8/19/2019 Tender2491 MCG
1/161
Tender Document
Improvement and Upgradation of road from Mahavir Chowk to Dundahera
Border, Gurgaon
PART 1: COMPLETE BIDDING DOCUMENT
MUNICIPAL CORPORATION GURGAON
GOVERNMENT OF HARYANA
8/19/2019 Tender2491 MCG
2/161
PART 1 : COMPLETE BIDDING DOCUMENT
8/19/2019 Tender2491 MCG
3/161
PRESS NOTICE
Municipal Corporation Gurgaon No. ____/MCG Dated: _______
Notice Inviting Tenders
The Governor of Haryana invites the bids from eligible bidders through online bids in the website:
http://mcg.etenders.in for the work detailed in the table.
Sr.
No.
Name of work Approxim
ate value
of woks
(Rs.)
Earnest Money
Deposit (Rs.)
Contractor/
Society
Cost of
document
(Rs.)
Time Limit Date and time
for bid
preparation
to Hash
Submission.
1. Improvement andupgradation of road from
Mahavir Chowk to
Dundahera Border,
Gurgaon
Rs. 4787 Lacs Rs.95.74 Lacs for
contractors and
Rs.47.87 Lacs for
Society
Rs.20,000/- 18
(Eighteen)
Months.
23.10.2015
14:01 to
05.11.2015
17:00
1. Pre bid meeting will be held on 03.11.2015 at 11.00 Hrs. in the office of the Conference room in the office of
Chief, Engineer, MCG, Gurgaon
2. Cost of bid document (to be paid only online) is Rs. 20,000/- (non-refundable) for each bid.
3. For further details and e-tendering schedule visit website
http://mcg.etenders.in
For & on behalf of Municipal Corporation Gurgaon
Executive Engineer-III
Municipal Corporation
Gurgaon.
8/19/2019 Tender2491 MCG
4/161
INVITATION FOR BID
(IFB)
8/19/2019 Tender2491 MCG
5/161
DETAIL NOTICE INVITING TENDER
The MCG invites the bids from eligible bidders through online bids in the website: http://mcg.etenders.in for
the work detailed in the table.
Sr
No
Name of work Estimated
Cost (Rs.)
Earnest
Money (Rs.)
Cost of
document
(Rs.)
Time limit Date and time for
bid preparation to
Hash Submission
1 2 3 4 5 6 7
1. mprovement and Upgradationof road from Mahavir Chowk to
Dundahera Border, Gurgaon
Rs. 4787 lacs Rs.95.74 Lacs
for contractors
and Rs.47.87
Lacs for
Society
Rs.20,000/- 18 (Eighteen)
Months.
23.10.2015 14:01 to
05.11.2015 17:00
1. Bidding Documents can be downloaded online from the Portal http://mcg.etenders.in by the Societies / Contractorsregistered on the Portal.
2. Pre bid meeting will be held on 03.11.2015 at 11.00 Hrs. in the Conference room in the office of Chief Engineer,Haryana MCG , Gurgaon to clarify the issues and to answer questions on any matter that may be raised at that stage as
stated in clause 9.2 of ‘Instructions to Bidders’ of the bidding document.
3 As the Bids to be submitted online are required to be encrypted and digitally signed, the Bidders are advised to obtain thesame at the earliest. For obtaining Digital Certificate, the Bidders may contact the representative of Next Tenders, the
Service Providers of Electronic Tendering System.
4 The contractual Agencies can submit their tender documents as per the dated mentioned in the KEY DATES:-
Sr.
No.Tender Stage Contractor Stage Start Date and Time
Expiry Date and
Time
1 Release of Tender - 23.10.2015 09:00 23.10.2015 14:00
2 - Download Tender Document 23.10.2015 14:01 05.11.2015 17:00
3 -Online Bid Preparation & HashSubmission
23.10.2015 14:01 05.11.2015 17:00
4. Pre Bid Meeting 03.11.2015 11:00 03.11.2015 17:00
5Technical and
Financial Lock-
05.11.2015 17:01 06.11.2015 19:00
6 - Re-encryption of Online Bids 06.11.2015 19:01 12.11.2015 17:00
7Open EMD &
Technical/PQ bid-
13.11.2015 09.00 16.11.2015 17:00
8TechnicalEvaluation
-13.11.2015 09.00 16.11.2015 17:00
9
Open Financial /
Price-Bid -
20.11.2015 09:00 20.11.2015 17.00
8/19/2019 Tender2491 MCG
6/161
5. The Bidders can download the bidding documents from the Portal http://mcg.etenders.in. Tender
Document Fees has to be paid online during the Bid Preparation and Hash Submission stage and Earnest Money
Deposit has to be submitted in a separate sealed EMD envelope. The bidders shall have to pay the Tender
Document Fees mentioned against the work at the time of Bid Preparation and Hash Submission stage. The
Earnest Money Deposit / earnest money will have to be in any one of the form as specified in the bidding
document. The EMD envelop has to reach in the office of Executive Engineer- III on or before 12.11.2015,
17.00 Hrs. However, as the details of the Earnest Money Deposit are required to be filled at the time of Bid
Preparation and Hash Submission stage, the Bidders are required to keep the EMD ready appropriately.
6. The tender shall be submitted by the tenderer in the following three separate envelops:
1. Earnest Money
2. N.I.T. and Technical Bid
3. Tender in Form – A (Price Bid)
-
-
-
Envelope ‘EMD’ (scanned copy online and
hard copy in physical form)
Envelope ‘T I’ (on line)
Envelope ‘C I’ (on line)
Note: Online Bidders are required to submit the physical EMD in a physical EMD Envelop –
‘EMD’. Price Bids and Technical Bid are to be submitted mandatory online and shall not be
accepted in any physical form.
Reference of the EMD is to be mentioned online.
Above envelop, as applicable, shall be kept in a big outer envelope, which shall also be sealed, In the firstinstance, the Envelope – ‘EMD’ of all the Bidders containing the Earnest Money Deposit shall be opened online
and physically. If the Earnest Money is found proper, Technical Bid shall be opened (online) in the presence of
such contractors who choose to be present. The Financial Offer in Envelop in ‘CI’ shall be opened (online) only if
the tenderer meet the qualification criteria as per the Bid document. The date of opening of Financial Bid
shall be fixed at the time of opening of Technical Bid.
The Contractual Agencies will submit the necessary documents as under.
Envelope ‘EMD’ – Earnest Money Deposit Envelope
Physical EMD Envelop – The Earnest Money Deposit will have to be in any one of the forms as
specified in
the bidding document.
Online EMD Envelope—Reference details of the Earnest Money Deposit instrument and scanned
copy of the Earnest Money Deposit .
In case Financial bid is submitted but Earnest Money Deposit has not been submitted by any
bidder, then bidder would be debarred from further tendering in Municipal Corporation,
Gurgaon for a period of minimum 1 year.
Adjustment of tender document fees of the Contractors / Agencies:
1. Single tender shall normally not be considered unless there are special circumstances to do so. In such
eventuality, decision to accept the single tender shall be as prescribed in the rules. If special
circumstances are not present, tenders shall be re-called. If re-tendering again results in a single tender, its
acceptance may be considered with proper justification and reasons”
2. Those bidders shall not be required to pay tender document fees, who choose to submit bids again on tender
being re-called on account of single tender / bid being received on first call.
8/19/2019 Tender2491 MCG
7/161
Envelope ‘CI’ – Price Bid Envelope
Information related to Price Bid of the tender to be submitted mandatorily online
The envelope marked EMD shall be submitted clearly marking the name of agency and name
of work. The contractual Agencies can submit their tender documents (Online) as per the
dates mentioned in the key Dates above:-
CONDITONS:-
1) DNIT & Prequalification criteria can be seen on any working day during office hours in office of
the undersigned.
2) Conditional tenders will not be entertained & are liable to be rejected.
3) In case the day of opening of tenders happens to be holiday, the tenders will be opened on the next
working day. The time and place of receipt of tenders and other conditions will remain unchanged.
4) The undersigned reserve the right to reject any tender or all the tenders without assigning any
reason.
5) The societies shall produce an attested copy of the resolution of the Co-Operative department for
the issuance of tenders.
6) The tender without earnest money / Earnest Money Deposit will not be opened.
7) The jurisdiction of court will be at Gurgaon.
8) The tender of the bidder who does not satisfy the qualification criteria in the bid documents are
liable to be rejected summarily without assigning any reason and no claim whatsoever on thisaccount will be considered.
9) The bid for the work shall remain open for acceptance during the bid validity period to be
reckoned from the last date of ‘manual submission of EMD. If any bidder/ renderer withdraws his
bid/ tender before the said period or makes any modifications in the terms and conditions of thebid, the earnest money shall stand forfeited. Bids shall be valid for 120 days from the date of bidclosing i.e. from last date of manual submission of EMD. In case the last day to accept the tender
happens to be holiday, validity to accept tender will be the next working day.
For and on behalf of Commissioner, MCG
Executive Engineer-III
Municipal Corporation
Gurgaon.
8/19/2019 Tender2491 MCG
8/161
SECTION 1
INSTRUCTION TO BIDDERS
(ITB)
8/19/2019 Tender2491 MCG
9/161
A. General
Section 1: Instruction to Bidders
Table of Clauses
D. Submission of Bids
1 Scope of Bid
2 Source of Funds
3 Eligible Bidders
4 Qualification of the Bidder
5 One Bid per Bidder
6 Cost of Bidding
7 Site Visit
19 Guidelines for E-tendering.
20 Deadline for Submission of Bids
21 Late Bids
22 Modification and withdrawal of Bids
E. Submission of Bids.
23 Bid Opening
24 Process to be Confidential
B. Bidding
Evaluation
Documents and 25 Clarification of Financial Bids and
Contracting the Employer
8 Content of Bidding Documents
9 Clarification of Bidding documents
& Pre-bid meeting.
26 Examination of bids & Determination of
Responsiveness27 Deleted.
10 Amendment of Bidding Documents 28 Deleted.
C. Preparation of Bids 29 Evaluation and Comparison of Financial
Bids
11 Language of Bid
12 Documents Comprising the Bid
13 Bid Prices
14 Currencies of Bid and Payment
15 Bid Validity
16 Earnest Money Deposit / Earnest Money
17 Alternative Proposals by Bidders
18 Deleted
30 Deleted.
F. Award of Contract
31 Award Criteria
32 Employer's Right to Accept any Bid and
to Reject any or all Bids33 Notification of Award and signing of
Agreement.
34 Performance Security
35 Advance payment and security.
36 Deleted
37 Corrupt or Fraudulent Practices
38 Maintenance-cum-defect liability period
8/19/2019 Tender2491 MCG
10/161
1. Scope of Bid
A. GENERAL
1.1. The Employer (named in Appendix to ITB) invites bids for the construction of works (as defined in
these documents and referred to as “the works”) detailed in the table given in IFB. The bidders may submit
bids for any or all of the works detailed in the table given in IFB.
1.2 The successful bidder will be expected to complete the works by the intended completion date specified
in the Contract data.
1.3. Throughout these bidding documents, the terms ‘bid’ and ‘tender’ and their derivatives (bidder/tenderer,
bidding/tendering, etc.) are synonymous.
2. Source of Funds
2.1. The expenditure on this project will be met from the budget of Municipal Corporation Gurgaon.
3. Eligible Bidders
3.1. This Invitation for Bids is open to all bidders.
3.2 All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a statement that the
Bidder is neither associated, nor has been associated, directly or indirectly, with the Consultant or any other
entity that has prepared the design, specifications, and other documents for the Project or being proposed a
Project Manager for the Contract. A firm that has been engaged by the Employer to provide consulting services
for the preparation or supervision of the works, and any of its affiliates, shall not be eligible to bid.
4. Qualification of the Bidder
4.1. All bidders shall provide in Section 2, Forms of Bid and Qualification Information, a preliminary
description of the proposed work method and schedule, including drawings and charts, as necessary. The
proposed methodology should include programme of construction backed with equipment planning and
deployment duly supported with broad calculations and quality assurance procedures proposed to be adopted
justifying their capability of execution and completion of work as per technical specifications, within stipulated
period of completion.
4.2 Deleted.
8/19/2019 Tender2491 MCG
11/161
4.3.* If the Employer has not undertaken prequalification of potential bidders, all bidders shall include the
following information and documents with their bids in Section 2:
(a) Copies of original documents defining the constitution or legal status, place of registration, and
principal place of business; written power of attorney of the signatory of the Bid to commit the
Bidder;
(b) Total monetary value of construction work performed for each of the last five years;
(c) Experience in works of a similar nature and size for each of the last five years, and details of
works underway or contractually committed; and clients who may be contacted for further
information on those contracts;
(d) Major items of construction equipment proposed to carry out the Contract;
(e) Qualifications and experience of key site management and technical personnel proposed for
Contract;
(f) Reports on the financial standing of the Bidder, such as profit and loss statements and
auditor’s reports for the past five years;
(g) Evidence of access to line (s) of credit and availability of other financial resources facilities
(10% of contract value), certified by the Bankers (Not more than 3 months old)
(h) Undertaking that the bidder will be able to invest a minimum cash up to 25% of contractvalue of work, during implementation of work.
(i)
(j)
Authority to seek references from the Bidder’s bankers;
Information regarding any litigation, current or during the last five years, in which the
Bidder is involved, the parties concerned, and disputed amount;
8/19/2019 Tender2491 MCG
12/161
4.4*
(k)
(l)
Proposals for subcontracting components of the Works amounting to more than 10 percent of the
Bid price (for each, the qualifications and experience of the identified sub-contractor in the relevant
field should be annexed); and
The proposed methodology and programme of construction, backed with equipment planning
and deployment, duly supported with broad calculations and quality control procedures
proposed to be adopted, justifying their capability of execution and completion of the work asper technical specifications within the stipulated period of completion as per milestones (for all
contracts over Rs. 5 crore).
Joint Venture
4.4.1. Joint ventures must comply with the following requirements:(a)
(i)
(ii)
(b)
(c)
Following are the minimum qualification requirements;
The lead partner shall meet not less than 50 percent of all the qualifying criteria given in para4.5.3 & 4.5.6. The joint venture must collectively satisfy the criteria of para 4.5.3 & 4.5.6. The
experience of the other joint venture partners shall be considered if it is not less than 30
percent of the qualifying criteria given in para 4.5.3 & 4.5.6 as mentioned below. However, in
case one of the joint venture partners is proposed to be included primarily to provide financialstrength to the joint venture, such joint venture partner shall have to commit to provideliquidity support to the project to the extent of 10 percent of the value of the contract.
The joint venture must satisfy collectively the criteria of para 4.5.4 and 4.5.5 below for whichpurpose the relevant figures for each of the partners shall be added together to arrive at the
joint venture’s total capacity. Individual members must each satisfy the requirements of para4.5.7 & 4.5.8 below.
The formation of a joint venture after prequalification, any change in a pre-qualified joint venture, will be subject to the written approval of the Employer prior to the
deadline for submission of bids. Such approval shall be denied if (i) partners withdraw
from a joint venture and the remaining partners do not meet the qualifyingrequirements; (ii) the new partners to a joint venture are not qualified individually or as
another joint venture; or (iii) in the opinion of the Employer, a substantial reduction in
competition may result.Bid shall be signed so as to legally bind all partners, jointly and severally, and shall
be submitted with a copy of the joint venture agreement providing the ‘joint and
several’ liability with respect to the contract.
4.4.2. Qualification of a joint venture does not necessarily qualify any of its partners
individually or as a partner in any other joint venture. In case of dissolution of a joint venture, each
one of the constituent firms may qualify if they meet all the qualification requirements, subject to the
written approval of the Employer.
Footnote:*Clause 4.4 of Joint venture is valid only when amount put to bid is more than Rs. 25crore
8/19/2019 Tender2491 MCG
13/161
4.5. QUALIFICATION CRETERIA
4.5.1 Qualification will be based on applicant’s meeting all the following minimum pass / fail criteriaregarding the Applicant’s general and particular experience, personnel and equipment capabilities, andfinancial position, as demonstrated by the Applicant’s responses in the forms attached to the letter of
application (Specified requirements for Joint Ventures are given under Para 4.4 above). Subcontractor’sexperience and resources shall not be taken into account in determining the Applicant’s compliance
with the qualifying criteria.
To qualify for more than one contract, the applicant must demonstrate having experience and resourcessufficient to meet the aggregate of the qualification criteria for each contract given in paragraph 4.5.4,
4.5.5, 4.5.6 and 4.5.9 below.
4.5.2 Base Year and Escalation
The base year shall be taken as (Particular year to be mentioned).
Following Enhancement factor will be used for the cost of works executed in the financial figures to a
Common base value for the works completed in India.
Year Before
OneTwo
ThreeFour
Five
Multiplying Factor.
1.101.21
1.331.46
1.61Applicant should indicate actual figures of cost and amount for the works executed by them
without accounting for the above mentioned factors.In case the financial figures and value of completed works are in foreign currency, the aboveenhanced multiplying factor will not be applied. Instead, current market exchange rate (State
Bank of India BC Selling rate as on the last date of submission of the Bid) will be applied forthe purpose of conversion of amount in foreign currency into Indian rupees.
4.5.3 General Experience.
The applicant shall meet the following minimum criteria:
(a) Average annual turnover (defined as billing for works in progress and completed in all
classes of Civil Engineering construction works only) over the last five years of 80percent of the value of contract / contracts applied for.
(b) Experience in successfully completing or substantially completing at least one contract of
Highway (road and / or bridge works) / airport runway of at least 40 percent or two works each
of 40% of the value proposed for contract within the last five years.
(c) The contractor or his identified sub-contractor should possess required valid electrical
license for executing the electrification works and should have executed similar electrical
works for a minimum amount as indicated in Appendix in any one year. Applicable only if
electric items involved.
The works may have been executed by the applicant as Prime contractor or as a
member of Joint Venture or sub contractor. As sub contractor, he should have acquired the
experience of execution of all major items of works under the proposed contract. In case a
project has been executed by a Joint Venture, the turnover or experience shall be evaluated in
proportion to their participation of the Joint Venture.
8/19/2019 Tender2491 MCG
14/161
Substantially completed works means those works which are at least 90% completed as on the date of
submission (i.e. gross value of work done up to the last date of submission is 90% or more of the original
contract price) and continuing satisfactorily.
For these, a certificate from the employer shall be submitted along with qualification information
clearly mentioning the name of work, Contract Value, billing amount. Date of commencement of works,
satisfactory performance of the Contractor and any other relevant information.
4.5.4 Personnel Capabilities
The Applicant must have suitable qualified personnel to fill the following positions. The applicant shall
supply information on a prime candidate and alternate for each position, both of whom should meet the
experience requirements specified below:Sr.No.
1.
Personnel
Project
Manager
Qualification
BE.Civil+10 Years
Exp
Up to
Rs. 50
lacs
-
More than
Rs. 50 lacs
upto Rs. 1
crore
1
More than
Rs. 1 crore
upto Rs. 5
crore
1
LOT Size
More than
Rs. 5 crore
upto Rs. 20
crore
1 No.
More than Rs.
20 crore upto
Rs. 50 crore
1 No.
More than Rs.
50 crore
1 No.
2.
3.
Site Engineer BE.Civil+3 Years
Exp.
Plant Engineer BE. Mech. +3 Years
Exp. Or
Dip.Mech.+7 Years
Exp.
-
-
1
1
1
1
2 No.
1 No.
4No.
1 No.
6 No.
2 No.
4.
5.
Quantity
Surveyor
Soil & Material
Engineer
Total:
BE. Civil +3 Years
Exp. Or Dip. Civil+7
Years Exp.
B.E. Civil + 3 Years
Exp. Or Dip. Civil +7 Years Exp..
1
-
1 No.
1
1
5 Nos.
1
1
5 Nos.
1 No.
1 No.
6 Nos.
1 No.
1 No.
8 Nos.
2No.
1 No.
12 Nos.
4.5.5. Equipment Capabilities – Bidder may require the following machinery / equipment.
Sr.
No.
1.
2.
3.
4.
5.
6.
7.
8.
9.
Type of Equipment
Tipper Trucks
Motor Grader
Dozer
Front end Loader
Smooth Wheeled Roller
Vibratory Roller
Hot Mix Plant with Electronic Controls(Minimum 80-100 TPH Capacity)
Paver Finisher with Electronic Sensor
Water Tanker
MaximumAge as ondate of bidsubmission
5-7
5
5
5
5
5
5
5
5
Upto Rs.50 lacs
*
*
*
*
*
*
*
*
*
More thanRs. 50 lacsupto Rs. 1
crore
*
*
*
*
*
*
*
*
*
Upto Rs.5crore
6
2
1
2
2
2
1
1
3
LOT SizeMore thanRs.5 crore uptoRs. 20 crore
10
2
1
2
2
21
1
3
More thanRs.20 croreuptoRs. 50 crore
15
3
1
2
3
21
1
4
More thanRs. 50 crore
20
4
2
4
4
3
2
2
5
10. Bitumen Sprayer
11. Tandem Roller
12. Concrete Mixers with Integral Weigh
Batching facility
13. Concrete Batching and Mixing Plant
(Minimum Capacity – 15 m3/hour)
14. Concrete paver capable of paving 7.5m
width in one single pass including all
accessories.. Such as automatic dowel bar
inserter, integral vibratory system and
electronic sensors ancillary equipment forapplying curing compound joint cutting
etc.
15. Concrete Batching and Mixing plant with
automatic control (minimum 100
cum/hour)
5
5
5
5
5
5
Total:
*
*
*
*
*
*
*
*
*
*
*
*
1
1
2
-
-
-
24
1
1
2
-
-
-
28
1
1
1
1
-
-
36
2
1
2
1
1
1
54
The above list is only suggestive, Machinery as required for execution be included.
8/19/2019 Tender2491 MCG
15/161
.5.6 Financial Position
The Applicant should demonstrate that he has access to, or has available, liquid assets (aggregate of
working capital, cash in hand uncommitted bank guarantees) and / or credit facilities of not less than 10 percent
of the value of the contract / contracts applied for (construction cash-flow may be taken as 10 percent of the
estimated value of contract / contracts).
4.5.7 The audited balance sheets for the last five years should be submitted, which must demonstrate of
soundness of Applicant’s financial position, showing long term profitability including an estimated financial
projection for the next two years. If necessary, the Employer will mark inquiries to applicant’s bankers.
4.5.8 Litigation History
The Applicant should provide accurate information on any litigation or arbitration resulting fromcontracts completed or under execution by him over least five years. A consistent history of awards against the
Applicant or any partner of a joint venture may result in disqualification of the applicant.
4.5.9 Bid Capacity
Applicant who meet the minimum qualification criteria will be qualified only if their available bid
capacity at the expected time of bidding is more than the total estimated cost of the works. The available bid
capacity will be calculated as under :-
Assessed Available Bid Capacity = (A*N*3-B), where
A = Maximum value of works executed in any year during last five years (updated to the current
price level ) rate of inflation may be taken as 10 percent per year which will take into account
the completed as well as works in progress.
B = Value at current price level of the existing commitments and ongoing works to be completed
during the nextone year
; and
N = Number of years prescribed for completion of the works for which the bids are invited.
(Note: In case of a Joint Venture, the available bid capacity will be applied for each partner to the
extent of his proposed participation in the execution of the work).
4.5.10 Disqualification
Even through the Applicant meet the above criteria , they are subject to be disqualified if they have:
- made misleading or false representation in the form, statements submitted; and / or
- Records of poor performance such as abandoning the work, rescinding of contract for which the reasons are attributable to the
non-performance of the contractor; consistent history of litigation awarded against the applicant or financial failure due to
bankruptcy. The rescinding of contract of a joint venture on account of reasons other than non performance, such as Most
Experienced partner of joint venture pulling out, court direction leading to breaking up a joint venture before the start of
work, which are not attributable to the poor performance of the contractor will, however, not affect the qualification of
the individual partners.
4.5.11. The Bidder shall produce affidavit that his firm has not been blacklisted by any State Government /Central Government/ Autonomous Body/ authority in India.
5. One Bid per Bidder
5.1. Each bidder shall submit only one bid for one package. A bidder who submits or participates in more than one Bid (other than as
subcontractor or in cases of alternatives that have been permitted or requested) will cause all the proposals with the Bidder’s participation
to be disqualified.
8/19/2019 Tender2491 MCG
16/161
6. Cost of Bidding
6.1. The bidder shall bear all costs associated with the preparation and submission of his Bid, and the
Employer will in no case be responsible and liable for those costs.
7. Site Visit
7.1. The Bidder, at the Bidder’s own responsibility and risk is encouraged to visit and examine the Site of
Works and its surroundings and obtain all information that may be necessary for preparing the Bid and entering
into a contract for construction of the Works. The costs of visiting the Site shall be at the Bidder’s own expense.
8.
B.
Content of Bidding Documents
BIDDING DOCUMENTS
8.1. The set of bidding documents comprises the documents listed below and addenda issued in accordance
with Clause 10:
SectionInvitation for Bids
Particulars Volume No.
1
2
3
4
5
6
7
8
9
10
8.2. Deleted
Instructions to Bidders
Qualification Information and other forms.
Conditions of Contract
Contract Data
Technical Specifications
Form of bid
Bill of Quantities
Securities and other forms
Drawings
Documents to be furnished by bidder
I
II
III
IV
V
8.3. The bidder is expected to examine carefully all instructions, conditions of contract, contract data, forms,
terms, technical specifications, bill of quantit ies, forms, Annexes and drawings in the Bid Document. Failure to
comply with the requirements of Bid Documents shall be at the bidder’s own risk. Pursuant to clause 26 hereof,
bids which are not substantially responsive to the requirements of the Bid Documents shall be rejected.
8/19/2019 Tender2491 MCG
17/161
9. Clarification of Bidding Documents
9.1. A prospective bidder requiring any clarification of the bidding documents may notify the Employer in writing or by cable
(hereinafter “cable” includes telex and facsimile) at the Employer’s address indicated in the invitation to bid. The Employer
will respond to any request for clarification which he receives earlier than 15 days prior to the deadline for submission of bids.
Copies of the Employer’s response will be put on website including a description of the enquiry but without identifying its
source.
9.2. Pre-bid meeting
9.2.1. The bidder or his official representative is invited to attend a pre-bid meeting which will take place at the address, venue, time
& date as indicated in appendix.
9.2.2. The purpose of the meeting will be to clarify issues and to answer questions on any matter that may be raised at that stage.
9.2.3. The bidder is requested to submit any questions in writing or by cable to reach the Employer not later than one week before the
meeting.
9.2.4. Minutes of the meeting, including the text of the questions raised (without identifying the source of enquiry) and the
responses given will be put on website. Any modification of the bidding documents listed in Sub-Clause 8.1 which may
become necessary as a result of the pre-bid meeting shall be made by the Employer exclusively through the issue of an
Addendum pursuant to Clause 10 and not through the minutes of the pre-bid meeting.
9.2.5. Non-attendance at the pre-bid meeting will not be a cause for disqualification of a bidder.
10. Amendment of Bidding Documents
10.1. Before the deadline for submission of bids, the Employer may modify the bidding documents by issuing
Addenda/ corrigendum
10.2. Any addendum/ corrigendum thus issued shall be part of the bidding documents and put on website only. The
Employer will assume no responsibility in this regard.
10.3. To give prospective bidders reasonable time in which to take an addendum /corrigendum into account in preparing
their bids, the Employer may, at his discretion, extend as necessary the deadline for submission of bids, in
accordance with Sub-Clause 20.2 below.
8/19/2019 Tender2491 MCG
18/161
11. Language of the Bid
C. PREPARATION OF BIDS
11.1. All documents relating to the bid shall be in the English language.
12. Documents Comprising the Bid.
12.1. The bid to be submitted by the bidder as Volume V of the bid document (refer Clause 8.1) shall be in
two separate envelops:
Envelope ‘TI’ shall be named “Technical Bid” and shall comprise
(i)
(ii)
Earnest Money Deposit in accordance with clause 16.
Qualification Information and supporting documents as specified in Section 2
(iii) Certificates, undertakings, affidavits as specified in Section 2
(iv) Deleted
(v) Undertaking that the bid shall remain valid for the period specified in Clause 15.1
(vi) Deleted.
Envelope ‘CI’ shall be named “Financial Bid” and shall comprise
(i)
(ii)
Form of Bid as specified in Section 6
Priced Bill of Quantities for items specified in Section 7
Each part will be separately sealed and marked in accordance with the Sealing and Marking
Instructions in Clause 19.
12.2. Deleted.
12.3. Following documents, which are not submitted with the bid, will be deemed to be part of the bid.
1
3
4
5
9
Invitation for Bids(IFB)
Instructions to Bidders
Conditions of Contract
Contract Data
Specifications
Drawings
Volume I
Volume II
Volume IV
Section Particulars Volume No.
8/19/2019 Tender2491 MCG
19/161
13. Bid Prices.
13.1. The contract shall be for the whole works as described in Sub-Clause 1.1, based on the priced Bill of
Quantities submitted by the Bidder.
13.2. Deleted.
13.3. All duties, taxes, and other levies payable by the contractor under the contract, or for any other cause
shall be included in the rates, prices and total Bid Price submitted by the Bidder.
13.4 The rates and prices quoted by the bidder are subject to adjustment during the performance of theContract in accordance with the provision of Clause 47 of the Conditions of Contract.
14. Currencies of Bid and Payment
14.1. The unit rates and the prices shall be quoted by the bidder entirely in Indian Rupees. All payments shall
be made in Indian Rupees.
15. Bid Validity.
15.1. Bids shall remain valid for a period not less than 120 days after the deadline date for bid submission
specified in Clause 20. A bid valid for a shorter period shall be rejected by the Employer as non-responsive. In
case of discrepancy in bid validity period between that given in the undertaking pursuant to Clause 12.1 (v) and
the Form of Bid submitted by the bidder, the latter shall be deemed to stand corrected in accordance with the
former and the bidder has to provide for any additional security that is required.
15.2. In exceptional circumstances, prior to expiry of the original time limit, the Employer may request that
the bidders may extend the period of validity for a specified additional period. The request and the bidders
responses shall be made in writing or by cable. A bidder may refuse the request without forfeiting his bid
security. A bidder agreeing to the request will not be required or permitted to modify his bid, but will be required
to extend the validity of his Earnest Money Deposit for a period of the extension, and in compliance with Clause 16 in all
respects.
8/19/2019 Tender2491 MCG
20/161
15.3. Deleted.
15.4. Deleted.
16. Earnest Money Deposited (EMD)
16.1. The Bidder shall furnish, as part of his Bid, a EMD in the amount as shown in column 4 of the
table of IFB for this particular work. This Earnest Money Deposit shall be in favour of Commissioner, Municipal Corporation,Gurgaon as named in Appendix and may be in one of the following forms:
a.
b.
Receipt in challan of cash deposit in the Municipal Corporation, Gurgaon .
Bank Guarantee from any scheduled Indian bank, in the format given in Section-8.
16.2. Bank guarantees (and other instruments having fixed validity) issued as surety for the bid shall be valid
for 45 days beyond the validity of the bid.
16.3. Any bid not accompanied by an acceptable EMD and not secured as indicated in Sub-Clauses
16.1 and 16.2 above shall be rejected by the Employer as non-responsive.
16.4. The EMD of the unsuccessful bidders will be returned within 28 days of the end of the bid validity period
specified in Sub-Clause 15.1.
16.5. The EMD of the successful bidder will be discharged when the bidder has signed the Agreement and furnished the
required Performance Security.
16.6. The EMD shall be forfeited
(a) If the Bidder withdraws the Bid after Bid opening during the period of Bid validity;
(b) Deleted
(c) In the case of a successful Bidder, if the Bidder fails within the specified time limit to
(i) Sign the Agreement; or
(ii) Furnish the required Performance Security.
(d) Deleted
8/19/2019 Tender2491 MCG
21/161
17. AlternativeProposals by Bidders
17.1. Bidders shall submit offers that fully comply with the requirements of the bidding documents, including the conditions of
contract (including time for completion), basic technical design as indicated in the drawing and specifications. Conditional
offer or alternative offers will not be considered further in the process of tender evaluation.
18. Format and Signing of Bid
18.1. Deleted.
18.2. Deleted.
18.3. Deleted.
19. Guidelines to e-tendering
D. SUBMISSION OF BIDS
19.1 These conditions will overrule the conditions stated in the tender documents, wherever relevant
and applicable.
19.2 Registration of the Contractors on the MCG Website
All the Contractors intending to register with MCG Intending to buy the tender document
online are required to register for Electronic Tendering on the MCG website.
order to participate in the tenders located using the Electronic System.
The Contractors registered with other Departments who are also eligible to participate in the Tenders processed
by Municipal Corporation Gurgaon are also required to be registered on the
Electronic Tendering System in GENERAL category.
For more details, please see the information in Registration Info link on the Home Page.
8/19/2019 Tender2491 MCG
22/161
19.3 Obtaining a Digital Certificate:
The Bids required to be submitted online should be signed electronically with a Digital Certificate to
establish the identity of the Bidder bidding online. These Digital Certificates are issued by an approved
Certifying Authority, authorized by the Controller of Certifying Authorities, Government of India.
A Digital Certificate is issued upon receipt of mandatory identity proofs and verification letters attested by
the banker with whom the contractor maintains the account with. Only upon the receipt of the required
documents, a Digital Certificate can be issued.
The registered contractors may obtain Class – II B Digital Certificates from any Certifying Authority or
Sub-Certifying Authority authorized by the Controller of Certifying Authorities or may obtain information
and application format and documents required to issue of digital certificate from:
1.
2.
Next Tender (India) Pvt. Ltd.
Yuchit, Juhu Tara Road,
Mumbai-400049
Email : [email protected]
The registered contractors may obtain the digital certificates from any other Certifying
Authority or Sub-certifying Authority authorized by the Controller of Certifying Authorities.,Government of India.
Bid for a particular Tender may be submitted only using the Digital Certificate, which is used to encrypt the
data and sign the hash during the stage of Bid Preparation and Hash Submission. In case, during the process
of a particular Tender, the Authorized User loses his / her Digital Certificate (i.e. due to virus attack,
hardware problem, operating system problem); he / she may not be able to submit the Bid online. Hence, the
Authorized User is advised to back up his / her Digital Certificate and keep the copies at safe place under
proper security to be used in case of emergencies.
In case of online tendering, if the Digital Certificate issued to the Authorized User of a Firm is used for
signing and submitting a Bid, it will be considered equivalent to a no-objection certificate / power of
attorney to that User. A Firm has to authorize a specific Individual via an Authorization Certificate / Letter
signed by the majority of the Partners to use the Digital Certificate as per Indian Information TechnologyAct 2000. Unless the Digital Certificate is revoked, it will be assumed to represent adequate authority of the
Authority User to bid on behalf of the Firm for the Tenders processed by the Public Works Department (B &
R), Government of Haryana as per Information Technology Act 2000. The Digital Signature of this
Authorized User will be binding on the Firm. It shall be the responsibility of Partners of the Firm to inform
the Certifying Authority or Sub Certifying Authority, if the Authorized User changes, and apply for a fresh
Digital Certificate and issue an Authorization Certificate for the new Authorized User. The procedure for
application of a Digital Certificate will remain the same for the new Authorized User.
The same procedure holds true for the Authorized Users in a Private / Public Limited Company. In this case,
the Authorization Certificate will have to be signed by the Directors of the Company.
19.4 Opening of an Electronic Payment Account:
For purchasing the tender documents online, contractors are required to pay the tender document fees onlineusing the electronic payments gateway service as mentioned in the NIT.
8/19/2019 Tender2491 MCG
23/161
Following modes of electronic payments are accepted on the electronic tendering system.
a) Credit Cards – Electronic Credit Card Transactions through the following Credit Card types
are supported : Master Card / VISA / American Express / Diners Club International / JCB Cards /
Citibank E-Cards.
b) Internet Banking– Electronic Internet Banking Transactions through Internet Banking
8/19/2019 Tender2491 MCG
24/161
Accounts of the following Banks are supported : HDFC Bank / Citi Bank / ICICI Bank / IDBI Bank /
UTI Bank / Oriental Bank of Commerce Global Trust Bank / Federal Bank / Centurion Bank of Punjab
Limited / IndusInd Bank / Kotak Mahindra Bank / Punjab National Bank.
19.5 Set up of Machine
In order to operate on the electronic tender management system, a user’s machine is required to be setup. A
help file on setting up of the system can be obtained from NexTenders (India) Pvt. Ltd. Or downloaded from
the home page of the website = http://mcg.etenders.in.
19.6 Online Viewing of Detailed Notice Inviting Tenders:
The Contractors can view the detailed Notice Inviting Tenders and the detailed Time Schedule (Key Dates)
for all the packages processed by Public Works Department using the Electronic Tendering System on the
‘http://mcg.etenders.in’.
19.7 Purchase of Tender Documents
19.8 Clarification of Bidding Documents and Pre-bid Meeting :- The clarification shall be given by the
employer on the venue, date & time as indicated in DNIT.
19.9 In case online Query Processing facility of online bidding is functional:
Prospective bidder should notify the Employer through the query processing facility available online set
up to the date and time indicated in the Notice Inviting Tender. In such case, the copies of the
employer’s response will be displayed online including a description of the enquiry, but without
identifying its source.
Prospective bidders can participate in the pre-bid meeting using the Query processing facility available
online.
Prospective bidders can use the Query processing facility available on-line to do so but not later than
one week before the meeting.
Responses given will be displayed online without delay.
19.10 Submission of Bid Seal (Hash) of Online Bids:
Submission of Bids will be preceded by submission of the digitally signed Bid Seals (Hashes) as stated in
the Tender Time Schedule (Key Dates) published in N.I.T.
The information related to bids should be filled in or uploaded in the available templates under each
envelope. After filing templates/uploading documents online, the hash of each envelope is required to be
generated and digitally signed by a digital certificate of the person duly authorized to sign on behalf of the
bidder.
19.11 Generation of Super Hash:
After the expiry of the time of submission of digitally signed Bid Seals (Hashes) by the Contractors has
lapsed, the bid round will be closed and a digitally signed Tender Super Hash will be generated by theauthorized Official of Municipal Corporation Gurgaon, Government of Haryana. This is equivalent to
sealing the Tender Box.
19.12 Submission of actual online Bids:
Contractors have to submit their encrypted Bids online and upload the relevant documents for which they
generated the respective Hashes during the stage of Bid Preparation and Hash Submission after the
generation of Super Hash within the date and time as stated in the Notice Inviting Tenders (Key Dates). The
electronic Bids of only the Contractors who have submitted their Bid Seals (Hashes) within the stipulated
8/19/2019 Tender2491 MCG
25/161
time, as per the Tender Time Schedule (Key Dates), will be accepted by the Electronic Tendering System. A
Contractor who does not submit his Bid Seals (Hashes) within the stipulated time will not be allowed to
submit his Bid.
Note : The bidder shall fill/upload the information related to bids in the available templates under two separate
envelopes marked “TI” and “CI”. After filling templates/uploading documents online, the hash of each envelope
is required to be generated and to be digitally signed. In case of online Bids, no information related to “Financial
Bid & Technical bid” shall be accepted manually.
19.13 Submission of Cost of Bid Documents and Earnest Money Deposit :
Contractor has to submit cost of bid documents mandatorily online through e-tendering website. Bid
Security in the form as prescribed in Clause 16 of Section – I (ITB) of bid document is to be delivered in
a sealed envelope to the officer well in stipulated time as prescribed in list of important dates.
19.14 Opening of Electronic Bids:
Electronic bid of contractors, whose cost of bid document and bid security have been received before
stipulated time, will only be opened.
The online bid data will be taken opened through the website http://mcg.etenders.in. The hasses
of each bid will be matched with the hash generated and submitted during the state – “Bid preparation and
Hash Submission’. In the event of a mismatch, the bid in question will be liable for a due process of
verification by Haryana MCG.
19.15 Key Dates:
The contractors are strictly advised to follow dates and times as indicated in the Notice Inviting Tenders.
The date and time as indicated in the top-right of the web-page is the system time and will be binding on all
contractors. All online activities are time tracked and the system enforces time-locks that ensure that no
activity or transaction can be take place outside the start and end dates and time of the stage as defined in the
Notice Inviting Tenders.
19.16. Online query system is not functional for this package.
19.17. In case there is any contradiction in tender process then instruction contained guidelines to e-tendering
will prevail.
20. Deadline for Submission of the Bids
20.1 Complete Bids (including Technical and Financial) must be received by the Employer at the address specifiedabove not la ter than the date indicated in appendix. In the event of the specified date for the submission of bids
declared a holiday for the Employer, the Bids will be received upto the appointed time on the next working day.
20.2 The Employer may extend the deadline for submission of bids by issuing an amendment in accordance with Clause
10, in which case all rights and obligations of the Employer and the bidders previously subject to the original deadline
will then be subject to the new deadline
8/19/2019 Tender2491 MCG
26/161
21. Deleted
21.1
22. Deleted.
8/19/2019 Tender2491 MCG
27/161
23. Bid Opening. E. BID OPENING AND EVALUATION
23.1. The Employer will open all the Bids received (except those received late), in the presence
of the Bidders or their representatives who choose to attend at time, date and the place specified in Appendix in the
manner specified in Clause 20 and 23.3. In the event of the specified date of Bid opening being declared a
holiday for the Employer, the financial Bids will be opened as per the scheduled finalized in the biddingdocument.
23.2. Deleted.
23.3. The envelope ‘TI’ containing “Technical Bid” shall be opened. The amount, form and validity of the
cost of bidding document and Earnest Money Deposit furnished with each bid will be announced.
If the cost of bidding document and bid security furnished does not conform to the amount and validity
period as specified in the Invitation for Bid (ref. Column 4 and 5), and has not been furnished in theform specified in Clause 16, the remaining technical bid will not be opened and will be disqualified for
opening of financial bid.
23.4.
(i)
(ii)
Subject to confirmation of the Earnest Money Deposit by the issuing Bank, the bidsaccompanied
with valid Earnest Money Deposit will be taken up for evaluation with respect to theQualification
Information and other information furnished in Part I of the bid pursuant to
Clause 12.1.
After receipt of confirmation of the bid security, the bidder will be asked in
writing(usually within 10 days of opening of the Technical Bid) to clarify or
modify his technical bid, if necessary, with respect to any rectifiable defects.
(iii) The bidders will respond in not more than 7 days of issue of the clarificationletter, which will also indicate the date, time and venue of opening of the
Financial Bid(usually on the 21st day of opening of the Technical Bid)
(iv) Immediately (usually within 3 or 4 days), on receipt of these clarifications the
Evaluation Committee will finalize the list of responsive bidders whose financial bids
are eligible for consideration.
23.5. Deleted.
8/19/2019 Tender2491 MCG
28/161
23.6. At the time of opening of “Financial Bid”, the names of the bidders which were foundresponsive in accordance with Clause 23.4 (iv) will be announced. The bids of only thesebidders will be opened. The remaining bids will not be opened. The responsive Bidders’ names, the Bidprices, the total amount of each bid, any discount, and such other details as the Employer may considerappropriate, will be announced by the employer at the opening.
23.7. In case bids are invited in more than one package, the order for opening of the “Financial Bid” shall be
that in which they appear in the “Invitation For Bid”.
23.8. The Employer shall prepare minutes of the Bid opening, including the information disclosed to those
present in accordance with Sub-Clause 23.6.
24. Process to be Confidential.
24.1. Information relating to the examination, clarification, evaluation, and comparison of
Bids and recommendations for the award of a contract shall not be disclosed to Bidders or any other
persons not officially concerned with such process until the award to the successful Bidder has been
announced. Any effort by a Bidder to influence the Employer’s processing of Bids or award decisions mayresult in the rejection of his Bid.
25. Clarification of Financial Bids.
25.1. To assist in the examination, evaluation, and comparison of Bids, the Employer may, at his discretion,
ask any Bidder for clarification of his Bid, including breakdowns of unit rates. The request for
clarification and the response shall be in writing or by cable, but no change in the price or substance of the Bidshall be sought,
offered, or permitted.
25.2. Subject to sub-clause 25.1, no Bidder shall contact the Employer on any matter relating to his bid from
the time of the bid opening to the time the contract is awarded. If the Bidder wishes to bring
additional information to the notice of the Employer, it should do so in writing.
25.3. Any effort by the Bidder to influence the Employer in the Employer’s bid evaluation, bid comparison or
contract award decisions may result in the rejection of the Bidder’s bid.
26. Examination of Bids and Determination of Responsiveness
26.1. During the detailed evaluation of “Technical Bid”, the Employer will determine whether each Bid (a)
meets the eligibility criteria defined in Clause 3 & 4; (b) has been properly signed; (c) is accompanied by the
required securities and; (d) is substantially responsive to the requirements of the Bidding documents. During
the detailed evaluation of the “Financial Bid”, the responsiveness of the bids will be further determined with
respect to the remaining bid conditions, i.e., priced bill of quantities, technical specifications, anddrawings.
8/19/2019 Tender2491 MCG
29/161
26.2. A substantially responsive “Financial Bid” is one which conforms to all the terms, conditions,
and specifications of the Bidding documents, without material deviation or reservation. A
material deviation or reservation is one (a) which affects in any substantial way the scope, quality, or
performance of the Works; (b) which limits in any substantial way, inconsistent with the Bidding
documents, the Employer’s rights or the
Bidder’s obligations under the Contract; or (c) whose rectification would affect unfairly the competitive
position of other Bidders presenting substantially responsive Bids.
26.3. If a “Financial Bid” is not substantially responsive, it will be rejected by the Employer, and may not
subsequently be made responsive by correction or withdrawal of the non-conforming deviation or
reservation.
27. Deleted
28. Deleted.
29. Evaluation and Comparison of Financial Bids.
29.1. The Employer will evaluate and compare only the Bids determined to be substantiallyresponsive in accordance with Sub-Clause 26.2.
29.2. In evaluating the Bids, the Employer will determine for each Bid the evaluated Bid Price by adjustingthe Bid Price as follows:
(a) adjustments to reflect discounts or other price offered in accordance with Sub-Clause 23.6.
8/19/2019 Tender2491 MCG
30/161
29.3. The Employer reserves the right to accept or reject any variation or deviation. Variations and deviations
and other factors, which are in excess of the requirements of the Bidding documents or
otherwise result in unsolicited benefits for the Employer, shall not be taken into account in Bid
evaluation.
29.4. The estimated effect of the price adjustment conditions under Clause 47 of the Conditions of Contract,
during the period of implementation of the Contract, will not be taken into account in Bid evaluation.
29.5. If the Bid of the successful Bidder is seriously unbalanced in relation to the Engineer’s estimate of the
cost of work to be performed under the contract, the Employer may require the Bidder to produce detailed price
analyses for any or all items of the Bill of Quantities, to demonstrate the internal consistency of those
prices with the construction methods and schedule proposed. After evaluation of the price
analyses, the Employer may require that the amount of the performance security set forth in Clause 34 be
increased at the expense of the
successful Bidder to a level sufficient to protect the Employer against financial loss in the event of default of the
successful Bidder under the Contract.
29.6. A bid which contains several items in the Bill of Quantities which are unrealistically priced low and
which cannot be substantiated satisfactorily by the bidders may be rejected as non-responsive.
29.7. The agency / bidder to whom the work is allotted shall be paid lowest of the following in the running /
final bills:-
1. Amount calculated with the accepted rates of lowest agency.
2. Amount worked out with the rates of L-2/L-3/L-4 and so on
3. Amount worked out with the accepted percentage above HSR+CP/analytical rates/NS item rates, worked out
in financial statement. Financial statement will be made a part of agreement.
30. Deleted.
F. AWARD OF CONTRACT
31. Award Criteria.
31.1 Subject to Clause 32, the Employer will award the Contract to the Bidder whose Bid has been
determined
(i)
(ii)
to be substantially responsive to the Bidding documents and who has offered the lowest
evaluated Bid Price; and
to be within the available bid capacity adjusted to account for his bid price which is evaluated
the lowest in any of the packages opened earlier than the one under consideration.
8/19/2019 Tender2491 MCG
31/161
In no case, the contract shall be awarded to any bidder whose available bid capacity is less than the
evaluated bid price, even if the said bid is the lowest evaluated bid. The contract will in such cases be awarded to
the next lowest bidder at his evaluated bid price.
32. Employer’s Right to accept any Bid and to reject any or all Bids.
32.1. Notwithstanding Clause 31, the Employer reserves the right to accept or reject any Bid, and to cancel
the Bidding process and reject all Bids, at any time prior to the award of Contract, without thereby incurrinany liability to the affected Bidder or Bidders or any obligation to inform the affected Bidder or Bidders o
the grounds for the Employer’s action.
33. Notification of Award and Signing of Agreement.
33.1. The Bidder whose Bid has been accepted will be notified of the award by the Employer prior toexpiration for the Bid validity period by cable, telex or facsimile confirmed by registered letter. This letter
(hereinafter and in the Conditions of Contract called the “Letter of Acceptance”) will state the sum that the
Employer will pay the Contractor in consideration of the execution, completion, and maintenance of the Works
by the Contractor as prescribed by the Contract (hereinafter and in the Contract called the “Contract Price”).
33.2. The notification of award will constitute the formation of the Contract, subject only to the furnishing of
a performance security in accordance with the provisions of Clause 34.
33.3. The Agreement will incorporate all agreements between the Employer and the successful Bidder. It will
be signed by the Employer and sent to the successful Bidder, within 28 days following the notification of award
along with the Letter of Acceptance. Within 21 days of receipt, the successful Bidder will sign the Agreement
and deliver it to the Employer.
33.4. Upon the furnishing by the successful Bidder of the Performance Security, the Employer will promptly
notify the other Bidders that their Bids have been unsuccessful.
34. Performance Security.
34.1. Within 21 days of receipt of the Letter of Acceptance, the successful Bidder shall deliver to the
Employer a Performance Security in any of the forms given below for an amount equivalent to 5%including EMD of the Contract price plus additional security for unbalanced Bids in accordance with
Clause 29.5 of ITB and Clause. 52 of Conditions of Contract:
-
-
a bank guarantee in the form given in Section 8; or
certified Cheque/Bank Draft as indicated in Appendix.
34.2. If the performance security is provided by the successful Bidder in the form of a Bank
Guarantee, it shall be issued either (a) at the Bidder’s option, by a Nationalized/Scheduled
Indian Bank or (b) by a foreign bank located in India and acceptable to the Employer.
34.3. Failure of the successful Bidder to comply with the requirements of Sub-Clause 34.1 shall constitutesufficient grounds for cancellation of the award and forfeiture of the Earnest Money Deposit .
35. Advance Payment and Security.
35.1. The Employer will provide an mobilization Advance Payment upto a 5% of the agreement cost as stipulated in
the Conditions of Contract, against bank guarantee of equivalent amount as approved by Commissioner, MCG.
8/19/2019 Tender2491 MCG
32/161
36. Deleted .
37. Corrupt or Fraudulent Practices.
37.1. The Employer will reject a proposal for award if it determines that the Bidder recommended for award
has engaged in corrupt or fraudulent practices in competing for the contract in question and will declare the firm
ineligible, either indefinitely or for a stated period of time, to be awarded a contract with MCG
and any other State Govt. agencies, if it at any time determines that the firm has engaged in corrupt or
fraudulent practices in competing for the contractor, or in execution.
37.2. Furthermore, Bidders shall be aware of the provision stated in Sub-Clause 23.2 and Sub-Clause
59.2 of the Conditions of Contract.
38. Maintenance-cum-Defect Liability Period
38.1 The Maintenance-cum-Defect Liability Period is Five years and the 10% bank guarantee deposited with
MCG will be released after successful completion of the defect liability period and its O&M.
.
8/19/2019 Tender2491 MCG
33/161
1.
2.
APPENDIX to ITB
Clause Reference
with respect to
Section-I.Name of the Employer is Executive Engineer –III, MCG [C1.1.1]
The last five years2010-2011
2011-2012
2012-20132013-2014
2014-2015
3.
4.
5.
6.
7.
8.
This annual financial turn over amount is Rs 1000.00 Lacs
( Rs. Ten crore only)
Value of work is Rs.4787 Lacs ( Rs. Forty seven Crore eighty seven lacs only)
80% of Contract Value is Rs.3829.6 Lacs
40% of contract Value is Rs. 1914.8. Lacs
Deleted.
The cost of electric work is Rs. N/A (in words)
The cost of water supply / sanitary works is Rs. N/A (in words)
Liquid assets and/or availability of credit facilities is Rs. 269.20 Lacs (Rs. Two crore
sixty nine lacs twenty thousand only).
[C1.4.5.3a]
[C1.4.5.3b]
[C1.4.5.3c]
[C1.4.5.3c]
[C1.4.5.6]
8/19/2019 Tender2491 MCG
34/161
9.
10.
11.
12.
13.
14.
15.
16.
17.
18.
Price level of the financial year 2014-15
The Pre- bid meeting will take place at O /o Chief Engineer, MCG.
(address of the venue on ________(time and date)
The technical bid will be opened at O/o Chief Engineer, MCG (address of
the venue on ________(time and date)
Deleted
Deleted
The bid should be submitted through e-tendering only latest by ___
(date and time)
The Bank Guarantee / Bank draft in favour of Commissioner, MCG Deleted .
Escalation factors (for the cost of works executed and financial figure to a
common base value for works completed).
Year before Multiply factorOne 1.10Two 1.21Three 1.33Four 1.46Five 1.61
[C1.4.5.9]
[C1.9.2.1]
[C1.4.5(a)]
[C1.19.2(b)]
[C1.20.1(a)]
[C1.23.1]
[C1.34.1, Cl.16]
[C1.36.1]
8/19/2019 Tender2491 MCG
35/161
Sr.No.
Type of Equipment.
[Reference CI. 4.5.5]
Maximum
Age as on Upto More than Upto
ANNEXURE-I
LOT Size
More than More than More than
1 Tipper Trucks2 Motor Grader3 Dozer4 Front end Loader5 Smooth Wheeled Roller6 Vibratory Roller7 Hot Mix Plant with Electronic
Controls (Minimum 80-100
TPH Capacity)8 Paver Finisher with Electronic
Sensor9 Water Tanker10 Bitumen Sprayer11 Tandem Roller
12 Concrete Mixers with IntegralWeigh Batching facility.
13 Concrete Batching and Mixing
Plant (Minimum Capacity –15m3 / hour)
14 Concrete paver capable ofpaving 7.5m width in one
single pass including allaccessories. Such as automatic
dowel bar inserter, integral
vibratory system andelectronic sensor ancillaryequipment for applying curing
compound joint cutting etc.
15 Concrete Batching and MixingPlant with automatic control
(minimum 100 Cum / hour).
date of bid
submission
5-7555555
5
555
5
5
5
5
Total:
Rs.50lacs
*******
*
***
*
*
*
*
Rs.50 lacsupto Rs.1
crore.
*******
*
***
*
*
*
*
Rs.5crore
6212221
1
311
2
-
-
-
24
Rs.5 croreupto Rs.20
crore
10212221
1
311
2
-
-
-
28
Rs. 20crore upto
Rs.50crore
15312321
1
411
1
1
-
-
36
Rs.50crore.
20424432
2
521
2
1
1
1
54
The above list is only suggestive Machinery as required for execution be included.
8/19/2019 Tender2491 MCG
36/161
ANNEXURE-II
List of Key Personnel to be deployed on Contract Work
[Reference CI. 4.5.4]
4.5.4 Personal Capabilities The Applicant must have suitable qualified personnel to fill the following positions. The applicant sill
supplyinformation on a prime candidate and alternate for each position, both of whom should meet the experience requirementsspecified below:
Sr.
No.
1.
Personnel
Project
Manager
Qualification
BE.Civil+10 Years
Exp
Upto
Rs. 50
lacs
-
More than
Rs. 50 lac
upto Rs.1Crore
1
More than
Rs. 1 Crore
upto Rs. 5Crore
1
LOT Size
More than
Rs. 5 Crore
upto Rs.20Crore
1 No.
More than Rs.
20 Crore upto
Rs. 50 Crore
1 No.
More than Rs.
50 crore
1 No.
2.
3.
Site Engineer BE.Civil+3 Years
Exp.
Plant Engineer BE. Mech. +3 Years
Exp. Or
Dip.Mech.+7 Years
Exp.
-
-
1
1
1
1
2 No.
1 No.
4No.
1 No.
6 No.
2 No.
4.
5.
Quantity
Surveyor
Soil & MaterialEngineer
Total:
BE. Civil +3 Years
Exp. Or Dip. Civil+7Years Exp.
B.E. Civil + 3 Years
Exp. Or Dip. Civil +
7 Years Exp..
1
-
1 No.
1
1
5 Nos.
1
1
5 Nos.
1 No.
1 No.
6 Nos.
1 No.
1 No.
8 Nos.
2No.
1 No.
12 Nos.
8/19/2019 Tender2491 MCG
37/161
SECTION 2
QUALIFICATION INFORMATION
8/19/2019 Tender2491 MCG
38/161
QUALIFICATION INFORMATION
The information to be filled in by the Bidder in the following pages will be used for purposes of
post qualification as provided for in clause 4 of the Instruction to Bidders. This information will not be
incorporated in the Contract.
1. For Individual Bidders
1.1. Constitution or legal status of Bidders
[Attach copy]
Place of registration: ______________________________________
Principal place of business: ______________________________________
Power of attorney of signatory of Bid
[Attach]
1.2 Total value of Civil Engineering construction
work performed in the last five years**
(in Rs. Millions)
20_____20_________ ß
20_____20__________
1.3.1. Work performed as prime contractor, work performed in the past as a nominated subcontractorwill also be considered provided the sub-contract involved execution of all main items of work
described in the bid document, provided further that all other qualification criteria are satisfied(in the
same name) on works of a similar nature over the last five years.**
Project Name of Description Contra Value of Date Stipulate Actual Remarks
Name the
Employer*
n of work ct No. Contract
(Rs.Crore)
of issue d period
of work oforder completi
on
date of
completion.
explaining
reasons fordelay & work
Completed
*Attach certificate(s) from the Engineers(s)-in charge
** immediately preceding the financial year in which bids are receivedß Attach certificate from Chartered Accountant.
8/19/2019 Tender2491 MCG
39/161
# 1.3.2 Quantities of work executed as prime contractor, work performed in the past as a nominatedsub-contractor, will also be considered provided the sub-contract involved execution of all main items of work
described in the bid document, provided further that all other qualification criteria are satisfied(in the samename and style) in the last five years:**
Year
20…-20…20…-20…
20…-20…
20…-20…
20…-20…
Nameof theWork
Name ofthe
Employer*CementConcrete
(including
RCC &PCC)
Quantity of work performed (cum)@ Remarks
Masonry Earth WBM WMM BituminousWorks Work
Remarks*(indicatecontract
Ref)
1.4. Information on Bid Capacity (Works for which bids have been submitted and works which are yet to be
completed) as on the date of this bid.
(A)
Description
Existing commitments and on-going works:
Place & Contract Name & Value of Stipulated Value of Anticipatedof work
1
State
2
No.
3
Address ofEmployer
4
Contract(Rs. Cr.)
5
Period ofCompletion
6
works*remaining
to becompleted(Rs. Cr.)
7
date ofcompletion
8
*Attach certificate(s) from the Engineers(s)-in charge** immediately preceding the financial year in which bids are received.
# Delete, if prequalification has been carried out.
8/19/2019 Tender2491 MCG
40/161
(B) Works for which bids already submitted:
Description Place & Name & Estimated Stipulated Date when Remarks, if
of works
1
State
2
Address ofEmployer
3
value ofworks (Rs.
Cr.)
4
period ofcompletion
5
decision isexpected
6
any
7
1.5. Availability of key items of Contractor’s Equipment essential for carrying out the works [Ref.Clause 4.5.5]. The Bidders should list all the information requested below. Refer also to Sub-Clause 4.3
(d) of the Instructions to Bidders.
Item of
Equipment
Requirement Availability proposals Remarks,
(from
whom toNo. Capacity Owned/Leased
to be procuredNos/capacity Age/Condition be
purchased)
8/19/2019 Tender2491 MCG
41/161
1.6. Qualifications and experience of key personal required for administration and execution of the Contract[Ref. Clause 4.5.4] Attach biographical data. Refer also to Sub Clause 4.3(e) of instructions to Bidders
and Sub clause 9.1 of the Conditions of Contract.
Position
Project Manager
Etc.
Name Qualification Year of Experience(General)
Year of Experiencein the proposed
position
1.7. Proposed sub-contracts and firms involved [refer ITB clause 4.3(k)]
Sanctions of work Value of Sub-contract Sub-contractor
(Name & Address)Experience in similar
work
Attach copies of certificates on possession of valid license for executing water supply/sanitary
work/building electrification work [Reference Clause 4.5.3(c)].
8/19/2019 Tender2491 MCG
42/161
*1.8. Financial reports for the last five years: balance sheets, profit and loss statements, auditors’ reports (incase of companies/corporation ), etc. List them below and attach copies.
1.9. Evidence of access to financial resources to meet the qualifications requirements: cash in hand, lines ofcredit, etc. List them below and attach copies of support documents.
1.10. Name, address, and telephone, telex and fax numbers of the Bidders’ bankers who may providereferences if contacted by the Employer.
1.11. Information on litigation history in which the Bidder is involved.
Other Party(ies) Employer Cause of Dispute Amount involved Remarks showing PresentStatus
1.12 Statement of compliance under the requirements of Sub –Clause 3.2 of the instructions to
Bidders.(Name of consultant engaged for project preparation is **………………………..…)
1.13. Proposed work method and schedule. The Bidders should attach descriptions, drawings and
charts as necessary to comply with the requirements of the Bidding documents.[Refer ITB Clause 4.1 &
4.3.(1)]
1.14.
1.15.
2.
3.
Programme
Quality Assurance Programme
Deleted
Additional Requirements
3.1. Bidders should provide any additional information required to fulfill the requirements of Clause 4 of the
Instructions to the Bidders, if applicable.
(i) Affidavit
(ii) Undertaking
(iii) Deleted
(iv) Deleted(v) Deleted.
*
**
Delete, if prequalification, has been carried out
Fill the Name of Consultant
*** Delete, if prequalification has not been carried out.
8/19/2019 Tender2491 MCG
43/161
SAMPLE FORMAT FOR EVIDENCE OF ACCESS TO OR
AVILABILITY OF CREDIT FACILITIES
(CLAUSE 4.2 (i ) OF ITB)
BANK CERTIFICATE
This is to certify that M/s. ________________________________________ is a reputed company with a
good financial standing.
If the contract for the work, namely __________________________________is awarded to the above firm,
we shall be able to provide overdraft/credit facilities to the extent of Rs.___________________ to meet
their working capital requirements for executing the above contract during the contract period.
_________________
(Signature)
Name of Bank
Senior Bank Manager
Address of the Bank
8/19/2019 Tender2491 MCG
44/161
AFFIDAVIT
1. I, the undersigned, do hereby certify that all the statement s made in the required attachment are true and
correct.
2. The undersigned also herby certifies that neither our firm M/s _ _
has abandoned any work Municipal Corporation Gurgaon, nor any contract awarded to us for such works
have been rescinded, during last five years prior to the date of this bid.
3. The undersigned also hereby authorize(s) and request(s) any bank, person, firm PSU / Authority or
corporation to furnish pertinent information deemed necessary and requested by the Department to
verify this statement or regarding my (our) competence and general reputation.
4. The undersigned understand and agrees that further qualifying information may be requested, and
agrees to furnish any such information at the request of the Department/Project implementing agency.
_______________________________________
(Signed by an Authorized Officer of the Firm)
________________
Title of Officer
________________
Name of Firm
________________
Date
8/19/2019 Tender2491 MCG
45/161
UNDERTAKING
I, the undersigned do hereby undertake that our firm M/s ________________________________
________________________ would invest a minimum cash up to 25% of the value of the work during
implementation of the Contract.
_______________________________________
(Signed by an Authorized Officer of the Firm)
________________
Title of Officer
________________
Name of Firm
________________
DATE
8/19/2019 Tender2491 MCG
46/161
SECTION 3
CONDITIONS OF CONTRACT
8/19/2019 Tender2491 MCG
47/161
A. General1. Definitions
2. Interpretation
Condition of Contract
Table of Contents
C. Quality Control33. Identifying Defects
34. Tests
3. Language and Law4. Engineer’s Decisions
5. Delegation
6. Communications7. Sub-contracting
8. Other Contractors
9. Personnel
35. Correction of Defects36. Uncorrected Defects
D. Cost Control
37. Bill of Quantities
38. Changes in Quantities10. Employer’s & Contractor’s Risks 39. Variations
11. Employer’s Risks
12. Contractor’s Risks13. Insurance14. Site Investigation Reports
15. Queries about the Contract Data
40. Payments for Variations
41. Cash Flow Forecasts42. Payment Certificates43. Payments
44. Compensation Events
16. Contractor to Construct the Works 45. Tax17. The Works to be Completed by
the Intended Completion Date
18. Approval by the Engineer19. Safety
20. Discoveries
21. Possession of the Site
22. Access to the Site
23. Instructions24. Disputes – Redressal systems
25. Deleted26. Deleted
46. Currencies
47. Price Adjustment
48. Retention49. Liquidated Damages
50. Deleted.
51. Advance Payment
52. Securities
53. Deleted54. Cost of Repairs
E. Finishing the Contract
55. Completion
56. Taking Over
B. Time Control 57. Final Account
27. Programme58. Operating and Maintenance
Manuals
28. Extension of the Intended 59. TerminationCompletion Date 60. Payment upon Termination
29. Deleted 61. Property
30. Delays Ordered by the Engineer 62. Release from Performance31. Management Meetings 63. Defect Liability Period
64. Video Photography
32. Early Warning F. Special Conditions of
Contract
8/19/2019 Tender2491 MCG
48/161
1. Definitions
CONDITIONS OF CONTRACT
A. GENERAL
1.1. Terms which are defined in the Contract Data are not also defined in the Conditions of
Contract but keep their defined meaning. Capital initials are used to identify defined terms.
Bill of Quantities means the priced and completed Bill of Quantities forming part of the Bid.
Compensation Events are those defined in Clause 44 hereunder.The Completion Date is the date of completion of the Works as certified by the Engineer in
accordance with Sub-clause 55.1.
The Contract is the contract between the Employer and the contractor to execute, complete
and maintain the works till the completion of Defects Liability Period. It consists of the documents
listed in Clause 2.3 below.
The Contract Data defines the documents and other information, which comprise the Contract.
The Contractor is a person or corporate body whose Bid to carry out the Works has been accepted bythe Employer.
The Contractor’s Bid is the completed Bidding document submitted by the contractor to the employerand includes Technical and Financial bids.The Contract Price is the price stated in the Letter of Acceptance and thereafter as adjustedin accordance with the provisions of the Contract.Days are calendar days; months are calendar months.
A Defect is any part of the Works not completed in accordance with the Contract ordistressed development in the work irrespective of any causes.
The Defects Liability Period is the period named in the contract Data and calculated from theCompletion Date.
The Maintenance-cum-Defect Liability Period The defect liability period is 5 years.
The Employer is the party who will employ the Contractor to carry out the Works.
The Maintenance –cum- Defect Liability Certificate is the certificate issued by Engineer, after the
defect liability period has ended and upon correction of Defects by the Contractor.
The Maintenance means the activities required to be carried out for routine maintenance of road relating
to works covered in scope of work as per the agreement.
The Engineer is the person named in the contract Data (or any other competent person appointed andnotified to the contractor to act in replacement of the Engineer) who is responsible for supervising thecontractor, administering the Contract, certifying payments due to the Contractor, issuing and valuingVariations to the Contract, awarding extensions of time, and valuing the Compensation Events.
8/19/2019 Tender2491 MCG
49/161
Equipment is the Contractor’s machinery and vehicles brought temporarily to the Site to Construct the Works.
The Initial contract Price is the contract Price listed in the Employer’s Letter of Acceptance.
The Intended Completion Date is the date on which it is intended that the Contractor shall completethe Works. The Intended Completion Date is specified in the Contract Data. The Intended Completion Date may
be revised only by the Engineer by issuing an extension of time.
Materials are all supplies, including consumables, used by the contractor for incorporation in theWorks.
Plant is any integral part of the Works which is to have a mechanical, electrical, electronic or biologicalfunction.
The Site is the area defined as such in the Contract Data.
Site Investigation Reports are those which were included in the Bidding documents and are factual
interpretative reports about the surface and sub-surface conditions at the site.
Specification means the Specification of the Work included in the Contract and any modification oraddition made or approved by the Engineer.
The Start Date is given in the Contract Data. It is date when the Contractor shall commence executionof the works. It does not necessarily coincide with any of the Site Possession Dates.
A Subcontractor is a person or corporate body who has a Contract with the Contractor to carry out apart of the work in the Contract which includes work on the Site.
Temporary Works are works designed, constructed, installed, and removed by the Contractor whichare needed for construction or installation of the Works.
A Variation is an instruction given by the Engineer, which varies the Works.
The Works are what the contract requires the contractor to construct, install maintain and turn over to
the Employer, as defined in the Contract Data.
2. Interpretation
2.1 In interpreting these conditions of Contract, singular also means plural, male also means female orneuter, and the other way around. Headings have no significance. Words have their normal meaning under
the language of the Contract unless specifically, defined. The Engineer will provide instructions clarifying queries
about the conditions of Contract.
2.2 If sectional completion is specified in the contract Data, references in the conditions of Contract to the
Works, the Completion Date, and the Intended Completion Date apply to any Section of the Works (other
than references to the Completion Date and Intended completion date for the whole of the Works)
8/19/2019 Tender2491 MCG
50/161
2.3. The documents forming the Contract shall be interpreted in the following order of priority:
(1)
(2)
(3)
(4)
(5)
(6)
(7)
(8)
(9)
Agreement
Letter of Acceptance, notice to proceed with the works
Contractor’s Bid
Contract Data
Conditions of Contract including Special Conditions of Contract
Specifications
Drawings, if any.
Bill of quantities and
Any other document listed in the Contract Data as forming part of the Contract.
3.
3.1
4.
Language and Law
The language of the Contract and the law governing the Contract are stated in the Contract