1
RAJIV GANDHI THERMAL POWER PLANT (A Unit of Haryana Power Generation Corporation Ltd)
(An ISO: 9001, ISO: 14001 & OHSAS: 18001 Certified Company)
(Regd. Office: UrjaBhawan, Sector-6, Panchkula
Web site www. hpgcl.gov.in Email.id: [email protected] Tel & fax no- 01693-250075
HPGCL
Providing services of 6 Nos. Ex-BHEL Persons for supervisory services during
overhauling of 600 MW, Unit-I, RGTPP, Khedar, Hisar
NIT NO. 32/SYD/2014-15/SYD-1030
DATED: 14/08/2014
ISSUED TO
____________________________
____________________________
____________________________
____________________________
XEN/Switchyard
FOR CHIEF ENGINEER/RGTPP
H.P.G.C.L, HISAR–
TELEPHONE NO. 01693-250075
August-2014
2
RAJIV GANDHI THERMAL POWER PLANT (A Unit of Haryana Power Generation Corporation Ltd)
(An ISO: 9001, ISO: 14001 & OHSAS: 18001 Certified Company)
(Regd. Office: UrjaBhawan, Sector-6, Panchkula
Web site www. hpgcl.gov.in Email.id: [email protected] Tel & fax no- 01693-250075
INDEX
Sr.
No. Description Page No.
1. NIT 3
2. Instructions to Bidders (Annexure-I) 4-6
3. Scope of Work (Annexure-II) 7
4. General Terms & Conditions (Annexure-III) 8-9
5. Terms of Payment (Annexure-IV) 10
6. Rate Quoting Sheet for Main Scope of Work (Annexure-V) 11
7. Deviation (Annexure-VI) 12
3
RAJIV GANDHI THERMAL POWER PLANT (A Unit of Haryana Power Generation Corporation Ltd)
(An ISO: 9001, ISO: 14001 & OHSAS: 18001 Certified Company) (Regd. Office: UrjaBhawan, Sector-6, Panchkula
Web site www. hpgcl.gov.in Email.id: [email protected] Tel & fax no- 01693-250075 HPGCL
NOTICE INVITING TENDER
Tender Enquiry No. NIT No 32/SYD/2014-15/SYD-1030 DATED 14/08/2014
Description of Item Providing services of 6 Nos. Ex-BHEL Persons for supervisory services during overhauling of 600 MW, Unit-I, RGTPP, Khedar, Hisar
Last date for receipt of request for issue of tender documents
08/09/2014 up to 15:00 hrs
Last Date for sale of tender 08/09/2014 up to 17:00 Hrs
Last date of submission of tender 09/09/2014 up to 13:00Hrs
Date of opening of qualifying criteria 09/09/2014 at 15:00Hrs
Earnest Money Rs. 10,000/- (Rupees- Ten Thousand Only)
QUALIFYING REQUIREMENT:
The bids will be accepted from those reputed firms who fulfills following qualifying criteria:-
I. The firm should have experience of providing services of Ex-BHEL Persons for supervisory services to carry out overhauling work of Pressure parts, Burners, APH & Ducts, PA,ID,FD Fans, Valves and ESP of 210 MW or higher capacity Unit of any Thermal Power plant of NTPC/Electricity Board/State Power Utility/PSU, two or more times, during last five years ending 31.07.14.
Firm has to submit Copy of Orders along with Performance Certificate from the same Power plant as a proof of satisfactory supervision of work.
II. The firm should have a own income Tax PAN, EPF code registration No. & Service Tax No. GENERAL CONDITIONS;
1. Tender documents can be purchased from the office of XEN/Switchyard, RGTPP on all working days on payment of Rs.1132/-(Non refundable). (cost of document: - Rs. 1000/- & S.Tax:- Rs.132/-) in cash at the counter or through DD in favour of Sr.A.O., RGTPP, Khedar, Hisar payable at any scheduled bank at Hisar.
2. In case the last date of sale / submission / opening of Tender documents is declared as holiday, the tender documents can be purchased / submitted / opened on the next working day
3. Tender documents can also be downloaded from the website of HPGCL i.e.www.hpgcl.gov.in. Before submitting tenders, the detailed instructions and terms & conditions available on website may be read carefully. The bidder shall submit a separate demand draft/BA-16 towards cost of tender documents along with Part-I offer in case of use of downloaded tender set.
4. Submission of offer does not mean that eligibility is confirmed. Tenders shall be considered of only those firms who fulfill qualifying criteria & deposited required EMD & tender cost.
5. The firm should either be registered with Labour Commissioner, Haryana or have to get the registration immediately after award of work.
6. The negotiations, if required may also be held with L-2 & L-3 bidders along with L-1 bidder, as per HPGCL policy.
7. Chief Engineer/RGTPP reserve the right to cancel the NIT or to change qualifying requirements and other terms & conditions without assigning any reason and will not responsible & will not pay for any expenses or losses that may be incurred by the tenderer in preparation of the tenders/offers.
-sd- XEN/Switchyard,
For Chief Engineer / RGTPP, HPGCL Khedar, Hisar
4
Annexure-I
HPGCL
INSTRUCTIONS TO BIDDERS
All tenderers must carefully observe the following instructions and offers/tenders not strictly in
accordance with these instructions will be liable to rejection:
1 QUALIFYING REQUIREMENT:
The bids will be accepted from those reputed firms who fulfills following qualifying criteria:- I. The firm should have experience of providing services of Ex-BHEL Persons for supervisory
services to carry out overhauling work of Pressure parts, Burners, APH & Ducts, PA,ID,FD Fans, Valves and ESP of 210 MW or higher capacity Unit of any Thermal Power plant of NTPC/Electricity Board/State Power Utility/PSU, two or more times, during last five years ending 31.07.14. Firm has to submit Copy of Orders along with Performance Certificate from the same Power plant as a proof of satisfactory supervision of work.
II. The firm should have a own income Tax PAN, EPF code registration No. & Service Tax No. Firm has to submit dully attested copy of documentary proofs.
2 Mode of Submission of offer:
The bids/tender shall be submitted in two Parts accordance with the procedure detailed hereunder:-
I. Part-I bid should be submitted in sealed envelope super scribing as “Part-1 bid for NIT No
32/SYD/2014-15/SYD-1030 DATED 14/08/2014”, consisting of following sealed envelopes:-
a. Envelope -1 should have cost of tender documents if tenders are downloaded from
web. The envelope should be super scribed as “Tender Cost for NIT No.“
32/SYD/2014-15/SYD-1030 DATED 14/08/2014”.
b. Envalope-2 should have EMD. The envelope should be super scribed as “EMD for NIT
No “32/SYD/2014-15/SYD-1030 DATED 14/08/2014”.
c. Envalope-3 should have attested copies of proof of qualifying criteria. The envelope
should be super scribed as “Qualifying Criteria for NIT No “32/SYD/2014-15/SYD-
1030 DATED 14/08/2014”.
d. Envalope-4 should have copy of the tender documents duly signed & stamped in
token of acceptance of terms & conditions. Power of attorney (if any) be also
furnished in this envelope. Bidders may also submit deviation if any on a separate
page clearly indicating as “Deviations” otherwise it will be presumed that bidders
have accepted all the terms & condition of the NIT. The envelope should be super
scribed as “Technical Bid for NIT No “32/SYD/2014-15/SYD-1030 DATED
14/08/2014”.
II. Part-II bid should be submitted in separate sealed envelope super scribing as “Price bid for
NIT No “32/SYD/2014-15/SYD-1030 DATED 14/08/2014”. The price bid is to be submitted
as per annexure-VIII. The Bids not quoted as per prescribed Annexure (Part-A & Part-B) are
likely to be rejected.
III. Part-I & Part-II bid should be sealed in a separate Envelope of adequate size & super scribed
as “Bid for NIT No “32/SYD/2014-15/SYD-1030 DATED 14/08/2014” and addressed to
XEN/Switchyard, RGTPP, Khedar, Hisar.
3 The qualifying criteria of only those firms will be considered who have deposited cost of tender
documents and EMD, otherwise the tender will be rejected out rightly.
4 Offers/tenders should positively reach before last date prescribed in NIT for their receipt, those
received late will not be considered in any case.
5 In any case, tenders received after due time of receiving will not be considered.
6 HPGCL will not be responsible for any postal delay in submission / receiving of tender on any
other account.
5
7 Telegraphic/telephonic/Fax/e-mailed tender will not be accepted.
8 The decision of HPGCL for consideration of tender will be final in respect of qualifying criteria.
9 Tenders must be complete in all respects.
10 The Offer/tender should be typed or written in ink. Offer/tender written in pencil shall be
ignored.
11 The Offers/tenders will be opened on the date & time prescribed in the Notice Inviting Tender
Documents. In case, the date of opening falls on a holiday or a holiday is subsequently declared
on that day, the tenders will be opened on the next working day following the holiday.
12 The prices quoted by the tenderer should be competitive and as prevailing in the market and
should be firm. Prices should be quoted per unit also wherever applicable and asked.
13 STUDY OF TENDER DOCUMENTS
Before tendering, the tenderer shall carefully study all the clauses and specifications of the
tender documents. If tenderers have any doubt for the meaning of any portion of the tender
specifications or find discrepancies or the tender documents issued are incomplete or needs
clarification aspects, scope of work etc., he shall at once contact the authority inviting the
tender for clarifications before submission of tender. No arguments on this account whatsoever
shall be entertained after the last date & time of submission of tenders.
14 SITE OF WORK INSPECTION
Before tendering, the qualifying tenderer is advised to inspect the site of work & the
environment and make acquaint/familiarize themselves with nature and quantum of actual
work and other prevalent conditions and facilities available. No claim will be entertained later,
on the ground of lack of knowledge.
15 EARNEST MONEY
(a) The tenderer shall be required to deposit earnest money of Rs. 10,000/- in one of the following
forms:-
(i) Demand draft drawn on the State Bank of Patiala, payable at Thermal Plant, Khedar,
Barwala, Hisar (IFSC Code STBP0001381) or any scheduled Bank at Hisar in favour of Sr.
A.O., RGTPP, Khedar, Hisar.
(ii) Cash at counter of RGTPP, Khedar, Hisar in the form of BA-16.
(b) Earnest money in the name of any officer other than the mentioned above and in any other
form will not be accepted.
(c) The earnest money of successful tenderer will be treated by the HPGCL as part of the security
deposit for faithful execution of the contract.
(d) The bank charges, if any, will be to the account of tenderer.
(e) No claim shall be entertained against the Corporation in respect of interest on earnest money
deposit or its depreciation in value.
(f) The failure on the part of successful tenderer to honor his commitment given in the tender will
constitute a default and in that event, his earnest money will stand forfeited by the HPGCL.
16 The earnest money should be submitted in a separate envelope along with Part-I, which should
bear the words ‘’ Earnest money amount Rs. 10,000/- enclosed for Tender enquiry No. NIT No
32/SYD/2014-15/SYD-1030 DATED 14/08/2014. The envelope should be properly sealed &
signed by the tenderer.
17 RATE/PRICE QUOTING METHOD
The tenderer shall quote the prices in English language and international numerals. The rates
shall be in whole rupees and shall be entered in figures as well as in words. For the purpose of
tender, the metric system of units shall be used.
18 OVERWRITING
All entries in the tender shall either be typed or written in ink. Erasers and over-writing are not
permitted and may render tenders liable to summary rejection. The tenderer shall duly attest all
cancellations and insertions.
19 POWER OF ATTORNEY
The power of attorney in the name of signatory on behalf of the company/firm, for signing the
tender documents and other papers of the contract should be furnished with Part-I tender.
20 DEVIATION
Any deviation shall be strictly with reference to sections and clause numbers given in the tender
schedule, which should be strictly adhered to. Tenderers will submit their deviation strictly as
per sheet at Annexure-VI.
6
21 RATE QUOTING SHEET
(i) The tenderers will quote their rates STRICTLY AS PER THE RATE QUOTING SHEET AT
ANNEXURE-V.
(ii) CONDITIONAL DISCOUNT offered by any tenderer will not be considered for the purpose of
relative comparison of rates quoted by participating tenderers.
However, after opening of tender, the tenderer may be called for negotiations.
22 The officer inviting tenders reserves the right to modify the tender as a whole or in parts and
will not be responsible and not pay for any expenses or losses that may be incurred by the
tenderer in the preparation of the tender.
23 The officer inviting tenders reserves the right to accept or reject any or all tenders without
assigning any reasons and will not be responsible and will not pay for any expenses or losses
that may be incurred by the tenderers in the preparation of the tenders.
24 VALIDITY
The validity of tenders should at least be for a period of 180 days from the date of opening of
Part-II tender.
25 The whole work against this tender shall be awarded to a single firm whose overall quoted
prices are lowest for the complete package.
26 Any statutory taxes/levies, if to be charged extra, should be clearly indicated by tenderer in their
offer separately, failing which it will be presumed that their quoted prices are inclusive of all
such statutory taxes/levies.
-sd- XEN/Switchyard,
For Chief Engineer / RGTPP, HPGCL Khedar, Hisar
7
Annexure-II
HPGCL
SCOPE OF WORK
Supervisory Services of 6 nos. EX-BHEL Persons are required during overhauling of 600 MW Unit, RGTPP, Khedar, Hisar, as mentioned below:-
Sr. No.
Description Field of supervision in
600 MW Unit
No. of days for which supervisory services
are required
1 1 no. EX-BHEL Person who is
expert in the field of Pressure Parts
Pressure Parts 20
2 1 no. EX-BHEL Person who is expert in the field of Burners
Burners 15
3 1 no. EX-BHEL Person who is expert in the field of APH &
Ducts APH & Ducts 20
4 1 no. EX-BHEL Person who is
expert in the field of PA, ID & FD Fans
PA, ID & FD Fans 15
5 1 no. EX-BHEL Person who is expert in the field of Valves
Valves 10
6 1 no. EX-BHEL Person who is
expert in the field of ESP ESP 15
-sd- XEN/Switchyard,
For Chief Engineer / RGTPP, HPGCL Khedar, Hisar
8
Annexure-III
GENERAL TERMS & CONDITIONS
1. FAILURE & TERMINATION OF CONTRACT
If the contractor fails to adhere to the time schedule or if his services are found to be
unsatisfactory, the RGTPP will be entitled at its option either:
a) To cover damages as per penalty clause mentioned at S.No.4 above if the said delay is not
covered by the force majeure reasons. OR
b) To get the work done from any other agency after serving a notice of 03 days on the
contractor at his risk and cost and without prejudice to the provision of the work order. OR
c) To cancel the contract & forfeit the security.
2. CONTRACT AGREEMENT
The contractor shall execute a contract agreement on specific Performa on NJSP of Rs.5/- on
receipt of work order within 07 days.
3. ACCOMODATION
Furnished accommodation in the Field Hostel will be provided, if available, at the prevailing daily
rates.
4. INCOME TAX CLEARANCE CERTIFICATE
After acceptance of the tender, the contractor will be required to submit Income Tax clearance
certificate in original or a certified copy thereof to the Accounts Wing before the release of his
payments.
5. INCOME TAX & SERVICE TAX
Sr.A.O., RGTPP, Khedar, Hisar shall make statutory deduction on account of Income Tax &
Service Tax including surcharge at source from the bills of the contractor at the prevailing rates.
6. The scope of work i.e. no. of man days (Annexure- II) is only tentative and as per the prevailing
conditions of the equipment. The actual quantum of work will be known after opening of the
equipment at the time of execution of work.
7. ARBITRATION:-
I. All matters, questions, disputes, differences and/or claims arising out of and/or concerning
and/or in connection with and/or in consequence of, and /or relating to any contract under
these Regulation, whether or not obligations of either or both the Supplier and the
Corporation under that contract be subsisting at the time of such dispute and whether or
not the contract has been terminated or purported to be terminated or completed, shall be
referred to the sole arbitrator of MD/HPGCL or officer appointed by MD, HPGCL as his
nominee. The award of the arbitrator shall be final and binding on both parties to the
contract.
The objection that the Arbitrator has to deal with matters, to which the contract relates, in
the course of his duties or, he has expressed his views on any or all of the matters in dispute
or difference, shall not be considered as a valid objection.
II. The Arbitration may, from time to time, with the consent of the parties to the contract
enlarge the time for making the award. The venue of the arbitration shall be the place from
which the acceptance of offer is issued or such other place as the Arbitrator, in his
discretion, may determine.
III. All arbitration proceedings under this Regulation shall be governed by the provisions of the
Arbitration and Conciliation Act, 1996 and the Rule thereunder, with any statutory
modifications thereof for the time being in force.
8. The contract is subject to jurisdiction of Courts of Hisar only.
9. HPGCL reserves the right to cancel the work order at any time without assigning any reasons
and will not be responsible and will not pay for any expenses or losses.
9
10. Any tenderer who has participated in Original NIT/ Corrigendum can revise Price bid / Part-II
tender suo-moto any times and at any time before opening of Price-bids but in that case all the
Price bids including original one shall be opened and lowest bid shall be considered for all the
purposes.
11. Any statutory taxes/levies, if to be charged extra, should be clearly indicated by tenderer in their
offer separately, failing which it will be presumed that their quoted prices are inclusive of all
such statutory taxes/levies.
12. Service Engineers will report at RGTPP site within 3 days from the date of intimation given by
concerned XEN-in-charge i.e. XEN/BMD-I, RGTPP, Khedar, Hisar.
13. Shutdown of Unit-I, RGTPP is expected in the month of October, 2014. However, exact date of
commencement of Shutdown will be intimated by concerned XEN-in-charge separately.
14. 100% payment will be made on submission of invoice as per actual days availed and after
successful completion of work.
15. Journey time of service engineer from firm’s work place to the RGTPP site and back, will not be
counted towards the actual nos. of days for which his services will be utilized at RGTPP site of
work.
16. Free medical facility shall be extended to Agency staff from HPGCL/RGTPP dispensary/First Aid
Centre.
17. A copy of service tax registration no. and pan no. is to be supplied by the firm.
18. Tentative No. of days for which Service personnel is required at RGTPP are as mentioned in
scope of work, which may be varied as per actual field condition/circumstances. However,
payment be made on basis of actual no. of days availed.
-sd- XEN/Switchyard,
For Chief Engineer / RGTPP, HPGCL Khedar, Hisar
10
Annexure-IV
TERMS OF PAYMENTS
100% of the contract value will be paid on submission of invoice after successful
completion of work.
Payment will be done on the basis of actual no. of days for which services of
engineer will be availed.
EMD amount will be refunded after one month period from the date of
completion of work.
-sd- XEN/Switchyard,
For Chief Engineer / RGTPP, HPGCL Khedar, Hisar
11
Annexure-V
RATE QUOTING SHEET
Sr. No.
Description
No. of days for which
supervisory services
are required
Unit
Rates to be quoted by the contractor
Unit Rate (i.e. per day
charges) Total Amount
1
1 no. EX-BHEL Person who is expert in the
field of Pressure Parts
20 No. of Day
2
1 no. EX-BHEL Person who is expert in the
field of Burners
15 No. of Day
3
1 no. EX-BHEL Person who is expert in the
field of APH & Ducts
20 No. of Day
4
1 no. EX-BHEL Person who is expert in the
field of PA, ID & FD Fans
15 No. of Day
5
1 no. EX-BHEL Person who is expert in the
field of Valves
10 No. of Day
6
1 no. EX-BHEL Person who is expert in the field of ESP
15 No. of Day
Total
Total Quoted Rate:
Rupees _______________________(in numbers)+ Service tax as applicable
Rupees _____________________________________________________(in words)+ Service tax as applicable
Note:
1. The whole work against this tender shall be awarded to a single firm whose overall quoted
prices are lowest.
2. Apart from the above, any statutory taxes/levies, if to be charged extra, should be clearly
indicated by tenderer in their offer separately, failing which it will be presumed that their
quoted prices are inclusive of all such statutory taxes/levies.
3. Rates to be quoted should be inclusive of travelling, lodging & boarding charges.
4. The tenderers will quote their rates strictly as per ibid RATE QUOTING SHEET.
Signature of bidder with office seal
12
Annexure-VI
DEVIATION
To
XEN/Switchyard, RGTPP, Khedar, Hisar. Subject: Deviation against job- Providing Cup Lock Scaffolding works inside Boiler of 600 MW
Unit-I, RGTPP, Khedar, Hisar, NIT No “32/SYD/2014-15/SYD-1030 DATED 14/08/2014”
We declare that we have read and fully understood the scope of works
specifications and all other terms & conditions of your bid documents for the subject
works. Further, I confirm that the following are our deviation, for this work:-
Sr. No.
Ref. Bid Documents & Clause No. Details of Deviation taken
Note:
1. Bidder may attach separate Sheet, if required.
2. Bidder shall clearly mention their deviations, if any.
3. If there are no deviations, bidders should mention NIL in the above statement.
4. Bidders must sign and put company’s seal in the space mentioned below.
Signature of bidder with office seal