Selection Guide Price List 2014

SELECTION GUIDEPrice List 2014

Gu

nn

ebo

rese

rves

th

e ri

ght

to m

odif

y, a

lter

or

up

dat

e p

rod

uct

info

rmat

ion

wit

hou

t n

otic

e.

GU

GB.

uk.

91

07

.R1

CONTENTSWelcome to Gunnebo 3

Choosing a product 4

Chubbsafes 6

Air 8

Water 9

Earth 10

Fire 11

Counter Unit 12

Epsilon 13

ForceGuard 14

AlphaPlus 15

Cobra 16

Zeta 17

Deca 18

Cobra Pro 19

Evolve 20

DuoGuard 22

ProGuard 22

Trident 24

Sigma Deposit 26

Omega Deposit 27

Sovereign Deposit 28

ProGuard DT 29

Profile NT 30

Archive Cabinet 31

Executive 32

Duplex 33

Office 34

Record Protection Cabinet 35

DataGuard NT 36

DataPlus 37

Centurion Vault 38

Centurion Door 39

ModuleGuard 40

MagTek A 41

Churchill 42

Magpie Wall Safe 44

Domestic 45

Vector 46

Bulldog 400 47

Sapphire 48

Ruby 49

Emerald 50

Notes 51

Rosengrens 52

2000C Safe Deposit Lockers 54

Sargasso 56

Notes 57

Terms & Conditions 58

Eurosafe is an association of safe manufacturers in mainland Europe established over 25 years ago. A sister organisation, Eurosafe UK was launched in March 2011 to represent the interests of British safe makers, and the suppliers and installers of safes and security containers

The primary objective of Eurosafe UK is to restore confidence in European standards for testing and rating cash safes, security cabinets, document fire safes and computer data safes.

Eurosafe UK will encourage insurers, specifiers, buyers and users to choose cash safes tested and certified by the BRE/LPCB in the UK or European test houses affiliated with the European Fire & Security Group (EFSG) or those products certified by the European Certifica-tion Board•Security (ECB•S).

Member companies will campaign to resist the lowering of security standards by manufacturing and supplying high quality, insurance approved products.

Those companies specialising in refurbishing used safes undertake to adhere strictly to BS7582: 2005 Code of practice for reconditioning of used safes.

Member companies will be encouraged to display the Eurosafe logo as a symbol of quality and ethical standards.

OUR ICONS EXPLAINED

TOP SELLER

NEW

Top selling product Key lock Burglary protectionFire protection for paper documents

New product for 2014

Electronic lockFire protection for data media

Explosives protection

Approved by The Association of Insurance Surveyors

Selection Guide 2014 3

Our product range

Gunnebo is acknowledged as a worldwide leader in security products with a reputation of excellence in quality, reliability and

optimum security. This approach is reflected in the nature of the product range.

Each of the products have been designed, manufactured and tested to benefit you. The result is a flexible and customisable

range of safes, cabinets and vaults. Such a comprehensive product range means that finding a security solution is a simple

process. After all, we do want to solve your problem.

Chubbsafes ...the premier cash & fire protection brand

Domestic users, retailers and banks are forever reviewing the secure storage of cash and

valuables within their environments. Faced with increasing threats to security, users are

constantly striving for products of the highest quality, reliability and technical specification.

Such products can be easily found within the Chubbsafes range. Choice doesn’t end once you

have selected the safe or cabinet that is perfect for you. Each solution can be customised with

a host of options (e.g. locking, fittings and deposit facilities) to meet your security needs.

Churchill Safes ...the premier underfloor safe brand

Churchill Safes are recognised as the leading brand for underfloor safes. Such success is based

upon understanding the security market and meeting customer needs. This commitment

and initiative is reflected in the Churchill Safes product range. Products vary from a small wall

safe to high security underfloor safes. Such a comprehensive range means that finding an

underfloor solution is a simple process.

Rosengrens ...the premier document protection brand

For every business protection of documentation is of paramount importance. Losing this

invaluable information can lead to a disastrous impact on the business.

Common outcomes include the loss of clients and a decline in capacity to attain new business.

With the Rosengrens product range you are sure to find a flexible and secure solution.

Combining unique design and innovative features, each safe or cabinet ensures that your

documents are securely protected to the highest standards.

WELCOME TO THE GUNNEBOSelection Guide 2014

Picking a new safe for the home or business can be a struggle, especially

when you don’t know where to start.

With Gunnebo, you can be assured that we will guide you carefully

through the selection process, a process which begins by identifying

your security objectives. Once complete, a number of suitable security

solutions will be offered and comprehensive support given regarding

the delivery and installation of the safe.

All in all, Gunnebo aims to make sure the selection process is a flexible,

simple and thorough one.

PLANNING, DELIVERY & INSTALLATIONThe complete service

Once you have selected a safe or cabinet, Gunnebo can offer you a

comprehensive installation survey (for certain products only). Gunnebo

will then agree with you a flexible installation schedule. The flexibility

of the installation process is evidence of Gunnebo’s commitment

towards ensuring the cost and time efficient completion of your purchase.

Gunnebo products are delivered and installed by trained Gunnebo

installers. Whatever the delivery environment (e.g. large bank or small

office), you can be assured that the installers will take the greatest care.

We are also focused on making sure the service on offer is achievable,

to the highest standards of workmanship and is promptly completed

within the contracted timescales.

CHOOSING A PRODUCT IS SIMPLE


DEFINITIONS

Key Lock: A manual key operated lock.

Mechanical Combination: A mechanical keyless dial lock with a

changeable combination.

Electronic Lock: An electronically operated keypad lock with a

changeable combination.

Manager Mode: Allows one user to control the functions of other

combination holders.

Number of Users: The number of users able to program in their own

access code.

Duress Feature: It is possible for an alarm engineer to link the lock

into a monitored alarm system. It is then possible, by a given

procedure, to operate the lock, open the safe and silently signal to the

monitoring station that this is being done under duress.

Time Delay: This feature allows for a pre-set delay between operating

the lock and being able to open the safe. The operation may vary

between lock types.

Time Lock: Time lock allows the user to set periods during which the

lock may be operated, e.g. during business hours only. The options

available will vary between locks.

Audit Trail: The lock is able to give a report (it will vary in detail from

model to model) of usage and may show times of operation, codes

used and operations performed.

Dual Control: Allows two users to enter their details before any

operation can be performed.

CustomisationDependant on the product grade or size, most safes or cabinets can have a

different lock (e.g. electronic), deposit option (e.g. front facing drawer trap) or

fitting (e.g. cupboard) to meet your customer requirements. For example, the

DataPlus can include pullout drawers so that it can hold more CDs, DVDs or

diskettes.

For further details and technical information regarding customisation please

feel free to contact Gunnebo or your local authorised dealer. As always,

Gunnebo will endeavour to provide a customisation solution which meets

your expectations.

Locking OptionsAs mentioned, Gunnebo can customise your safe or cabinet with a different

lock.

Our comprehensive lock range includes the latest industry locks which offer a

wide range of features. So whether it be the “mechanical combination” lock

or a more hi-tech electronic solution, Gunnebo are sure to have a lock which

will meet your security needs. We have explained the key terms associated

with locks below.

If you have any additional questions please contact Gunnebo or your local

Gunnebo Authorised Dealer.

CHOOSING THE RIGHT PRODUCT

To find out which product is most suitable for your security requirements you

need to answer the following questions:

1. What do you want to protect?

Cash, Valuables, Documents or Data media

2. What is the volume or size that you want to protect?

Having done this you can either choose from BRE (Burglary Resistant

Equipment) or FRE (Fire Resistant Equipment) products. The BRE range

includes safes, cabinets and vaults designed to protect cash and valuables.

Available in differing sizes and specifications our safes offer optimum

protection for up to £150,000 or £1,500,000 in valuables.

The FRE range includes files and cabinets designed to protect against fire.

You can either protect data media or documents and in some cases a mixture

of both. These products are rated according to their level of fire protection.

Cash RatingCash Rating is “The amount an insurance company will cover in a safe/

cabinet overnight.“

The actual amount of cover can vary between insurance companies and

locations and may be different to the manufacturer’s recommended rating. If

this is important to you, you should check what cover your insurance company

will offer.

As a general rule, this rating is multiplied by a factor of 10 for jewellery. Hence,

a Duoguard Grade I with a cash rating of £10,000 will store jewellery in

domestic circumstances worth up to £100,000.

Fire ProtectionMeasured through tests carried out by Independent testing authorities.

“The longer the period in minutes, the greater the fire resistance offered. The

critical temperature before paper documents combust is 177°C. Whereas,

data media is damaged at temperatures over 52°C or humidity over 85%.”

Care should be taken to ensure that the test certificate held by the

equipment is applicable to modern media i.e a DIS label.

TestingTo provide the appropriate level of protection for our products, Gunnebo

ensures that they are tested against the latest industry standards. These

standards vary according to whether you want to protect data media or

documents. This is because the temperature at which data media (e.g. 52 °C)

and documents (e.g. 177 °C) deteriorate differs according to the item protected.

In order to fully protect data media, industry standards indicate that products

should carry ECB•S EN 1047-1 or NT Fire 017 60/120 DIS.

The ECB•S test monitors the internal temperature of the data cabinet until it

has completely cooled down during the “soak-out” period. Assessing products

during this period is essential since internal temperatures can peak up to 6 to

8 hours after a fire has been extinguished. Such a test ensures that all products

are comprehensively tested and upon passing, will fully protect your data media

for the 60 or 120 minutes stated.

For document protection all products must have an appropriate industry

standard 30 minute paper certificate as a minimum.

EN 15659 (30 P), UL72-Class 350, ECB•S EN 1047-1 or NT Fire 017 are

acceptable standards for paper document protection.

...the premier cash & fire protection brand

Domestic users, retailers and banks are forever reviewing the secure

storage of cash and valuables within their environments. Faced with

increasing threats to security, users are constantly striving for products of

the highest quality, reliability and technical specification. Such products

can be easily found within the Chubbsafes range. Choice doesn’t end once

you have selected the safe or cabinet that is perfect for you. Each solution

can be customised with a host of options (e.g. locking, fittings and deposit

facilities) to meet your security needs.

Visit Gunnebo UK on LinkedIn

www.chubbsafes.com

8 Selection Guide 2014

air£1,000 cash rating

Model above is Air Laptop

View the product videos on our YouTube channel

www.youtube.com/chubbsafes

Key Features

• Compact safe for the home or office

• Recommended cash rating of £1000

• Suitable for storage of valuables such as jewellery and cameras

• Choice of key lock or electronic lock

• Steel door and body with dual, plated steel moving boltwork

• Two sizes available – 9 and 16 litres – as well as special models for hotels and laptop storage

• Removable shelf in Air 15

ModelExternal (mm)

Height Width Depth*Internal (mm)

Height Width DepthVolume (litres)

Weight (kg)

CashRating

RetailPrice

Delivery Price

Aldridge Product

Code

Key Lock

Air 10K 200 310 200 190 300 150 9 7 £1,000 £69 £21 L18857

Air 15K 250 350 250 240 340 200 16 10 £1,000 £82 £21 L18859

Electronic Lock

Air 10E 200 310 200 190 300 150 9 7 £1,000 £89 £21 L18858

Air 15E 250 350 250 240 340 200 16 10 £1,000 £110 £21 L18860

Air: Laptop 200 430 350 190 420 300 24 12 £1,000 £126 £21 L18861

Air: Hotel** 200 430 350 190 420 300 24 12 £1,000 £189 £21 L18862 * Lock and handle projection 35mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery** CEU unit and software available at an additional cost

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

For your safe spares please contact Gunnebo Safe Spares on 07919 015975 or 01902 271378You can now buy spares online www.safespares.co.uk

Available through our preferred distributor – Aldridge Security

Tel: 08444 125 101 (Landline), 03444 125101 (Mobile), Ireland 01 647 0048E-Mail: [email protected] Web: www.aldridgesecurity.co.ukFax: London 0800 137 933, Manchester 0800 137 932, Ireland 01 647 0049

Visit www.chubbsafeselements.com to find out more

Scan the QR-code with your smartphone for quick access to the site!


water£2,000 cash rating

Key Features


• Cash rating of £2000

• Certified by ECB•S according to EN 14450 Level S1 for burglary protection

• Suitable for storage of valuables such as jewellery, cameras or other valuable equipment


• Steel door and body with reinforced bolts and anti-drilling plate for extra protection

• Four sizes available – capacity from 29 to 51 litres

• One removable shelf as standard

• Interior LED light on electronic lock models

Model above is Water 40E



ModelExternal (mm)



Weight (kg)

CashRating

RetailPrice

Drop off Delivery Price**

Delivery & Position

Price

Aldridge Product

Code

Key Lock

Water 30K 275 375 350 269 369 294 29 31 £2,000 £225 £21 £115 L18863

Water 40K 375 375 350 369 369 294 40 36 £2,000 £269 £60 £115 L18865

Water 50-1K 375 475 350 369 469 294 51 43 £2,000 £312 £60 £115 L18867

Water 50-2K 475 375 350 469 369 294 51 43 £2,000 £344 £60 £115 L18869

Electronic Lock

Water 30E 275 375 350 269 369 294 29 31 £2,000 £387 £21 £115 L18864

Water 40E 375 375 350 369 369 294 40 36 £2,000 £430 £60 £115 L18866

Water 50-1E 375 475 350 369 469 294 51 43 £2,000 £492 £60 £115 L18868

Water 50-2E 475 375 350 469 369 294 51 43 £2,000 £512 £60 £115 L18870 * Lock and handle projection 35mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

EN 14450

S1

EN 1300 EN 1300




Visit www.chubbsafeselements.com to find out moreScan the QR-code with your smartphone for quick access to the site!


earth£4,000 cash rating

Key Features


• Cash rating of £4000

• Certified by ECB•S according to EN 14450 Level S2 for burglary protection


• Body consists of two steel plates filled in-between with a fire-retardant material

• Four sizes available – 15, 38, 54 and 76 litres


• Interior LED light on electronic lock models

ModelExternal (mm)



Weight (kg)

CashRating

RetailPrice


Delivery & Position

Price

Aldridge Product

Code

Key Lock

Earth 15K 300 370 350 210 280 250 15 38 £4,000 £239 £60 £115 L18871

Earth 40K 440 450 400 350 360 300 38 60 £4,000 £344 £60 £115 L18873

Earth 55K 590 450 400 500 360 300 54 76 £4,000 £401 £60 £115 L18875

Earth 75K 790 450 400 700 360 300 76 92 £4,000 £466 £60 £115 L18877

Electronic Lock

Earth 15E 300 370 350 210 280 250 15 38 £4,000 £428 £60 £115 L18872

Earth 40E 440 450 400 350 360 300 38 60 £4,000 £495 £60 £115 L18874

Earth 55E 590 450 400 500 360 300 54 76 £4,000 £644 £60 £115 L18876

Earth 75E 790 450 400 700 360 300 76 92 £4,000 £666 £60 £115 L18878 * Lock and handle projection 35mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

EN 14450

S2


EN 1300 EN 1300

Model above is Earth 15E





Visit www.chubbsafeselements.com to find out more

Scan the QR-code with your smartphone for quick access to the site!


fire£4,000 cash rating

Key Features

• Combined fire and burglary protection in one safe

• Perfect for the protection of cash and valuables as well as passports, property records,

legal papers and other important documents

• Certified by ECB•S for 30 minutes fire-resistance (EN 15659, 30 P)

• Certified by ECB•S for Level S2 burglary protection (EN 14450)


• Four sizes available – 18, 26, 31 and 51 litres


ModelExternal (mm)



Weight (kg)

FireRating (mins)

CashRating

RetailPrice


Delivery & Position

Price

Aldridge Product

Code

Key Lock

Fire 20K 315 445 440 185 334 290 18 52 30 £4,000 £281 £60 £115 L18962

Fire 25K 490 360 440 360 249 290 26 62 30 £4,000 £360 £60 £115 L18963

Fire 30K 460 440 440 330 329 290 31 68 30 £4,000 £378 £60 £115 L18964

Fire 50K 670 440 440 540 329 290 51 91 30 £4,000 £459 £60 £115 L18965

Electronic Lock

Fire 20E 315 445 440 185 334 290 18 52 30 £4,000 £442 £60 £115 L18958

Fire 25E 490 360 440 360 249 290 26 62 30 £4,000 £521 £60 £115 L18959

Fire 30E 460 440 440 330 329 290 31 68 30 £4,000 £544 £60 £115 L18960

Fire 50E 670 440 440 540 329 290 51 91 30 £4,000 £727 £60 £115 L18961 * Lock and handle projection 35mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

EN 14450

S2

EN 1300 EN 1300EN 15659

30 minutes




Model above is Fire 25E



Visit www.chubbsafeselements.com to find out moreScan the QR-code with your smartphone for quick access to the site!


Key Features

• Helps prevent banknote theft at cash tills

• Mounted under the counter to securely store and protect banknotes

• Easy-to-reach deposit slot

• Stores up to 350 banknotes

• Two key locks – one to open storage unit and one to release from counter for easier emptying

• Solid sheet steel construction

Counter UnitBurglary protection for banknotes

ModelExternal dimensions (mm)

Height Width Depth

Note Capacity

(qty)

Weight (kg)

RetailPrice

Delivery Price

Aldridge Product

Code

CU-350 235 105 190 350 2,4 £45 £21 L18856

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Selection Guide 2014 13For your safe spares please contact Gunnebo Safe Spares on 07919 015975 or 01902 271378

You can now buy spares online www.safespares.co.uk

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Key Features

• Door is made of 6mm steel

• Body is made of 2mm steel

• 16mm diameter steel bolts operating in three directions secure the door

• Epsilon cabinets have a key deposit feature on the side of the safe which allows keys to

be securely deposited inside. Once inside, an anti-fishing plate prevents their removal

• Keys are stored on key hooks which, thanks to internal ladder racking, can be adjusted

to accommodate keys of different lengths

• A four point anchoring kit is supplied so the safe can be securely rear fixed to resist

unauthorised removal once installed

• Double bitted 8 lever key lock

EpsilonBurglary protection for keys


Height Width Depth Internal dimensions (mm)


Weight (kg)

Key Capacity

RetailPrice

Delivery Price

Aldridge Product

Code

Key Lock

Size 1 500 400 130 496 396 77 16 18 88 £216 £21 L21769

Size 2 500 400 180 496 396 127 25 23.5 128 £255 £21 L21770

Size 3 500 400 200 496 396 147 29 24 168 £272 £21 L21771

Size 4 500 400 250 496 396 197 39 27.5 208 £319 £21 L21772 NB. If rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery

Model above isSize 3



Key Features

• Multipurpose cabinet for the protection of cash and valuables (e.g. audio-visual equipment and mobile phones)

• Recommended cash rating of £2,000

• Single wall body constructed from 3mm steel plate. Doors secured by 3-way moving boltwork with a fixed dogging bar

• Secured by a double bitted high security key lock as standard

• Supplied with removable shelves as standard

• Cabinet must be fixed to the floor via the anchoring points in the base

• Available in four sizes

• Finished in a light grey colour

ForceGuard£2,000 cash rating

ModelNumber of doors

External dimensions (mm) Height Width Depth*

Internal dimensions (mm) Height Width Depth

Volume (litres)

Weight (kg)

LockingFittings

(Supplied) Shelf

CashRating

RetailPrice

Delivery & Base Fixing

Price

Size 1 1 1000 600 450 975 575 400 236 80 Key Lock 3 £2,000 £750 £156

Size 2 2 1500 900 450 1475 875 400 534 140 Key Lock 4 £2,000 £1,245 £183

Size 3 2 1900 900 450 1875 875 400 680 225 Key Lock 4 £2,000 £1,508 £211

Size 4 2 1900 1220 450 1875 1195 400 920 275 Key Lock 4 £2,000 £1,812 £310 * Projection of handle is 50mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery


EN 1300

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Key Features


• Suitable for the home and commercial environments

• Constructed with a 6mm steel door

• Double walled construction consisting of 3mm outer steel, 2mm steel inner body with an overall wall thickness

of 40mm. Cavity between the inner and outer body is filled in-between with a fire-retardant material

• Hardened steel plates protect the boltwork and lock against drilling

• 25mm diameter steel bolts secure the door

• Available with double bitted 8 lever key lock or Chubbsafes own programmable electronic lock

• Override key supplied with electronic version

• Fixing kit allows DIY base or rear fixing of safe

• Supplied with removable shelf as standard

AlphaPlus£3,000 cash rating

Model above is Size 2




Height Width Depth* Internal dimensions (mm)


Weight (kg)

Fittings(Supplied)

Shelf

CashRating

RetailPrice


Delivery & Position

Price

Aldridge Product

Code

Key Lock

Size 2 270 350 345 190 270 252 13 26 1 £3,000 £169 £21 £115 L21750

Size 3 320 440 395 240 360 302 26 40 1 £3,000 £224 £60 £115 L21752

Size 6 610 460 395 530 380 302 60 65 1 £3,000 £340 £60 £115 L21754

Electronic Lock

Size 2 270 350 345 190 270 252 13 26 1 £3,000 £203 £21 £115 L21751

Size 3 320 440 395 240 360 302 26 40 1 £3,000 £252 £60 £115 L21753

Size 6 610 460 395 530 380 302 60 65 1 £3,000 £382 £60 £115 L21755 * Lock and handle projection 40mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location



Key Features

• A quality cash safe constructed using highly reliable materials


• Tested to European standard EN 14450, level S2

• Offers 30 minutes fire protection for documents. Tested in accordance to JIS S1037

• Manufactured in accordance with Quality Management System ISO 9001:2008

• Supplied with fittings (see table below)

• Available in five sizes

• Supplied as standard with a key lock and a mechanical combination lock

Cobra£4,000 cash rating




Height Width Depth

InternalVolume(litres)

Weight (kg)

LockingFittings

Shelf Drawer

FireRating (mins)

CashRating

RetailPrice


Price

Size 1 400 500 475 270 370 320 32 185 Key & KC N/A N/A 30 £4,000 £640 £179

Size 2 600 500 475 470 370 320 56 225 Key & KC 1 N/A 30 £4,000 £765 £198

Size 3 750 500 475 620 370 320 73 265 Key & KC 1 1 30 £4,000 £883 £216

Size 4 750 630 575 620 500 420 130 373 Key & KC 1 1 30 £4,000 £1,143 £258

Size 5 980 630 575 850 500 420 179 467 Key & KC 1 1 30 £4,000 £1,344 £288 * Projection of handle is 63mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

LockAdditional

Cut Key

All models £49

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

EN 14450

S2

JIS S1037

30 minutes



BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Key Features

• Cash safe for the home and commercial environments


• Tested and certified to European Standard EN 1143-1

• Secured by a double bitted key lock or user-friendly electronic lock. Both locks

comply to EN 1300

• Supplied with a shelf/shelves as standard – see table below

• Fixing kit allows DIY securing of safe to floor and/or wall

Zeta£6,000 cash rating


Height Width Depth Internal dimensions (mm)Height Width Depth

Volume (litres)

Weight (kg)

Fittings (Supplied)

Shelf

Cash Rating

RetailPrice

Drop off Delivery

Price*


Price

Aldridge Product Code**

Key Lock

15K 280 370 350 190 280 250 13 40 1 £6,000 £424 £60 £115 L21756

25K 330 450 400 240 360 300 26 54 1 £6,000 £523 £60 £139 L21757

35 K 450 450 400 360 360 300 39 67 1 £6,000 £608 £60 £141 –

45 K 570 450 400 480 360 300 52 81 1 £6,000 £681 £60 £148 –

55 K 690 450 400 600 360 300 65 94 2 £6,000 £767 £60 £152 –

Electronic Lock

15E 280 370 350 190 280 250 13 40 1 £6,000 £598 £60 £115 L21758

25E 330 450 400 240 360 300 26 54 1 £6,000 £696 £60 £139 L21759

35 E 450 450 400 360 360 300 39 67 1 £6,000 £784 £60 £141 –

45 E 570 450 400 480 360 300 52 81 1 £6,000 £856 £60 £148 –

55 E 690 450 400 600 360 300 65 94 2 £6,000 £942 £60 £152 – * Drop off delivery to a kerbside location NB. For base or rear fixing installations customer could be asked to sign a disclaimer at time of delivery** Sizes 15 & 25 available through Aldridge Security

Model above is45K

EN 1143-1

Grade 0

EN 1300EN 1300NEW

NOW AVAILABLE

IN 5 SIZES



BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

Key Features

• Grade 1 burglary protection certified by ECB•S in accordance with EN 1143-1

• Certified by ECB•S for 30 mins fire-resistance (EN 15659, 30 P)

• Door can be easily removed for installations via stairs reducing the overall weight

by approximately 15%

• Fitted with either a Class A key lock or a Class B high-security electronic lock,

approved in accordance with European standard EN 1300

• Supplied with 1 x removable shelf as standard

• Electronic lock has 2 users and a time delay feature

• Model 45 will accept certain sizes of laptop safe


Deca£10,000 cash rating


Height Width Depth* Internal dimensions (mm)Height Width Depth


Weight (kg)

Fittings (Supplied)

Shelf

FireRating(mins)

Cash Rating

RetailPrice



Price

Key Lock

25K 340 500 345 262 424 216 24 93 1 30 £10,000 £543 £60 £136

45K 460 440 430 383 364 300 42 121 1 30 £10,000 £612 £60 £146

Electronic Lock

25E 340 500 345 262 424 216 24 93 1 30 £10,000 £712 £60 £136

45E 460 440 430 383 364 300 42 121 1 30 £10,000 £783 £60 £146 * Add 26mm for hinge projection and handle moulding NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location

Model above is45E

EN 1143-1

Grade I

EN 1300 EN 1300EN 15659

30 minutes

NEW



BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

Key Features

• Grade I burglary protection certified by ECB•S in accordance with the European standard, EN 1143-1

• Fitted with either a Class A key lock or a Class B high-security electronic lock, approved in accordance with

European standard EN 1300

• Safes equipped with an electronic lock also have an LED light inside

• Ergonomic, soft-touch handle

• Interior ladder racking system for flexible positioning of multiple shelves. One shelf is supplied as standard

• Thinner walls for increased internal capacity

Cobra Pro£10,000 cash rating




Weight (kg)

CashRating

RetailPrice



Price

Key Lock

Size 2K 650 500 510 570 420 370 88 214 £10,000 £898 £60 £190

Size 3K 800 600 550 720 520 410 153 294 £10,000 £1,028 £60 £207

Electronic Lock

Size 2E 650 500 510 570 420 370 88 214 £10,000 £1,139 £60 £190

Size 3E 800 600 550 720 520 410 153 294 £10,000 £1,272 £60 £207 * Handle projection 56mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery** Drop off delivery to a kerbside location

EN 1143-1

Grade I

EN 1300 EN 1300

Fitting Shelf

Size 2 £23

Size 3 £31

Model above is Size 3K




Chubbsafes

EVOLVE

Combining a smart, sleek design with the highest European standard in

security: now that’s an innovative idea. Chubbsafes Evolve is the only

ergonomic safe with an automated opening and locking system to have

achieved EN 1143-1 certification on the market today. That means you

get a stylish, modern safe designed to enhance your personal comfort

that’s perfect for your home, small office or retail location... all with the

tried-and-tested security you expect from Chubbsafes.

BURGLARY RESISTANT

AUTOMATED OPENING

AND LOCKING SYSTEM

TRIED-AND-TESTED

SECURITY

THE NEXT GENERATION OF SAFES HAS ARRIVED.

SMART. SECURE. SLEEK.

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent


Automated opening and locking system with keypad lock placement at the top of door.

Ergonomic, handle-free design with chamfered edges.

Class B high-security electronic lock, approved in accordance with EN 1300.

Grade 1 burglary protection certified by the European Certification Board of Security (ECB•S) in accordance with the European standard, EN 1143-1.

Three sizes that favour height over depth to adapt to a range of different spaces.

Ideal for home, small office or retail location.

Innovative storage options for quick access to smaller items.

Plug-in version with battery-power back-up system.

Technical information


H W DInternal dimensions (mm)

H W DVolume (litres)

Weight (kg)

M100 690 600 500 590 500 328 100 151

M125 876 600 500 776 500 328 125 186

M185 1200 600 500 1100 500 328 185 247

ModelFittings

(Supplied) Shelf*Cash

RatingRetailPrice

Delivery & Base Fixing Price

M100 1 £10,000 £2939 £190

M125 2 £10,000 £3093 £211

M185 2 £10,000 £3496 £238

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

* Pull out drawers and shelves available on request. POA

NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery



DuoGuard GI & ProGuard GII, GIII£10,000 to £35,000 cash rating (Grade I, II, II)

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Height Width Depth


Weight(kg)

Fittings(Supplied)

Shelf

FireRating(mins)

CashRating

Retail Price Delivery & Base Fixing

PriceKey Lock Electronic

Grade I 40 435 500 456 335 400 295 40 90 1 60 £10,000 £973 £1,136 £190

60 530 500 521 430 400 360 62 115 1 60 £10,000 £1,153 £1,316 £211

110 690 600 561 590 500 386 114 161 2 60 £10,000 £1,353 £1,566 £226

150 875 600 561 775 500 386 150 196 2 60 £10,000 £1,482 £1,640 £238

200 1150 600 561 1050 500 386 203 243 2 60 £10,000 £1,704 £1,862 £276

300 1600 600 561 1500 500 386 290 322 3 60 £10,000 £2,206 £2,368 £318

350 1600 675 585 1500 575 410 354 352 3 60 £10,000 £2,434 £2,596 £354

450 1850 675 615 1750 575 440 443 415 4 60 £10,000 £2,769 £2,931 £354

Grade II 60 530 500 521 430 400 360 62 234 1 N/A £17,500 £1,393 £1,701 £207

110 690 600 561 590 500 386 114 334 2 N/A £17,500 £1,735 £1,972 £219

150 875 600 561 775 500 386 150 402 2 N/A £17,500 £2,025 £2,333 £243

200 1150 600 561 1050 500 386 203 501 2 N/A £17,500 £2,496 £2,803 £335

300 1600 600 561 1500 500 386 290 744 3 N/A £17,500 £2,771 £3,049 £407

350 1600 675 585 1500 575 410 354 846 3 N/A £17,500 £3,043 £3,321 £469

Grade III 110 690 600 561 600 510 396 121 315 2 N/A £35,000 £2,211 £2,544 £214

150 875 600 561 785 510 396 159 377 2 N/A £35,000 £2,487 £2,729 £248

200 1150 600 561 1060 510 396 214 486 2 N/A £35,000 £2,519 £2,805 £331

300 1600 600 561 1510 510 396 305 655 3 N/A £35,000 £3,205 £3,491 £394

350 1600 675 585 1510 585 420 371 703 3 N/A £35,000 £3,744 £3,990 £469

450 1850 675 616 1760 585 451 463 813 4 N/A £35,000 £4,186 £4,493 £508 * Projection of handle is 65mm NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

TOP SELLER EN 1300 EN 1300EN 1047-1

60 minutes

EN 1143-1

Grade I−III

Key Features

• Constructed using Chubbsafes revolutionary new lightweight barrier material

• Recommended cash rating of up to £35,000 (Grade III)

• Tested and certified by the ECB•S to European standard EN 1143-1

• Offers 60 minutes fire protection for documents (Grade l only). Tested and certified to European Standard EN 1047-1 Class S 60 P

• Supplied with a high security EN 1300 approved class A key lock or class B electronic lock


• Can be customised with locking options and fitting options (e.g. shelf, drawer)

• New modern design with a contemporary two tone satin finish

• Available in a comprehensive range of product sizes

Model above isModel 200



Fitting Shelf Full width drawer Lockable cupboard

All Grades Size 40 £21 N/A N/A

Size 60 £23 N/A N/A

Size 110–300 £31 £241 £254

Size 350 £36 £274 £285

Size 450 £42 £314 £314

Model Capsules (per 10) Capsule Deposit Envelope Slot

All Grades Size 40 N/A N/A N/A

Size 60 N/A N/A N/A

Size 110–300 £24 £386 £453

Size 350 £24 £386 £453

Size 450 £24 £386 £453 Maximum deposit size: 1. Envelope Slot25mm x 180mm (H x W)

LockAdditional

Cut KeyMechanical

CombinationTwo

Key LocksKey and

CombinationTwo

CombinationsElectronic

Key and Electronic

All Grades* All sizes £59 £141 £155 £237 £265 £333 £346 * Dual locking not available on Grade II size 60

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



TridentFrom £60,000 to £150,000 cash protection, fire protection

and explosives protection (Grades IV, V, VI)

Key Features

• Recommended cash rating of up to £150,000 (Grade VI)

• Tested and certified to the highest industry standards for burglary, fire and explosives protection

• A series of EN 1300 certified key locks, combination locks and electronic locks are available to choose from


• Full access of contents at 90° door opening

• Available in right or left hinge versions

• Can be customised with locking options and fitting options (e.g. shelf, drawer)

• New modern design in a contemporary black finish

• Available in 8 sizes for each grade

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

Model above isModel 600

EN 1300EN 1143-1

Grade IV−VI E

X

EN 1143-1

Grade IV−VI

EN 1300NT Fire 017

60 minutes



Height Width Depth


Weight (kg)

LockingFittings

(Supplied) Shelf

Total depth with door(s) at 90° (mm)

Total width with door(s) at 180˚ (mm)

FireRating(mins)

CashRating

RetailPrice


Price

Grade IV Size 110 790 730 560 620 560 320 111 560 Two Key Locks 2 1205 1420 60 £60,000 £3,697 £302

Size 170 920 730 640 750 560 400 168 695 Two Key Locks 2 1285 1420 60 £60,000 £4,010 £335





Size 910 1850 1250 740 1680 1080 500 907 2060 Two Key Locks 4 1385 2568 60 £60,000 £9,716 POA


Grade V Size 110 790 730 560 620 560 320 111 595 Two Key Locks 2 1205 1420 60 £100,000 £4,224 £302








Grade VI Size 110 790 730 560 620 560 320 111 635 Two Key Locks 2 1205 1420 60 £150,000 £6,990 £335







Size 1120 1850 1500 740 1680 1330 500 1117 2710 Two Key Locks 4 1465 3068 60 £150,000 £22,110 POA * Projection of handle is 63mm. Depth of hinge is not included in these measurements NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

NEW LARGER

SIZE



BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

Fitting Shelf Reinforced Shelf Full Width Drawer

All Grades Size 110 £37 POA N/A

Size 170 £37 POA N/A

Size 210 £37 POA £308

Size 310 £37 POA £308

Size 420 £37 POA £308

Size 600 £49 POA £354

Size 910 N/A POA POA

Size 1120 N/A POA POA

LockAdditional

Cut KeyKey and

CombinationTwo

CombinationsKey and

Electronic

Grade IV & V £59 £237 £265 £346

Grade VI £59 £237 £265 £710


BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

Key Features

• Deposit cash safe allows individuals to securely deposit cash, cheques and vouchers


• Deposit slot (170mm x 16mm) fitted with an anti-fishing device to prevent unauthorised removal of deposited items

• Constructed with an 8mm steel door and 3mm steel body. Hardened steel plates protect boltwork and lock against drilling

• Available with double bitted key lock or electronic lock (sizes 2 & 3 only)

• Override key supplied with electronic version

• Fixing kit allows DIY base or rear fixing of safe

• Shelf supplied as standard

Sigma Deposit£1,000 cash rating




Weight (kg)

CashRating

RetailPrice

Delivery Price

Aldridge Product

Code

Key Lock

Size 1 305 375 350 299 369 289 32 27 £1,000 £168 £21 L21760

Size 2 375 375 350 369 369 289 39 33 £1,000 £190 £21 L21761

Size 3 475 375 350 469 369 289 50 38 £1,000 £227 £21 L21763

Electronic Lock

Size 2 375 375 350 369 369 289 39 33 £1,000 £222 £21 L21762

Size 3 475 375 350 469 369 289 50 38 £1,000 £271 £21 L21764 * Electronic lock projection is 40mm NB. If base or rear fixing is ordered customer could be asked to sign a disclaimer at time of delivery

Model above is Size 2E








Key Features

• A quality cash safe for the deposit of cash and valuables


• Door is made from 10mm steel and body is made of 6mm steel

• The door is secured by a three way moving bolt mechanism

• An anti-fishing device prevents unauthorised removal of deposited items

• Available with double bitted key lock or electronic lock

• Deposit opening measures 80mm x 265mm x 220mm (HxWxD)

• Shelf supplied with size 2

Omega Deposit£3,000 cash rating


Height Width Depth Internal dimensions (mm)


Weight (kg)

CashRating

RetailPrice

Drop off Delivery

Price*


Price

Aldridge Product

Code

Key Lock

Size 1 455 340 380 212 328 308 24 54 £3,000 £263 £60 £139 L21765

Size 2 698 340 380 455 328 308 48 75 £3,000 £370 £60 £153 L21766

Electronic Lock

Size 1 455 340 380 212 328 308 24 54 £3,000 £299 £60 £139 L21767

Size 2 698 340 380 455 328 308 48 75 £3,000 £433 £60 £153 L21768 * Drop off delivery to a kerbside location NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

Model above is Size 1





BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent



Key Features

• High quality deposit safe constructed from modern high specification materials

• Recommended cash rating of up to £100,000 (Grade V) see table below

• Deposit feature allows multiple users to constantly deposit cash and valuables securely

whilst the main body of the safe remains locked

• Deposit drawer secured by double bitted key lock

• Can be customised with locking options


Sovereign DepositUp to £100,000 cash rating (Grade I, III & V)

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent


Height Width Depth*Internal dimensions (mm)

Height Width Depth

InternalVolume(litres)**

Weight (kg)

LockingTotal depth

with door at 90° (mm)

FittingsSupplied

CashRating

RetailPrice


Price

Grade I Size 1 882 528 603 460 360 360 60 525 Key Lock 1076 Empty £10,000 £1,449 £207

Size 2 972 668 663 550 500 420 116 694 Key Lock 1276 Empty £10,000 £1,699 £225


Grade III Size 2 972 668 663 550 500 420 116 754 Key Lock 1276 Empty £35,000 £2,166 £469


Grade V Size 2 972 668 663 588 538 444 140 798 Two Key Locks 1276 Empty £100,000 £5,108 £469

Size 3 1272 668 663 888 538 444 212 1052 Two Key Locks 1276 Empty £100,000 £5,991 £529 * Projection of handle is 56mm Max Deposit size is 110 x 320 x 200mm (HxWxD) ** Internal volume does not include allowance for anti-fishing devices NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

LockAdditional

Cut KeyMechanical

CombinationTwo

Key LocksKey and

CombinationTwo

CombinationElectronic

Key and Electronic

All Grades All sizes £59 £141 £155 £237 £265 £333 £346

Model Retaining Shelf Retaining Cupboard

All Grades All sizes £122 £388

Model shown isSize 2

NEW

AVAILABLE FROM MAY 2014



ProGuard DT GI & GIIUp to £17,500 cash rating (Grade I, II)

Key Features

• Constructed using Chubbsafes lightweight barrier material

• Up to 30% lighter than the previous version. Leads to easier product handling during installations

• Recommended cash rating is £10,000 (Grade I) or £17,500 (Grade II)

• Tested and certified by the ECB•S to European Standard EN 1143-2 D in Grades DI & II

• Deposit feature allows multiple users to constantly deposit cash and valuables securely whilst the

main body of the safe remains locked

• Deposit drawer equipped with an anti-fishing device to prevent anyone removing the contents of the

safe through the drawer

• Supplied with a high security EN 1300 approved class A key lock


• Available in four sizes in Grade I or II



Height Height* Width Depth


Weight (kg)

LockingFittings

SuppliedCash

RatingRetailPrice


Price

Grade I Size 60 687 500 521 587 314 400 360 45 144 Key Lock Empty £10,000 £2,004 £221

Size 110 847 600 561 747 474 500 386 91 203 Key Lock Empty £10,000 £2,262 £238



Grade II Size 60 687 500 521 587 314 400 360 45 329 Key Lock Empty £17,500 £2,273 £238



Size 200 1307 600 561 1207 934 500 386 180 665 Key Lock Empty £17,500 £3,480 £328 * Projection of handle is 65mm Maximum Deposit size for Size 60 is 30 x 330 x 220 (mm) Height* and litres* shown are usable heights and volumes below anti-fishing devices Maximum Deposit size for Sizes 110, 150, 200 is 30 x 430 x 220 (mm) NB. For base fixing installations customer could be asked to sign a disclaimer at time of delivery

LockAdditional

Cut KeyMechanical

CombinationTwo

Key LocksKey and


Two Combinations

Key and Electronic

All Grades* All sizes £59 £141 £155 £237 £333 £265 £346 * Dual locking not available on Grade ll size 60

BR

E –

Bu

rgla

ry R

esis

tant

Equ

ipm

ent

EN 1300EN 1143-2 D

Grade I−II

Model shown isSize 150



Key Features

• Highly reliable document protection using modern materials and technology

• Tested and certified to NT Fire 017 – 60 Paper (25" model) or NT Fire 017 – 120 Paper (30" model)

• Fire resistance up to 120 minutes (30" models)

• Each drawer is protected from fire. Even if one of the drawers is accidently left open,

the other closed drawers are still protected by the built in fire resistant partitions

• Designed to accommodate foolscap or A4 filing

Profile NT60 or 120 minutes document protection

Profile NT60 25" Fire File

External dimensions (mm Height Width Depth

Internal dimensions (mm)* Height Width Depth

Volume(litres)

Weight (kg)

Fire Rating(mins)

RetailPrice

Delivery & Position

Price

Profile 1HR 2DR 734 544 638 291 387 481 108 120 60 £646 £136

Profile 1HR 4DR 1408 544 638 291 387 481 216 200 60 £1,094 £158

Profile NT120 30" Fire File

External dimensions (mm) Height Width Depth

Internal dimensions (mm)* Height Width Depth

Volume (litres)

Weight (kg)

Fire Rating (mins)

RetailPrice

Delivery & Position

Price

Profile 2HR 2DR 734 544 776 291 387 619 139 172 120 £855 £136

Profile 2HR 3DR 1071 544 776 291 387 619 208 229 120 £1,134 £158

Profile 2HR 4DR 1408 544 776 291 387 619 278 287 120 £1,438 £177 * Each drawer’s internal dimensions

Model above isProfile 4DR

NT Fire 017

60 minutes

NT Fire 017

120 minutes

FRE

– Fi

re R

esis

tant

Equ

ipm

ent



Model shown is Size 325

Key Features

• Archive Cabinet has a steel, double-wall construction insulated with special fire-resistant barrier

material.

• Available in four sizes with a generous storage capacity ranging from 325–880 litres. Sizes 640

and 880 available as double door versions

• Secured by three-way boltwork, locking at the top, bottom and side of the door.

• Class A (EN 1300) key lock fitted as standard.

• Can be customised with a range of fittings (eg.lockable compartments, pull-out frames)

• Anchor points in the base allow the cabinet to be fixed to the floor.

• All cabinets have a light-grey, powder-coated finish, suitable for any office space.

Archive Cabinet £1,000 recommended cash rating




Weight (kg)

Fittings(Supplied)

Shelf

CashRating

RetailPrice

Delivery & Position

Price

Size 325 1500 700 550 1290 594 430 325 95 3 £1,000 £744 £136

Size 450 1950 700 550 1780 594 430 450 120 4 £1,000 £867 £136

Size 640 1950 950 550 1780 844 430 640 150 4 £1,000 £1,154 £136

Size 880 1950 1260 550 1780 1154 430 880 200 4 £1,000 £1,352 £173 * Projection of handle is 50mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery

Fitting Shelf Pull-out Frame Lockable Compartment

Size 325 £52 £147 £252

Size 450 £52 £147 £252

Size 640 £68 £175 £320

Size 880 £85 £180 £421

FRE

– Fi

re R

esis

tant

Equ

ipm

ent

EN 1300



Key Features

• Compact fire safe designed to protect valuable documents (eg. passports, receipts and

insurance documents)

• Tested and certified to UL72 Class 350 and NT Fire 017 – 60 Paper offering 60 minutes

fire protection

• Secured by either a key lock or user-friendly programmable electronic lock

• All sizes come with internal fittings as standard – see table below

• Anchoring points in base allow safe to be fixed to the floor

Executive60 minutes document protection

Model shown is Size 40



Fittings Supplied Tray Shelf

Size 15 1 –

Size 25 1 –

Size 40 1 1

Size 65 – 2

FRE

– Fi

re R

esis

tant

Equ

ipm

ent

NT Fire 017

60 minutes

UL72 Class 350

1 hour


Height Width DepthInternal dimensions (mm)


Weight (kg)

Fire Rating(mins)

RetailPrice

Drop off Delivery

Price*

Delivery & Position

Price

Key Lock

Size 15 300 390 320 210 310 215 14 25 60 £150 £21 £115

Size 25 345 425 450 240 320 320 25 45 60 £182 £60 £115

Size 40 525 410 450 415 305 320 41 57 60 £241 £60 £115

Size 65 670 550 510 515 395 340 71 120 60 £557 £60 £115

Electronic Lock

Size 15 300 390 320 210 310 215 14 25 60 £203 £21 £115

Size 25 345 425 450 240 320 320 25 45 60 £235 £60 £115

Size 40 525 410 450 415 305 320 41 57 60 £293 £60 £115

Size 65 670 550 510 515 395 340 71 120 60 £599 £60 £115 * Drop off delivery to a kerbside location Dimensions exclude handle and hinge projections NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery



FRE

– Fi

re R

esis

tant

Equ

ipm

ent

Model shown is 550

Additional Fitting Shelf Pull-out File Frame

450 £65 £199

550 £54 £178

775 £65 £199

Key Features

• Certified to protect documents from fire for up to one hour (EN 15659 – 60 Paper)

• Tested and certified to European standard EN 14450, level S2

• EN 1300 Class A certified key lock fitted as standard

• Shelves fitted as standard see table below. Shelves are designed to accept hanging folders

suspended underneath

• Pull out filing frames and additional shelves available as an optional extra

• Available in 3 sizes with capacities ranging from 446 to 773 litres. All models have double doors



Height1 Width Depth1 Internal dimensions (mm)

Height2 Width2 Depth

InternalVolume (litres)

Weight (kg)

Fittings(Supplied)

Shelf

Fire Rating(mins)

Retail Price

Delivery & Position

Price

Key Lock

450 1200 1250 585 1030 1110 390 446 440 2 60 £2,572 £177

550 1950 940 585 1760 800 390 550 460 4 60 £2,796 £191

775 1950 1250 585 1785 1110 390 773 650 4 60 £3,737 £225 NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery

EN 15659

60 minutes

EN 1300EN 14450

S2

NEW

Duplex60 minutes document protection, up to £4,000 cash rating



FRE

– Fi

re R

esis

tant

Equ

ipm

ent

Model shown isSize 300Key Features

• Fire-resistant safe designed to protect documents from fire and theft

• Ideal for offices and small businesses

• Tested and certified in accordance with NT Fire 017 – 120 Paper. Offering 120 minutes fire protection

• Secured by a user friendly programmable electronic lock

• Supplied with removable shelves as standard

• Available in seven sizes

Office120 minutes document protection




Weight (kg)

Fittings(Supplied)

Shelf

Fire Rating(mins)

RetailPrice

Delivery & Position

Price

Size 115 795 580 510 635 425 345 94 185 2 120 £672 £136

Size 125 995 585 510 830 425 345 123 200 3 120 £846 £158

Size 225 1175 645 635 1010 480 460 226 285 3 120 £1,174 £177

Size 300 1285 740 635 1120 575 460 301 340 3 120 £1,497 £191

Size 385 1600 740 635 1435 575 460 385 380 4 120 £1,570 £275

Size 450 1600 835 635 1435 670 460 447 410 4 120 £1,822 £295

Size 785 1695 1210 655 1535 1045 485 783 670 4 120 £2,762 £348 * Projection of handle is 40mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery

NT Fire 017

120 minutes



FRE

– Fi

re R

esis

tant

Equ

ipm

ent

Model shown is Size 24-2

EN 1300NT Fire 017

120 minutes

Key Features

• Quality document protection using high specification materials

• Tested to NT Fire 017 – 120 Paper

• Fire resistance of 120 minutes


• Can be customised by using fixed shelves, filing rails and lockable cupboards


Record Protection Cabinet120 minutes document protection, up to £1,500 cash rating



Height Width Depth


Weight (kg)

LockingFittings

(Supplied) Shelf

Fire Rating(mins)

RetailPrice

Delivery & Position

Price

Size 12-2 859 759 549 700 600 382 160 235 Key Lock 1 120 £1,560 £158

Size 18-2 1209 759 549 1050 600 382 240 313 Key Lock 2 120 £1,922 £177

Size 24-2 1559 759 549 1400 600 382 321 391 Key Lock 3 120 £2,465 £191

Size 30-2 1909 759 549 1750 600 382 401 470 Key Lock 4 120 £2,736 £207 * Projection of handle is 65mm. Depth of hinge is not included in these measurements

Fitting Shelf Pull-out File Frame Lockable Cupboard

Size 12-2 £23 £100 £104

Size 18-2 £23 £100 £104

Size 24-2 £23 £100 £104

Size 30-2 £23 £100 £104



Model shown is 120

Additional Fitting Shelf Drawer

25 £34 £115

40 £34 £115

80 £35 £135

120 £45 £159

DataGuard NT120 minutes data media protection

Key Features

• Certified NT Fire 017 – 120 Diskette for two-hour protection of data media from fire

• Single-door safe with no insert required – means internal capacity is maximised and up to

60% more storage space than other safes in the same class

• User-friendly, slam-action door, which when shut provides full fire protection without

needing to be locked

• Fittings supplied as standard – see table below for details

• Available in four sizes, ranging from 30–128 litres

• Secured by either a key lock or electronic lock


Height1 Width Depth1 Internal dimensions (mm)

Height2 Width2 Depth


Weight (kg)

Fittings Fire Rating(mins)

Retail Price

Delivery & Position

PriceShelf Drawer

Key Lock

25 530 546 566 280 346 306 30 145 1 0 120 £804 £136

40 700 546 566 450 346 306 48 190 1 1 120 £971 £146

80 1025 546 590 775 346 330 89 263 1 2 120 £1,278 £158

120 1025 702 590 775 502 330 128 330 1 2 120 £1,521 £207

Electronic Lock

25 530 546 566 280 346 306 30 145 1 0 120 £869 £136

40 700 546 566 450 346 306 48 190 1 1 120 £1,036 £146

80 1025 546 590 775 346 330 89 263 1 2 120 £1,345 £158

120 1025 702 590 775 502 330 128 330 1 2 120 £1,586 £207 1External heights and depths include plinth and handle projection NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery2Internal heights and widths are also equal to the clear opening measurements

NT Fire 017

120 minutes

FRE

– Fi

re R

esis

tant

Equ

ipm

ent



FRE

– Fi

re R

esis

tant

Equ

ipm

ent

DataPlus£4,000 Cash rating, 120 minutes data media protection

Key Features

• Quality media protection using high specification materials

• Tested to highest international standards EN 1047-1, UL72 Class 125 and EN 14450 S2

• Fire resistance of 120 minutes


• Can be customised by using fixed shelves, pull out drawers and lockable cupboards

• Electronic and mechanical combination locks available

• Available in five sizes



Height Width Depth


Weight (kg)

Locking Cash RatingFire Rating

(mins)RetailPrice

Delivery & Position

Price

Size 1 911 746 780 565 490 400 111 315 Key Lock £4,000 120 £3,378 £225

Size 2 1191 746 780 845 490 400 167 390 Key Lock £4,000 120 £3,842 £234

Size 3 1471 746 780 1125 490 400 221 490 Key Lock £4,000 120 £4,414 £248

Size 4 1941 746 780 1595 490 400 313 640 Key Lock £4,000 120 £5,457 £424

Size 5 1941 1036 830 1570 780 450 556 860 Key Lock £4,000 120 £6,966 £439 * Handle projection is 65mm NB. If base fixing is ordered customer could be asked to sign a disclaimer at time of delivery

Fitting Fixed shelfExtensible shelf with adjustable dividers

Lockable cupboard

Size 1 £36 £125 £216

Size 2 £36 £125 £216

Size 3 £36 £125 £216

Size 4 £36 £125 £216

Size 5 £57 £173 £249

EN 1047-1

120 minutes

UL72 Class 125

2 hours

EN 14450

S2




Key Features

• Optimum protection for high value assets

• Consists of modular panels which are assembled together using a welded or bolted method of construction

• Tested and certified by the ECB•S to the latest security standard, EN 1143-1

• Can be integrated into various environments (for example new buildings, existing buildings and to strengthen strong room units)

• Can be designed on a bespoke basis, to suit any shape or size, subject to a full and comprehensive site survey

• Available in a range of security grades

Centurion VaultProtection of high value assets

GradeWall thickness

(mm)

Weightper m2 wall, floor, ceiling

(kg)

Max span (clearance)for a permissible ceiling load of Retail

Price

Delivery &Installation

Price100 kp/m2 500 kp/m2

Euro V 85 300 3350 3350 POA POA

Euro VI 85 300 3350 3350 POA POA

Euro VII 85 300 3350 3350 POA POA

Euro V 100 360 4000 4000 POA POA

Euro VI 100 360 4000 4000 POA POA

Euro VII 100 360 4000 4000 POA POA

Euro VIII 100 360 4000 4000 POA POA

Euro IX 125 440 5250 4750 POA POA

Euro IX CD 125 440 5250 4750 POA POA

Euro X 150 520 5200 5000 POA POA

Euro X CD 150 520 5200 5000 POA POA

Euro XI 220 730 5060 5060 POA POA

Euro XI CD 220 730 5060 5060 POA POA

Euro XII 280 920 4960 4960 POA POA

Euro XII CD 280 920 4960 4960 POA POA

Hig

h V

alu

e A

sset

Pro

tect

ion



Hig

h V

alu

e A

sset

Pro

tect

ion

Key Features

• Optimum protection for high value assets

• Consists of a door frame, grille gate and the main strong room door

• Tested and certified by the ECB•S to the latest security standard, EN 1143-1

• Supplied with one key lock and one mechanical combination lock (up to grade Euro XCD) as standard.

One key lock and two mechanical combination locks on Grades Xl and Xll

• Can be customised with locking and alarm options to meet your specific security needs

• Available in a range of security grades

Centurion DoorProtection of high value assets

Grade Number of boltsTotal Weight

(kg)Frame Depth

(mm)Clear opening

H x W (mm)RetailPrice

Delivery &Installation

Price

Euro V 6 1500 230 1970 x 900 POA POA

Euro VI 6 1500 230 1970 x 900 POA POA

Euro VII 6 1500 230 1970 x 900 POA POA

Euro VIII 6 1700 290 1970 x 900 POA POA

Euro IX 6 1700 290 1970 x 900 POA POA

Euro IX CD 6 1700 290 1970 x 900 POA POA

Euro X 6 3000 415 1970 x 900 POA POA

Euro X CD 6 3000 415 1970 x 900 POA POA

Euro XI 6 3000 415 1970 x 900 POA POA

Euro XI CD 6 3000 415 1970 x 900 POA POA

Euro XII 10 3500 415 1970 x 900 POA POA

Euro XII CD 10 3500 415 1970 x 900 POA POA



Hig

h V

alu

e A

sset

Pro

tect

ion

Key Features

• ModuleGuard security enclosures are certified Grade II–lll by ECB•S in accordance with the EN 1143-1

certification for burglary resistance

• ModuleGuard door can also be supplied with embrasure as single item to suit wall thickness less than 280mm

• The lightweight panels reduce transportation costs, ease installation and allow for placement higher up in

buildings where floor loads are limited

• Possible applications include reinforced protection for cash-counting rooms, archives and storerooms

• ModuleGuard has also been granted level CR4 according to the EN 1627-30 standard. It has also undergone

certified ballistics test and has been certified level FB4 in accordance with EN 1522

ModuleGuardLightweight security enclosure

DoorsClear Opening

H x W (mm)Weight

(kg)Retail Price

Embrasure less than 280mm

Delivery & Installation

Grade ll 2055 x 750 500 £7,546 £408 POA

Grade ll 2055 x 900 600 £8,000 £408 POA

Grade ll 2055 x 1050 700 £8,140 £544 POA

Grade ll 2055 x 1200 800 £8,233 £680 POA

Grade ll 2055 x 1350 900 £8,444 £815 POA

Grade ll 2055 x 1500 1000 £8,903 £952 POA

Grade lll 2055 x 750 500 £8,085 £408 POA

Grade lll 2055 x 900 600 £8,539 £408 POA

Grade lll 2055 x 1050 700 £8,679 £544 POA

Grade lll 2055 x 1200 800 £8,772 £680 POA

Grade lll 2055 x 1350 900 £8,983 £815 POA

Grade lll 2055 x 1500 1000 £9,442 £952 POA Door supplied with single key lock as standard. Other locking options are available POA

Panels Width (mm) Thickness (mm)Max Panel Length

(mm)Weight (kg m2) Retail Price


Grade ll 300 75 2240 69 POA POA




Grade lll 300 75 2240 73 POA POA






Hig

h V

alu

e A

sset

Pro

tect

ion

Optional Extras Supply Price

Alarm Sensor £39

FB4 Bullet resistance to EN 1522 £115

FB6 Bullet resistance to EN 1522 POA

3 Point Self-locking POA

Door Closer POA

Panic Bar Internal Release POA

Extra Keys (ordered with door) £19

Glazed infill Full Height £200

Glazed infill Half Height £227

MagTek A4 RC4

Overall Dimensions (mm) HxW 2130 x 1150

Passage Dimensions (mm) HxW 2040 x 900

Retail Price £5,028

Delivery & Installation Price POA

MagTek AAluminium manual attack resistant door

Key Features

• Elegantly designed to protect sensitive areas such as cash transit rooms, back office rooms and

security enclosures

• Fitted with a European profile cylinder key lock as standard, other lock options are available,

eg. biometric, push button. 3 x keys supplied as standard

• Single leaf door set with 3-point Euro Lock and handle on both secure and attack sides as standard.

Double leaf option also available

• Fixed aluminium frame with inclusion of special steel armour for fixing into finished masonry

opening

• Level 4 certification in accordance with XP ENV 1627-30. Other security levels available. Optional

ballistic protection available up to FB6 NS in accordance with EN 1522

• Door can be fitted as left or right opening for more convenience

• Available in indoor or outdoor versions

• Option of RAL 9010, 9006, 7035 or 7037 powder coated finish as standard on indoor version.

Other colours available on request

• Can be used in conjunction with CityWall to form a secure enclosure

...the premier underfloor safe brand

Churchill Safes are recognised as the leading brand for underfloor safes.

Such success is based upon understanding the security market and

meeting customer needs. This commitment and initiative is reflected in

the Churchill Safes product range. Products vary from a small wall safe

to high security underfloor safes. Such a comprehensive range means that

finding an underfloor solution is a simple process.



Key Features

• Wall safe designed to protect cash and valuables


• Construction includes a 10mm door & 6mm outer frame

• Equipped with a double bitted key lock as standard

• Can be customised with combination or digital locking option

• Sizes 4 and 5 supplied with shelf


Magpie Wall Safe£1,000 cash rating

ModelDoor (mm)

Height WidthExternal dimensions (mm)

Height Width Depth* Weight

(kg)Locking

Fittings(Supplied)

Shelf

CashRating

RetailPrice

DeliveryPrice

M2 127 178 140 229 121 9 Key Lock N/A £1,000 £182 £21

M3 210 178 229 229 121 12 Key Lock N/A £1,000 £224 £21

M4 293 178 306 229 165 18 Key Lock 1 £1,000 £291 £21

M5 369 240 381 305 165 27 Key Lock 1 £1,000 £341 £21 *Please add 30mm for dial projection

ModelAdditional

Cut KeyMechanical


All models £32 £141 £181

Model shown is M5

Wal

l Saf

e

NEW



Key Features

• Traditional underfloor safe which protects cash and valuables

• Recommended cash rating of up to £4,000

• Easy upgrade option: can be upgraded to £6,000 (by using the Vector door)

• Construction includes a 30mm thick door coated in a unique and

environmentally friendly coating

• Secured by a double bitted key lock (VdS class 1) as standard

• Unique spring loaded escutcheon

• Can be customised with combination or electronic locking option

• Available in three models

• Deposit facility available – supplied with 12 capsules

• Supplied with full installation instructions

Domestic£4,000 cash rating

ModelAdditional

Cut KeyMechanical


All models £35 £141 £333


Height* Width Depth Internal dimensions (mm)

Height Width Depth Safe Opening

(mm)Weight

(kg)Locking

CashRating

RetailPrice

DeliveryPrice

D2L 375 240 240 229 215 215 140 14.5 Key Lock £4,000 £295 £21

D3L 455 315 315 305 290 290 140 24.5 Key Lock £4,000 £328 £21

D4L Deposit 455 315 315 305 290 290 140 26.5 Key Lock £4,000 £421 £21 * External height includes a 125mm neck

Model above isD3L

TOP SELLER VdS Class 1

Un

derf

loor

Saf

es



Un

derf

loor

Saf

es

Key Features

• Traditional underfloor safe which protects cash and valuables


• Construction includes a 45mm thick door coated in a unique and environmentally friendly coating

• Secured with a double bitted key lock (VdS class 1) as standard




• Available in three models


Vector£6,000 cash rating

ModelAdditional

Cut KeyMechanical


All models £35 £141 £333



Height Width Depth

Safe Opening

(mm)

Weight (kg)

LockingCash

RatingRetailPrice

DeliveryPrice

V2 375 240 240 229 215 215 140 16 Key Lock £6,000 £463 £21

V3 455 315 315 305 290 290 140 26 Key Lock £6,000 £496 £21

V4 Deposit 455 315 315 305 290 290 140 28 Key Lock £6,000 £544 £21 * External height includes a 125mm neck

Model above isV3

VdS Class 1



Un

derf

loor

Saf

es

Key Features

• Large capacity square door underfloor safe which protects cash and valuables

• Supplied with an air pump assisted door for easy lift





• Available in two models


Bulldog 400£6,000 cash rating

ModelAdditional

Cut KeyMechanical


All models £35 £141 £333

ModelDoor (mm)

External dimensions (mm) Height * Width Depth

Internal dimensions (mm) Height Width Depth

Safe Opening

(mm)

Weight (kg)

LockingCash

RatingRetailPrice

DeliveryPrice

CBS11 356 x 255 425 490 350 255 458 330 240 x 300 45 Key Lock £6,000 £810 £60

CBS12 356 x 255 590 490 350 420 458 330 240 x 300 50 Key Lock £6,000 £871 £60 * External height includes 150mm neck

Model above isCBS12

VdS Class 1



Key Features


• Easy upgrade options: can be upgraded to £17,500 recommended cash rating by using a Ruby door

• The door is constructed from stainless steel protecting the contents from thermal and mechanical attack





• All deposit versions include a lockable deposit cap

• Available in 2 models

• Supplied with reinforcing mesh and full installation instructions

Sapphire£10,000 recommended cash rating

Model above isES4 Deposit

ModelAdditional

Cut KeyMechanical


All models £35 £141 £333



Height Width Depth

Safe Opening

(mm)

Weight (kg)

LockingCash

RatingRetailPrice

DeliveryPrice

ES3 470 300 300 300 290 290 140 27 Key Lock £10,000 £787 £21

ES4 Deposit 470 300 300 300 290 290 140 27 Key Lock £10,000 £959 £21 * External height includes a 125mm neck

Un

derf

loor

Saf

es

VdS Class 1



Key Features

• Underfloor safe which protects cash and valuables


• The door is constructed from stainless steel protecting the contents from

thermal and mechanical attack








Ruby£17,500 recommended cash rating

Model above isER14 Deposit

ModelAdditional

Cut KeyMechanical


All models £35 £141 £333



Height Width Depth

Safe Opening

(mm)

Weight (kg)

LockingCash

RatingRetailPrice

DeliveryPrice

ER13 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,349 £21

ER14 Deposit 470 300 300 300 290 290 140 29 Key Lock £17,500 £1,472 £21 * External height includes a 125mm neck

Un

derf

loor

Saf

es

VdS Class 1



Key Features

• Underfloor safe which protects cash and valuables


• The door is constructed from solid stainless steel 45mm thick

protecting the contents from thermal and mechanical attack







Emerald£35,000 recommended cash rating



Height Width Depth

Safe Opening

(mm)

Weight (kg)

LockingCash

RatingRetailPrice

DeliveryPrice

EE23 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,469 £60

EE24 Deposit 560 300 300 300 290 290 140 32 Key Lock £35,000 £1,647 £60 * External height includes a 220mm neck

ModelAdditional

Cut KeyElectronic

All models £35 £333

Un

derf

loor

Saf

es

Model above isEE24D

TOP SELLER VdS Class 2



Not

es

Notes

...the premier document protection brand

For every business protection of documentation is of paramount importance. Losing this

invaluable information can lead to a disastrous impact on the business.

Common outcomes include the loss of clients and a decline in capacity to attain new business.

With the Rosengrens product range you are sure to find a flexible and secure solution.

Combining unique design and innovative features, each safe or cabinet ensures that your

documents are securely protected to the highest standards.



Key Features

• Dual control locking mechanism.

• Each locker is secured by client lock 32A81S, second lock is custodian controlled.

32A81S lock can be supplied in brass or chrome finish.

• Can be upgraded to Gunnebo’s unique semi automated box access/

management system*. All columns are supplied pre-wired for this function as

standard.

• Fast and easy to install.

• Unique security design.

Inner containers

• Fibre inner container supplied as standard.

• Steel finish available as an optional extra.

Numbering

• Numbering as per customer’s requirements.

Total Security

• Safe deposit lockers can be integrated into a vault room which is secured by a

vault door for extra security.

• Manufactured in accordance with the ISO 9001 quality management system

and the ISO 14001 environmental management system.

Locker Groups

• Locker columns available in three heights as standard.

• Special column height dependent on locker quantity available on request.

• Numerous configurations to suit all customer requirements available, using

standard column heights and locker heights (50–650mm).

Finish

• Painted powder coat to RAL number of choice. Stainless steel finish available as

an optional extra.

2000C Safe Deposit LockersProtection of high value assets Suitable for Banks, Hotels and Independent Locker Rental Companies

Hig

h V

alu

e A

sset

Pro

tect

ion

* Safe Control Access/Management System

Key Features

• Smoother locker rental and service

for customers. Features include

invoice generation, registration

and pricing.

• Real time information eg. locker

availability.

• Access management – options

include swipe card and pin number.

• Events history.

• Offsite management – using safe

control, guardian locks can be

deactivated remotely.

• Database of client information.



For further information please contact the Gunnebo sales department on 01902 455111.

Hig

h V

alu

e A

sset

Pro

tect

ion

Standard Column Heights

Cassette sizeLocker Sizes Available

1720

mm

2020

mm

2220

mm

1720

2020

2220

1720W

2020W

2220W

260mm

310mm

390m

m

435m

m

50

310 620

200

325

525/

650

75

100

125

175

300

475/

600

Horizontal view

FOLIO

320x230mm

For wide columns

multiply width x 2



FRE

– Fi

re R

esis

tant

Equ

ipm

ent

Key Features

• Optimum solution for the protection of documents

• Tested and certified by the ECB•S to the European standard EN 1047-1 Class S 120 P

Offering 120 minutes fire protection for paper documents

• Secured by key lock as standard. Can be equipped with electronic or dual locking as an option


• Can be customised with a wide range of fittings (e.g. fixed shelf, lockable cupboard)

• Available in two sizes

Sargasso120 minutes document protection



Height Width DepthWeight

(kg)Volume (litres)

LockingNo. of Lever Arch Files**

FittingsSupplied

FireRating(mins)

RetailPrice

Delivery & Position

Price

P120 1403 890 664 1203 733 434 458 383 Key Lock 30 Empty 120 £3,772 £225

P177 1970 1250 664 1770 1093 434 801 840 Key Lock 75 Empty 120 £5,956 £407 * Projection of handle is 50mm ** Lever Arch width 75mm

Fitting Fixed Shelf Extensible Shelf Extensible A4 File Frame Lockable Cupboard Data Insert

P120 £36 £109 £174 £301 £968

P177 £42 £146 £278 £570 £968

Lock Two Key Locks Combination Electronic

All sizes £155 £141 £333

Model above isP177

EN 1047-1

120 minutes



Not

es

Notes


Terms & Conditions

Preamble

1. Our Terms & Conditions shall apply in all instances. Gunnebo reserves the right, at any time, to modify, alter, or update the terms of use, product prices and product information and you agree to be bound by such modifications, alterations, or updates on subsequent visits. Your placement of an order indicates your acceptance of these terms and conditions.

Definitions

2. For the avoidance of doubt, the following expressions shall (unless the context otherwise admits) have the following meanings:

i. “Contract” shall mean the written agreement between the two parties concerning performance of the Works, encompassing the tender enquiry, subsequent submission and agreement of any pricing considerations made therein;

ii. “Contract Sum” shall mean the value of Gunnebo’s works, based upon Gunnebo’s tender submission, subject to any variances, to be ascertained and paid in accordance with the provisions hereinafter;

iii. “Customer” shall mean the party to whom Gunnebo are directly contracted; an end user Client, Main Contractor or Sub-Contractor;

iv. “Gunnebo” shall mean Gunnebo UK Ltd or their designated representatives;

v. “Works” shall mean the equipment and resources necessary to enable the completion of the Contract;

vi. “Equipment” shall mean all materials pertinent to the tender submission, subject to any variances, and necessary plant, solely for our use, to facilitate the Works;

vii. “Delivery Period” shall mean the length of time required to facilitate design and manufacture of equipment necessary for the completion of the Works;

viii. “Site” shall mean the place where the Works are to take place, including an allowance of space for any necessary unloading, safe storage and consideration for efficient transportation of equipment;

ix. “In Writing” shall mean communication by document signed by the parties, or by letter, facsimile, and electronic mail;

x. “Gross Negligence” shall mean an act or omission implying a failure to pay due regard to serious consequences, which a conscientious party would normally foresee as likely to ensue.

Product Information

3. All information and data generated during the tender process are binding only to the extent that they are by reference expressly included in the Contract.

Intellectual Property

4. All drawings and technical information relating to the Works shall remain the property of the submitting party. Drawings and technical information received by one party shall not, without the consent of the other party, be used for any other purpose than that for which they were provided. They may not, without the consent of the submitting party, otherwise be used or copied, reproduced, transmitted or communicated to a third party.

5. Where, under a separate contract, it is a contractual requirement of the Customer’s to provide their customer with an Operational and Maintenance Manual, Gunnebo reserve the right to charge for this service.

Quality Assurance

6. Should the need arise for either the Customer to inspect equipment prior to dispatch, a request In Writing would be necessary a minimum of 72 hours before any proposed visit. Unless otherwise agreed, any inspection would be at the place of manufacture, during normal working hours. Any tests undertaken will be carried out in accordance with general practice in the appropriate branch of industry concerned in the country of manufacture. All costs associated with an inspection visit are to be borne solely by the Customer.

7. Records of Quality Inspections are maintained by Gunnebo and can be provided, on receipt of a request In Writing.

Preparatory Work

8. Gunnebo will provide information in good time, detailing the manner in which equipment will be installed and offer the Customer advice to aid their preparation of suitable foundations, access requirements and interfacing with others, where necessary.

9. The Customer shall recognise the limitations of Gunnebo’s responsibilities and ensure that all preparatory work outside of Gunnebo’s remit is completed in time for the commencement of the Works.

10. Gunnebo will conform to the Customer’s site induction procedures. Should this be required to take place prior to commencement, Gunnebo reserve the right to charge for this provision.

11. Gunnebo operatives will be provided with a project specific method statement and risk assessments pertinent to the environment that they will face.

12. The Customer shall provide welfare facilities free of charge for the use of Gunnebo operatives, available from the date of commencement and throughout the duration of the Works.

13. The Delivery Period shall commence once Gunnebo are in receipt of all pertinent information. The duration of this period will be governed by capacity in production and completeness of information received.

14. The date of commencement will be determined by the duration of the Delivery Period. Should information prove to be incomplete, Gunnebo shall identify the remedial action required by the Customer. Gunnebo may endeavour to furnish the Customer with indicative timescales, but will not commit to a date of commencement until all outstanding matters are resolved.

15. Due to the manner with which Gunnebo commencement is determined, Gunnebo shall not be held liable for any conflict between the date of commencement and any target of the Customer.

Impact on Commencement or Continuity

16. If the Customer anticipates that the fulfilment of their obligations will delay the completion of the Works; whether this manifests as a delay to commencement or leads to Gunnebo’s progress being hampered; the Customer shall notify Gunnebo In Writing, stating the reason and, if possible, the time when they will be able to comply with their obligations. The amount of time permitted to Gunnebo for the completion of the Works shall be automatically extended accordingly. Gunnebo shall endeavour to provide timely advice as to the impact upon duration and cost, and seek amendment of the Contract Sum, where applicable.

17. Without prejudice to Gunnebo’s rights elsewhere in this document, if the Customer fails to fulfil, correctly and timely, his obligations necessary for completion of the Works, the following remedies shall apply:

i. If the equipment has not been delivered to Site, Gunnebo shall arrange for temporary storage at the Customer’s risk and cost;

ii. The element of the Works completed shall be valued accordingly and the Customer shall pay any part of the Contract Sum which, but for such delay, would have become due;

iii. Gunnebo may suspend in whole or in part his performance of the Contract. Notice to the Customer shall be raised forthwith In Writing;

iv. The Customer shall reimburse Gunnebo for any costs which are reasonably incurred as a result of measures undertaken to mitigate the situation.

18. Should the Customer’s inability to fulfil their obligations not be attributable to Force Majeure, Gunnebo may, by notice In Writing, require the Customer to remedy the default within a determined and reasonable period. If, for any reason, the Customer fails to remedy the default within such period, Gunnebo may, by notice In Writing, terminate its employment under the Contract. Gunnebo shall then be entitled to compensation for the losses incurred as a result of the Customer’s default. The compensation shall not exceed the Contract Sum.

Variations

19. During the currency of the Contract and subject to provisions elsewhere in this document, Gunnebo will act upon requests In Writing from the Customer, to vary the scope, design and construction of the Works.

20. To minimise impact upon the overall duration of the Works, the Customer shall ensure that any request contains an exact description of the variation required.

21. As soon as possible after receipt of a request for a variation, Gunnebo shall notify the Customer In Writing whether it is possible to conform with the request. Should the request fall within Gunnebo‘s sphere of expertise, then Gunnebo shall advise In Writing the value of such work and the extent of the impact upon the overall duration of the Works, assuming continuity can be achieved. The amount of time permitted to Gunnebo for the completion of the Works shall be automatically extended accordingly, with the Contract Sum amended, as applicable.

22. Gunnebo shall not be obliged to carry out variations required by the Customer until either the parties have

agreed on how the variations will affect the Contract Sum, the time for completion and other terms of the Contract, or the dispute has been settled through Adjudication or Arbitration.

23. If completion of the Works is delayed as a result of disagreement between the parties on the consequences of variations, the Customer shall pay any part of the Contract Price which would have become due if the Works had not been delayed.

Commissioning

24. Where specifically requested at the moment of enquiry, commissioning tests shall be carried out to determine whether the equipment is fit for purpose.

25. The Customer shall provide free of charge any power, lubricants, water, fuel, raw materials and other materials or equipment to enable such tests.

26. Any such tests shall be carried out during normal working hours, conducted in accordance with general practice in the appropriate branch of industry.

27. If the commissioning tests show the Works not to be in accordance with the Contract, Gunnebo will within a determined and reasonable period remedy any deficiencies.

28. The Customer is not entitled to use the Works or any part thereof before commissioning. If the Customer does so without Gunnebo’s consent In Writing, he shall be deemed to have taken over the Works. Gunnebo shall then be relieved of their duty to carry out such tests.

Completion

29. The Works shall be considered complete when either the commissioning has proved equipment to be fit for purpose or the Client has begun making use of equipment.

30. If Gunnebo anticipates that they will not be able to comply with their obligations within the times specified in the Contract, they shall forthwith notify the Customer thereof In Writing, stating the reason, and, if possible, when compliance can be expected. If Gunnebo fails to give such notice, the Customer shall be entitled to compensation for certain additional costs which will be incurred and which could have been avoided had such notice been received.

31. Should there be no reasonable entitlement to an extension of time great enough to accommodate for the eventual completion date of the Works; Gunnebo’s delay entitles the Customer to liquidated and ascertained damages from the date at which completion should have occurred. Liquidated and ascertained damages shall not exceed 1% of the Contract Sum per week and are capped at a maximum of 10% of the Contract Sum, calculated on a pro-rata basis against the Works. All other claims for compensation against Gunnebo based on such delay shall be excluded, except where Gunnebo has been guilty of Gross Negligence.

32. The liquidated and ascertained damages become due at the Customer’s request In Writing but not before commissioning or termination of the Contract.

33. If Gunnebo’s delay is such that the Customer has become entitled to the maximum level of damages and the Works are still not completed, the Customer may demand In Writing completion within a final reasonable period which shall not in any event be less than one week. If Gunnebo does not complete the Works within such final period and this is not due to any circumstance for which the Customer is responsible, then the Customer may by notice In Writing to Gunnebo terminate Gunnebo’s employment under the Contract.

34. It shall be a condition precedent to the Customer’s right to liquidated and ascertained damages that he shall lodge a claim In Writing for such damages within three months after the time when completion should have taken place.

35. Gunnebo shall be entitled to an extension of the time for completion if delay occurs:

i. because of any of the circumstances covered under the heading Force Majeure;

ii. as a result of variation to the Works;iii. as a result of suspension of the Works;iv. by an act or omission on the part of the Customer;v. by an act or omission on the part of another trade

engaged on the same project.

36. The extension of time shall be reasonable having regard to all the circumstances. This provision applies regardless of whether the reason for the delay occurs before or after the agreed time for completion.


Payment

37. Subject to a demonstrable level of credit worthiness, and unless otherwise agreed, payment shall be made within 30 days from the date of the invoice.

38. Each invoice will identify the percentage of equipment on site and installed in relation to the Contract Sum.

39. Should the installation be delayed due to a cause for which the responsibility rests with the Customer or any of their contractors other than Gunnebo, the Customer shall compensate Gunnebo for:

i. waiting time and time spent on extra journeys;ii. costs and extra work resulting from the delay, including

removing, securing and setting up the installation equipment;

iii. additional costs, including costs as a result of Gunnebo having to keep his plant on Site for a longer time than expected;

iv. additional costs for journeys and board and lodging for Gunnebo’s personnel;

v. additional financing costs and costs of insurance;vi. other documented costs incurred by Gunnebo as a result

of changes in the installation programme.

40. Should the installation element be measured on a time related basis, all pertinent expense incurred will be incorporated into the Contract Sum.

41. If the Customer fails to pay by a stipulated date, Gunnebo shall be entitled to interest from the day on which payment was due. The rate of interest shall be 8% above the Bank of England base rate at that time when payment was due. In cases of late payment Gunnebo may, after having notified the Customer In Writing, suspend performance of the Contract until payment is received. If the Customer has not paid the amount due within three months, Gunnebo shall be entitled to terminate its employment under Contract by notice In Writing and to claim compensation for the loss.

Retention of Title and Transfer of Risk

42. The equipment shall remain the property of Gunnebo until paid for in full.

43. Gunnebo shall be liable for any damage to the equipment which occurs before the risk has passed to the Customer. This applies irrespective of the cause of the damage, unless the damage has been caused by the Customer or anyone for whom he is responsible in connection with performance of the Contract.

44. Gunnebo shall be liable for damage to the Customer’s property occurring before commissioning of the Works only if it is proved that such damage was caused by negligence on the part of Gunnebo or anyone for whom we are responsible in connection with the performance of the Contract. Gunnebo shall, however, under no circumstance be liable for loss of production, loss of profit or any other consequential economic loss.

45. The risk of loss or damage to the equipment shall pass to the Customer on handover or commissioning of the Works, unless such loss or damage results from Gunnebo’s negligence.

Product Liability

46. Gunnebo shall remedy any defect or non-conformity in the Works resulting from faulty design, materials or workmanship. However, we shall not be liable for loss of production, loss of profit or any other consequential economic loss.

47. Gunnebo’s liability is limited to defects in the Works which appear within a period of one year from commissioning. If the daily use of the equipment exceeds that which is agreed, this period shall be reduced proportionately. If commissioning has been delayed for reasons for which the Customer is responsible, Gunnebo’s liability for defects shall not be extended beyond 18 months after delivery.

48. The Customer shall without undue delay notify Gunnebo In Writing of any defect which appears. Such notice shall under no circumstance be given later than two weeks after the expiry of the period stated previously. The notice shall contain a description of the defect. If the Customer fails to notify Gunnebo In Writing of a defect within the set time limit, the right to have the defect remedied is lost. Where the defect is such that it may cause damage, the Customer shall immediately inform Gunnebo In Writing. The Customer shall bear the risk of damage resulting from his failure so to notify.

49. Should no defect be found for which Gunnebo is liable, we shall be entitled to compensation for the costs incurred as a result of acting upon the notice.

50. If, within a reasonable time, Gunnebo does not fulfil our

obligations, the Customer may, by notice In Writing, fix a final time for completion of Gunnebo’s obligations. If Gunnebo fails to fulfil his obligations within such final time, the Customer may himself undertake or employ a third party to undertake necessary remedial works at the risk and expense of Gunnebo. Where successful remedial works have been undertaken by the Customer or a third party, reimbursement by Gunnebo of reasonable costs incurred by the Customer shall be in full settlement of Gunnebo’s liabilities for the said defect.

51. Where the defect has not been successfully remedied, Gunnebo offer either of the following remedies:

i. The Customer is entitled to a reduction of the Contract Sum in proportion to the reduced value of the Works, provided that under no circumstance shall such reduction exceed 10% of the revised Contract Sum, or;

ii. Where the defect is so substantial as to significantly deprive the Customer of the benefit of the Contract, the Customer may terminate Gunnebo’s employment under the Contract by notice In Writing to Gunnebo. The Customer is then entitled to compensation for the loss he has suffered up to a maximum of 10% of the Contract Sum.

Force Majeure

52. Either party shall be entitled to suspend performance of their obligations under the Contract to the extent that such performance is impeded or made unreasonably onerous by any of the following circumstances beyond the control of the parties: industrial disputes, fire, war, extensive military mobilisation, insurrection, requisition, seizure, embargo, restrictions in the use of power.

53. A circumstance referred to in this clause, occurring after the formation of the Contract, shall give a right to suspension only if its effect on the performance of the Contract could not be reasonably foreseen at the time of the formation of the Contract.

54. The party claiming to be affected by Force Majeure shall notify the other party In Writing without delay on the occurrence of any Force Majeure and on the cessation of such circumstance. If Force Majeure prevents the Customer from fulfilling his obligations, they shall compensate Gunnebo for expenses incurred in securing and protecting the Works.

55. Regardless of what might otherwise follow from these General Terms and Conditions, either party shall be entitled to terminate the Contract by notice In Writing to the other party if performance of the Contract is suspended under Force Majeure for more than six months.

Anticipated Non-Performance

56. Notwithstanding other provisions in these General Terms and Conditions regarding suspension, each party shall be entitled to suspend the performance of their obligations under the Contract, where it is clear from the circumstances that the other party will not be able to perform his obligations. A party suspending their performance of the Contract shall forthwith notify the other party thereof In Writing.

Consequential Loss

57. Save as otherwise stated in these General Terms and Conditions there shall be no liability for either party towards the other party for loss of production, loss of profit, loss of use, loss of contracts or for any other consequential or indirect loss whatsoever.

Settlement of Disputes

58. In the event that an adjudicator has not been nominated during the formulation of the Contract, any dispute or difference arising under out of or in connection with these General Terms & Conditions may be referred to adjudication at anytime to an adjudicator nominated by the president or vice-president for the time being of the Chartered Institute of Arbitrators and shall be conducted in accordance with the Scheme for Construction Contracts (England & Wales) Regulation 1998 SI No 649 or any amendment or re-enactment thereof. The Adjudicator’s decision shall be final and binding on the parties until the dispute of difference is finally determined either by agreement between the parties or the courts.

Governing Law and Jurisdiction

59. These General Terms & Conditions shall be governed by and construed in all respects in accordance with the laws of England and Wales, and the English Courts shall have jurisdiction with regard to all matters arising from these General Terms & Conditions.

Severability

60. If any condition, clause or provision of these General Terms & Conditions is held to be illegal or unenforceable, it may be severed and the validity or enforceability of the remainder of these General Terms & Conditions shall not be affected thereby.

Third Party Rights

61. Notwithstanding any other provision of these General Terms & Conditions, nothing in these General Terms & Conditions confers or purports to confer any right to enforce any of its terms on any person who is not a party to it and the provisions of the Contracts (Rights of Third Parties) Act 1999 shall be of no effect in respect of the Agreement.

Construction Industry Scheme

62. Gunnebo shall provide the Customer with its unique taxpayer reference number and company registration number in sufficient time to allow the Customer to verify Gunnebo’s payment status for the purposes of Chapter 3 of Part 3 of the Finance Act 2004 and the Income Tax (Construction Industry Scheme) Regulations 2005. Gunnebo warrants that at the date of this Contract it is registered for gross payment under section 63(2) of the Finance Act 2004 and that it shall remain registered for gross payment until all payments under this Contract have been made.

CDM Regulations

63. Gunnebo shall comply with the Health and Safety at Work Act 1974, the Factories Act 1961, the Offices, Shops, Railway Premises Act 1963, the Management of Health and Safety at Work Regulations 1992 and The Construction (Design and Management) Regulations 2007 (CDM) and amendments and regulations made under or thereto.

Return Policy

64. We appreciate that there may well be a time when a purchase may not prove to be of satisfaction and a refund will be sought. Should a customer wish to return a product from our standard safe range, the following conditions shall apply:

• Gunnebo will only accept returns within seven (7) days of delivery;

• Goods shall be returned to Gunnebo point of dispatch, as identified on the proof of delivery notice and invoice;

• A re-stocking charge, equal to 25% of the Contract Sum will apply.

• Any postage and packing costs incurred on returned items are non-refundable. The returned product must be in a condition that can only be described “as new” and securely packaged with the original packaging or a suitable alternative of similar quality; Any and all manuals and accessories must be returned in conjunction with the product. With the above criteria having been satisfied, a refund will be issued, minus our outgoing delivery cost.


65. Where ‘Delivery’ is priced in this Selection Guide this is drop off only and does not include base fixing or positioning.

66. All products have a separate delivery and position or delivery and base fixing price. This price includes delivery to ground floor or upper floor (via a lift) with clear access. Ground floor is defined as level with pavement and no external steps. Delivery must occur during the working day hours of 8.30am – 5.30pm. Delivery outside these hours will incur an additional cost (POA). Gunnebo can also remove and dispose of your old safe/cabinet after delivering your new product (POA).

Delivery location

67. Delivery charges are for within mainland UK. However, certain postcodes are considered geographic extremities (Northern Ireland, Isle of Man, Channel Islands, Scottish Islands, Scilly Islands). Gunnebo can deliver to these locations and outside the UK at an additional cost.

Prices

68. The full price of your product and delivery will be shown on your order acknowledgement.

Gunnebo UK LtdFairfax HousePendeford Business ParkWobaston RoadWolverhamptonWest MidlandsWV9 5HAUnited Kingdom Phone: +44 (0) 1902 455111Fax: +44 (0) 1902 [email protected]

FM 01305EMS 577165

Gu

nn

ebo

rese

rves

th

e ri

ght

to m

odif

y, a

lter

or

up

dat

e p

rod

uct

info

rmat

ion

wit

hou

t n

otic

e.

GU

GB.

uk.

91

07

.R1

Sales

Selection Guide Price List 2014