in drawing using19MM BWP plywood of required thickness
finished with 1.5mm thick laminate as shown in the drawing and all
other sides shall be finished with white enamel paint as detailed
therein.The storage units shall be provided with handles (SS finish)
as directed. Nos 7.00as directed. Nos 7.00
11 CASH COUNTING TABLE
Providing and fixing cash counting table of size 5'0"x2'0"x 2'6" withlaminate finish and melamine polish etc. Nos 1.00
12 Daftri Table : Same as Officer table Size 4'0" x 2'0" x 2'6"Nos 1.00
13 LOW HEIGHT STORAGE
Providing and fixing in position Low Height Storage (2'6"high) asProviding and fixing in position Low Height Storage (2'6"high) as
shown in drawing using19MM BWP plywood of required thickness
finished with 1.5mm thick laminate as shown in the drawing and all
other sides shall be finished with white enamel paint as detailed
therein. The storage units shall be provided with handles (SS finish)
as directed.All exposed plywood surfaces to be finished with 1.5mm laminate of
approved make & shade and all exposed edges of plywood to have
1"x0.25" TW lipping. All exposed TW sections to be melamined in
matching colour laminate and internal surfaces to have white enamelmatching colour laminate and internal surfaces to have white enamel
paint as directed. Item to include all necessary hardware and fittings
in SS finish, Godrej multipurpose locks including magnetic ball
catcher etc., complete in all respects. sft 110.00
14 ENTRENCE DOOR
Providing and main entrance door fabricated ,assembled and fixed in
position with tw frame of size 4"x2.5" and shutter made out of tw
4x1.5" styles and rails and infilled 12mm thick etched glass with
necessary tw beading and melamine polish etc complete. sft 30.00necessary tw beading and melamine polish etc complete. sft 30.00
15 FALSE CEILING (GYPSUM BOARD)
Providing and fixing in position false ceiling in Gupboard 12mm thick
for horizontals and verticals fixed over GO framework as specified by
India Gypsum Co. including trapdoors for AC units in 19mm thick MR
grade plywood with SS hinges & locks with moulding 1"x1" for edges
including finishing with White plastic emulsion paint etc., complete in
all respects. Note : Only the plan area will be measured for payment.all respects. Note : Only the plan area will be measured for payment.
No extra payment will be made for cutouts, grooves, mouldings etc sft 450.00
16 ARMSTRONG FALSE CEILING
Providing and fixing Armstrong false celing using 19mm thick celing
panel of 2' 0"x2' 0" size grid fissured pattern /elite RH99/ any
approved pattern and fixing the same on grid suspension system
using main T bar, cross bar and wall moulding, hanger wire holder,
down clip etc all as standred specification (Rate to include cut out for
electrical fittings, spot lights sft 950.00electrical fittings, spot lights sft 950.00
17 VERTICAL BLINDS
Providing and fixing 100mm wide VERTICAL BLINDS of fabric 100%polyester, as approved, with regular imported mechanism andincluding all standard fittings, accessories as per the manufacturersspecification, for windows. sft 150.00
18 CHEQUE WRITING DESK
Providing and fixing WRITING DESK of 450mm deep in 12mm thickclear glass with bevelled edges supported on TW brackets of 75mmx400mm x 50mm finished with melamine polish etc., complete as per400mm x 50mm finished with melamine polish etc., complete as perdrawings and as directed. Nos 1.00
19 TEXTURE PAINTING
Providing and painting with texture paint of approved shade andcolour including necessary primer, putty, and finishing with texturepaint as per instruction and curing etc complete. sft 400.00
20 CHEQUE DROP BOX
Manufacturing and Supplying cheque drop box made out of 19mm thblock board with slit for cheque drops and necessary shutter forremoving the instruments with locking arrangement, exposed surfacefinished with 1mm thick laminate of approved colour and make andfinished with 1mm thick laminate of approved colour and make andinside surface painted with white enamel paint of approved make etccomplete. no 1.00
21 SUGGESATION BOX
Manufacturing and Supplying suggesation box made out of 19mm thblock board with slit for cheque drops and necessary shutter forremoving the instruments with locking arrangement, exposed surfacefinished with 1mm thick laminate of approved colour and make andinside surface painted with white enamel paint of approved make etccomplete no 1.00
22 SOFT BOARD/PINP BOARD
Providing and fixing soft board/pinp board using 12mm thick softboard cover with 6mm ply backing with boarder design beading goodquality velvet cloth. Size: 6'0"x4'0" no 1.00
23 WICKET GATE
Providing and fixing wicket gate using 30mm block board with 1mmlamination both sides covered with teak wood beading all visibleedges with necessary hard ware,T- bolts, etc.complete. Sft 10.00
TOTAL COST OF INTERIORSTOTAL COST OF INTERIORS
Recommended