Version No. 008
Building Regulations 2018S.R. No. 38/2018
Version incorporating amendments as at1 December 2019
TABLE OF PROVISIONSRegulation Page
Part 1—Preliminary 1
Division 1—Introduction 1
1 Objectives 12 Authorising provisions 23 Commencement 24 Revocations 2
Division 2—Definitions and interpretation 3
5 Definitions 36 Interpretation 127 Numerical values 138 Use of buildings 139 Approved forms 13
Part 2—Building Code of Australia 14
10 Building Code of Australia 1411 Use of BCA terms 1412 Classification of buildings 1413 Relevant building surveyor must determine the
classification of a building 14
Part 3—Owner-builders 15
Division 1—Applications for certificates of consent for owner-builders 15
14 Applications for certificates of consent 1515 Information to accompany application for certificate of
consent 1616 Additional information to accompany application for
certificate of consent if land is owned by body corporate 1617 Additional information to accompany application for
certificate of consent if land is subject to trust 17
1
18 Fee for an application for certificate of consent 1819 Required knowledge for owner-builders 18
Division 2—Certificates of consent 18
20 Information in certificate of consent 1821 Register of certificates of consent 1922 Publication of information kept on the register of
certificates of consent 20
Part 4—Building permits 21
Division 1—Exemptions 21
23 Exemptions from building permits 21
Division 2—Applications for building permits 21
24 Applications for building permits 2125 Application for permit to construct or alter building 2226 Application for permit to demolish or remove building 2427 Exemption from application requirements for certain
building work 2528 Application for permit where swimming pool or spa
proposed 2529 Additional information to accompany application for
permit 26
Division 3—Report or consent of reporting authorities 27
30 Prescribed reporting authorities 2731 Prescribed matters 2832 Time limits for application to be given to reporting
authority 2833 Further time for an applicant to supply a report or consent 2934 Time limits relating to the report or consent of reporting
authorities 2935 Time within which relevant building surveyor must decide
application for building permit 3036 Maximum fees for report and consent 30
Division 4—Building permits 31
36A Manner in which relevant building surveyor may be satisfied of builder's insurance details 31
36B Specification of builders in relation to specific building work 32
37 Issue of building permit 3238 Building surveyor to document determination of
performance solution 3239 Building surveyor to provide copy of permit 3340 Applicant to make documents, permit available 33
2
41 Provision and display of permit information 3342 Owner to notify of change of details or owner 3443 Builder to notify change of name or address 35
Division 5—Duties of building surveyor 35
44 Documents to be given to council 3545 Lodgement fees 3747 Information the relevant building surveyor must give to the
Authority 3847A Relevant building surveyor must notify Authority and
relevant council of certain information 4148 Guarantees and bonds 42
Division 6—Duties of council 42
49 Period that documents must be kept 4250 Relevant council to make documents available on request 4351 Requests for information from relevant council 4352 Fees for requests for information 44
Division 7—Time limits for building work and permits 44
53 Commencement of work 4454 Completion of building work 4455 Lapsing of building permit 4556 Notice of imminent lapse of building permit—
commencement of work 4657 Notice of imminent lapse of building permit—completion
of work 4658 Copy of notice of imminent lapse of building permit to be
provided 4659 Extension of building permit 47
Division 8—Combined allotments 47
60 Application to treat a combined allotment as one allotment 4761 Information to be contained in or documents to accompany
application 4862 Building surveyor may request more information 4963 Application may be refused if information not provided 4964 Determination to treat a combined allotment as one
allotment 5065 Effect of determination 5166 Revocation of determination 5167 Private building surveyor may exercise functions of
municipal building surveyor under this Division 51
3
Part 5—Siting 52
Division 1—Introduction 52
68 Application 5269 What is an existing building? 5270 What is a single dwelling? 5371 Approved building envelope design overrides siting
requirement 53
Division 2—Single Class 1 buildings and associated Class 10a buildings 54
72 Application of Division 5473 Maximum street setback 5474 Minimum street setbacks 5575 Building height 5876 Site coverage 5876A Minimum garden area 5977 Permeability 6178 Car parking 6279 Side and rear setbacks 6280 Walls and carports on boundaries 6481 Daylight to existing habitable room windows 6682 Solar access to existing north-facing habitable room
windows 6783 Overshadowing of recreational private open space 6984 Overlooking 7085 Daylight to habitable room windows 7286 Private open space 73
Division 3—Siting of Class 10a buildings 74
87 Siting of Class 10a buildings 74
Division 4—Class 10b structures 74
88 Application of Division 7489 Front fence height 7490 Fence setbacks from side and rear boundaries 7591 Fences on or within 150 mm of side or rear boundaries 7692 Fences on intersecting street alignments 7793 Fences must not include barbed wire 7894 Fences and daylight to habitable room windows in existing
dwelling 7895 Fences and solar access to existing north-facing habitable
room windows 7996 Fences and overshadowing of recreational private open
space 8097 Masts, poles etc. 81
4
Part 6—Projections beyond street alignment 82
98 Projections beyond street alignment 8299 Architectural features—narrow street 82100 Architectural features—medium street 82101 Architectural features—wide street 83102 Windows and balconies 83103 Verandahs 84104 Sunblinds and awnings 84105 Service pipes, rainwater heads and service installations 84106 Window shutters 84107 Signs 85108 Service cabinet doors 85109 Report and consent required 85110 Footings adjoining boundaries are permissible 86
Part 7—Protection of adjoining property and the public 88
Division 1—Protection of adjoining property by means of protection work 88
111 Required protection work 88112 Matters relevant building surveyor must consider when
determining if protection work required 88113 Protection work notice 90114 Protection work response notice 91115 Notice of relevant building surveyor determination 91
Division 2—Protection of the public 92
116 Protection of the public 92
Division 3—Demolition 92
117 Demolition 92
Division 4—Excavations and retaining walls 93
118 Excavations 93119 Retaining walls 93
Part 8—Building work 95
Division 1—Methods of assessment of compliance 95
120 Testing of materials 95121 Fire performance requirements—performance solutions 95122 Certificates of compliance—proposed building work 96123 Certificates of compliance—building work 97124 Registered building practitioner must document
performance solutions in certificate of compliance 98125 Evidence of suitability—certificate from professional
engineer or other qualified person 99
5
126 Forms of certificates of compliance 100
Division 2—Special provisions 100
127 Record of pile-driving 100128 Branding of timber 100129 Requirements for permits involving fire safety matters 102130 Report and consent for building over easements 102131 Report concerning need for electricity substations 103132 Report and consent for septic tank systems 103133 Stormwater drainage 104134 Buildings above or below certain public facilities 104
Part 9—Fire safety requirements 105
144 Definition of owner 105145 Automatic smoke detection and alarm systems 105146 Residential care buildings—automatic fire suppression
systems 107147 Shared accommodation buildings—automatic fire
suppression systems 108
Part 9A—Safety requirements for, registration of, and certification of barriers for, swimming pools and spas 113
Division 1—Application of Part 113
147A Application of this Part 113
Division 2—Requirements for barriers for swimming pools and spas 113
147B Application of Division 113147C Requirement for barriers 113147D Requirements for doors or gates 114147E Requirements for windows in walls used as barriers 115
Division 3—Maintenance and operation of barriers for swimming pools and spas 115
147F Swimming pool and spa barrier maintenance 115147G Swimming pool and spa barrier operation 116147H Swimming pool and spa barrier gate must remain closed 116
Division 4—Registration of swimming pools and spas 116
147I Certain swimming pools and spas exempted from section 216D of the Act 116
147J Prescribed information for swimming pool and spa registers 117
147K A register must be maintained in the following form and manner 118
6
147L Application for registration of swimming pools and spas constructed, or where construction commenced, before 1 June 2020 118
147M Application for registration of swimming pools and spas constructed on or after 1 June 2020 119
147N Application for registration of relocatable swimming pools and relocatable spas 120
147O Relevant council may require owner to apply for registration of swimming pool or spa 120
147P Form and fee for registration application 121147Q Council must register swimming pool or spa on receipt of
application 121147R Relevant council must give a notice to the applicant of
registration of swimming pool or spa and certain other matters 122
147S Removal of swimming pool or spa from a register 123
Division 5—Inspection and certification of compliance of barriers 124
Subdivision 1—Date of construction of a swimming pool or spa 124
147T Determination by the relevant council of the date of construction of a swimming pool or spa 124
147U Determination by the relevant council of the date of construction of a relocatable swimming pool or relocatable spa 125
Subdivision 2—Certificates of pool and spa barrier compliance 125
147V Obligation to lodge certificate of pool and spa barrier compliance 125
147W Exemption from requirement to provide first certificate of pool and spa barrier compliance for certain swimming pools and spas 127
147X Fees for lodging a certificate of pool and spa barrier compliance with a relevant council 128
147Y Issuing of certificates of pool and spa barrier compliance 129147Z Relevant council may extend time for lodgement of a
certificate of pool and spa barrier compliance 130
Subdivision 3—Alterations to a registered swimming pool or spa or related barrier 131
147ZA Application of this Subdivision 131147ZB Issue of certificate of pool and spa barrier compliance by
relevant building surveyor following completion of work 131147ZC Owner must lodge certificate of pool and spa barrier
compliance with relevant council following certain work 132147ZD Relevant council must update applicable barrier standard in
register 132
7
147ZE Relevant council must confirm receipt of certificate of pool and spa barrier compliance 132
Division 6—Issuing of certificates of pool and spa barrier non-compliance and related matters 133
147ZF Circumstances in which a certificate of pool and spa barrier non-compliance must be immediately issued 133
147ZG Procedure if a barrier does not meet the applicable barrier standard 134
147ZH Further inspection of a non-compliant barrier 135147ZI Issuing a certificate of pool and spa barrier
non-compliance under this Division 137147ZJ Fees for lodging a certificate of pool and spa barrier non-
compliance with a relevant council 137147ZK Municipal building surveyor may serve a barrier
improvement notice on owner 138
Division 7—General 139
147ZL Relevant council's actions following transfer of land containing a registered swimming pool or registered spa 139
147ZM Relevant council to provide information from register to the Authority 140
Part 10—Designation of special areas for building work 141
148 Mapping of designated special areas 141149 Alteration to and creation of designated special area 141150 Termite risk areas 141151 Construction in termite risk areas 142152 Significant snowfall areas 142153 Report and consent for building in areas liable to flooding 142154 Report and consent for construction on designated land or
designated works 144
Part 11—Bushfire safety 145
Division 1—Construction in designated bushfire prone areas 145
156 Relevant building surveyor must accept bushfire attack level in planning scheme or site assessment for planning permit 145
157 Relevant building surveyor must accept bushfire attack level of 12·5 146
158 Specific use bushfire protected buildings—construction requirements 146
Division 2—Requirements for buildings replacing buildings destroyed in the 2009 bushfires 148
159 Application of this Division 148
8
160 Static water supply for fire fighting purposes 148161 Access for emergency vehicles 150162 Report and consent required for non-complying static
water supply and access 152
Division 3—Private bushfire shelters 152
163 Application of this Division 152164 Private bushfire shelter construction requirements 152165 Private bushfire shelter performance requirements—
performance solutions 153166 Private bushfire shelter maintenance and operation 154
Part 12—Inspections, notices and orders, and register of powers of entry 155
Division 1—Inspections and directions 155
167 Prescribed mandatory notification stages for construction or alteration of building 155
168 Prescribed mandatory notification stages for demolition or removal of building 155
169 Prescribed mandatory notification stages for construction of swimming pool or spa 156
170 Omission of irrelevant mandatory notification stage 156171 Building permit must specify mandatory notification stages 156172 Building surveyor must cause fire and smoke resisting
building elements to be inspected 157173 Record of inspection of building work 158174 Prescribed persons carrying out inspections 158175 Relevant building surveyor to keep and make available
directions to fix building work 159176 Person to whom authorised person must give documents
under section 37J of the Act 160
Division 2—Notices and orders 160
177 Emergency orders 160178 Form of emergency orders 161179 Building notices 161180 Form of building notice 161181 Building orders 162182 Form of building orders 162182A Additional information in order or notice served in
accordance with section 236(4A) of the Act 163
Division 3—Powers of entry 163
183 Register of exercise of powers of entry 163
9
Part 13—Occupancy permits and certificates of final inspection 166
Division 1—General 166
184 Application of Part 166185 Exemptions from occupancy permit 166
Division 2—Applications for occupancy permit 166
186 Application for occupancy permit 166187 Reporting authorities for occupancy permit 167188 Time limits for application to be given to reporting
authority 168189 Time limits relating to the report or consent of reporting
authorities 168190 Time within which relevant building surveyor must decide
application for occupancy permit 169191 Time within which municipal building surveyor must
decide application to amend occupancy permit 169
Division 3—Occupancy permits 170
192 Form of occupancy permit 170193 Relevant building surveyor to provide copy of permit 170194 Occupancy permit must specify essential safety measures
and related requirements 170195 Condition on occupancy permit 171196 Compliance with AS 1851—2012 taken to be compliance
with earlier standards 172
Division 4—Display and inspection requirements for occupancy permits 173
197 Display of occupancy permit at approved location 173198 Approved location for display of permit 173199 Owner to make permit available for inspection 174
Division 5—Certificates of final inspection 174
200 Form of certificate of final inspection 174201 Relevant building surveyor to notify chief officer of issue
of certificates of final inspection 174
Division 6—Records 175
202 Keeping of occupancy permit records 175203 Documents to be given to council 176204 Prescribed time to give council other documents 177205 Information to be supplied to council 178
Part 14—Places of public entertainment 179
206 Prescribed classes of buildings or places 179
10
207 Prescribed temporary structures 180208 Exemption from permit for temporary structures 180209 Prescribed place of public entertainment 181210 Conditions on occupancy permits 181211 Safety officer qualifications 182212 Structural design of prescribed temporary structures 182
Part 15—Maintenance of buildings and places of public entertainment 183
Division 1—Maintenance of essential safety measures 183
Subdivision 1—General 183
213 Application of this Division 183214 Definitions in this Division 183
Subdivision 2—Maintenance determinations 185
215 Maintenance determinations for essential safety measures in buildings and places of public entertainment 185
216 Owner must comply with maintenance determination 186217 Compliance with AS 1851—2012 taken to be compliance
with earlier standards 186
Subdivision 3—Maintenance schedules 187
218 Relevant building surveyor must prepare or update maintenance schedule for an existing building or place of public entertainment 187
219 Owner of building or place of public entertainment may apply for maintenance schedule 188
220 Building surveyor may prepare maintenance schedule 188221 Building surveyor must give owner copy of maintenance
schedule 189222 Maintenance schedules 189
Subdivision 4—Reporting and records 190
223 Owner must prepare annual essential safety measures report 190
224 Contents and form of annual essential safety measures report 191
225 Records relating to essential safety measures must be made available 192
226 Maintenance responsibility of owner of building or place of public entertainment 193
227 Essential safety measures not to be removed from approved locations 194
11
Division 2—Maintenance of exits and paths of travel relating to buildings or places of public entertainment 194
228 Maintenance of exits and paths of travel by occupiers of buildings or places of public entertainment 194
Part 16—Existing buildings 195
Division 1—Change of use of existing buildings 195
229 Change of use 195230 Private building surveyor may exercise functions of
municipal building surveyor under regulation 229 196
Division 2—Subdivision of existing buildings 196
231 Subdivision of existing building 196232 Private building surveyor may exercise functions of
municipal building surveyor under regulation 231 197
Division 3—Alterations 197
233 Alteration to existing building 197234 Alterations affecting exits and paths to exits 198235 Extension of non-complying external wall 199236 Application of requirements in the BCA Volume One
relating to access to buildings for persons with disabilities 199
Division 4—General 203
237 Small live music venue classification 203
Part 17—Building product accreditation 205
Division 1—Definitions 205
238 Definitions 205
Division 2—Accreditation persons and bodies 205
239 Prescribed persons and bodies to accredit building products 205240 Definition of Certificate of Accreditation in the BCA 205
Division 3—Accreditation by Committee 206
241 Application of Division 206242 Application for accreditation 206243 Information in application to remain confidential 207244 Accreditation fees 207245 Certificate of accreditation 207246 Revocation of accreditation 208247 Holder may request revocation of accreditation 209248 Notice of revocation of accreditation 209249 Accreditation ceases to have effect on revocation 210250 Offence to falsely claim product accredited 210
12
Division 4—Register and records 210
251 Register of accredited products 210252 Records 211
Part 18—Building practitioners 212
Division 1—Registration 212
254 Information to accompany application for registration 212254A Other financial probity criteria 213255 Certificate of registration 214256 Condition of registration 214256A Authority to be advised of nominee director changes 214
Division 1A—Register of Building Practitioners 215
256B The Register of Building Practitioners 215256C Publication of information on Register of Building
Practitioners 216
Division 2—Prescribed qualifications and classes of building practitioner 218
257 Prescribed classes of building practitioner 218258 Prescribed qualifications 218259 Building surveyor work 219260 Building inspector work 219261 Domestic builder work 219
Division 3—Requirements for advertising and written statements 220
262 Advertisements or written statements by registered building practitioners 220
263 Advertisements or written statements by partnerships 220
Division 3A—Probity and discipline 220
263A Authority must be notified of probity matters 220263B Grounds for disciplinary action 224263C Grounds for immediate suspension 224
Division 4—General 224
264 Notice of suspension or cancellation of registration 224265 Professional standards 225266 Duplicate certificate fee 225267 Period for which private building surveyor may not act 225
Division 5—Exemptions for certain building practitioners 225
268 Relevant building surveyor exempt from section 24A in relation to certain types of building work 225
13
269 Relevant building surveyor exempt from section 24(6) and (7) of the Act in relation to certain building permit applications 226
Part 19—Appeals and reviews 227
271 Appeal periods 227272 Appeal, referral and application fees 231273 Fees for fast track appeals 232274 Refund of fees by Authority 233275 Review period 233
Part 20—Infringement notices 234
276 Authorised officers 234277 Prescribed offences 234278 Prescribed penalties 234
Part 21—Exemptions 235
279 Exemptions from building regulations 235280 Exemption for Class 10 buildings on farm land 235281 Exemptions relating to building surveyors for certain
buildings 235
Part 22—Transitional and savings provisions 238
283 Registration of building practitioners not affected by revocation of Building Interim Regulations 2017 238
284 Domestic builder (manager) 238285 Appointment of private building surveyor 238
Part 23—Revocation of temporary fees 240
286 Revocation of regulations prescribing fees 240
Schedule 1—Revocations 241
Schedule 2—Duties and responsibilities of an owner-builder 242
Schedule 3—Exemptions for building work and buildings 244
Schedule 4—Forms 253
Schedule 5—Prescribed matters reported on by prescribed reporting authorities 332
Schedule 6—Planning schemes 336
Schedule 7—Planning schemes applying to allotments containing homes destroyed in the 2009 bushfires 345
Schedule 8—Essential safety measures 346
Schedule 9—Prescribed classes of building practitioners and prescribed qualifications 351
14
Schedule 10—Work authorised to be carried out by a registered building surveyor 399
Schedule 11—Work authorised to be carried out by a registered building inspector 402
Schedule 12—Domestic building work authorised to be carried out by registered domestic builders 404
Schedule 13—Planning schemes that have an approved infrastructure contributions plan 412
════════════
Endnotes 413
1 General information 413
2 Table of Amendments 415
3 Amendments Not in Operation 416
4 Explanatory details 417
15
16
Version No. 008
Building Regulations 2018S.R. No. 38/2018
Version incorporating amendments as at1 December 2019
Part 1—Preliminary
Division 1—Introduction1 Objectives
The objectives of these Regulations are—
(a) to remake with amendments the regulations which control the design, construction and use of buildings and places of public entertainment; and
(b) to prescribe standards for the construction and demolition of buildings; and
(c) to prescribe standards of safety for places of public entertainment; and
(d) to regulate matters relating to the use and maintenance of buildings and places of public entertainment; and
(e) to prescribe requirements for the design and siting of single dwellings and associated buildings; and
(f) to prescribe standards and matters relating to the maintenance of fire safety and safety measures; and
(g) to prescribe requirements for swimming pools and spas including—
(i) swimming pool and spa safety; and
1
Reg. 1(g) substituted by S.R. No. 116/2019 reg. 5.
(ii) registration of swimming pools and spas; and
(iii) inspection of swimming pools and spas; and
(iv) prescribing maximum fees relating to the registration of, lodgement of documents and information searches relating to, swimming pools and spas; and
(h) to provide for matters relating to the accreditation of building products, construction methods, designs, components and systems connected with building work; and
(i) to prescribe qualifications and provide for other matters relating to registration of building practitioners; and
(j) to prescribe fees in relation to matters before the Building Appeals Board, the Authority and the Building Regulations Advisory Committee; and
(k) to provide for other matters for the purposes of the Building Act 1993.
2 Authorising provisions
These Regulations are made under sections 7, 9, 15A, 261 and 262 of, and Schedule 1 to, the Building Act 1993.
3 Commencement
These Regulations come into operation on 2 June 2018.
4 Revocations
The Regulations listed in Schedule 1 are revoked.
2
Division 2—Definitions and interpretation5 Definitions
(1) In these Regulations—
allotment means land that can be disposed of separately under section 8A of the Sale of Land Act 1962 without being subdivided;
applicable barrier standard, in relation to a swimming pool or spa barrier, means—
(a) the requirements of the Act and these Regulations with which the barrier must comply (the barrier requirements) in force at the date of construction of the swimming pool or spa; or
(b) if after the date of construction of the swimming pool or spa, building work is carried out on the whole or part of the barrier resulting in the whole or part of the barrier having to comply with any subsequent barrier requirements—
(i) the subsequent barrier requirements in force at the date of the issue of any building permit for the building work; or
(ii) the subsequent barrier requirements in force at the date of the commencement of the building work if no building permit was issued for the building work;
approved means approved by the relevant building surveyor;
3
Reg. 5(1) def. of applicable barrier standard inserted by S.R. No. 116/2019 reg. 6.
approved building envelope means documented design parameters that deal with a siting matter regulated under Part 5 that—
(a) are specified in a planning permit for the subdivision of land granted under the Planning and Environment Act 1987 on or after 1 July 1994; and
(b) are—
(i) specified in an agreement made under section 173 of the Planning and Environment Act 1987 that is recorded on the Register under the Transfer of Land Act 1958 in relation to the relevant allotment; or
(ii) shown as restrictions on the plan of subdivision of land certified under the Subdivision Act 1988 that is recorded on the Register under the Transfer of Land Act 1958 in relation to the relevant allotment;
architectural feature means eaves, brackets, cornices, light fixtures, coping, fascia, windowsills and similar parts of a building that are for decorative purposes and which can be removed from a building or structure without adversely affecting that building's structural integrity;
AS 1851—2012 means AS 1851—2012 Routine service of fire protection systems and equipment published on 3 December 2012, as in force or as issued from time to time;
4
AS 3959 means AS 3959:2018 Construction of buildings in bushfire-prone areas published on 14 November 2018, as incorporated for the time being by the BCA;
BCA means the Building Code of Australia;
BCA Volume One means Volume One of the National Construction Code Series including any variations or additions in the Victoria Appendix set out in Schedule 1 to that Volume;
BCA Volume Two means Volume Two of the National Construction Code Series including any variations or additions in the Victoria Appendix set out in Schedule 1 to that Volume;
bushfire attack level has the same meaning as in AS 3959;
certificate of final inspection means a certificate issued under section 38 of the Act;
clear to the sky in relation to an area means an unroofed area or an area roofed with a material that transmits at least 90% of light;
combined allotment means two or more adjoining allotments or an allotment and adjoining land;
commencement date in relation to building work has the same meaning as in regulation 55(1);
completion date in relation to building work has the same meaning as in regulation 55(2);
date of construction of a swimming pool or spa means the date the swimming pool or spa was constructed as determined by the relevant council under regulation 147T or 147U (as the case requires);
5
Reg. 5(1) def. of AS 3959 substituted by S.R. No. 40/2019 reg. 5(a).
Reg. 5(1) def. of BCA Volume One amended by S.R. No. 40/2019 reg. 5(b).
Reg. 5(1) def. of BCA Volume Two amended by S.R. No. 40/2019 reg. 5(c).
Reg. 5(1) def. of date of construction inserted by S.R. No. 116/2019 reg. 6.
declared road means a freeway or an arterial road, both within the meaning of the Road Management Act 2004;
designated land means any land declared to be designated land under Part 10 of the Water Act 1989;
designated special area means—
(a) an area liable to flooding; or
(b) an area designated under regulation 150 as an area in which buildings are likely to be subject to attack by termites; or
(c) an area designated under regulation 152 as likely to be subject to significant snowfalls; or
(d) designated land; or
(e) designated works;
designated works means any works declared to be designated works under Part 10 of the Water Act 1989;
drainage authority in relation to a district means the Authority to which Division 3 of Part 10 of the Water Act 1989 applies in relation to that district;
electricity supply authority has the same meaning as electricity corporation has in section 85 of the Electricity Industry Act 2000;
essential safety measure has the same meaning as it has in regulation 214;
farm land has the same meaning as it has in section 2(1) of the Valuation of Land Act 1960;
fence includes—
(a) a screen; or
6
(b) a structure similar to a fence;
fire performance requirement means—
(a) performance requirement BP1.1, DP2, DP3, DP4 or DP6 of the BCA Volume One (to the extentthat it relates to fire safety); or
(b) performance requirement CP1, CP2, CP3, CP4, CP5, CP6, CP7, CP8, CP9, DP5, EP1.1, EP1.2, EP1.3, EP1.4, EP1.5, EP1.6, EP2.1 or EP2.2 of the BCA Volume One; or
(c) performance requirement P2.1.1, P2.3.1 or P2.3.2 of the BCA Volume Two (to the extent that it relates to fire safety for a Class 1b building or a Class 10 building not associated with a Class 1a building);
fire safety engineer means a registered building practitioner in the category of engineer, class of engineer (fire safety);
floodplain management authority in relation to a district means an Authority or Minister to which Division 4 of Part 10 of the Water Act 1989 applies in relation to that district;
Form means a form in Schedule 4;
gas supply authority means—
(a) in relation to an area served by a reticulated gas supply, a gas company within the meaning of the Gas Safety Act 1997; and
(b) in relation to pipelines to which the Pipelines Act 2005 applies, the Minister responsible for the administration of that Act;
7
height in relation to—
(a) a building (other than a wall or fence) at any point, means the vertical distance between natural ground level and the top of the roof covering; and
(b) a wall at any point, means the vertical distance between the natural ground level at the base of the wall and the point at which the outer wall intersects the plane of the top of the roof covering or the top of the parapet, whichever is higher; and
(c) a fence at any point, means the vertical distance between the natural ground level at the base of the fence and the top of the fence;
Keeper of Public Records means the Keeper of Public Records within the meaning of the Public Records Act 1973;
maintenance determination has the same meaning as it has in regulation 214;
maintenance schedule has the same meaningas it has in regulation 214;
medium street means a street that is more than 6 m in width but not exceeding 10 m in width;
narrow street means a street that is 6 m or less in width;
north-facing habitable room window means a window of a habitable room that has an axis perpendicular to its surface oriented true north 20° west to true north 30° east;
pergola means an open structure that is unroofed but may have a covering of open weave permeable material;
8
planning permit means a planning permit granted under the Planning and Environment Act 1987;
planning scheme means a planning scheme approved under the Planning and Environment Act 1987 as in force from time to time;
private open space means—
(a) an unroofed area of land; or
(b) a deck, terrace, patio, balcony, pergola, verandah, gazebo, swimming pool or spa;
recreational private open space means any part of a private open space on an allotment—
(a) which is—
(i) at the side or rear of an existing dwelling on the allotment; or
(ii) within the front setback of an existing dwelling on the allotment and which is screened for at least 90% of its perimeter by a wall, fence or other barrier that is at least 1·5 m high and that has no more than 25% of its area open; and
(b) which is primarily intended for outdoor recreation activities;
register, in relation to a swimming pool or spa, means the swimming pool and spa register of a council;
registered spa means a spa that is registered under Division 4 of Part 9A on a swimming pool and spa register;
9
Reg. 5(1) def. of register inserted by S.R. No. 116/2019 reg. 6.Reg. 5(1) def. of registered spa inserted by S.R. No. 116/2019 reg. 6.
registered swimming pool means a swimming pool that is registered under Division 4 of Part 9A on a swimming pool and spa register;
relocatable spa means a spa that is capable of being relocated;
relocatable swimming pool means a swimming pool that is capable of being relocated;
septic tank system has the same meaning asit has in section 53J(1) of the Environment Protection Act 1970;
service authority means any of the following—
(a) a council;
(b) a drainage authority;
(c) an electricity supply authority;
(d) a gas supply authority;
(e) a sewerage authority;
(f) a water supply authority;
10
Reg. 5(1) def. of registered swimming pool inserted by S.R. No. 116/2019 reg. 6.
Reg. 5(1) def. of relocatable spa inserted by S.R. No. 116/2019 reg. 6.
Reg. 5(1) def. of relocatable swimming pool inserted by S.R. No. 116/2019 reg. 6.
setback, from a boundary or building, means a horizontal distance from that boundary or building;
sewerage authority in relation to a sewerage district under the Water Act 1989 means the Authority for that sewerage district under that Act;
site coverage in relation to an allotment means that part of the allotment, which is covered by buildings, expressed as a percentage of the area of the allotment;
spa unless otherwise stated includes a relocatable spa;
street includes road, highway, carriageway, lane, footway, square, court, alley and right of way;
street alignment means the line between a street and an allotment;
swimming pool unless otherwise stated includes a relocatable swimming pool;
the Act means the Building Act 1993;
water supply authority in relation to a water district under the Water Act 1989 means the Authority for that water district under that Act;
wide street is a street that is more than 10 m in width.
(2) For the purposes of subregulation (1), land is in an area liable to flooding if—
11
Reg. 5(1) def. of spa inserted by S.R. No. 116/2019 reg. 6.
Reg. 5(1) def. of swimming pool inserted by S.R. No. 116/2019 reg. 6.
(a) by or under the Water Act 1989 it is determined as being liable to flooding (however expressed); or
(b) it is identified in a planning scheme under the Planning and Environment Act 1987 as being in an area liable to flooding (however expressed); or
(c) it is described on a certified or sealed plan of subdivision or plan of strata subdivision or plan of cluster subdivision (as the case requires) as being liable to flooding (however expressed); or
(d) it is designated by the relevant council as likely to be flooded by waters from—
(i) a waterway, as defined in section 3(1) of the Water Act 1989; or
(ii) any land upon which water concentrates or upon or over which surface water usually or occasionally flows (whether in a defined channel or otherwise) including land affected by flow from a drainage system.
(3) For the purposes of subregulation (1), the width of a street must take into account the accumulative width of all parts of a street including, for example, footways and roads.
6 Interpretation
If a provision of any document applied, adopted or incorporated by, or referred to in, these Regulations is inconsistent with any provision in these Regulations, the provision in these Regulations prevails.
7 Numerical values
12
The numerical values prescribed in these Regulations must be applied subject to tolerances according to any appropriate code, standard, rule, specification or provision adopted by reference in these Regulations, or normal trade practice, or good practice, as the case requires.
8 Use of buildings
In these Regulations any reference to the purpose for which a building is used includes the purpose for which it is proposed to be used.
9 Approved forms
(1) The Authority may from time to time approve forms for the purposes of these Regulations.
(2) The Authority must publish any approved form in the Government Gazette.
13
Part 2—Building Code of Australia10 Building Code of Australia
The BCA is adopted by and forms part of these Regulations as modified by these Regulations.
11 Use of BCA terms
Subject to the Act and to regulations 5 and 6, words and expressions used in these Regulations have the same meanings as they have in the BCA.
12 Classification of buildings
For the purposes of these Regulations, buildings must be classified as set out in the BCA.
13 Relevant building surveyor must determine the classification of a building
(1) The relevant building surveyor must determine the classification of a building when performing a function under the Act or these Regulations.
(2) If there is any doubt as to the classification of a building under the BCA, the relevant building surveyor must classify the building as belonging to the class it most closely resembles.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
14
Part 3—Owner-builders
Division 1—Applications for certificates of consent for owner-builders
14 Applications for certificates of consent
(1) An application for a certificate of consent to carry out domestic building work on land must be in the form approved by the Authority and contain the information set out in subregulation (2).
(2) For the purposes of section 25C(2)(a) of the Act, the following information is the prescribed information to be contained in the application—
(a) the address of the land on which the domestic building work is to be carried out;
(b) the name, address, telephone number and ABN, ACN or ARBN (if applicable) of each owner of the land;
(c) if the applicant is not an owner of the land, the name, address, telephone number and ABN, ACN or ARBN (if applicable) of the applicant;
(d) a description of the proposed domestic building work;
(e) details of the cost of the proposed domestic building work;
(f) whether or not a building permit referred to in section 25E(1)(e), (f) or (g) of the Act has been issued in the previous 5 years;
(g) the type of work in which the applicant is engaged or intends to engage, and whether it is for profit or gain;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
15
(h) if the applicant intends to seek an exemption under section 25E(4) of the Act, details of the grounds on which the exemption is sought.
15 Information to accompany application for certificate of consent
For the purposes of section 25C(2)(c)(i) of the Act, an application for a certificate of consent must be accompanied by the following information—
(a) any evidence or proof of identity of the applicant that is required by the Authority;
(b) if the land is under the operation of the Transfer of Land Act 1958, a copy of the certificate of title for the land dated within 7 days before the date of the application;
(c) if the land is not under the operation of the Transfer of Land Act 1958, any evidence of ownership of the land required by the Authority;
(d) if the applicant co-owns the land, a written statement from each other owner, stating that the owner authorises the making of the application dated within 28 days before the date of the application.
16 Additional information to accompany application for certificate of consent if land is owned by body corporate
For the purposes of section 25C(2)(c)(i) of the Act, an application for a certificate of consent must be accompanied by the following information in addition to the information required under regulation 15, if the land to which the application relates is owned by a body corporate—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
16
(a) if the owner is a company incorporated under the Corporations Act, a copy of a record of a current company extract dated within 7 days before the date of the application, from the records maintained by the Australian Securities and Investments Commission continued under the ASIC Act that shows the company name, ABN, ACN, the names of the directors and the address of the company's registered office;
(b) if the body corporate is not a company incorporated under the Corporations Act, any evidence of incorporation required by the Authority;
(c) a written authorisation of the body corporate to the making of the application and the carrying out of the domestic building work on the land by the applicant dated within 28 days before the date of the application;
(d) a description of the nature of the business of the body corporate.
17 Additional information to accompany application for certificate of consent if land is subject to trust
For the purposes of section 25C(2)(c)(i) of the Act, an application for a certificate of consent must be accompanied by the following information, in addition to the information required under regulation 15, if the land to which the application relates is the subject of a trust—
(a) a certified copy of the trust deed, together with any subsequent amendments, showing the name of the trust, the name of each trustee and the name of each beneficiary and which is certified within 28 days before the date of the application;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
17
(b) a written authorisation by each trustee of the trust to the making of the application and to the carrying out of the domestic building work by the applicant on the land dated within 28 days before the date of the application;
(c) a description of the nature of the business of the trust (if any).
Note
It is an offence under section 246 of the Act to make false or misleading statements or provide false or misleading information.
18 Fee for an application for certificate of consent
For the purposes of section 25C(2)(c)(ii) of the Act, the fee for an application for the issue of a certificate of consent is 6·9 fee units.
19 Required knowledge for owner-builders
For the purposes of section 25E(1)(ab) of the Act, the knowledge of the duties and responsibilities of an owner-builder set out in Schedule 2 is prescribed.
Division 2—Certificates of consent20 Information in certificate of consent
For the purposes of section 25G(1)(a) of the Act, a certificate of consent must contain the following information
(a) the date of issue of the certificate;
(b) a description of the proposed domestic building work to which the certificate relates;
(c) the address of the land on which the domestic building work to which the certificate relates is to be carried out;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
18
(d) details of the cost of the proposed domestic building work;
(e) an identification number of the certificate;
(f) the name, address, telephone number and ABN, ACN or ARBN (if applicable) of each owner of the land;
(g) if the applicant is not an owner of the land, the name, address, telephone number and ABN, ACN or ARBN (if applicable) of the applicant;
(h) if an owner of the land is a body corporate, the names of all the directors of the body corporate;
(i) if the land is subject to a trust, the name of that trust and the names of all the trustees of that trust.
21 Register of certificates of consent
For the purposes of section 25H(2) of the Act, the register of certificates of consent kept by the Registrar of the Authority must contain the following information in relation to each certificate of consent issued
(a) the date of issue of the certificate;
(b) the identification number of the certificate;
(c) the address of the land to which the certificate relates;
(d) the name, address, telephone number and ABN, ACN or ARBN (if applicable) of each owner of the land;
(e) the description of the proposed domestic building work to be carried out on the land;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
19
(f) if the applicant for the certificate is not an owner of the land, the name, address, telephone number and ABN, ACN or ARBN (if applicable) of the applicant;
(g) if an owner of the land is a body corporate, the names of all the directors of the body corporate;
(h) if the land is subject to a trust, the name of the trust and the names of all the trustees of the trust.
22 Publication of information kept on the register of certificates of consent
(1) For the purposes of section 25H(3) of the Act, the Authority may publish on the Authority's website the following information that is kept on the register of certificates of consent in relation to each certificate of consent issued—
(a) the date of issue of the certificate;
(b) the identification number of the certificate;
(c) a description of the proposed domestic building work to which the certificate relates;
(d) the address of the land on which the domestic building work to which the certificate relates is to be carried out.
(2) The Authority may publish the information under subregulation (1) relating to a certificate of consent issued in the previous 10 years.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
20
Part 4—Building permits
Division 1—Exemptions23 Exemptions from building permits
A building permit is not required under the Act for the buildings and building work specified in column 2 of the Table in Schedule 3.
Division 2—Applications for building permits24 Applications for building permits
(1) An application for a building permit must be in the form of Form 1.
(2) For the purposes of clause 1(a) of Schedule 2 to the Act, the prescribed information to be contained in the application is the information set out in Form 1.
(3) For the purposes of clause 1(b) of Schedule 2 to the Act, the documents to accompany the application are—
(a) the documents set out in Form 1 to accompany the application; and
(b) subject to regulation 27, the documents required under regulations 25, 26 and 28.
(4) An application for a building permit must contain sufficient information to show that the proposed building work will comply with the Act and these Regulations.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
21
25 Application for permit to construct or alter building
(1) An application for a building permit to construct or alter a building must be accompanied by the following—
(a) a copy of any planning permit relating to the proposed building work to which the permit application applies;
(b) drawings showing the plan at each floor level, elevations, sections, dimensions and the sizes and locations of structural members to a scale of not less than 1:100, together with any details that are necessary to show compliance to a scale of not less than 1:20, or to other approved scales;
(c) specifications describing materials and methods to be used in the construction or alteration;
(d) allotment plans to a scale of not less than 1:500 or other approved scales, showing the matters set out in subregulation (2);
(e) a statement of the use or proposed use of all buildings shown on allotment plans;
(f) a copy of any computations or reports necessary to demonstrate that the building and building work will, if constructed in accordance with the computations and reports, comply with the Act and these Regulations;
(g) if the application is for a building permit to alter an existing building, copies of drawings and allotment plans that clearly differentiate between the existing building and the proposed building work for which the permit is sought.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
22
(2) The following matters are to be shown on an allotment plan—
(a) the boundaries and dimensions of the allotment and any easements that are relevant to the proposed building work;
(b) the distance to the nearest intersecting street;
(c) the position and dimensions of the proposed building and its relationship to—
(i) the boundaries of the allotment; and
(ii) any existing building on the allotment; and
(iii) any part of a building or land on an adjoining allotment if necessary to show compliance with the Act and these Regulations;
(d) the levels of the allotment, floors of the building, street drainage channel and stormwater drain;
(e) the layout of drains to the point of discharge on the allotment together with details necessary to show compliance with the Act and these Regulations;
(f) the location, dimensions and area of impermeable surfaces covering the allotment if necessary for the purposes of regulation 77;
(g) the location and dimensions of car parking spaces for the purposes of regulation 78;
(h) the location, dimensions and area of private open space for the purposes of regulation 86.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
23
(3) An application for a building permit to construct or alter a building must also be accompanied by any additional copies of the documents set out in subregulation (1) that the relevant building surveyor reasonably requires.
26 Application for permit to demolish or remove building
(1) An application for a building permit to demolish or remove a building must be accompanied by the following—
(a) a copy of any planning permit relating to the proposed building work to which the permit application applies;
(b) an outline and a description of the building or part of the building to be demolished or removed;
(c) an allotment plan showing the location of—
(i) the building in relation to the boundaries of the allotment and adjoining buildings; and
(ii) other buildings on the allotment; and
(iii) streets, footpaths or crossings adjoining the allotment;
(d) if only a part of the building is to be demolished or removed, computations or other information to show that the remainder of the building will comply with the Act and these Regulations either as it remains after the proposed demolition or removal takes place or after other works are undertaken;
(e) information showing the position and description of hoardings, allotment boundaries, barricades, temporary crossings, protective awnings and outriggers;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
24
(f) a written description of the demolition or removal procedure;
(g) evidence that the demolisher has the necessary knowledge, experience, equipment and storage facilities to properly conduct the demolition operations.
(2) An application for a building permit to demolish or remove a building must also be accompanied by any additional copies of the documents set out in subregulation (1) that the relevant building surveyor reasonably requires.
27 Exemption from application requirements for certain building work
The relevant building surveyor may exempt an application for a building permit in respect of building work from any requirement under regulation 25 or 26 which the relevant building surveyor considers is not required to demonstrate that the building work will comply with the Act and these Regulations.
28 Application for permit where swimming pool or spa proposed
An application for a building permit to construct a swimming pool or spa and any associated safety barrier must include, in addition to other information required under this Part, detailed drawings and specifications of the proposed barrier that—
(a) clearly show the location of the swimming pool or spa and the barrier on the allotment; and
(b) demonstrate the barrier's compliance with these Regulations.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
25
29 Additional information to accompany application for permit
The relevant building surveyor may require all or any of the following information to be submitted in relation to an application for a building permit and the allotment to which it relates—
(a) details of measures for the protection of the public under regulation 116;
(b) documentary evidence to support the use of a material, product, form of construction or design in a form referred to in clause A5.1 of the BCA Volume One or clause A5.2 of the BCA Volume Two;
(c) a survey plan of existing site conditions prepared by a licensed surveyor within the meaning of the Surveying Act 2004;
(d) if the allotment is under the operation of the Transfer of Land Act 1958, a copy of the certificate of title to the allotment;
(e) evidence of ownership of the allotment or evidence that a contract has been entered into pursuant to section 9AA of the Sale of Land Act 1962 in relation to the allotment;
(f) evidence that the building work is to be carried out under the permit by a builder who is specified under section 24B of the Act for that work;
(fa) an extract of the major domestic building contract (if applicable) showing the names of the parties to the contract under which the proposed building work under the permit is to be carried out;
(fb) a copy of the certificate of insurance (if applicable) from an insurer providing
Reg. 29(b) substituted by S.R. No. 40/2019 reg. 6(1).
Reg. 29(f) substituted by S.R. No. 75/2018 reg. 5(1).
Reg. 29(fa) inserted by S.R. No. 75/2018 reg. 5(1).
Reg. 29(fb) inserted by S.R. No. 75/2018 reg. 5(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
26
the required insurance in relation to the proposed building work to be carried out under the permit;
(g) details as to whether the allotment is—
(i) in an area that is liable to flooding within the meaning of regulation 5(2); or
(ii) in an area that is designated under regulation 150 as an area in which buildings are likely to be subject to attack by termites; or
(iii) in an area designated under regulation 152 as likely to be subject to significant snowfalls; or
(iv) in an area that is a designated bushfire prone area as determined under section 192A of the Act; or
(v) designated land;
(h) details as to whether an approved building envelope applies to the allotment or to an adjoining allotment;
(i) a list of any essential safety measures to be provided for the building or place of public entertainment to which the building permit relates.
Division 3—Report or consent of reporting authorities
30 Prescribed reporting authorities
For the purposes of clause 7(2) of Schedule 2 to the Act, the following are prescribed reporting authorities—
(a) the chief officer;
Reg. 29(g)(iv) amended by S.R. No. 75/2018 reg. 5(2).
Reg. 29(i) amended by S.R. No. 40/2019 reg. 6(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
27
(b) a relevant council;
(c) a relevant service authority;
(d) a relevant electricity supply authority.
31 Prescribed matters
For the purposes of clause 7(2) of Schedule 2 to the Act—
(a) a matter set out in column 2 of the Table in Part 1 of Schedule 5 is a prescribed matter in relation to the chief officer; and
(b) a matter set out in column 2 of the Table in Part 2 of Schedule 5 is a prescribed matter in relation to the relevant council; and
(c) a matter set out in column 2 of the Table in Part 3 of Schedule 5 is a prescribed matter in relation to the relevant service authority; and
(d) a matter set out in column 2 of the Table in Part 4 of Schedule 5 is a prescribed matter in relation to the relevant electricity supply authority.
32 Time limits for application to be given to reporting authority
For the purposes of clause 4(2) of Schedule 2 to the Act, the prescribed time within which the relevant building surveyor must give a copy of an application for a building permit to each reporting authority required to report on or consent to the application is—
(a) in the case of an application relating to a Class 1 or 10 building, 3 business days after the relevant building surveyor receives the application; or
(b) in any other case, 5 business days after the relevant building surveyor receives the application.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
28
33 Further time for an applicant to supply a report or consent
For the purposes of clause 5(4) of Schedule 2 to the Act, the further time prescribed for an applicant to supply a report or consent to the relevant building surveyor is—
(a) in the case of an application relating to a Class 1 or 10 building, 3 months; or
(b) in any other case, 6 months.
34 Time limits relating to the report or consent of reporting authorities
(1) For the purposes of clause 6(1), (2) and (3) of Schedule 2 to the Act, the prescribed time is—
(a) in the case of an application relating to a Class 1 or 10 building—
(i) for a matter under Division 2 of Part 5 or regulation 89, within 15 business days after a reporting authority is given an application for a building permit by the relevant building surveyor; and
(ii) in all other cases, within 10 business days after a reporting authority is given an application for a building permit by the relevant building surveyor; or
(b) in the case of an application relating to any other class of building—
(i) for a matter referred to the chief officer, within 15 business days after the chief officer is given an application for a building permit by the relevant building surveyor; and
(ii) in all other cases, within 10 business days after a reporting authority is given
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
29
an application for a building permit by the relevant building surveyor.
(2) For the purposes of clause 6A(2), (3) and (4) of Schedule 2 to the Act, the prescribed time is 15 business days after the reporting authority receives a copy of the application for the building permit.
35 Time within which relevant building surveyor must decide application for building permit
(1) For the purposes of section 19 of the Act, the relevant building surveyor must decide an application for a building permit—
(a) in the case of a Class 1 or 10 building, within 10 business days after the relevant day; or
(b) in any other case, within 15 business days after the relevant day.
(2) In this regulation the relevant day means the earlier of—
(a) the day on which all reports and consents required to be supplied by reporting authorities in relation to the application are received by the relevant building surveyor; or
(b) the day by which the reports and consents referred to in paragraph (a) must be supplied to the relevant building surveyor.
36 Maximum fees for report and consent
(1) The maximum fee payable for the consideration by a responsible authority under the Planning and Environment Act 1987 as a reporting authority of an application for a building permit for demolition of a building referred to the reporting authority under section 29A of the Act for report and consent is 5·75 fee units.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
30
(2) The maximum fee payable for the consideration by the relevant council of an application for a building permit referred to it under regulation 132(1) or 134(2) or Part 5, 6 or 10 is 19∙61 fee units.
(3) The maximum fee payable for the consideration by the relevant council of an application for a building permit referred to it under regulation 116(4) for report and consent is 19·9 fee units.
(4) The maximum fee payable for the consideration by the relevant council of an application for a building permit referred to it under regulation 133(2) for report and consent is 9·77 fee units.
Division 4—Building permits36A Manner in which relevant building surveyor may be
satisfied of builder's insurance details
For the purposes of section 24A(2) of the Act, the relevant building surveyor may be satisfied of the matters in section 24A(1)(c)(i) of the Act by examining—
(a) an extract of the major domestic building contract showing the names of the parties to the contract in relation to the proposed building work; and
(b) a copy of the certificate of insurance from an insurer providing the required insurance in relation to the proposed building work.
36B Specification of builders in relation to specific building work
Reg. 36A inserted by S.R. No. 75/2018 reg. 6.
Reg. 36B inserted by S.R. No. 75/2018 reg. 6.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
31
For the purposes of paragraph (a) of the definition of prescribed amount in subsection 24B(8) of the Act, the amount is $10 000.
37 Issue of building permit
(1) A building permit must be in the form of Form 2.
(2) A building permit must be signed by the relevant building surveyor.
(3) The relevant building surveyor must include on the building permit—
(a) the commencement date and completion date of the building work; and
(b) the mandatory notification stages for inspecting that building work.
38 Building surveyor to document determination of performance solution
The relevant building surveyor must record the following in writing if the relevant building surveyor determines that a performance solution meets a performance requirement of the BCA in relation to proposed building work—
(a) the performance requirement with which the performance solution complies;
(b) details of any one or more of the following that the relevant building surveyor uses or relies on in making the determination—
(i) the assessment method or methods;
(ii) the details of any expert judgement;
(iii) the details of any tests or calculations;
(iv) the details of any standards or other information.
39 Building surveyor to provide copy of permit
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
32
(1) The relevant building surveyor must within7 days after issuing a building permit give to the applicant for the building permit—
(a) a copy of the permit; and
(b) 2 copies of the plans, specifications and other documents (except for computations or reports) lodged with the application (whether or not with amendments) with evidence of approval stamped and endorsed on them.
(2) The relevant building surveyor must give a copy of a building permit within 7 days after the issue of the permit to—
(a) the builder named in the permit; and
(b) the owner of the allotment to which the permit relates if the owner did not apply for the permit.
40 Applicant to make documents, permit available
An applicant for a building permit must provide a copy of the permit and one copy of any documents given to the applicant under regulation 39(1)(b) to the builder named in the building permit.
41 Provision and display of permit information
(1) The builder named in the building permit must ensure that a copy of the building permit and one copy of each document given to the builder under regulation 40 are available for inspection at the allotment while the building work to which the building permit applies is being carried out on that allotment.
Penalty: 10 penalty units.
(2) The builder named in the building permit must ensure that—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
33
(a) the following information is displayed on the allotment to which the permit relates in a conspicuous position accessible to the public before the commencement of the building work to which the permit applies (including demolition or removal of a building on the allotment)—
(i) the registration numbers and contact details of the builder and the relevant building surveyor;
(ii) the building permit number and the date of issue of the permit; and
(b) the information referred to in paragraph (a) continues to be displayed and remains visible and legible for the duration of the building work.
Penalty: 10 penalty units.
42 Owner to notify of change of details or owner
An owner of a building or land to which a building permit relates must notify the relevant building surveyor within 14 days after—
(a) any change—
(i) in the name of the owner; or
(ii) in the postal address of the owner; or
(iii) in the address for serving or giving documents to the owner; or
(b) the owner has transferred the ownership in the building or land.
Penalty: 10 penalty units.
43 Builder to notify change of name or address
Reg. 42 substituted by S.R. No. 75/2018 reg. 7.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
34
A building practitioner registered under Part 11 of the Act who is, or is to be, specified as the builder in a building permit must notify the owner of a building or land to which the building permit relates and the relevant building surveyor within 14 days after any change in the name or address of the building practitioner specified in the permit.
Penalty:10 penalty units.
Division 5—Duties of building surveyor44 Documents to be given to council
(1) The following documents are prescribed for the purposes of section 30(1A) of the Act—
(aa) a notice given to the relevant building surveyor under section 25AA(1) of the Act;
(a) a notice given to the relevant building surveyor under section 25A(2) of the Act;
(b) a notice given to the relevant building surveyor under section 25AB(2) of the Act;
* * * * *
(d) a determination made by the relevant building surveyor under regulation 111(2);
(e) a notice served on the relevant building surveyor under section 84(1) of the Act;
(f) a notice given to the relevant building surveyor under section 85(1)(b) of the Act;
Reg. 44(1)(aa) inserted by S.R. No. 40/2019 reg. 7.
Reg. 44(1)(a) amended by S.R. No. 75/2018 reg. 8(1).
Reg. 44(1)(b) amended by S.R. No. 75/2018 reg. 8(2).
Reg. 44(1)(c) revoked by S.R. No. 75/2018 reg. 8(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
35
(g) a determination of the relevant building surveyor under section 87(1) of the Act;
(h) any determination of the Building Appeals Board;
(i) a report and consent of a reporting authority prescribed under regulation 30;
(j) a record under regulation 38 of a determination of the relevant building surveyor that a performance solution meets a performance requirement of the BCA;
(k) a determination of the municipal building surveyor or a private building surveyor exercising the functions of a municipal building surveyor under regulation 64(1);
(l) a document setting out any requirement of the relevant building surveyor under regulation 116 to take precautions to protect the safety of the public;
(m) any certificate issued under section 238 of the Act on which the relevant building surveyor has relied together with any record of a building practitioner made under regulation 124(1) that relates to the certificate;
(n) any exemption from, or consent to partial compliance with, certain requirements of these Regulations relating to a building or building work that has been given by the municipal building surveyor or a private building surveyor exercising the functions of a municipal building surveyor under regulation 229(2) or 231(2) or by the relevant building surveyor under regulation 233(3) or 234(2);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
36
(o) any document required by the relevant building surveyor under clause 2 of Schedule 2 to the Act;
(p) a copy of any permit required for the construction, installation or alteration of a septic tank system issued under section 53M(5) of the Environment Protection Act 1970 if the building work to which the permit applies involves such construction, installation or alteration.
(2) The prescribed time for the purposes of section 30(1A) of the Act in relation to a document prescribed in subregulation (1) is 7 days after the issue of the building permit.
(3) The following documents are prescribed for the purposes of section 30(1A) of the Act in relation to a building permit for which an occupancy permit is not required—
(aa) a notice given to the relevant building surveyor under section 25AA(1) of the Act;
(a) a notice given to the relevant building surveyor under section 25A(2) of the Act;
(b) a notice given to the relevant building surveyor under section 25AB(2) of the Act.
(4) The prescribed time for the purposes of section 30(1A) of the Act in relation to a document prescribed in subregulation (3) is 7 days after the relevant building surveyor issues a certificate of final inspection in relation to the building work.
45 Lodgement fees
(1) For the purposes of clause 1(d) of Schedule 2 to the Act, the prescribed lodgement fee for the lodging of documents by the relevant building
Reg. 44(2) amended by S.R. No. 75/2018 reg. 8(4).
Reg. 44(3) inserted by S.R. No. 75/2018 reg. 8(5).
Reg. 44(3)(aa) inserted by S.R. No. 40/2019 reg. 7.
Reg. 44(4) inserted by S.R. No. 75/2018 reg. 8(5).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
37
surveyor under section 30 of the Act is 8·23 fee units.
(2) Despite subregulation (1), no lodgement fee is payable for lodging documents in relation to an application for a building permit that relates to a class of building referred to in regulation 281.
* * * * *
47 Information the relevant building surveyor must give to the Authority
(1) A relevant building surveyor must within 7 days after the end of each month give to the Authority in a form approved by the Authority—
(a) details of all permits and certificates of final inspection issued by the relevant building surveyor during that month; and
(b) the following details relating to the building work to which each building permit issued by the relevant building surveyor during that month applies, including—
(i) whether any of the building work will be carried out in a designated bushfire prone area determined under section 192A of the Act and the applicable bushfire attack level determined for the site;
(ii) whether the building work relates to a change of use of a building;
(iii) whether the building work involves the construction of a private bushfire shelter; and
Reg. 46 revoked by S.R. No. 40/2019 reg. 8.
Reg. 47(1)(b)(i) amended by S.R. Nos 75/2018 reg. 9(1), 180/2018 reg. 4.
Reg. 47(1)(b)(iii) amended by S.R. No. 75/2018 reg. 9(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
38
(c) details of any notice given to the relevant council under section 80A(3)(a) or (4)(a) of the Act during that month, if the relevant building surveyor is a registered body corporate.
(2) In addition to the details under subregulation (1), on and from 1 July 2019, the relevant building surveyor must within 7 days after the end of each month give to the Authority in a form approved by the Authority the following details relating to the building work to which each building permit issued by the relevant building surveyor during that month applies—
(a) whether an occupancy permit is required in relation to the building work;
(b) the mandatory notification stages for the building work set out under Part 12;
(c) whether the building work is to be carried out on land that is subject to a determination under regulation 64(1);
(d) whether any exemption from, or consent to partial compliance with, certain requirements of these Regulations relating to the building work has been given by the relevant building surveyor under regulation 229(2), 231(2), 233(3) or 234(2);
(e) whether the building work involves the construction of a swimming pool or spa or an associated safety barrier;
(f) whether the relevant building surveyor determined under regulation 111(2) that protection work is required in relation to the building work.
Reg. 47(1)(c) inserted by S.R. No. 75/2018 reg. 9(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
39
(3) The relevant building surveyor must, within 7 days after the end of each month, give to the Authority in a form approved by the Authority the following details in relation to any building permit issued by the relevant building surveyor—
(a) any lapse of a building permit during that month;
(b) details to the knowledge of the relevant building surveyor of any building work to which the permit applies that is commenced, completed or abandoned during that month.
(4) In addition to the details under subregulation (3), on and from 1 July 2019, the relevant building surveyor must within 7 days after the end of each month give to the Authority in a form approved by the Authority the following details relating to any building permit issued by the relevant building surveyor—
(a) any extension granted during that month by the relevant building surveyor under regulation 59 to the commencement date or completion date of the building work to which the permit applies and the new dates;
(b) any inspection of building work to which the permit applies at a mandatory notification stage under section 34 of the Act;
(c) any determination by the relevant building surveyor that protection work is required in relation to building work to which the permit applies under regulation 111(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
40
47A Relevant building surveyor must notify Authority and relevant council of certain information
(1) For the purposes of section 25AD(1) of the Act, the following events are prescribed—
(a) the builder named in a building permit ceases to be engaged to carry out the building work to which the permit relates;
(b) the relevant building surveyor changes the builder named on a building permit.
(2) For the purposes of section 25AD(1) of the Act, the following information is prescribed—
(a) if the builder named in a building permit ceases to be engaged to carry out building work to which the permit relates—
(i) the building permit number; and
(ii) the address of the building or land to which the building permit relates; and
(iii) the builder named in the building permit; and
(iv) the day that the builder named in the building permit ceased to be engaged to carry out the building work;
(b) if the relevant building surveyor changes the builder named on a building permit—
(i) the building permit number; and
(ii) the address of the building or land to which the building permit relates; and
(iii) the name of the builder named in the building permit and the builder's registration number (if applicable); and
(iv) the day on which the relevant building surveyor changed the name of the builder named in the building permit.
Reg. 47A inserted by S.R. No. 75/2018 reg. 10.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
41
48 Guarantees and bonds
(1) The prescribed circumstances for the purposes of section 22 of the Act are the demolition, removal or re-erection of a building.
(2) For the purposes of section 22(a) and (b) of the Act, the amount of the bond or the amount in respect of which an undertaking and guarantee is given (as the case requires)—
(a) in the case of the demolition or removal of a building, must not exceed the lesser of—
(i) the estimated cost of building work to which the building permit applies; or
(ii) the sum of $100 for every 1 m2 of floor area of the building; and
(b) in the case of the re-erection of a building, must not exceed the lesser of—
(i) the estimated cost of the building work to which the building permit applies; or
(ii) $10 000.
Division 6—Duties of council49 Period that documents must be kept
If a council is required to keep documents under the Act or these Regulations or any corresponding previous regulations in relation to building permits and applications for building permits, including documents relating to protection work, the documents must be kept in any manner specified by the Keeper of Public Records until the building is demolished or removed from the allotment.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
42
50 Relevant council to make documents available on request
On the request of an owner or mortgagee of the building or land, or a person authorised in writing by an owner or mortgagee of a building or land, the relevant council must provide the person making the request with a copy of any documents submitted with an application for a building permit in relation to the building or land.
51 Requests for information from relevant council
(1) Any person may request the relevant council to provide in relation to any building or land—
(a) details of any permit or certificate of final inspection issued in the preceding 10 years; and
(b) details of any current determination made under regulation 64(1) or exemption granted under regulation 231(2); and
(c) details of any current notice or order issued by the relevant building surveyor under the Act.
(2) Any person may request the relevant council to provide in relation to any building or land details as to whether the building or land is—
(a) in an area that is liable to flooding within the meaning of regulation 5(2); or
(b) in an area that is designated under regulation 150 as an area in which buildings are likely to be subject to attack by termites; or
(c) in an area for which a bushfire attack level has been specified in a planning scheme; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
43
(d) in an area designated under regulation 152 as likely to be subject to significant snowfalls; or
(e) designated land; or
(f) designated works.
(3) An owner or mortgagee of a building or land, or a prescribed building practitioner reporting on a building under section 137B of the Act, may request the relevant council to provide the approved dates of the inspections carried out of the mandatory notification stages of building work carried out on the building or land.
52 Fees for requests for information
The fee for the provision of information under regulation 51(1), (2) or (3) is 3·19 fee units.
Division 7—Time limits for building work and permits
53 Commencement of work
If a building permit is issued, the building work must commence—
(a) in the case of the re-erection of a Class 1 or 10 building, within 6 months of the date of issue of the building permit; or
(b) in any other case, within 12 months of the date of issue of the building permit.
54 Completion of building work
(1)If a building permit is issued, the building work must be completed—
(a) in the case of a building permit to re-erect a building, within 12 months after the date of issue of the building permit; or
Reg. 51(2)(d) amended by S.R. No. 40/2019 reg. 9.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
44
(b) in the case of a Class 1 or 10 building, within 24 months after the date of issue of the building permit; or
(c) in the case of a swimming pool or spa or any associated barrier or safety equipment—
(i) if the building work is being carried out on an allotment concurrently with other building work that is being carried out on the same allotment, within the period of completion for the other building work referred to in paragraph (a), (b) or (d) (as the case requires); or
(ii) in any other case, within 6 months after the building work commences; or
(d) in any other case, within 36 months of the date of issue of the building permit.
(2) If building work is to be completed in more than one stage and more than one building permit is issued in relation to that building work, a reference in subregulation (1) to the date of issue of a building permit is taken to be a reference to the date of issue of the first of those building permits.
55 Lapsing of building permit
(1) A building permit lapses if the building work to which the permit applies has not commenced by the last day of the period within which the work must commence under regulation 53 (the commencement date).
(2) A building permit lapses if the building work to which the permit applies is not completed by the last day of the period within which the work must be completed under regulation 54 (the completion date).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
45
(3) A building permit that has lapsed is no longer in force for the purposes of the Act and these Regulations.
56 Notice of imminent lapse of building permit—commencement of work
If, immediately before 30 days before the commencement date of building work including any extension to that date granted under regulation 59, the relevant building surveyor has not carried out an inspection of the first mandatory notification stage of the work under section 34 of the Act, the relevant building surveyor must, without delay, give a notice in the form of Form 3 to the applicant for the building permit that applies to the building work of the date on which the building permit will lapse under regulation 55.
57 Notice of imminent lapse of building permit—completion of work
If, immediately before 30 days before the completion date of building work including any extension to that date granted under regulation 59, the relevant building surveyor has not carried out an inspection of the final mandatory notification stage of the work under section 34 of the Act, the relevant building surveyor must, without delay, give a notice in the form of Form 4 to the applicant for the building permit that applies to the building work of the date on which the building permit will lapse under regulation 55.
58 Copy of notice of imminent lapse of building permit to be provided
Within 7 days after a notice is issued under regulation 56 or 57, the relevant building surveyor must cause a copy of the notice to be given to—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
46
(a) the owner, if the applicant for the relevant building permit is not the owner; and
(b) the builder who is specified as the builder in the building permit subject to the notice of imminent lapse.
59 Extension of building permit
(1) An application for an extension of the commencement date or the completion date of building work may be made in writing to the relevant building surveyor by the applicant for the building permit applying to the building work.
(2) An application under subregulation (1) must be made before the commencement date or the completion date (as the case requires).
(3) The relevant building surveyor may extend the commencement date or completion date of the building work prior to the lapse of a building permit if the relevant building surveyor considers that the extent of the building work warrants an extension.
(4) If any extension is granted under subregulation (3), the relevant building surveyor must notify the applicant without delay—
(a) that the extension has been granted; and
(b) the new commencement date or completion date of the building work (as the case requires).
Division 8—Combined allotments60 Application to treat a combined allotment as one
allotment
(1) An application may be made to the municipal building surveyor of the relevant council to treat a combined allotment as one allotment for the purposes of the Act and these Regulations by the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
47
owner, or owners, of the land in the combined allotment.
(2) An application under subregulation (1) must contain the information set out in regulation 61(1) and be accompanied by the documents set out in regulation 61(2).
61 Information to be contained in or documents to accompany application
(1) An application under regulation 60(1) must contain—
(a) a description of any proposed building work on the combined allotment to which the application applies; and
(b) a description of any building on the combined allotment to which the application applies; and
(c) a description of how any proposed building work described under paragraph (a)—
(i) will impact on the structural adequacy of any building on the combined allotment to which the application applies; and
(ii) makes reasonable provision for the amenity of any building on the combined allotment to which the application applies; and
(iii) makes reasonable provision for the safety and health of people using any building on the combined allotment to which the application applies; and
(iv) makes reasonable provision for avoiding the spread of fire to or from any adjoining building on the combined allotment.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
48
(2) An application under regulation 60(1) must be accompanied by—
(a) if any land in the combined allotment is under the operation of the Transfer of Land Act 1958, a copy of the certificate of title to the land; and
(b) if any land in the combined allotment is not under the operation of the Transfer of Land Act 1958, any evidence of ownership of the land required by the municipal building surveyor; and
(c) copies of drawings and allotment plans that clearly differentiate between any existing building on the combined allotment and any proposed building work on the combined allotment to which the application applies.
62 Building surveyor may request more information
The municipal building surveyor may require an applicant under regulation 60(1) to provide additional information or documents within a specified period if the municipal building surveyor considers it is necessary for the purposes of making a determination under regulation 64.
63 Application may be refused if information not provided
(1) If information or a document required under regulation 62 is not provided within the period specified by the municipal building surveyor, the municipal building surveyor may refuse the application.
(2) Before refusing an application under subregulation (1), the municipal building surveyor must give the applicant 30 days notice in writing of the municipal building surveyor's intention to refuse the application.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
49
64 Determination to treat a combined allotment as one allotment
(1) On receiving an application under regulation 60(1), the municipal building surveyor may determine or refuse to determine that a combined allotment can be treated as one allotment for the purposes of the Act and these Regulations.
(2) In deciding whether to make a determination under subregulation (1), the municipal building surveyor must be satisfied—
(a) of the structural adequacy of any building on the combined allotment; and
(b) that reasonable provision is made for—
(i) the amenity of any building on the combined allotment; and
(ii) the safety and health of people using any building on the combined allotment; and
(iii) avoiding the spread of fire to or from any adjoining building on the combined allotment.
(3) A determination under subregulation (1) must be in the form of Form 5.
(4) The municipal building surveyor, within 7 days after making a determination under subregulation (1), must give a copy of the determination to the applicant.
(5) The municipal building surveyor, within 7 days after refusing to make a determination under subregulation (1), must notify the applicant of that decision.
Reg. 64(2)(a) amended by S.R. No. 180/2018 reg. 5.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
50
65 Effect of determination
Land to which a determination under regulation 64(1) applies is taken to be one allotment for the purposes of the Act and these Regulations.
66 Revocation of determination
(1) The municipal building surveyor may revoke a determination under regulation 64(1) if there is a change of circumstances that would significantly affect any of the matters referred to in regulation 64(2).
(2) The municipal building surveyor, within 7 days after revoking a determination under subregulation (1), must give each owner of land in the combined allotment written notice of the revocation.
67 Private building surveyor may exercise functions of municipal building surveyor under this Division
A private building surveyor may exercise the functions of the municipal building surveyor in accordance with this Division in relation to building work for which the private building surveyor has been appointed under Part 6 of the Act to issue a building permit.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
51
Part 5—Siting
Division 1—Introduction68 Application
(1) A regulation in this Part does not apply to the construction of a building if—
(a) a planning permit is required for the construction of that building; and
(b) the relevant planning scheme regulates the same matter as that regulation in relation to the siting of that building.
(2) Section 188A of the Act applies to applications for building permits to which this Part applies.
Note
Section 11 of the Act addresses the circumstances of where there is an inconsistency between a planning scheme and a building regulation in relation to a siting matter.
69 What is an existing building?
In this Part, a reference to an existing building (including an existing dwelling) on an adjoining allotment is a reference to a building—
(a) that was in existence in its current completed form before 1 July 1994; or
(b) for which there is an occupancy permit, a copy of which has been given to the relevant council; or
(c) for which there is a certificate of final inspection, a copy of which has been given to the relevant council (but only if that part of the building can be occupied without the need for any further certificate of final inspection); or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
52
(d) that has been completed (but only if the building can be occupied without the need for an occupancy permit or a certificate of final inspection).
70 What is a single dwelling?
For the purposes of the definition of single dwelling in section 188A(4) of the Act, the specified classes of building are—
(a) a Class 1 building; and
(b) any Class 10 building associated with a Class 1 building.
71 Approved building envelope design overrides siting requirement
(1) A design in relation to a building on an allotment that does not comply with a regulation in this Part is taken to comply with that regulation if—
(a) an approved building envelope applies to the allotment; and
(b) the approved building envelope deals with the same siting matter as the regulation; and
(c) the design of the building is consistent with the approved building envelope in relation to that siting matter.
(2) If an adjoining allotment is not subject to the same agreement or is not shown on the same certified plan of subdivision, subregulation (1) does not apply to regulations 79, 80, 81, 82, 83, 84, 90, 91, 94, 95 and 96 to the extent that they relate to that adjoining allotment.
(3) In this regulation—
agreement has the same meaning as in paragraph (b)(i) of the definition of approved building envelope in regulation 5(1);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
53
plan of subdivision has the same meaning as in paragraph (b)(ii) of the definition of approved building envelope in regulation 5(1).
Division 2—Single Class 1 buildings and associated Class 10a buildings
72 Application of Division
This Division applies to the construction of a single Class 1 building and associated Class 10a buildings on an allotment.
73 Maximum street setback
(1) A Class 1 building when first constructed must not be set back from the front street alignment more than one-third of the depth of the allotment unless the allotment is equal to or greater than 0·40469 ha.
(2) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
(3) For the purposes of subregulation (1), if a building is on a battleaxe allotment—
(a) a reference to the allotment is taken not to include a driveway that forms part of the battleaxe allotment; and
(b) a reference to the front street alignment is taken to be a reference to the common boundary between the battleaxe allotment and the front allotment (excluding the common boundary between any driveway that forms part of the battleaxe allotment and the front allotment).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
54
(4) In this regulation—
battleaxe allotment means—
(a) an allotment situated behind another allotment that has a street frontage; and
(b) the allotment has access to the street through a driveway, whether or not the driveway forms part of the allotment;
driveway includes any land related and contiguous to the driveway;
front allotment means an allotment that has a street frontage and that is situated in front of a battleaxe allotment.
74 Minimum street setbacks
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
(b) a schedule to that zone specifies a setback from a street alignment—
a building on that allotment must be set back from a street alignment not less than the relevant setback specified for the street alignment in the schedule.
(2) If subregulation (1) does not apply, a building must be set back from a street alignment not less than the distance specified in respect of that alignment in Table 74.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
55
Table 74—Street setbacks
Adjoining development context
Minimum setback from front street alignment
Minimum setback from side street alignment
Existing dwellings on adjoining allotments facing the same street
The average distance of the setbacks of the front walls of the existing buildings on the adjoining allotments facing the front street, or 9 m, whichever is the lesser
Not applicable
Existing dwelling on one adjoining allotment facing the same street and no building on the other adjoining allotment facing the same street
The same distance as the setback of the front wall of the existing building on the adjoining allotment facing the same street, or 9 m, whichever is the lesser
Not applicable
No existing dwellings on adjoining allotments facing the same street
6 m for a building facing a declared road4 m for a building facing any other street
Not applicable
Corner allotmentIf there is a building on the adjoining allotment facing the same street
The same distance as the setback of the front wall of the existing building on the adjoining allotment facing the front street, or 9 m, whichever is the lesser
The same distance as the setback of the front wall of the existing building on the adjoining allotment facing the side street or 2 m, whichever is the lesser
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
56
Adjoining development context
Minimum setback from front street alignment
Minimum setback from side street alignment
Corner allotmentIf there is no building on the adjoining allotment facing the same street
6 m for a building facing a declared road4 m for a building facing any other street
2 m
(3) The following may encroach into the setback distance required by subregulation (1) or (2) by not more than 2·5 m—
(a) porches, verandahs and pergolas that have a maximum height of less than 3·6 m above natural ground level;
(b) eaves, fascia and gutters;
(c) sunblinds and shade sails;
(d) permanent and fixed screens referred to in regulation 84(5)(d) or 84(6);
(e) decks, steps or landings less than 800 mm in height.
(4) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
(5) In this regulation street does not include lane, footway, alley or right of way.
(6) For the purposes of this regulation, an allotment does not adjoin another allotment if its boundary only touches the boundary of the other allotment at one point (for example, at a corner).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
57
75 Building height
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
(b) that zone, or a schedule to that zone, specifies a maximum height for buildings—
the height of a building on that allotment must not exceed the relevant height specified in that zone or schedule (as the case may be).
(2) If subregulation (1) does not apply, the height of a building must not exceed—
(a) 10 m if the slope of the natural ground level at any cross section of the site of the building that is wider than 8 m is 2·5° or more; and
(b) 9 m in any other case.
(3) If a wall is constructed in accordance with regulation 80, and despite regulation 79, any part of a building on the allotment that is within 1 m of a side or rear boundary and that is adjacent to the wall must be constructed so as not to exceed the height formed by a line that connects—
(a) any point at the top of the wall; and
(b) any point at a height of 3·6 m at a setback of 1 m from the boundary.
(4) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
76 Site coverage
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
58
(b) a schedule to that zone specifies a maximum site coverage for buildings—
buildings must not occupy more of the allotment than the site coverage specified in that schedule.
(2) If subregulation (1) does not apply, buildings must not occupy more than 60% of an allotment.
(3) The following items may be disregarded when calculating site coverage under subregulation (1) or (2)—
(a) not more than 600 mm of the width of eaves, fascia and gutters;
(b) unroofed swimming pools or spas, unroofed terraces, unroofed patios, unroofed decks and pergolas.
(4) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
76A Minimum garden area
(1) This regulation applies if—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
(b) the zone in the planning scheme specifies a minimum garden area requirement; and
(c) the minimum garden area requirement in the zone applies to the allotment.
Reg. 76A inserted by S.R. No. 100/2018 reg. 4.
Reg. 76A(1)(c) substituted by S.R. No. 180/2018 reg. 6.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
59
(2) The allotment must have a minimum garden area of—
(a) in the case of an allotment that has an area equal to or greater than 400 m2 and less than or equal to 500 m2—not less than 25% of the area of the allotment; and
(b) in the case of an allotment that has an area greater than 500 m2 and less than or equal to 650 m2—not less than 30% of the area of the allotment; and
(c) in the case of an allotment that has an area greater than 650 m2—not less than 35% of the area of the allotment.
(3) In this regulation—
garden area means any area on an allotment with a minimum dimension of 1 m other than an area covered by a building, a driveway or an area set aside for car parking.
(4) For the purposes of subregulation (3), an area covered by a building does not include any of the following—
(a) a Class 10a building not exceeding 10 m2 in area;
(b) a Class 10b or Class 10c building or structure;
(c) eaves, fascia and gutters not exceeding a total width of 600 mm;
(d) a pergola;
(e) unroofed terraces, unroofed patios, unroofed ramps, unroofed decks, unroofed steps or landings less than 800 mm in height;
(f) any part of a building that does not project above ground level;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
60
(g) a disabled access ramp;
(h) flues, pipes and rainwater heads;
(i) domestic fuel tanks and water tanks;
(j) heating and cooling equipment and other services;
(k) any other domestic appliance or apparatus that is normally associated with, and services, a Class 1 or Class 10 building.
(5) This regulation does not apply to an allotment if the allotment has less garden area than the minimum garden area required under the planning scheme applying to the allotment on 27 March 2017.
77 Permeability
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
(b) a schedule to that zone specifies that an allotment must have a minimum area of permeable surfaces—
the amount of the allotment that must have a permeable surface must not be less than the minimum area of permeability specified in that schedule.
(2) If subregulation (1) does not apply, and if a building is to be constructed on an allotment, at least 20% of the area of the allotment must have a permeable surface.
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
61
78 Car parking
(1) If a new Class 1 building is to be constructed on an allotment, provision must be made for 2 car parking spaces on the allotment that are accessible from the street.
(2) Of the 2 required car parking spaces—
(a) the first space must be at least 6 m long and 3·5 m wide; and
(b) the second space must be at least 4·9 m long and 2·6 m wide.
(3) A building may project into a car parking space if it is at least 2·1 m above that space.
(4) Despite subregulation (2), if the 2 required car parking spaces adjoin each other in a garage or carport or in a space constrained by walls, the total space may be 5·5 m in width.
(5) An alteration to a building on an allotment must not reduce the number of car parking spaces on the allotment unless there are more than 2 car parking spaces on the allotment, in which case the number of car parking spaces may be reduced to 2.
(6) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
79 Side and rear setbacks
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
62
(b) a schedule to that zone in the planning scheme specifies minimum setbacks from side and rear boundaries—
a building on the allotment must be set back from a side or rear boundary not less than the relevant setback specified in that schedule.
(2) If subregulation (1) does not apply, a building must be set back from a side or rear boundary not less than the distance specified in respect of that boundary in Table 79.
Table 79—Side and rear setbacks
Building height at any point
Minimum setback from side or rear boundary at that point
36 m or less 1 m
More than 3·6 m but not more than 6·9 m
1 m plus an additional distance calculated at the rate of 300 mm for every metre of height over 3·6 m
More than 6·9 m 2 m plus an additional distance calculated at the rate of 1 m for every metre of height over 6·9 m
(3) The following may encroach into the setback distance required by subregulation (1) or (2)—
(a) landings with an area of not more than 2 m2 and less than 1 m in height;
(b) unroofed stairways and ramps;
(c) pergolas;
(d) shade sails;
(e) eaves, fascia and gutters, if the encroachment is not more than 600 mm;
(f) carports that comply with regulation 80.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
63
(4) The following may encroach into the setback distance required by subregulation (1) or (2) by not more than 500 mm—
(a)porches and verandas;
(b)masonry chimneys;
(c)sunblinds;
(d)permanent and fixed screens referred to in regulation 84(5)(d) or (6);
(e)flues, pipes and rainwater heads;
(f)domestic fuel tanks and water tanks;
(g)heating and cooling equipment and other services.
(5) This regulation does not apply to a wall that complies with regulation 80.
(6) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
80 Walls and carports on boundaries
(1) This regulation applies to the construction of—
(a) a wall of a building constructed on or within 200 mm of a side or rear boundary of an allotment; or
(b) a carport constructed on or within 1 m of a side or rear boundary of an allotment and which is open on the side facing the boundary or boundaries.
(2) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
64
(b) a schedule to that zone specifies the maximum length of the wall, or of the carport, or of the wall and carport, or the maximum of any of those lengths combined with the length of any existing wall or carport—
that length must not exceed any such maximum length specified in that schedule.
(3) If subregulation (2) does not apply, the length of the wall, or of the carport, or of the wall and carport, or any of those lengths combined with the length of any existing wall or carport, must not exceed the greater of the following—
(a) the length of any existing wall or carport constructed on an adjoining allotment, which is within 200 mm of the boundary of that allotment, if the proposed construction abuts the existing wall or carport;
(b) 10 m plus 25% of the remaining length of the boundary of the adjoining allotment, in any other case.
(4) The wall or carport must not exceed—
(a) an average height of 32 m where the average is calculated after excluding any length that is less than 2 m in height; and
(b) a maximum height of 36 m.
(5) Despite subregulation (4), if the wall or carport abuts an existing wall or carport it may be constructed to the same height as that wall or carport.
(6) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
65
81 Daylight to existing habitable room windows
(1) A building must be set back from a habitable room window in an existing dwelling on an adjoining allotment to provide for a light court to the window that has a minimum area of 3 m2 and a minimum dimension of 1 m clear to the sky.
(2) The area of the light court required under subregulation (1) may include land on the adjoining allotment.
(3) A wall or carport with an average height of more than 3 m opposite a habitable room window in an existing dwelling on an adjoining allotment must be set back from that window at least half the height of the wall or carport if the wall or carport is within a 55° angle in the horizontal plane about a vertical axis through the centre of the window.
(4) For the purposes of subregulation (3), the angle may be swung to not less than 35° from the plane of the wall containing the window.
(5) If the window referred to in subregulation (3) is above ground floor level, then for the purposes of that subregulation, the wall or carport height is to be measured from the floor level of the room containing the window.
(6) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
66
Note
The following diagram illustrates the operation of aspects of regulation 81(3).
Regulation 81: Daylight to existing habitable room windows
82 Solar access to existing north-facing habitable room windows
(1) This regulation applies if—
(a) a building is to be constructed on an allotment; and
(b) a north-facing habitable room window or part of a window of an existing dwelling on an adjoining allotment is—
(i) within 3 m of a boundary of the allotment on which the building isto be constructed; and
(ii) oriented towards the boundary; and
(iii) will be situated below the eaves or the top of a parapet of the building being constructed.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
67
(2) The proposed building must be set back from the boundary not less than the distance specified in Table 82 for a distance of 3 m from each side of the window or that part of the window that is within 3 m of the boundary.
Table 82—Setbacks from north-facing habitable room windows
Building height at any point
Minimum setback from side or rear boundary at that point
36 m or less 1 m
More than 3·6 m but not more than 6·9 m
1 m plus an additional distance calculated at the rate of 600 mm for every metre of height over 3·6 m
More than 6·9 m 3 m plus an additional distance calculated at the rate of 1 m for every metre of height over 6·9 m
(3) The following may encroach into the setback distance required by subregulation (2) by not more than 500 mm and to a height not exceeding 2·5 m—
(a) flues and pipes;
(b) domestic fuel tanks and water tanks;
(c) heating and cooling equipment and other services.
(4) A rainwater head may encroach into the setback distance required by subregulation (2) by not more than 500 mm.
(5) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
68
Note
The following diagram illustrates the operation of aspects of regulation 82.
Regulation 82: Solar access to existing north-facing habitable room windows
83 Overshadowing of recreational private open space
(1) A building must not reduce the sunlight to a recreational private open space of an existing dwelling on an adjoining allotment to the extent that less than the required minimum area of the recreational private open space has less than 5 hours of sunlight between 9 a.m. and 3 p.m. on 22 September.
(2) If a building is to be constructed on an allotment and the existing amount of sunlight to a recreational private open space on an adjoining allotment is less than the amount required under subregulation (1), the amount of sunlight to that area must not be further reduced by the construction of the building.
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
69
(4) In this regulation the required minimum area of a recreational private open space is the lesser of—
(a) 75% of the recreational private open space; and
(b) 40 m2 with a minimum dimension of 3 m.
84 Overlooking
(1) A habitable room window or raised open space of a building on an allotment must not provide a direct line of sight into a habitable room window or on to a secluded private open space of an existing dwelling on an adjoining allotment.
(2) In the case of a direct line of sight from a habitable room window, the line of sight is any line measured from a height of 1·7 m above the floor level of the habitable room and contained within the space enclosed by—
(a) a vertical plane measured at an angle of 45° from each side of the window; and
(b) a horizontal plane 1·7 m above the floor level of the habitable room; and
(c) the ground level below; and
(d) a horizontal distance of 9 m from the window.
(3) In the case of a direct line of sight from a raised open space, the line of sight is any line measured from a height of 1·7 m above the floor level and along the perimeter of the raised open space to any point within a horizontal distance of 9 m from the raised open space and extending 45° beyond any point where the perimeter of the raised open space meets a wall of a building.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
70
(4) In the case of a secluded private open space, the horizontal distance of 9 m referred to in subregulation (2)(d) or (3) is to be measured from the ground level.
(5) A habitable room window complies with this regulation if—
(a) in the case where a habitable room window provides a direct line of sight into a habitable room window of an existing dwelling on an adjoining allotment, it is offset a minimum of 1·5 m from the edge of one window to the edge of the other; or
(b) it has a sill height at least 1·7 m above floor level; or
(c) it has obscure glazing in any part of the window below 1·7 m above floor level; or
(d) the direct line of sight is obscured by a permanent and fixed screen that has no more than 25% of its area open.
(6) A raised open space complies with this regulation if the direct line of sight into the habitable room window or on to the secluded private open space on the adjoining allotment is obscured by a permanent and fixed screen which has no more than 25% of its area open.
(7) A window referred to in subregulation (5)(c) may be able to be opened provided that when open the obscure glazing does not permit a direct line of sight on to the secluded private open space or into the habitable room window referred to in subregulation (1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
71
(8) This regulation does not apply to a new habitable room window or raised open space that faces a property boundary if—
(a) there is a visual barrier at least 1·8 m high at the boundary; and
(b) the floor level of the room or the raised open space is less than 800 mm above the ground level at the boundary.
(9) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
(10) In this regulation—
raised open space means a landing with an area of more than 2 m2, a balcony, a terrace, a deck or a patio;
secluded private open space means any part of private open space on an allotment—
(a) which is screened for at least 90% of its perimeter by a wall, fence or other barrier that is at least 1·5 m high and that has no more than 25% of its area open; and
(b) which is primarily intended for outdoor recreation activities.
85 Daylight to habitable room windows
(1) A habitable room window of a building on an allotment must face—
(a) an outdoor space or light court with a minimum area of 3 m2 and a minimum dimension of 1 m clear to the sky, not including land on an adjoining allotment; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
72
(b) a verandah, porch, deck or balcony on the allotment if it is open for at least one-third of its perimeter; or
(c) a carport on the allotment if—
(i) it has 2 or more sides open; and
(ii) it is open for at least one-third of its perimeter.
(2) For the purposes of subregulation (1), a side of a carport or verandah may be taken to be open if the roof covering of the carport or verandah adjacent to that side is not less than 500 mm from another building on the allotment or the adjoining allotment boundary.
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
86 Private open space
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
(b) a schedule to that zone in the planning scheme specifies a minimum area and dimension for private open space—
a Class 1 building on that allotment must have private open space of at least the area and dimension specified in that schedule.
(2) If subregulation (1) does not apply, a Class 1 building on an allotment must have private open space—
(a) of not less than 80 m2 or 20% of the area of the allotment, whichever is the lesser; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
73
(b) which includes an area at the side or rear of the building—
(i) that is at least 25 m2 with a minimum dimension of 3 m; and
(ii) that has convenient access from a habitable room (other than a bedroom).
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Division 3—Siting of Class 10a buildings87 Siting of Class 10a buildings
(1) A Class 10a building that is appurtenant to a building of another class must be on the same allotment as the building of the other class unless the Class 10a building is approved under the Subdivision Act 1988 or any corresponding previous enactments.
(2) The report and consent of the relevant council must be obtained to an application for a building permit for the construction of a building that does not comply with this regulation.
Division 4—Class 10b structures88 Application of Division
This Division applies to the construction of Class 10b structures on an allotment.
89 Front fence height
(1) If—
(a) an allotment is in a zone of a planning scheme specified in Schedule 6; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
74
(b) a schedule to that zone specifies a maximum height for a fence, or part of a fence, that is within 3 m of the street alignment at the front of an allotment—
the height of a fence, or part of a fence, that is within 3 m of the street alignment at the front of that allotment must not exceed the relevant maximum height specified in that schedule.
(2) If subregulation (1) does not apply, the height of a fence, or part of a fence, that is within 3 m of the street alignment at the front of an allotment must not exceed the relevant maximum height specified in Table 89.
Table 89—Front fence heights
Street type Maximum fence height
A declared road 2 m
Any other street 15 m
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
90 Fence setbacks from side and rear boundaries
(1) A fence exceeding 2 m in height must be set back from a side or rear boundary of an allotment (including a boundary that is a side or rear street alignment) not less than the distance specified in respect of that boundary in Table 90.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
75
Table 90—Side and rear setbacks
Fence height at any point
Minimum setback from side or rear boundary at that point
More than 20 m but not more than 36 m
1 m
More than 3·6 m but not more than 6·9 m
1 m plus an additional distance calculated at the rate of 300 mm for every metre of height over 3·6 m
More than 6·9 m 2 m plus an additional distance calculated at the rate of 1 m for every metre of height over 6·9 m
(2) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
91 Fences on or within 150 mm of side or rear boundaries
(1) Despite regulation 90, one or more fences that are more than 2 m in height may be constructed on, or within 150 mm of, a side or rear boundary of an allotment (other than a boundary that is a side or rear street alignment) if the total length of the fence or fences or that total length combined with the length of any wall, or carport, or wall and carport constructed in accordance with either regulation 80(2) or (3) (as the case requires) on or adjacent to that boundary, does not exceed the greater of the following lengths—
(a) 10 m plus 25% of the remaining length of the boundary of an adjoining allotment;
(b) the length of any wall or carport constructed on an adjoining allotment that is on or within 150 mm of the boundary of that allotment and that abuts those fences.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
76
(2) A fence constructed on or within 150 mm of a side or rear boundary of an allotment in accordance with this regulation must not exceed—
(a) an average height of 3 m; and
(b) a maximum height of 3·6 m along the boundary.
(3) Despite subregulation (2), if a fence abuts an existing wall it may be constructed to the same height as that wall.
(4) This regulation does not apply to a fence if the fence is provided to comply with regulation 84, or with a planning scheme that regulates the same matter as regulation 84, and—
(a) the fence is not more than 2·5 m in height; and
(b) the part of the fence between 2·0 m and 2·5 m in height has between 20% and 25% of its area open.
(5) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
92 Fences on intersecting street alignments
(1) Despite regulation 90(1), a fence exceeding a height of 1 m above the footpath must be set back from the point of intersection of street alignments by at least 9 m.
(2) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
(3) In this regulation street does not include lane, footway, alley or right of way.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
77
93 Fences must not include barbed wire
(1) A fence adjacent to a street alignment or public open space must not contain barbed wire or other sharp protrusions unless—
(a) despite regulation 90(1), the fence is set back at least 150 mm from the street alignment or boundary of the public open space; or
(b) the barbed wire or other sharp protrusion is at a height of at least 2 m above the level of the street or public open space; or
(c) the fence is on an allotment that has an area of 2000 m2 or more and is used principally for raising livestock.
(2) In this regulation, public open space has the same meaning as in section 3(1) of the Subdivision Act 1988.
94 Fences and daylight to habitable room windows in existing dwelling
(1) A fence more than 2 m in height must be set back from a habitable room window in an existing dwelling on an adjoining allotment to provide for a light court to the window that has a minimum area of 3 m2 and a minimum dimension of 1 m clear to the sky.
(2) The area of the light court required under subregulation (1) may include land on the adjoining allotment.
(3) A fence with an average height of more than 3 m opposite a habitable room window in an existing dwelling on an adjoining allotment must be set back from that window at least half the height of the fence if the fence is within a 55° angle in the horizontal plane about a vertical axis through the centre of the window.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
78
(4) For the purposes of subregulation (3), the angle may be swung to not less than 35° from the plane of the wall containing the window.
(5) If the window referred to in subregulation (3) is above ground floor level, then for the purposes of that subregulation, the fence height is to be measured from the floor level of the room containing the window.
(6) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
95 Fences and solar access to existing north-facing habitable room windows
(1) This regulation applies if—
(a) a fence more than 2 m in height is to be constructed on an allotment; and
(b) a north-facing habitable room window or part of a window of an existing dwelling on an adjoining allotment is—
(i) within 3 m of a boundary of the allotment on which the fence is to be constructed; and
(ii) oriented towards the boundary; and
(iii) situated below the height of the fence being constructed.
(2) The proposed fence must be set back from the boundary not less than the distance specified in Table 95 for a distance of 3 m from the edge of each side of the window or that part of the window that is within 3 m of the boundary.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
79
Table 95—Setbacks from north-facing habitable room windows
Fence height at any point
Minimum setback from side or rear boundary at that point
3.6 m or less 1 m
More than 3·6 m but not more than 6·9 m
1 m plus an additional distance calculated at the rate of 600 mm for every metre of height over 3·6 m
More than 6·9 m 3 m plus an additional distance calculated at the rate of 1 m for every metre of height over 6·9 m
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
96 Fences and overshadowing of recreational private open space
(1) A fence more than 2 m in height must not reduce the sunlight to a recreational private open space of an existing dwelling on an adjoining allotment to the extent that less than the required minimum area of the recreational private open space has less than 5 hours of sunlight between 9 a.m. and 3 p.m. on 22 September.
(2) If a fence is to be constructed on an allotment and the existing amount of sunlight to a recreational private open space on an adjoining allotment is less than the amount required under subregulation (1), the amount of sunlight to that area must not be further reduced by the construction of the fence.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
80
(3) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
(4) In this regulation the required minimum area of a recreational private open space is the lesser of—
(a) 75% of the recreational private open space; and
(b) 40 m2 with a minimum dimension of 3 m.
97 Masts, poles etc.
(1) A mast, pole, aerial, antenna, chimney, flue or service pipe—
(a) when attached to a building, must not exceed a height of 3 m above the highest point of the roof of the building; or
(b) when not attached to a building, must not exceed 8 m above the ground level.
(2) The report and consent of the relevant council must be obtained to an application for a building permit in relation to a design that does not comply with this regulation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
81
Part 6—Projections beyond street alignment98 Projections beyond street alignment
Except where otherwise provided in this Part, a building must not project beyond the street alignment.
99 Architectural features—narrow street
(1) An architectural feature of a building on a narrow street must not project beyond the street alignment.
(2) Despite subregulation (1), an architectural feature may project beyond a narrow street no more than 240 mm horizontally beyond the street alignment and at a height of at least 2.7 m above the level of the street if—
(a) any footpath or kerb forming part of the street is not more than 240 mm in height above the street level; and
(b) the architectural feature is constructed from non-combustible material.
100 Architectural features—medium street
An architectural feature of a building on a medium street must not project beyond the street alignment unless the architectural feature—
(a) projects no more than 600 mm horizontally beyond the street alignment; and
(b) is at least—
(i) 5 m in height above any part of the street that may be used by a motor vehicle; or
(ii) 2.7 m in height above the level of the street in any other case; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
82
(c) is constructed from non-combustible material.
101 Architectural features—wide street
An architectural feature of a building on a wide street must not project beyond the street alignment unless the architectural feature—
(a) projects no more than 1.2 m horizontally beyond the street alignment; and
(b) is at least—
(i) 5 m in height above any part of the street that may be used by a motor vehicle; or
(ii) 2.7 m in height above the level of the street in any other case; and
(c) is constructed from non-combustible material.
102 Windows and balconies
(1) A window or balcony must not project beyond the street alignment—
(a) of a narrow street; or
(b) of a medium street.
(2) A window or balcony must not project beyond the street alignment of a wide street—
(a) more than 1 m horizontally; and
(b) at a height less than—
(i) 5 m above any part of the street that may be used by a motor vehicle; or
(ii) 3 m above the level of the street in any other case; and
(c) within 1·2 m of the side boundary of an adjoining allotment.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
83
103 Verandahs
A verandah must not project beyond the street alignment unless the verandah—
(a) is set back at least 750 mm from the kerb; and
(b) is at a height of at least 3 m above the level of the street.
104 Sunblinds and awnings
A sunblind or awning must not project beyond the street alignment—
(a) more than 2·4 m horizontally; and
(b) at any height less than—
(i) 5 m above any part of the street that may be used by a motor vehicle; or
(ii) 2·4 m above the level of the street in any other case.
105 Service pipes, rainwater heads and service installations
A service pipe, rainwater head or service installation must not project beyond the street alignment—
(a) more than 200 mm horizontally in the case of a service pipe; and
(b) more than 300 mm horizontally in the case of a rainwater head or service installation; and
(c) at any height less than 2·7 m above the level of the street.
106 Window shutters
Window shutters may project horizontally not more than 50 mm beyond the street alignment when in the fully open position.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
84
107 Signs
A sign or similar Class 10b structure must not project beyond the street alignment unless the sign or structure—
(a) is set back at least 750 mm from the kerb; and
(b) is at a height of at least 2·7 m above the level of the street.
108 Service cabinet doors
(1) A service cabinet door must not project beyond the street alignment more than 600 mm when in the fully open position.
(2) In this regulation, service cabinet means a cabinet or cupboard containing a meter, electrical equipment, water connections, fire equipment or other similar equipment.
109 Report and consent required
(1) The report and consent of the relevant council must be obtained to an application for a building permit to construct any of the following parts of a building if the part projects beyond the street alignment at a different height or distance to that specified in this Part—
(a) an architectural feature;
(b) a window;
(c) a balcony;
(d) a verandah;
(e) a sunblind;
(f) an awning;
(g) a service pipe;
(h) a rainwater head;
(i) a service installation;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
85
(j) a window shutter;
(k) a sign or similar Class 10b structure;
(l) a service cabinet door.
(2) The report and consent of the relevant council must be obtained to an application for a building permit to construct a building if any part of the building not specified in subregulation (1) would project beyond the street alignment.
(3) The relevant council may give its consent under subregulation (1) or (2) if it considers that the projection of the part of the building beyond the street alignment will not be detrimental to the safety of the public.
(4) Despite subregulations (1) and (2), the report and consent of the relevant council under subregulation (1) or (2) need not be obtained to an application for a building permit if
(a) a planning permit is required for the construction of the building; and
(b) the relevant planning scheme regulates the projection of part of a building beyond the street alignment of the same class of part of building referred to in subregulation (3).
110 Footings adjoining boundaries are permissible
(1) A footing may support a party wall.
(2) A footing may extend beyond the boundaries of a street alignment—
(a) to a distance of not more than 300 mm if the highest projecting part of the footing is at a depth of at least 450 mm but less than 3 m below the level of the street; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
86
(b) to a distance of not more than 1 m if the highest projecting part of the footing is at a depth of at least 3 m below the level of the street.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
87
Part 7—Protection of adjoining property and the public
Division 1—Protection of adjoining property by means of protection work
111 Required protection work
(1) Protection work must be provided by the owner, in relation to an adjoining property, before and during the carrying out of any building work, if the relevant building surveyor determines that protection work is required.
(2) The relevant building surveyor must determine whether protection work is required as a result of proposed building work when deciding an application for a building permit in relation to that work.
(3) The relevant building surveyor may at any time determine that protection work is required in relation to building work.
(4) A determination under subregulation (2) or (3) must be in the form of Form 6.
(5) Within 7 days after making a determination under this regulation, the relevant building surveyor must give a copy of the determination to—
(a) the applicant for the relevant building permit; and
(b) if the owner referred to in subregulation (1) is not the applicant, the owner.
112 Matters relevant building surveyor must consider when determining if protection work required
For the purposes of making a determination under regulation 111, the relevant building surveyor must have regard to—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
88
(a) any allotment plan provided to the relevant building surveyor under regulation 25 or regulation 26; and
(b) specifications that describe the materials and methods to be used in the proposed building work; and
(c) any demolition required as part of the proposed building work; and
(d) any excavation required as part of the proposed building work; and
(e) any proposed building work in relation to party walls and retaining walls; and
(f) the nature and likely extent of any damage or other adverse effect on the stability or otherwise of an adjoining property that may be caused by the proposed building work; and
(g) any certificate under section 238 of the Act from a registered building practitioner in the category of engineer, class of engineer (civil), who designed the building work; and
(h) any certificate under section 238 of the Act from an independent engineer who is a registered building practitioner in the category of engineer, class of engineer (civil), certifying that the structural design of the building work complies with the Act and these Regulations; and
(i) any other matter the relevant building surveyor considers relevant.
113 Protection work notice
(1) The notice required to be served by the owner on the adjoining owner and the relevant building
Reg. 113(1) amended by S.R. No. 75/2018 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
89
surveyor by section 84 of the Act must be in the form of Form 7 and must be accompanied by the following—
(a) any determination of the relevant building surveyor made under regulation 111;
(b) 3 copies of the notice required to be given by the adjoining owner to the owner under section 85 of the Act;
(c) a statement in a form approved by the Authority, that explains the operation of the protection work process under the Act and these Regulations and the procedure for the resolution of disputes relating to protection work;
(d) plans and specifications for any building work, building or structure that may affect the adjoining property and that contain sufficient detail to show how the proposed building work will affect the adjoining property;
(e) plans and specifications for the proposed protection work that contain sufficient detail to show how the protection work will protect the adjoining property from the effects identified in paragraph (d);
(f) one copy of an allotment plan complying with regulation 25(1)(d).
(2) For the purposes of section 84(2) of the Act—
(a) the prescribed details of the proposed building work are—
(i) the relevant details set out in Form 7; and
(ii) the details in the documents required under subregulation (1)(d); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
90
(b) the prescribed details of the proposed protection work are—
(i) the relevant details set out in Form 7; and
(ii) the details in the documents required under subregulation (1)(e); and
(c) the prescribed information is any information set out in Form 7 that is not a prescribed detail under paragraph (a) or (b).
114 Protection work response notice
(1) The notice required to be given by the adjoining owner to the owner under section 85 of the Act agreeing or disagreeing to the proposed protection work or requiring more information must be in the form of Form 8.
(2) The prescribed information to be contained in a notice under section 85 of the Act is the information set out in Form 8.
115 Notice of relevant building surveyor determination
A written notice of determination by the relevant building surveyor under section 87 of the Act must—
(a) be in the form of Form 9; and
(b) include a statement informing the recipient of the notice of any right of appeal to the Building Appeals Board under section 141 of the Act; and
(c) include the prescribed appeal period under regulation 271 that applies in relation to that right of appeal; and
Reg. 114(1) amended by S.R. No. 75/2018 reg. 11.
Reg. 115(a) amended by S.R. No. 75/2018 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
91
(d) be accompanied by the owner's proposal for protection work under section 84 of the Act; and
(e) be accompanied by the adjoining owner's notice under section 85(1)(b) of the Act (if any).
Division 2—Protection of the public116 Protection of the public
(1) Precautions must be taken before and during building work to protect the safety of the public if required by the relevant building surveyor.
(2) The precautions must be approved by the relevant building surveyor before building work is commenced.
(3) Before and during the carrying out of building work all excavations must be fenced or otherwise guarded against being a danger to life or property.
(4) The report and consent of the relevant council must be obtained to an application for a building permit relating to the erection of precautions over the street alignment unless a local law requires the taking of precautions and the precautions comply with the local law.
Division 3—Demolition117 Demolition
(1) Precautions must be taken before and during demolition in accordance with AS 2601 The demolition of structures as in force or as issued or as published from time to time and the following—
(a) the demolition must not be commenced until the precautionary measures have been
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
92
inspected and approved by the relevant building surveyor;
(b) no part of any external wall on or within3 m of a street alignment may be pulled down except during the hours that the relevant building surveyor directs;
(c) protective outriggers must be installed where necessary to guard against danger to life or property or when required by the relevant building surveyor;
(d) the site must be cleared of all debris.
(2) The relevant building surveyor may exempt minor demolition work from the requirements of subregulation (1) if the relevant building surveyor is of the opinion that the nature of the demolition work does not warrant those measures.
Division 4—Excavations and retaining walls118 Excavations
(1) All excavations and backfilling must be executed in a safe and workmanlike manner.
(2) Unless exempted by the relevant building surveyor, all water must be removed or diverted from excavations before the laying of footings.
119 Retaining walls
(1) The municipal building surveyor may require the owner of an allotment to provide retaining walls or other means of maintaining the stability of the soil if the municipal building surveyor considers that the stability of the ground on the allotment or any adjoining property has been or may be adversely affected by any excavation or filling of soil on the allotment.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
93
(2) An owner of an allotment must comply with a requirement in relation to the allotment under subregulation (1).
Penalty:10 penalty units.
(3) Subregulation (1) does not apply if the owner of the allotment is required to provide protection work in relation to an adjoining property under regulation 111.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
94
Part 8—Building work
Division 1—Methods of assessment of compliance120 Testing of materials
(1) The relevant building surveyor may require that the owner or builder carrying out building work for which a building permit has been issued arrange for the testing of any material used in the building work.
(2) The relevant building surveyor may, as a result of tests carried out under subregulation (1), prohibit the use of any material that—
(a) does not meet the requirements of these Regulations; or
(b) is found to be unsuitable or unfit for the purposes for which it is intended.
(3) Tests required under subregulation (1) must be carried out by an Accredited Testing Laboratory or a Registered Testing Authority or an approved person or organisation.
121 Fire performance requirements—performance solutions
Despite anything to the contrary in the BCA, the relevant building surveyor must not determine that a performance solution complies with a fire performance requirement of the BCA unless the relevant building surveyor—
(a) holds a Graduate Certificate in Performance-Based Building & Fire Codes from Victoria University; or
(b) holds a qualification that the Victorian Building Authority considers is equivalent to that Certificate; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
95
(c) relies on a report of the chief officer under regulation 129, that states that the chief officer is satisfied that a satisfactory degree of fire safety is achieved by that performance solution; or
(d) relies on a certificate under section 238 of the Act by a fire safety engineer, who did not design the building work, that states that the performance solution complies with that performance requirement; or
(e) relies on a certificate under section 238 of the Act by a registered building surveyor, who did not design the building work, and who holds a qualification referred to in paragraph (a) or (b), that states that the performance solution complies with that performance requirement; or
(f) relies on a determination of the Building Appeals Board under section 160A of the Act that the performance solution complies with that performance requirement; or
(g) relies on a certificate of accreditation issued by the Building Regulations Advisory Committee that states that the performance solution complies with that performance requirement; or
(h) relies on a Certificate of Conformity issued by a person or body duly authorised by the Australian Building Codes Board, that states that the performance solution complies with that performance requirement.
122 Certificates of compliance—proposed building work
The prescribed classes of proposed building work and the prescribed categories and classes of registered building practitioners in relation to
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
96
proposed building work for the purposes of section 238(1)(a) of the Act are as follows—
(a) for a certificate relating to the design or part of the design of building work relating to a structural, sewerage, water or drainage matter—category of engineer, class of engineer (civil);
(b) for a certificate relating to the design or part of the design of building work relating to a mechanical matter including hydraulic services within a building—category of engineer, class of engineer (mechanical);
(c) for a certificate relating to the design or part of the design of building work relating to an electrical matter—category of engineer, class of engineer (electrical);
(d) for a certificate relating to the design or part of the design of building work relating to a fire safety matter—category of engineer, class of engineer (fire safety);
(e) for a certificate relating to the design or part of the design of any of the above classes of building work—category of building surveyor.
123 Certificates of compliance—building work
The prescribed classes of building work and the prescribed categories and classes of registered building practitioners in relation to building work for the purposes of section 238(1)(b) of the Act are as follows—
(a) for a certificate relating to the inspection of domestic building work relating to a structural, sewerage, water or drainage matter—category of engineer, class of engineer (civil);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
97
(b) for a certificate relating to the inspection of domestic building work relating to a mechanical matter including hydraulic services within a building—category of engineer, class of engineer (mechanical);
(c) for a certificate relating to the inspection of domestic building work relating to an electrical matter—category of engineer, class of engineer (electrical);
(d) for a certificate relating to the inspection of domestic building work relating to a fire safety matter—category of engineer, class of engineer (fire safety);
(e) for a certificate relating to the inspection of domestic building work—category of building surveyor or building inspector;
(f) for a certificate relating to the erection of a prescribed temporary structure—category of building surveyor or building inspector or category of engineer, class of engineer (civil) or category of person who erects or supervises the erection of prescribed temporary structures.
124 Registered building practitioner must document performance solutions in certificate of compliance
(1) A registered building practitioner who issues a certificate under section 238 of the Act that certifies that a performance solution complies with a performance requirement of the BCA in relation to proposed building work must record in writing the following—
(a) the performance requirement with which the performance solution complies;
(b) details of any of the following that the registered building practitioner uses or relies
Reg. 124(1)(b) amended by S.R. No. 180/2018 reg. 7.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
98
on in determining that the performance solution complies with the performance requirement—
(i) the assessment method or methods;
(ii) the details of any expert judgement;
(iii) the details of any tests or calculations;
(iv) the details of any standards or other information.
(2) A registered building practitioner must within 7 days after a request from the relevant building surveyor give to the relevant building surveyor a copy of the record prepared under subregulation (1).
125 Evidence of suitability—certificate from professional engineer or other qualified person
(1) The BCA Volume One applies as if in clause A5.2(1)(e) for "a professional engineer or other appropriately qualified person" there were substituted "a registered building practitioner in the category or class prescribed in the Building Regulations 2018 for the purposes of section 238 of the Building Act 1993 in relation to the relevant class of building work".
(2) The BCA Volume Two applies as if in clause A5.2(1)(e) for "a professional engineer or other appropriately qualified person" there were substituted "a registered building practitioner in the category or class prescribed in the Building Regulations 2018 for the purposes of section 238 of the Building Act 1993 in relation to the relevant class of building work".
126 Forms of certificates of compliance
A certificate under section 238 of the Act must be in a form approved by the Authority and
Reg. 125(1) amended by S.R. No. 40/2019 reg. 10(1).
Reg. 125(2) amended by S.R. No. 40/2019 reg. 10(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
99
published from time to time in the Government Gazette.
Division 2—Special provisions127 Record of pile-driving
Any person installing piles must—
(a) keep a record of all pile-driving operations undertaken during the construction including any determination of allowable loadings; and
(b) make the records available for inspection by the relevant building surveyor during the progress of the pile-driving operations; and
(c) within 28 days of the completion of the pile-driving operations forward the complete records of the pile-driving operations to the relevant building surveyor.
Penalty:10 penalty units.
128 Branding of timber
(1) Despite performance requirement BP1.1 of the BCA Volume One and performance requirement P2.1.1 of the BCA Volume Two, every piece of timber to be used for structural purposes must be—
(a) stress-graded in accordance with whichever of the following standards is applicable to the type of timber—
(i) AS 2082 Timber—Hardwood—Visually stress-graded for structural purposes, as in force or as issued or published from time to time (AS 2082);
(ii) AS 2858 Timber—Softwood—Visually stress-graded for structural purposes, as in force or as issued or published from time to time (AS 2858);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
100
(iii) AS/NZS 1748 Timber—Solid—Stress-graded for structural purposes, as in force or as issued or published from time to time; and
(b) marked at least once with—
(i) the source of the stress grading; and
(ii) the word "seasoned" or the letter "S" if seasoned in accordance with AS 2082 or AS 2858; and
(iii) the stress grade or stress grade colour in accordance with AS 1613 Timber—Colours for marking F-grades, as in force or as issued or published from time to time.
(2) Nothing in this regulation applies to timber—
(a) to be used as a stump, sole plate or as fencing material; or
(b) having a dimension of 25 mm or less; or
(c) comprising part of a manufactured component which complies with AS 1720.1 Timber structures—Part 1: Design methods, as in force or as issued or published from time to time; or
(d) which has been previously used, but which in the opinion of the relevant building surveyor is suitable to be used for structural purposes.
129 Requirements for permits involving fire safety matters
(1) The report and consent of the chief officer must be obtained to an application for a building permit which involves any of the following fire safety matters if those matters do not meet the deemed-to-satisfy provisions of the BCA—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
101
(a) fire hydrants;
(b) fire control centres or fire control rooms;
(c) fire precautions during construction;
(d) fire mains;
(e) control valves;
(f) booster assemblies;
(g) open space and perimeter vehicular access to the extent it relates to emergency vehicles;
(h) fire indicator panels;
(i) fire services controls in passenger lift cars.
(2) In a report under subregulation (1), the chief officer may consent to a variation of the requirements of the BCA if the chief officer is satisfied that a satisfactory degree of fire safety is achieved.
(3) When a building permit is issued which involves the installation of fire sprinklers and the installation does not meet the deemed-to-satisfy provisions of the BCA, the relevant building surveyor must forward details of the installation to the chief officer.
130 Report and consent for building over easements
(1) The report and consent of the relevant service authority must be obtained to an application for a building permit to construct a building over an easement vested in that service authority.
(2) This regulation does not apply to implied easements under the Subdivision Act 1988.
Notes
1 Section 148 of the Water Act 1989 prohibits a person from building a structure, or placing any filling on land without the consent of the Melbourne Water Corporation or other water supply authority—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
102
over which an easement exists either in favour of a water supply authority, or for water supply, sewerage or drainage purposes; or
within 5 m laterally of any works of the Melbourne Water Corporation; or
within 1 m laterally of any works of any other water supply authority.
2 Section 148 of the Water Act 1989 also prohibits the removal of any soil, rock or other matter that supports, protects or covers any works of the Melbourne Water Corporation or water supply authority.
131 Report concerning need for electricity substations
(1) If an application is made for a building permit for the construction of a building, the relevant building surveyor may require a report from the relevant electricity supply authority as to whether an electricity substation is necessary on the allotment and, if so, the size and location of the substation.
(2) This regulation does not apply to the construction of a Class 1 or 10 building.
132 Report and consent for septic tank systems
(1) The report and consent of the relevant council must be obtained to an application for a building permit that requires—
(a) the installation or alteration of a septic tank system; or
(b) the construction of a building over an existing septic tank system.
(2) The report and consent of the relevant council need not be obtained to an application for a building permit referred to in subregulation (1) if a permit for the construction, installation or alteration of the septic tank system that is relevant to the application has been issued under
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
103
section 53M(5) of the Environment Protection Act 1970.
133 Stormwater drainage
(1) The design of every stormwater drainage system to the point of discharge from an allotment must be approved by the relevant building surveyor.
(2) The report of the relevant council indicating the location of the point of discharge from an allotment either within the allotment or at the allotment boundary must be obtained in relation to an application for a building permit for the carrying out of building work that includes a stormwater drainage system.
(3) The design of every stormwater drainage system must—
(a) be approved by the relevant building surveyor; and
(b) the point of discharge must be consistent with the point of discharge identified in the report obtained under subregulation (2).
134 Buildings above or below certain public facilities
(1) This regulation does not apply to a part of a building to which Part 6 applies.
(2) The report and consent of the relevant council must be obtained to an application for a building permit for the construction of a building above or below a street, railway, bus terminal or similar public facility whether or not such a building is connected to other buildings.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
104
Part 9—Fire safety requirements
* * * * *
* * * * *
144 Definition of owner
In this Part, owner in relation to a dwelling, a sole-occupancy unit or a building means—
(a) in the case of a dwelling, sole-occupancy unit or a building being purchased under a terms contract (within the meaning of the Sale of Land Act 1962) under which the purchaser has become entitled to possession or to the receipt of the rents and profits, the purchaser of that dwelling, sole-occupancy unit or building; and
(b) in the case of any other dwelling, sole-occupancy unit or building, the owner of that dwelling, sole-occupancy unit or building.
145 Automatic smoke detection and alarm systems
(1) This regulation applies to a Class 1 or 3 building or a Class 4 part of a building or a sole-occupancy unit contained in a Class 2 building or a Class 9a
Pt 9 (Heading) substituted by S.R. No. 116/2019 reg. 7.
Pt 9 Divs 1, 2 (Headings and regs 135–143) revoked by S.R. No. 116/2019 reg. 8.
Pt 9 Div. 3 (Heading) revoked by S.R. No. 116/2019 reg. 9.
Reg. 144 amended by S.R. No. 116/2019 reg. 10.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
105
building that is a residential care building that was constructed, or for which a building permit was granted, before 1 August 1997.
(2) A Class 1 building must have installed throughout the building—
(a) a smoke alarm system that complies with Part 3.7.5 of the BCA Volume Two; or
(b) an approved smoke alarm system powered from a mains electricity supply, if there is such a supply to the building.
(3) A building, other than a Class 1 building, must have installed throughout the building one of the following as required by Specification E2.2a of the BCA Volume One—
(a) a smoke alarm system that complies with clause 3 of Specification E2.2a of the BCA Volume One;
(b) a smoke detection system that complies with clause 4 of Specification E2.2a of the BCA Volume One;
(c) a combination of a smoke alarm system and a smoke detection system that complies with clause 5 of Specification E2.2a of the BCA Volume One.
(4) This regulation must be complied with by—
(a) in the case of a sole-occupancy unit contained in a Class 2 building, the owner of the sole-occupancy unit; or
(b) in any other case, the owner of the building.
(5) Subregulation (3) does not apply to a building in which there is installed throughout the building
Reg. 145(2)(a) amended by S.R. No. 40/2019 reg. 11(1).
Reg. 145(3) amended by S.R. No. 40/2019 reg. 11(2).
Reg. 145(3)(b) amended by S.R. No. 40/2019 reg. 11(3).
Reg. 145(3)(c) inserted by S.R. No. 40/2019 reg. 11(4).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
106
an approved smoke detection and alarm system that consists of either one or both of the following—
(a) an approved smoke alarm system powered from a mains electricity supply;
(b) an approved smoke detection system.
(6) This regulation does not apply to a Class 1a or Class 4 part of a building or a sole-occupancy unit contained in a Class 2 building that complies with regulation 707 of the Building Interim Regulations 2017 as in force immediately before its revocation.
(7) This regulation does not apply to a Class 1bor 3 building or a Class 9a building that is a residential care building that complies with regulation 709 of the Building Interim Regulations 2017 as in force immediately before its revocation.
146 Residential care buildings—automatic fire suppression systems
(1) This regulation applies to a Class 9a building that is a residential care building that was constructed, or for which a building permit was granted, before 1 August 1997.
(2) A fire sprinkler system in accordance with the deemed-to-satisfy provisions contained in clause E1.5 of the BCA Volume One must be installed throughout a residential care building.
(3) This regulation must be complied with by the owner of the building.
(4) This regulation does not apply to a building that has an approved automatic fire suppression system installed throughout the building.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
107
147 Shared accommodation buildings—automatic fire suppression systems
(1) This regulation applies to a Class 3 building that is a shared accommodation building constructed, or for which a building permit was granted, before 1 July 2003.
(2) A fire sprinkler system in accordance with deemed-to-satisfy provisions contained in clause E1.5 of the BCA Volume One must be installed throughout a shared accommodation building.
(3) This regulation must be complied with by the owner of the building.
(4) This regulation does not apply to a shared accommodation building that has a rise in storeys of not more than 2 and—
(a) the distance of travel from the entrance doorway of each sole-occupancy unit is not more than 6 m—
(i) to the nearest exit; or
(ii) to a point from which travel in different directions to at least 2 exits is available; and
(b) that has a fire hose reel system in accordance with the deemed-to-satisfy provisions contained in clause E1.4 of the BCA Volume One or, in the case of a fire compartment having a floor area not greater than 500 m2, portable fire extinguishers to cover Class A fire risks in accordance with AS 2444—2001 Portable fire extinguishers and fire blankets—Selection and location as in force or as issued or published from time to time; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
108
(c) that has emergency lighting in accordance with the deemed-to-satisfy provisions contained in clause G4.4 or clause E4.2 of the BCA Volume One (as appropriate); and
(d) that has exit signs in accordance with the deemed-to-satisfy provisions contained in Part E4 of the BCA Volume One; and
(e) that has a management plan.
(5) This regulation does not apply to a shared accommodation building that has a rise in storeys of more than 2 and—
(a) the distance of travel from the entrance doorway of each sole-occupancy unit—
(i) to the nearest exit; or
(ii) to a point from which travel in different directions to at least 2 exits is available—
is not more than 6 m; and
(b) that has building elements with a fire-resistance level of not less than 60/60/60 separating each sole-occupancy unit from—
(i) a public corridor, public lobby or the like; or
(ii) a room not within the sole-occupancy unit; or
(iii) the landing of an internal non-fire-isolated stairway; or
(iv) another sole-occupancy unit; and
Reg. 147(4)(e) amended by S.R. No. 75/2018 reg. 12(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
109
(c) any doorways from each sole-occupancy unit that provide access to a public corridor, public stairway, internal non-fire-isolated stairway or the like are protected with a self-closing fire door having a fire-resistance level of not less than -/30/30; and
(d) that has a fire hose reel system in accordance with the deemed-to-satisfy provisions contained in clause E1.4 of the BCA Volume One; and
(e) that has emergency lighting in accordance with clause G4.4 or clause E4.2 contained in the BCA Volume One (as appropriate); and
(f) that has exit signs in accordance with the deemed-to-satisfy provisions contained in Part E4 of the BCA Volume One; and
(g) that has a management plan.
(6) This regulation does not apply to a shared accommodation building—
(a) in which—
(i) each storey that has sleeping facilities has its own direct egress to a street or to open space; and
(ii) the distance of travel from the entrance doorway of each sole-occupancy unit to the nearest exit, or to a point from which travel in different directions to at least 2 exits is available, is not more than 6 m; or
Reg. 147(5)(g) amended by S.R. No. 75/2018 reg. 12(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
110
(b) that was constructed, or for which a building permit was granted, before 1 August 1997; or
(c) that has an approved automatic fire suppression system installed throughout the building.
(7) In this regulation—
management plan means a plan that includes the following information—
(a) contact details for emergency services including fire, ambulance and police;
(b) 24-hour contact details of the manager of the shared accommodation building;
(c) a list of the type of fire protection equipment available for the shared accommodation building;
(d) a map showing the location of fire protection equipment available for the shared accommodation building;
(e) a warning that fire protection equipment must be kept clear of obstructions at all times;
(f) a program of annual training to ensure that any staff of the shared accommodation building know how to operate the fire protection equipment available for the shared accommodation building;
(g) an emergency plan that complies with subregulation (8);
(h) a program of evacuation drills to ensure the efficacy of the emergency plan.
(8) For the purposes of subregulation (7)(g), an emergency plan must—
Reg. 147(7) inserted by S.R. No. 75/2018 reg. 12(2).
Reg. 147(8) inserted by S.R. No. 75/2018 reg. 12(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
111
(a) comply with AS 3745—2010 Planning for emergencies in facilities published on 25 November 2010, as in force or as issued from time to time; or
(b) include the following information—
(i) a map of the shared accommodation building that identifies the location of all exits from the shared accommodation building;
(ii) a map that identifies the assembly point at which occupants of the shared accommodation building must meet in the event of an evacuation;
(iii) details of the actions any staff must take to notify building occupants of an evacuation, in the event of an evacuation;
(iv) details of the stages of the evacuation warning system and the actions that must be taken at each stage, if an evacuation warning system is installed in the building.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
112
Part 9A—Safety requirements for, registration of, and certification of barriers
for, swimming pools and spas
Division 1—Application of Part147A Application of this Part
This Part applies to land on which a swimming pool or spa is located if the swimming pool or spa—
(a) is appurtenant to a Class 1, 2, 3 or 10 building or a Class 4 part of a building; and
(b) is capable of containing water to a depth of greater than 300 mm.
Note
Swimming pools or spas that are not capable of containing water to a depth of greater than 300 mm are exempt from these Regulations—see item 8 of the Table in Schedule 3.
Division 2—Requirements for barriers for swimming pools and spas
147B Application of Division
This Division applies to a swimming pool or spa that was constructed, or for which a building permit was granted, before 8 April 1991.
Note
A building permit includes a building approval or a building permit under the Building Control Act 1981—see clause 8 of Schedule 4 to the Act.
147C Requirement for barriers
The owner of the land on which a swimming pool or spa is located must ensure that one or more of
Pt 9A (Headings and regs 147A–147ZM) inserted by S.R. No. 116/2019 reg. 11.
Reg. 147A inserted by S.R. No. 116/2019 reg. 11.
Reg. 147B inserted by S.R. No. 116/2019 reg. 11.
Reg. 147C inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
113
the following barriers are in place to restrict access to the part of the land on which the swimming pool or spa is located—
(a) a wall of a building, but only if—
(i) any door or gate in the wall complies with regulation 147D; and
(ii) any openable part of any window in the wall complies with regulation 147E;
(b) a fence and gate complying with AS 1926.1—1993 Swimming pool safety Part 1: Fencing for swimming pools, published 26 July 1993 as in force or as issued from time to time;
(c) a paling or imperforate fence if—
(i) it is at least 1·5 m in height measured above the ground level on the approach side; and
(ii) any door or gate in the fence complies with regulation 147D.
Penalty: 50 penalty units.
147D Requirements for doors or gates
For the purposes of regulation 147C(a)(i) and (c)(ii)—
(a) the door or gate must have a self-locking or self-latching device that prevents the door or gate, if the door or gate is in its closed position, from being opened by a person unable to reach the opening mechanism for the door or gate; and
(b) the opening mechanism on the door or gate must be located not less than 1·5 m above the ground level or the internal floor level (as the case requires), measured from the approach side; and
Reg. 147D inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
114
(c) the door or gate must be fitted with a device that returns the door or gate to its closed position
(i) from any position in the range of positions from fully open to resting on the lock or latch; and
(ii) from a stationary start from any position within that range without the application of manual force.
147E Requirements for windows in walls used as barriers
For the purposes of regulation 147C(a)(ii), the openable part of the window in the wall—
(a) must be not less than 2·4 m above the ground or paving immediately external to the window; or
(b) must be not less than 1·5 m above the floor of the room containing the window; or
(c) must have a catch, bolt, lock or other stop located not less than 15 m above the floor of the room containing the window so that the openable part of the window cannot be opened more than 125 mm; or
(d) must have a securely fitted fly screen.
Division 3—Maintenance and operation of barriers for swimming pools and spas
147F Swimming pool and spa barrier maintenance
The owner of the land on which a swimming pool or spa is located must take all reasonable steps to ensure that a barrier restricting access to the swimming pool or spa is properly maintained.
Reg. 147E inserted by S.R. No. 116/2019 reg. 11.
Reg. 147F inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
115
Penalty: 50 penalty units.
147G Swimming pool and spa barrier operation
An occupier of the land on which a swimming pool or spa is located must take all reasonable steps to ensure that a barrier restricting access to the swimming pool or spa is operating effectively.
Penalty: 50 penalty units.
147H Swimming pool and spa barrier gate must remain closed
(1) An occupier of the land on which a swimming pool or spa is located must take all reasonable steps to ensure that any gate or door forming part of a barrier restricting access to the swimming pool or spa remains closed except when a person is entering or leaving the part of the land on which the swimming pool or spa is located.
Penalty: 50 penalty units.
(2) A person who opens a gate or door forming part of a barrier restricting access to the swimming pool or spa must ensure that the gate or door is closed immediately after entering or leaving the part of the land on which the swimming pool or spa is located.
Penalty: 50 penalty units.
Division 4—Registration of swimming pools and spas
147I Certain swimming pools and spas exempted from section 216D of the Act
Section 216D of the Act does not apply to any swimming pool or spa that is not capable of containing water to a depth of greater than 300 mm.
Reg. 147G inserted by S.R. No. 116/2019 reg. 11.
Reg. 147H inserted by S.R. No. 116/2019 reg. 11.
Reg. 147I inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
116
147J Prescribed information for swimming pool and spa registers
(1) For the purposes of section 216D(3)(a) of the Act, the prescribed information for a registered swimming pool or registered spa is—
(a) the address of the land on which the swimming pool or spa is located; and
(b) the name of the owner of the land; and
(c) whether the swimming pool or spa is a relocatable swimming pool or a relocatable spa; and
(d) the date of construction of the swimming pool or spa as determined by the relevant council under regulation 147T; and
(e) the applicable barrier standard for the swimming pool or spa barrier; and
(f) the following information in relation to the most recent certificate of pool and spa barrier compliance lodged with the relevant council for the swimming pool or spa barrier—
(i) the date the certificate was issued;
(ii) the registration number of the swimming pool and spa inspector who issued the certificate;
(iii) a statement by the inspector who issued the certificate as to whether the inspector carried out building work on the barrier before the issuing of the certificate; and
(g) the following information in relation to a certificate of pool and spa barrier non-compliance lodged with the relevant council for the swimming pool or spa barrier—
Reg. 147J inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
117
(i) the date the certificate was issued;
(ii) the registration number of the swimming pool and spa inspector who issued the certificate; and
(h) if the relevant council has granted an exemption under regulation 147W, the date any document was accepted by the relevant council under that regulation; and
(i) the date by which the next certificate of pool and spa barrier compliance for the swimming pool or spa is required to be lodged with the relevant council; and
(j) the dates and the permit numbers of any building permits issued after the date of construction of the swimming pool or spa for building work for the alteration, modification, replacement or renewal of the whole or part of the swimming pool or spa barrier.
(2) For the purposes of section 216D(3)(b) of the Act, the prescribed information is the address of the land on which the swimming pool or spa is located.
147K A register must be maintained in the following form and manner
For the purposes of section 216D(4) of the Act, a register must be maintained in electronic form or in document form.
147L Application for registration of swimming pools and spas constructed, or where construction commenced, before 1 June 2020
(1) This regulation applies to a swimming pool or spa (other than a relocatable swimming pool or relocatable spa)—
(a) constructed before 1 June 2020; or
Reg. 147K inserted by S.R. No. 116/2019 reg. 11.
Reg. 147L inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
118
(b) in respect of which construction was commenced but not completed before 1 June 2020.
(2) The owner of the land on which the swimming pool or spa is located must apply to the relevant council for registration of the swimming pool or spa before or on the later of—
(a) 1 June 2020; or
(b) 30 days after the date the occupancy permit or certificate of final inspection for the swimming pool or spa is issued.
Penalty: 10 penalty units.
(3) An application for registration of a swimming pool or spa must be made under this regulation despite information relating to the swimming pool or spa having been entered on the register by the relevant council under section 216D(3)(b) of the Act.
147M Application for registration of swimming pools and spas constructed on or after 1 June 2020
(1) This regulation applies to a swimming pool or spa (other than a relocatable swimming pool or relocatable spa) for which a building permit for construction of the swimming pool or spa was issued—
(a) on or after 1 June 2020; or
(b) before 1 June 2020 but construction of the swimming pool or spa did not commence until on or after that date.
(2) The owner of the land on which the swimming pool or spa is located must—
(a) apply to the relevant council for registration of the swimming pool or spa within 30 days after the date on which the owner receives
Reg. 147M inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
119
the occupancy permit or certificate of final inspection for the swimming pool or spa; and
(b) lodge the certificate of pool and spa barrier compliance issued by the relevant building surveyor under regulation 147Y with the relevant council at the time of applying for registration of the swimming pool or spa.
Penalty: 10 penalty units.
147N Application for registration of relocatable swimming pools and relocatable spas
(1) This regulation applies to a relocatable swimming pool or relocatable spa that has been erected for 3 or more consecutive days.
(2) The owner of the land on which the relocatable swimming pool or relocatable spa is located must apply to the relevant council for registration of the relocatable swimming pool or relocatable spa before or on—
(a) 4 June 2020, if the relocatable swimming pool or relocatable spa was erected 3 or more days before 1 June 2020 and remains erected on 1 June 2020; or
(b) the 4th day after the relocatable swimming pool or relocatable spa was erected, in any other case.
Penalty: 10 penalty units.
147O Relevant council may require owner to apply for registration of swimming pool or spa
(1) If a relevant council has entered information relating to a swimming pool or spa in the register under section 216D(3)(b) of the Act, but the owner has not applied for registration of the swimming pool or spa under regulation 147L, 147M or 147N, the relevant council may give a notice in writing to the owner of the land requiring
Reg. 147N inserted by S.R. No. 116/2019 reg. 11.
Reg. 147O inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
120
the owner to apply for registration of the swimming pool or spa within a period specified in the notice of not less than 14 days after the owner receives the notice.
(2) An owner must comply with a notice given to the owner under subregulation (1).
Penalty: 10 penalty units.
147P Form and fee for registration application
(1) An application for registration under this Division must be made in the form of Form 22 and be accompanied by—
(a) any documents required in that Form if available; and
(b) the registration fee determined by the relevant council in accordance with the Local Government Act 1989; and
(c) in the case of an application for registration under regulation 147L, the information search fee determined by the relevant council in accordance with the Local Government Act 1989.
(2) The maximum registration fee payable to the relevant council for an application for registration under this Part is 2·15 fee units.
(3) The maximum information search fee payable to the relevant council is 3·19 fee units.
147Q Council must register swimming pool or spa on receipt of application
On receiving an application that complies with regulation 147P under regulation 147L, 147M or 147N, the relevant council must enter information relating to a swimming pool or spa in the register of that council.
Reg. 147P inserted by S.R. No. 116/2019 reg. 11.
Reg. 147Q inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
121
147R Relevant council must give a notice to the applicant of registration of swimming pool or spa and certain other matters
(1) After registering a swimming pool or spa on the register, the relevant council must give a notice in writing to the applicant for registration of the swimming pool or spa of the following matters—
(a) that the swimming pool or spa has been registered;
(b) the date of construction of the swimming pool or spa determined under regulation 147T;
(c) the applicable barrier standard for the swimming pool or spa barrier;
(d) that the owner of the land may appeal to the Building Appeals Board under section 144(2) of the Act against a determination by the relevant council of the date of construction of the swimming pool or spa within 30 days after the owner receives the determination;
(e) for a swimming pool or spa registered under regulation 147L, the date by which the first certificate of pool and spa barrier compliance is required to be lodged with the relevant council;
(f) for a swimming pool or spa registered under regulation 147M, the date by which the next certificate of pool and spa barrier compliance is required to be lodged with the relevant council;
(g) for a relocatable swimming pool or relocatable spa registered under regulation 147N, the date by which the first certificate of pool and spa barrier compliance is
Reg. 147R inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
122
required to be lodged with the relevant council.
(2) For the purposes of subregulation (1)(e), the date specified in the notice must be—
(a) 1 June 2021, for a swimming pool or spa with a date of construction on or before 30 June 1994; or
(b) 1 June 2022 for a swimming pool or spa with a date of construction on or after 1 July 1994 and before 1 May 2010; or
(c) 1 June 2023, for a swimming pool or spa with a date of construction on or after 1 May 2010.
(3) For the purposes of subregulation (1)(f), the date specified in the notice must be 4 years after the date that the first certificate of pool and spa barrier compliance was lodged with the relevant council.
(4) For the purposes of subregulation (1)(g), the relevant council must specify a date that is no later than 30 days after the date that the relocatable swimming pool or relocatable spa was registered with that council.
(5) Despite subregulation (1), if a relevant council is satisfied that a registered swimming pool or registered spa (other than a relocatable swimming pool or relocatable spa) was constructed before 1 June 2020 without a building permit in force, the relevant council may specify in the notice under subregulation (1) a date that is no earlier than 1 June 2021.
147S Removal of swimming pool or spa from a register
(1) If an owner of land on which a registered swimming pool or registered spa is or was located demonstrates to the satisfaction of the relevant council that a registered swimming pool or
Reg. 147S inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
123
registered spa no longer exists or is no longer capable of containing water to a depth of greater than 300 mm, the relevant council must remove from the register the information about the swimming pool or spa set out in regulation 147J as soon as practicable.
(2) After removing the information about the swimming pool or spa from the register, the relevant council must give a notice in writing to the owner stating that—
(a) the information about the swimming pool or spa has been removed from the register; and
(b) the owner is no longer required under these Regulations to lodge a further certificate of pool and spa barrier compliance with the relevant council for the swimming pool or spa.
Division 5—Inspection and certification of compliance of barriers
Subdivision 1—Date of construction of a swimming pool or spa
147T Determination by the relevant council of the date of construction of a swimming pool or spa
(1) On an application for registration of a swimming pool or spa (other than a relocatable swimming pool or relocatable spa) under Division 4, the relevant council must determine the date of construction of the swimming pool or spa.
(2) In determining the date of construction under subregulation (1) the relevant council may have regard to—
(a) any information regarding the period of construction or the date of any building
Reg. 147T inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
124
permit issued in relation to the construction of the swimming pool or spa provided in the application; or
(b) any information contained in the records of the relevant council; or
(c) any other relevant information obtained by the relevant council.
Note
In subregulation (2)(a), a building permit includes a building approval or a building permit under the Building Control Act 1981—see clause 8 of Schedule 4 to the Act.
147U Determination by the relevant council of the date of construction of a relocatable swimming pool or relocatable spa
(1) On an application for registration of a relocatable swimming pool or relocatable spa under Division 4, the relevant council must determine the date of construction of the relocatable swimming pool or relocatable spa.
(2) For the purposes of subregulation (1), the date of construction of a relocatable swimming pool or relocatable spa is the date that the relocatable swimming pool or relocatable spa was last erected on the land specified in the application for registration as being the land on which the swimming pool or spa is located.
Subdivision 2—Certificates of pool and spa barrier compliance
147V Obligation to lodge certificate of pool and spa barrier compliance
(1) The owner of land on which a swimming pool or spa is located must lodge a certificate of pool and spa barrier compliance that complies with subregulation (2) with the relevant council before
Reg. 147U inserted by S.R. No. 116/2019 reg. 11.
Reg. 147V inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
125
or on the date specified in the notice most recently given to or served on the owner (as the case requires) (the applicable date) by the relevant council under—
(a) regulation 147R(1)(e); or
(b) regulation 147R(1)(f); or
(c) regulation 147R(1)(g); or
(d) subregulation (4)(b); or
(e) regulation 147W(2)(b); or
(f) regulation 147Z(3); or
(g) regulation 147ZE(b); or
(h) regulation 147ZK(1)(b); or
(i) regulation 147ZL(2)(c).
Penalty: 10 penalty units.
(2) A certificate of pool and spa barrier compliance lodged by an owner with a relevant council in accordance with subregulation (1) must be dated not more than 30 days before the date it is lodged.
(3) Subregulation (1) does not apply to an owner who has been exempted under regulation 147W(1) from lodging a certificate of pool and spa compliance in accordance with a notice under regulation 147R(1)(e).
(4) Following lodgement of a certificate of pool and spa barrier compliance with the relevant council by an owner in accordance with subregulation (1), the relevant council must give a notice in writing to the owner of—
(a) the date the certificate of pool and spa barrier compliance was lodged with the relevant council; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
126
(b) the date by which the next certificate of pool and spa barrier compliance is required to be lodged with the relevant council which must be 4 years after the previous certificate was lodged with the relevant council.
147W Exemption from requirement to provide first certificate of pool and spa barrier compliance for certain swimming pools and spas
(1) A relevant council may exempt an owner from the requirement under regulation 147V(1)(a) to lodge a certificate of pool and spa barrier compliance with the relevant council for a barrier for a swimming pool or spa required to be registered under regulation 147L if—
(a) the owner lodges an occupancy permit or certificate of final inspection with the relevant council which—
(i) relates to a building permit issued in relation to the barrier before 1 June 2020; and
(ii) was issued after an inspection of the barrier carried out on or after 1 June 2019; or
(b) the owner lodges a document with the relevant council that—
(i) is signed by a registered building surveyor or registered building inspector who inspected the barrier on or after 1 June 2017; and
(ii) is dated no more than 4 years before the date of the lodgement of the document; and
(iii) states that at the time of the inspection by the registered building surveyor or registered building inspector the barrier
Reg. 147W inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
127
complied with the applicable barrier standard.
(2) If an owner is exempted under subregulation (1), the relevant council must give a notice in writing to the owner stating—
(a) that the owner is exempted from the requirement to lodge the next certificate of pool and spa barrier compliance by the applicable date under regulation 147V(1)(a) for the barrier; and
(b) the date by which the next certificate of pool and spa barrier compliance is required to be lodged with the relevant council, which must be 4 years after the date of the inspection of the barrier relating to the occupancy permit, certificate of final inspection or the document.
147X Fees for lodging a certificate of pool and spa barrier compliance with a relevant council
(1) A fee, determined by the relevant council in accordance with the Local Government Act 1989, is payable to the relevant council by the owner for the lodgement of a certificate of pool and spa barrier compliance with the relevant council by the owner under regulation 147V(1).
(2) The maximum fee that a relevant council may determine under subregulation (1) is 1·38 fee units.
(3) An owner must pay the fee under subregulation (1) at the time of lodging the certificate of pool and spa barrier compliance with the relevant council.
Penalty: 10 penalty units.
Reg. 147X inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
128
147Y Issuing of certificates of pool and spa barrier compliance
(1) If, following an inspection on or after 1 June 2020 of a swimming pool or spa and related barrier under regulation 169(d), the relevant building surveyor is satisfied that the barrier complies with the applicable barrier standard, the relevant building surveyor must issue a certificate of pool and spa barrier compliance and give the certificate to the owner of the land on which the swimming pool or spa is located.
(2) A swimming pool and spa inspector engaged by the owner of land on which a swimming pool or spa is located must issue a certificate of pool and spa barrier compliance to the owner if—
(a) the inspector has inspected the barrier relating to the swimming pool or spa; and
(b) the inspector is satisfied that the barrier complies with the applicable barrier standard.
(3) The municipal building surveyor carrying out functions under Part 8 or acting as an authorised person under section 228 of the Act may issue a certificate of pool and spa barrier compliance at any time in relation to a swimming pool or spa barrier.
(4) A certificate of pool and spa barrier compliance must be in the form of Form 23.
(5) If a person issues a certificate of pool and spa barrier compliance under this regulation, the person must, as soon as practicable after issuing the certificate, give the certificate to the owner of the land on which the swimming pool or spa is located.
Reg. 147Y inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
129
147Z Relevant council may extend time for lodgement of a certificate of pool and spa barrier compliance
(1) The relevant council may at any time on its own motion, or at the request of the owner of land on which a swimming pool or spa is located, extend the period for lodgement of a certificate of pool and spa barrier compliance for the swimming pool or spa, if the relevant council is satisfied that—
(a) the owner has provided a reasonable excuse as to why it was not possible to lodge the certificate of pool and spa barrier compliance by the applicable date under regulation 147V(1); or
(b) arrangements have been put in place by the owner for an inspection by a swimming pool and spa inspector to inspect the barrier; or
(c) arrangements have been put in place by the owner for building work to be carried out to rectify—
(i) non-compliances of the barrier with the applicable barrier standard listed in a certificate of pool and spa barrier non-compliance; or
(ii) non-compliances of the barrier with the applicable barrier standard specified in a written notice provided by a swimming pool and spa inspector under regulation 147ZG(1); or
(d) building work being carried out on the land means an inspection of the barrier would not be appropriate; or
(e) a building notice, a building order or an emergency order under Part 8 of the Act has been issued in relation to the swimming pool or spa barrier.
Reg. 147Z inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
130
(2) The relevant council may extend the period for provision of a certificate of pool and spa barrier compliance by not more than 6 months at a time.
(3) If the relevant council decides to grant an extension under subregulation (1), the relevant council must give a notice in writing to the owner of the land specifying a new due date for the lodgement of a certificate of pool and spa barrier compliance as soon as practicable after that decision is made.
Subdivision 3—Alterations to a registered swimming pool or spa or related barrier
147ZA Application of this Subdivision
This Subdivision applies to any building work that is carried out on a swimming pool barrier or spa barrier for which a building permit is required in relation to a registered swimming pool or registered spa.
147ZB Issue of certificate of pool and spa barrier compliance by relevant building surveyor following completion of work
(1) On the completion of the building work, the relevant building surveyor must—
(a) inspect the barrier; and
(b) determine if the barrier complies with the applicable barrier standard.
(2) If, following an inspection under subregulation (1), the relevant building surveyor determines that the barrier complies with the applicable barrier standard, the relevant building surveyor must issue a certificate of pool and spa barrier compliance in the form of Form 23 and give the certificate to the owner of the land on which the swimming pool or spa is located.
Reg. 147ZA inserted by S.R. No. 116/2019 reg. 11.
Reg. 147ZB inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
131
147ZC Owner must lodge certificate of pool and spa barrier compliance with relevant council following certain work
An owner given a certificate of pool and spa barrier compliance under regulation 147ZB(2) must lodge the certificate with the relevant council within 14 days after receiving the certificate.
Penalty: 10 penalty units.
147ZD Relevant council must update applicable barrier standard in register
If a certificate of pool and spa barrier compliance is lodged by an owner under regulation 147ZC and the relevant building surveyor has certified that the barrier complies with the applicable barrier standard in the certificate which differs from the applicable barrier standard specified in the register, the relevant council must update the applicable barrier standard on the register to include the applicable barrier standard referred to in the certificate.
147ZE Relevant council must confirm receipt of certificate of pool and spa barrier compliance
Following lodgement of a certificate of pool and spa barrier compliance under regulation 147ZC, the relevant council must give a notice in writing to the owner as soon as practicable of—
(a) the lodgement of the certificate of pool and spa barrier compliance; and
(b) the date by which the next certificate of pool and spa barrier compliance is required to be lodged with the relevant council; and
(c) if the applicable barrier standard has been updated in accordance with regulation 147ZD—
Reg. 147ZC inserted by S.R. No. 116/2019 reg. 11.
Reg. 147ZD inserted by S.R. No. 116/2019 reg. 11.
Reg. 147ZE inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
132
(i) that the applicable barrier standard for the pool or spa has been updated; and
(ii) details of the applicable barrier standard that now applies to the swimming pool or spa barrier.
Division 6—Issuing of certificates of pool and spa barrier non-compliance and related matters
147ZF Circumstances in which a certificate of pool and spa barrier non-compliance must be immediately issued
If following the inspection of a swimming pool or spa barrier, a swimming pool and spa inspector is of the opinion that any of the following circumstances exist, the inspector must immediately issue a certificate of pool and spa barrier non-compliance to the owner of the land on which the pool or spa is located—
(a) within 60 days of the inspection—
(i) the barrier is not capable of being made compliant with the applicable barrier standard; or
(ii) the owner is unlikely to bring the barrier into compliance with the applicable barrier standard;
(b) the non-compliance of the barrier with the applicable barrier standard poses a significant and immediate risk to life or safety;
(c) the barrier does not comply with the applicable barrier standard in any of the following ways—
(i) a door or gate forming part of the barrier, when in the closed position, is able to be opened by a person who is
Reg. 147ZF inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
133
unable to reach the opening mechanism for that door or gate;
(ii) a door or gate forming part of the barrier is unable to be completely closed;
(iii) any part of the barrier is less than 1 metre in height measured above ground level from the approach side.
147ZG Procedure if a barrier does not meet the applicable barrier standard
(1) If a swimming pool and spa inspector, inspects a barrier of a swimming pool or spa and determines that the barrier does not meet the applicable barrier standard, and regulation 147ZF does not apply, the inspector must give the owner of the land on which the swimming pool or spa is located a notice in writing in accordance with subregulation (3).
(2) The swimming pool and spa inspector must give the notice under subregulation (1) to the owner as soon as practicable after the inspection of the barrier.
(3) A notice under subregulation (1) must—
(a) state that the barrier must be brought into compliance with the applicable barrier standard; and
(b) specify the matters in respect of which the barrier does not comply with the applicable barrier standard; and
(c) specify the date, being not more than 60 days after the owner receives the notice, by which the matters specified in paragraph (b) must be brought into compliance with the applicable barrier standard; and
Reg. 147ZG inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
134
(d) specify the date and time that the swimming pool and spa inspector proposes to reinspect the barrier to check if it complies with the applicable barrier standard.
(4) Following the reinspection of the barrier—
(a) if the swimming pool and spa inspector is satisfied that the barrier complies with the applicable barrier standard, the inspector must issue a certificate of pool and spa barrier compliance and give the certificate to the owner; or
(b) if the swimming pool and spa inspector is not satisfied that the barrier complies with the applicable barrier standard, the inspector must—
(i) issue a certificate of pool and spa barrier non-compliance; or
(ii) give the owner a notice under regulation 147ZH(1).
(5) The swimming pool and spa inspector must issue a certificate of pool and spa barrier non-compliance if the inspector is prevented by the owner from undertaking a reinspection of the barrier and the date specified under subregulation (3)(c) in the notice under subregulation (1) has passed.
147ZH Further inspection of a non-compliant barrier
(1) On reinspection of a barrier under regulation 147ZG, the swimming pool and spa inspector, if satisfied that progress has been made in bringing the barrier into compliance with the applicable barrier standard, may give a notice in writing to the owner of the land on which the swimming pool or spa is located in accordance with subregulation (2).
Reg. 147ZH inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
135
(2) Notice under subregulation (1) must—
(a) state that the barrier must be brought into compliance with the applicable barrier standard; and
(b) specify the matters in respect of which the barrier does not comply with the applicable barrier standard; and
(c) specify the date, being not more than 7 days after the owner receives the notice, by which the matters specified in paragraph (b) must be brought into compliance with the applicable barrier standard; and
(d) specify the date and time that the swimming pool and spa inspector proposes to reinspect the barrier to check if it complies with the applicable barrier standard.
(3) The swimming pool and spa inspector must give the notice under subregulation (1) to the owner as soon as practicable after the reinspection of the barrier under regulation 147ZG.
(4) Following the further reinspection of the barrier—
(a) if the swimming pool and spa inspector is satisfied that the barrier complies with the applicable barrier standard, the inspector must issue a certificate of pool and spa barrier compliance and give the certificate to the owner; or
(b) if the swimming pool and spa inspector is not satisfied that the barrier complies with the applicable barrier standard, the inspector must issue a certificate of pool and spa barrier non-compliance.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
136
(5) The swimming pool and spa inspector must issue a certificate of pool and spa barrier non-compliance if the inspector is prevented by the owner from undertaking a further reinspection of the barrier and the date specified under subregulation (2)(c) in the notice under subregulation (1) has passed.
147ZI Issuing a certificate of pool and spa barrier non-compliance under this Division
(1) A certificate of pool and spa barrier non-compliance issued under this Division must be in the form of Form 24.
(2) If a swimming pool and spa inspector issues a certificate of pool and spa barrier non-compliance under this Division, the inspector—
(a) must lodge that certificate as soon as practicable with the relevant council; and
(b) must give a copy of the certificate to the owner.
147ZJ Fees for lodging a certificate of pool and spa barrier non-compliance with a relevant council
(1) A fee, determined by the relevant council in accordance with the Local Government Act 1989, is payable to the relevant council by the owner of land on which a swimming pool or spa is located for the lodgement of a certificate of pool and spa barrier non-compliance, which relates to the swimming pool or spa barrier, with the relevant council under regulation 147ZI(2)(a).
(2) The maximum fee that a relevant council may determine under subregulation (1) is 26 fee units.
(3) If a certificate of pool and spa barrier non-compliance is lodged with the relevant council under regulation 147ZI(2)(a), the relevant council must give a notice in writing to the owner
Reg. 147ZI inserted by S.R. No. 116/2019 reg. 11.
Reg. 147ZJ inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
137
of the land on which the swimming pool or spa relating to the barrier is located that states—
(a) the fee determined by the relevant council under subregulation (1); and
(b) that the fee must be paid by the owner within a period of not less than 28 days after the date the notice is received by the owner.
(4) An owner must pay the fee determined under subregulation (1) within the period specified in the notice given under subregulation (3).
Penalty: 10 penalty units.
147ZK Municipal building surveyor may serve a barrier improvement notice on owner
(1) If a certificate of pool and spa barrier non-compliance for a swimming pool or spa barrier is lodged with a relevant council, the municipal building surveyor may serve a barrier improvement notice in accordance with subregulation (2) on the owner of the land on which the swimming pool or spa is located requiring the owner—
(a) to bring the non-compliant matters listed in the certificate of non-compliance into compliance with the applicable barrier standard; and
(b) to lodge with the relevant council a certificate of pool and spa barrier compliance by a date specified in the notice that is not less than 14 days after the owner receives the notice.
(2) A barrier improvement notice served on an owner under subregulation (1) must be in the form of Form 25.
Reg. 147ZK inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
138
(3) A municipal building surveyor must not serve a barrier improvement notice on an owner for a swimming pool or spa barrier under this regulation—
(a) if the municipal building surveyor has issued a notice or order under Part 8 of the Act in relation to the barrier; or
(b) if a person has applied for an injunction under Part 13 of the Act in relation to the barrier; or
(c) if a prosecution has commenced against a person in relation to the barrier under Part 13 of the Act.
Division 7—General147ZL Relevant council's actions following transfer of land
containing a registered swimming pool or registered spa
(1) On receipt of a notice of acquisition under the Local Government Act 1989 that relates to land on which a registered swimming pool or registered spa is located, the relevant council must update the register with details of the name of the new owner of the land as soon as practicable.
(2) The relevant council must give a notice in writing to the new owner of the land of the following matters—
(a) confirmation that their name has been recorded on the register;
(b) the applicable barrier standard that applies to the swimming pool or spa barrier located on the land;
Reg. 147ZL inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
139
(c) the date by which the next certificate of pool and spa barrier compliance is required to be provided to the relevant council by the new owner.
147ZM Relevant council to provide information from register to the Authority
For the purposes of section 216D(5) of the Act, on request from the Authority a relevant council must submit the requested information to the Authority in the form approved by the Authority.
Reg. 147ZM inserted by S.R. No. 116/2019 reg. 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
140
Part 10—Designation of special areas for building work
148 Mapping of designated special areas
A council must prepare maps for all designated special areas within its municipal district.
149 Alteration to and creation of designated special area
(1) If in a municipal district a designated special area is altered or a new designated special area is created a relevant council must, as soon as practicable—
(a) amend the map for the designated special area that has been altered; or
(b) prepare a map of the new designated special area that has been created.
(2) A council must advise the Authority within 7 days if a designated special area within its municipal district is altered or if a new designated special area is created.
(3) The relevant council must lodge with the Authority within 7 days copies of designated special area maps amended or prepared under regulation 148 or subregulation (1).
(4) A council must make an up-to-date copy of each designated special area map applicable to its municipal district that has been prepared under regulation 148 or subregulation (1) available to the public for inspection without charge at the offices of the council during normal business hours.
150 Termite risk areas
A council may designate areas within its municipal district in which buildings are likely to be subject to attack by termites.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
141
151 Construction in termite risk areas
Despite anything to the contrary in performance requirement BP1.1 of the BCA Volume One and performance requirement P2.1.1 of the BCA Volume Two—
(a) a primary building element is only required to be protected against attack by termites if it is part of a building being constructed in an area designated under regulation 150; and
(b) a detached Class 10 building is not required to be protected against termite attack.
152 Significant snowfall areas
(1) For the purposes of the BCA, a council may designate areas in its municipal district that in its opinion are likely to be subject to significant snowfalls.
(2) The BCA Volume One applies as if in Schedule 3, in the definition of Alpine area, after the word "snowfalls" there were inserted at the end of paragraph (a) "as designated by a council under regulation 152(1) of the Building Regulations 2018".
(3) The BCA Volume Two applies as if in Schedule 3, in the definition of Alpine area, after the word "snowfalls" there were inserted at the end of paragraph (a) "as designated by a council under regulation 152(1) of the Building Regulations 2018".
153 Report and consent for building in areas liable to flooding
(1) This regulation does not apply to—
(a) a Class 10 building; or
(b) an unenclosed floor area of a building; or
Reg. 152(2) amended by S.R. No. 40/2019 reg. 12(1).
Reg. 152(3) amended by S.R. No. 40/2019 reg. 12(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
142
(c) an alteration to an existing building if the area of the existing building is not increased by more than 20 m2.
(2) The report and consent of the relevant council must be obtained to an application for a building permit if the site is on an allotment that is in an area liable to flooding.
(3) The report and consent of the relevant council under subregulation (2) need not be obtained to an application for a building permit if
(a) a planning permit is required for the construction of the building; and
(b) the relevant planning scheme regulates the level of the lowest floor of the building in relation to any flood level declared under the Water Act 1989 or otherwise determined by the floodplain management authority or the relevant council.
(4) The relevant council must not give its consent under subregulation (2) if it is of the opinion that there is likely to be a danger to the life, health or safety of the occupants of the building due to flooding of the site.
(5) In its report under subregulation (2) the relevant council may specify a level for the surface of the lowest floor of a building on the site.
(6) Before specifying a floor level under subregulation (5) the relevant council must—
(a) consult with the floodplain management authority for that site; and
(b) specify a level at least 300 mm above any flood levels declared under the Water Act 1989 or otherwise determined by the floodplain management authority, unless the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
143
floodplain management authority consents to a lower floor level.
(7) The relevant council must without delay advise the floodplain management authority and the sewerage authority for that site of the floor level (if any) specified under subregulation (5).
154 Report and consent for construction on designated land or designated works
(1) The report and consent of the relevant council must be obtained for an application for a building permit for the construction of a building on designated land or designated works.
(2) The report and consent of the relevant council under subregulation (1) may include recommendations controlling the location and construction of retaining walls and fences in relation to designated land or designated works.
(3) Before giving its consent under subregulation (1), the relevant council must consult with the waterway management authority for the designated land or designated works.
(4) The report and consent of the council need not be obtained to an application for a building permit referred to in subregulation (1) if the consent of the relevant waterway management authority has been obtained as a requirement of a planning permit for the construction of the building.
(5) In this regulation—
waterway management authority in relation to designated land or designated works means the Authority to which Division 2 of Part 10 of the Water Act 1989 applies that has the waterway management district (within the meaning of that Act) which contains the designated land or designated works.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
144
Part 11—Bushfire safety
Division 1—Construction in designated bushfire prone areas
* * * * *
156 Relevant building surveyor must accept bushfire attack level in planning scheme or site assessment for planning permit
(1) Despite anything to the contrary in the BCA, if a building is to be constructed in a designated bushfire prone area and the bushfire attack level for the site is specified in a planning scheme applying to that site, the relevant building surveyor must accept that bushfire attack level for the purpose of determining the construction requirements that are applicable to the building.
(2) Despite anything to the contrary in the BCA, if a building is to be constructed in a designated bushfire prone area and
(a) a planning permit is required for the construction of the building; and
(b) a site assessment for the purpose of determining the bushfire attack level for the site has been considered as part of the application for the planning permit
the relevant building surveyor must accept that site assessment for the purpose of determining the bushfire attack level of the site and the construction requirements that are applicable to the building.
Reg. 155 revoked by S.R. No. 75/2018 reg. 14.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
145
157 Relevant building surveyor must accept bushfire attack level of 12·5
(1) Despite anything to the contrary in the BCA, the relevant building surveyor must accept that the bushfire attack level is 12·5 when determining the construction requirements that apply to a building if—
(a) the building is to be constructed in a designated bushfire prone area; and
(b) the bushfire attack level for the site—
(i) is determined as LOW by the relevant building surveyor; or
(ii) must be accepted by the relevant building surveyor as LOW under regulation 156.
(2) In this regulation building means—
(a) a Class 1, 2 or 3 building; or
(b) a Class 10a building that is associated with a Class 1, 2 or 3 building; or
(c) a deck that is associated with a Class 1, 2 or 3 building; or
(d) a specific use bushfire protected building.Note
Regulation 158 inserts a definition of Specific use bushfire protected building into the BCA Volume One.
158 Specific use bushfire protected buildings—construction requirements
(1) The BCA Volume One applies as if in Schedule 3 after the definition of Spandrel panel there were inserted—
"Specific use bushfire protected building means—
Reg. 158(1) amended by S.R. No. 40/2019 reg. 13.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
146
(a) a Class 9a or 9c building; or
(b) a building from which a school within the meaning of section 1.1.3(1) of the Education and Training Reform Act 2006 is operated; or
(c) a building from which an early childhood centre is operated; or
(d) a Class 4 part of a building associated with a building referred to in paragraphs (a) to (c); or
(e) a Class 10a building or deck associated with a building referred to in paragraphs (a) to (c).".
(2) The BCA Volume One applies as if in Part G5—
(a) in the Application at the foot of clause GP5.1, there were inserted after paragraph (a)—
"(ab) a specific use bushfire protected building; or";
(b) in clause G5.1, there were inserted after paragraph (a)—
"(ab) a specific use bushfire protected building; or";
(c) in clause G5.2, there were inserted after paragraph (a)—
"(ab) a specific use bushfire protected building; or".
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
147
Division 2—Requirements for buildings replacing buildings destroyed in the 2009 bushfires
159 Application of this Division
This Division applies to a Class 1a building on an allotment if—
(a) construction of the building is proposed on the same allotment as a Class 1a building that was destroyed in bushfires between 1 January 2009 and 31 March 2009 (inclusive); and
(b) the allotment is subject to a Bushfire Management Overlay under a planning scheme specified in Schedule 7, which applies to that allotment; and
(c) a planning permit is not required for the construction of the building.
160 Static water supply for fire fighting purposes
(1) This regulation does not apply in relation to an allotment if—
(a) the bushfire attack level of the allotment is determined as LOW or 12·5 in accordance with AS 3959; and
(b) there is a fire hydrant connected to a reticulated water supply within 120 m of the rear of the building.
(2) A static water supply for fire fighting purposes (the static water supply) must be provided on the allotment in accordance with this regulation.
(3) The static water supply must be—
(a) used solely for fire fighting purposes; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
148
(b) able to hold 10 000 litres in onsite static storage located on the allotment; and
(c) located within 60 m of the building; and
(d) situated so as to enable emergency vehicles access to within 4 m of the water supply outlet.
(4) If the static water supply is not able to be readily seen from the building or access driveway, a sign in or to the like effect of the sign illustrated in the diagram at the foot of this subregulation must be located on the allotment so that it is—
(a) easily seen by persons operating emergency vehicles; and
(b) pointing in the direction of the water supply.Regulation 160(4): Sign indicating static water supply location
(5) All below-ground water pipelines relating to the static water supply must be installed to the depths of—
(a) 300 mm if subject to vehicle traffic; or
(b) 75 mm if under a house or concrete slab; or
(c) 225 mm in all other locations.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
149
(6) All fixed above-ground water pipelines and fittings relating to the static water supply, including the water supply, must be constructed of non-corrosive and non-combustible materials, or be protected from the effects of radiant heat and flame.
(7) If the static water supply is above ground, the following additional requirements apply—
(a) there must be at least one pipe fitting no less than 64 mm, 3 thread/25 mm 50 mm nominal bore British Standard Pipe (BSP) round male coupling;
(b) all pipework and valving between the water supply and the water supply outlet must be no less than 50 mm nominal bore;
(c) if the water supply is less than 20 m from the building, each outlet must face away from the building to allow access during emergencies.
161 Access for emergency vehicles
(1) The driveway to the building must be designed to allow an emergency vehicle access in accordance with this regulation.
(2) The driveway to the building must be designed so that—
(a) any curves in the driveway have a minimum inner radius of 10 m; and
(b) the average grade for the driveway is no more than 1 in 7 (144%) (81o) with a maximum of no more than 1 in 5 (20%) (113o) for no more than 50 m; and
(c) any dips in the driveway have no more than a 1 in 8 (125%) (71o) entry and exit angle.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
150
8m 8m
4m
8m 8m
4m 4m
(3) If the driveway from the road to the building or static water supply, including gates, bridges and culverts, is greater than 30 m in length, the driveway must—
(a) be designed, constructed and maintained for a load limit of at least 15 tonnes and be of all-weather construction; and
(b) provide a minimum trafficable width of 35 m, and be clear of encroachments to a height of 4 m from the ground.
(4) If the driveway from the road to the building or static water supply is longer than 100 m, a turning area for emergency vehicles close to the building must be provided for by either—
(a) a turning circle with a minimum radius of 8 m; or
(b) the driveway encircling the building; or
(c) a T head or Y head with a minimum forced surface of each leg being 8 m in length measured from the centre point of the head and 4 m trafficable width.
Note
The following diagrams illustrate aspects of subregulation (4)(c).
Regulation 161—Y head Regulation 161—T head
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
151
(5) If the driveway from the road to the building or static water supply is longer than 200 m, passing bays must be provided every 200 m and must—
(a) be 20 m long; and
(b) have a trafficable width of 6 m.
(6) In this regulation static water supply has the same meaning as in regulation 160.
162 Report and consent required for non-complying static water supply and access
(1) The report and consent of the chief officer must be obtained to an application for a building permit to construct a building to which this Division applies if the requirements of regulation 160 or 161 are not proposed to be complied with.
(2) In reporting on and considering whether to consent to a variation of the requirements of regulation 160 or 161 under subregulation (1), the chief officer must take into account whether a satisfactory degree of bushfire safety will be achieved if the variation is consented to.
Division 3—Private bushfire shelters163 Application of this Division
This Division applies to a Class 10c building associated with a Class 1 building.Note
A Class 10c building is a Private bushfire shelter as defined in the BCA Volume One and the BCA Volume Two.
164 Private bushfire shelter construction requirements
(1) The BCA Volume One applies as if in Schedule 3, in the definition of Private bushfire shelter, for "Class 1a dwelling" there were substituted "Class 1 building".
Reg. 164(1) amended by S.R. No. 40/2019 reg. 14(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
152
(2) The BCA Volume Two applies as if—
(a) in Schedule 3, in the definition of Private bushfire shelter, for "Class 1a dwelling" there were substituted "Class 1 building"; and
(b) in clause O2.7(f), for "Class 1a dwelling" there were substituted "Class 1 building"; and
(c) in performance requirement P2.7.6(e), for "associated dwelling" there were substituted "associated Class 1 building"; and
(d) in the Application at the foot of performance requirement P2.7.6, after "Class 10c building" there were inserted "associated with a Class 1 building".
165 Private bushfire shelter performance requirements—performance solutions
Despite anything to the contrary in the BCA, a relevant building surveyor must not determine that a performance solution complies with performance requirement P2.7.6 of the BCA Volume Two unless the relevant building surveyor—
(a) relies on a certificate under section 238 of the Act by a fire safety engineer, who did not design the building work, that states that the performance solution complies with that performance requirement; or
(b) relies on a determination of the Building Appeals Board under section 160A of the Act that the performance solution complies with that performance requirement; or
Reg. 164(2)(a) amended by S.R. No. 40/2019 reg. 14(2).
Reg. 164(2)(b) amended by S.R. No. 40/2019 reg. 14(3).
Reg. 164(2)(c) amended by S.R. No. 40/2019 reg. 14(4).
Reg. 164(2)(d) amended by S.R. No. 40/2019 reg. 14(5).
Reg. 165 amended by S.R. No. 40/2019 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
153
(c) relies on a certificate of accreditation issued by the Building Regulations Advisory Committee that states that the performance solution complies with that performance requirement; or
(d) relies on a Certificate of Conformity issued by a person or body duly authorised by the Australian Building Codes Board that states that the performance solution complies with that performance requirement.
166 Private bushfire shelter maintenance and operation
(1) The occupier of an allotment containing a Class 10c building associated with a Class 1 building must ensure that the Class 10c building is maintained in a state that enables the Class 10c building to fulfil its purpose.
Penalty:20 penalty units.
(2) The occupier of an allotment containing a Class 10c building associated with a Class 1 building must ensure that any paths of travel from the Class 1 building to the Class 10c building are maintained in an efficient condition and kept readily accessible, functional and clear of obstruction so that access to the Class 10c building is maintained.
Penalty:20 penalty units.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
154
Part 12—Inspections, notices and orders, and register of powers of entry
Division 1—Inspections and directions167 Prescribed mandatory notification stages for
construction or alteration of building
For the purposes of the definition of mandatory notification stage in section 3(1) of the Act, in relation to the construction of a new building or alteration to an existing building, the following stages of building work are prescribed—
(a) before placing a footing;
(b) before pouring an in situ reinforced concrete member that is specified in the relevant building permit by the relevant building surveyor;
(c) the completion of framework;
(d) during the carrying out of building work specified in the relevant building permit by the relevant building surveyor for the purposes of any inspection required by regulation 172;
(e) final, on the completion of all building work.
168 Prescribed mandatory notification stages for demolition or removal of building
For the purposes of the definition of mandatory notification stage in section 3(1) of the Act, in relation to the demolition or removal of a building, the following stages of building work are prescribed—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
155
(a) the completion of any precautions required to be taken under regulation 116 or 117;
(b) final, on the completion of all demolition or removal work.
169 Prescribed mandatory notification stages for construction of swimming pool or spa
For the purposes of the definition of mandatory notification stage in section 3(1) of the Act, in relation to the construction of a swimming pool or spa, the following stages of building work are prescribed—
(a) the completion of any excavation related to the installation of the swimming pool or spa;
(b) before pouring any footing or in situ reinforced concrete member that is specified in the relevant building permit by the relevant building surveyor;
(c) the completion of any precautions required to be taken under regulation 116;
(d) final, on the completion of the swimming pool or spa and related safety barrier.
170 Omission of irrelevant mandatory notification stage
The relevant building surveyor may omit a mandatory notification stage set out in regulation 167 for building work if that stage is not relevant to the building work.
171 Building permit must specify mandatory notification stages
The relevant building surveyor must specify the mandatory notification stages for building work determined under regulations 167, 168, 169 and 170 in the building permit issued for that building work.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
156
172 Building surveyor must cause fire and smoke resisting building elements to be inspected
(1) The relevant building surveyor must cause to be inspected the building work relating to the following in each storey of a Class 2, 3, or 4 building—
(a) any building element that is lightweight construction and that is required to resist the spread of fire in at least one sole-occupancy unit;
(b) one of each stair shaft, lift shaft or service shaft that is lightweight construction and that is required to resist the spread of fire;
(c) the components of any building element referred to in paragraph (a) or (b);
(d) the junctions of any building element referred to in paragraph (a) or (b) with other building elements.
(2) The relevant building surveyor must cause to be inspected at least one of each type of fire protection method for each type of service penetration to any building element that is required to resist the spread of fire or smoke on each storey of a Class 2, 3, 4, 9a or 9c building.
(3) An inspection for the purposes of this regulation must be carried out when the building element is accessible and able to be clearly viewed.
(4) This regulation does not apply in relation to building work carried out under a permit issued before 2 June 2018.
(5) In this regulation lightweight construction means construction which incorporates or comprises sheet or board material, plaster, render, sprayed application, or other material similarly susceptible to damage by impact, pressure or abrasion.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
157
173 Record of inspection of building work
For the purposes of section 35A(1) of the Act, a record of an inspection under section 34 or 35 of the Act must contain the following information—
(a) the date and time of the inspection;
(b) the purpose of the inspection;
(c) the building permit number of the permit relating to the building work;
(d) the address of the building or land on which the building work is being carried out;
(e) the name and registration number of the registered building practitioner who carried out the inspection;
(f) the stage of the building work inspected (if applicable);
(g) the outcome of the inspection.
174 Prescribed persons carrying out inspections
For the purposes of section 35B(b) of the Act, the prescribed classes of inspection and the prescribed classes of person are as follows—
(a) in the case of an inspection of building work relating to a structural, sewerage, water or drainage matter—a person registered under Part 11 of the Act in the category of engineer, class of engineer (civil);
(b) in the case of an inspection of building work relating to a mechanical matter including hydraulic services within a building—a person registered under Part 11 of the Act in the category of engineer, class of engineer (mechanical);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
158
(c) in the case of an inspection of building work relating to an electrical matter—a person registered under Part 11 of the Act in the category of engineer, class of engineer (electrical);
(d) in the case of an inspection of building work relating to a fire safety matter—a person registered under Part 11 of the Act in the category of engineer, class of engineer (fire safety).
* * * * *
175 Relevant building surveyor to keep and make available directions to fix building work
The relevant building surveyor must—
(a) keep a copy of each written direction to fix building work that the relevant building surveyor gives under Division 2 of Part 4 of the Act until the earliest of the following—
(i) an occupancy permit or certificate of final inspection relating to the building work is issued;
(ii) the direction is revoked;
(iii) the direction is quashed or set aside by the Building Appeals Board; and
(b) make copies of directions kept under paragraph (a) available for inspection by any person during office hours.
Reg. 174(d) amended by S.R. No. 40/2019 reg. 16(1).
Reg. 174(e)(f) revoked by S.R. No. 40/2019 reg. 16(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
159
176 Person to whom authorised person must give documents under section 37J of the Act
For the purposes of section 37J of the Act, the relevant building surveyor is a prescribed person to whom an authorised person must give the documents set out in that section.
Division 2—Notices and orders177 Emergency orders
For the purposes of section 105(1) of the Act, an emergency order made under section 102 of the Act must include—
(a) the location of the building, land or place of public entertainment to which the order applies; and
(b) the name of the owner, occupier or builder to whom or which the order is directed; and
(c) the reason or reasons why the order was made; and
(d) the period within which the order must be complied with; and
(e) the date of any inspection of the building, land or place of public entertainment carried out by the municipal building surveyor or relied on by the municipal building surveyor when deciding whether to make the order (if applicable); and
(f) the name and qualifications of any person other than the municipal building surveyor who carries out an inspection referred to in paragraph (e); and
(g) the date of making of the order; and
(h) the name and address of the municipal building surveyor.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
160
178 Form of emergency orders
An emergency order made under section 102 of the Act may be in the form of Form 10.
179 Building notices
For the purposes of section 108(2) of the Act, a building notice served under section 106 of the Act must include—
(a) the location of the building or place of public entertainment to which the notice applies; and
(b) the name and address of the owner to whom or which the notice is directed; and
(c) the reason or reasons why the notice was served; and
(d) the date of any inspection of the building, land or place of public entertainment carried out or relied on by the relevant building surveyor when deciding whether to serve the notice (if applicable); and
(e) the name and qualifications of any person other than the relevant building surveyor who carries out an inspection referred to in paragraph (d); and
(f) the date of making of the notice; and
(g) the name and address of the relevant building surveyor.
180 Form of building notice
A building notice served under section 106 of the Act may be in the form of Form 11.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
161
181 Building orders
For the purposes of section 114(1)(c) of the Act, a building order made under section 111, 112 or 113 of the Act must include—
(a) the location of the building, land or place of public entertainment to which the order applies; and
(b) the name and address of the person to whom the order is directed; and
(c) the reason or reasons why the order was made; and
(d) the date of any inspection of the building, land or place of public entertainment carried out or relied on by the relevant building surveyor when deciding whether to make the order (if applicable); and
(e) the name and qualifications of any person other than the relevant building surveyor who carries out an inspection referred to in paragraph (d); and
(f) the date of making of the order; and
(g) the name and address of the relevant building surveyor.
182 Form of building orders
(1) A building order made under section 111 may be in the form of Form 12.
(2) A building order made under section 112 of the Act may be in the form of Form 13.
(3) A building order made under section 113 of the Act may be in the form of Form 14.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
162
182A Additional information in order or notice served in accordance with section 236(4A) of the Act
For the purposes of section 236(4B) of the Act, the additional information to be included in the order or notice is—
(a) that the order or notice has been served in accordance with section 236(4A) of the Act; and
(b) a prominent warning that it is an offence under section 236(7) of the Act for a person to remove or deface the order or notice without the prior consent of the relevant building surveyor, the relevant council or the Authority; and
(c) the penalty for committing an offence under section 236(7) of the Act.
Division 3—Powers of entry183 Register of exercise of powers of entry
(1) For the purposes of section 230(1), (2) or (3) of the Act, the register of the exercise of powers of entry must include the following information in relation to each power of entry exercised under Subdivision 5 of Division 2 of Part 13 of the Act—
(a) the power of entry exercised;
(b) the date and time of the entry;
(c) the purpose of the entry;
(d) the address of the building or land entered;
(e) the names of the persons and registration numbers of any registered building practitioners involved in the exercise of the power of entry;
Reg. 182A inserted by S.R. No. 180/2018 reg. 8.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
163
(f) a record of any acknowledgement of consent given under section 228G of the Act;
(g) whether consent was withdrawn by the occupier of the building or land at any time;
(h) a description of things done while in or on the building or land;
(i) whether the entry involved the use of a warrant;
(j) a record of any receipt required to be given under section 229A of the Act for a thing seized;
(k) whether a police officer provided assistance under section 229H of the Act;
(l) the time of departure.
(2) For the purposes of section 230(4) of the Act, the register of the exercise of powers of entry must include the following information—
(a) in the case of an entry made under section 228D of the Act, the following—
(i) the date and time of the entry;
(ii) the purpose of the entry;
(iii) the address of the building or land entered;
(iv) the names of the persons and registration numbers of any registered building practitioners involved in the exercise of the power of entry;
(b) in the case of an entry made under section 228J of the Act, the following—
(i) the date and time of the entry;
(ii) the purpose of the entry;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
164
(iii) the address of the building or land entered;
(iv) the names of the persons and registration numbers of any registered building practitioners involved in the exercise of the power of entry;
(v) a description of things done while in or on the building or land;
(vi) a record of any receipt required to be given under section 229A of the Act for a thing seized;
(vii) whether a police officer provided assistance under section 229H of the Act;
(viii) the time of departure.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
165
Part 13—Occupancy permits and certificates of final inspection
Division 1—General184 Application of Part
Subject to these Regulations, this Part applies to all buildings and places of public entertainment.
185 Exemptions from occupancy permit
(1) For the purposes of section 21(2)(c) of the Act, an occupancy permit is not required—
(a) in respect of building work relating to—
(i) a Class 10 building; or
(ii) an alteration to a Class 1a building; or
(iii) an alteration within a sole-occupancy unit in a Class 2 or 3 building; or
(b) in respect of building work specified in column 2 of the Table in Schedule 3.
(2) A building specified in column 2 of the Table in Schedule 3 is exempted from the requirement for an occupancy permit in relation to building work carried out on that building.
Division 2—Applications for occupancy permit186 Application for occupancy permit
(1) An application for an occupancy permit must be in the form of Form 15.
(2) For the purposes of clause 1(a) and (b) of Schedule 2 to the Act—
(a) the information to be contained in the application is the information that must be set out in Form 15; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
166
(b) the application must be accompanied by the following documents—
(i) any compliance certificate within the meaning of Part 12A of the Act given for plumbing work carried out in conjunction with the building work in the building to which the application applies;
(ii) any certificate of compliance within the meaning of section 3 of the Electricity Safety Act 1998 for electrical work carried out in conjunction with the building work in the building or place of public entertainment to which the application applies.
187 Reporting authorities for occupancy permit
(1) The report and consent of the chief officer must be obtained in relation to an application for an occupancy permit—
(a) if the chief officer was a reporting authority in relation to the application for the building permit which required the issue of the occupancy permit; or
(b) relating to a building or building work involving the transmission signal of alarms required, under these Regulations or any previous corresponding regulations, to be connected to a fire station or other alarm monitoring service.
(2) Subject to subregulation (3), the report and consent of the relevant council must be obtained in relation to an application for an occupancy permit relating to—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
167
(a) the installation or alteration of a septic tank system; or
(b) the construction of a building over an existing septic tank system.
(3) The report and consent of the relevant council need not be obtained in relation to an application for an occupancy permit referred to in subregulation (2) if a certificate approving the use of the septic tank system the subject of the application has been issued under section 53MB of the Environment Protection Act 1970.
188 Time limits for application to be given to reporting authority
For the purposes of clause 4(2) of Schedule 2 to the Act, the prescribed time within which the relevant building surveyor must give a copy of an application for an occupancy permit to each reporting authority required to report on or consent to the application is—
(a) in the case of an application relating to a Class 1 building, 3 business days after the relevant building surveyor receives the application; and
(b) in any other case, 5 business days after the relevant building surveyor receives the application.
189 Time limits relating to the report or consent of reporting authorities
For the purposes of clause 6(1), (2) and (3) of Schedule 2 to the Act, the prescribed time is—
(a) in the case of an application relating to a Class 1 building, within 5 business days after a reporting authority is given a copy of an application for an occupancy permit by the relevant building surveyor; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
168
(b) in any other case, within 10 business days after a reporting authority is given a copy of an application for an occupancy permit by the relevant building surveyor.
190 Time within which relevant building surveyor must decide application for occupancy permit
(1) For the purposes of sections 43 and 56 of the Act, the relevant building surveyor must decide an application for an occupancy permit—
(a) in the case of a Class 1 building, within 2 business days after the relevant day; and
(b) in any other case, within 5 business days after the relevant day.
(2) In this regulation the relevant day means the earlier of the following days—
(a) the day on which all reports and consents required to be supplied by reporting authorities in relation to the application are received by the relevant building surveyor;
(b) the day by which the reports and consents referred to in paragraph (a) must be supplied to the relevant building surveyor.
191 Time within which municipal building surveyor must decide application to amend occupancy permit
The municipal building surveyor must decide an application to amend an occupancy permit under section 70(1)(a) of the Act—
(a) in the case of a Class 1 building, within 7 business days after the day the application is received by the municipal building surveyor; or
(b) in any other case, within 14 business days after the day the application is received by the municipal building surveyor.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
169
Division 3—Occupancy permits192 Form of occupancy permit
An occupancy permit issued under Part 5 of the Act must be in the form of Form 16.
193 Relevant building surveyor to provide copy of permit
The relevant building surveyor must give a copy of an occupancy permit to the applicant for the occupancy permit within 7 days after issuing the permit.
194 Occupancy permit must specify essential safety measures and related requirements
(1) The relevant building surveyor or the Authority (as the case requires) must ensure that an occupancy permit (including that permit as amended from time to time) issued in relationto a building or place of public entertainment specifies—
(a) all essential safety measures required to be provided for the building or place as part of the building work carried out under the building permit requiring the occupancy permit; and
(b) the level of performance, determined by the relevant building surveyor or the Authority (as the case requires), that each essential safety measure must achieve to fulfil its purpose; and
(c) the frequency and type of inspection, testing and maintenance required for each essential safety measure determined by the relevant building surveyor or the Authority (as the case requires).
Reg. 194(1)(a) amended by S.R. No. 40/2019 reg. 17.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
170
(2) In determining matters in subregulation (1)(b) and (c), the relevant building surveyor or the Authority must specify the provision of the building regulations with which the installation and operation of the essential safety measure must comply and which sets out the frequency and type of inspection, testing and maintenance required for the essential safety measure.
(3) In this regulation—
building means—
(a) a Class 1b, 2, 3, 5, 6, 7, 8 or 9 building; and
(b) a Class 4 part of a building;
provision of the building regulations has the same meaning as in section 160 of the Act.
(4) This regulation does not apply in relation to a smoke alarm installed in a sole-occupancy unit in a Class 1b or 2 building or a Class 4 part of a building.
195 Condition on occupancy permit
(1) It is a condition of an occupancy permit that each essential safety measure specified in an occupancy permit under regulation 194 must—
(a) be inspected and tested as specified in the occupancy permit; and
(b) be maintained as specified in the occupancy permit so that each essential safety measure achieves the level of performance specified in the occupancy permit.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
171
(2) If a maintenance determination is made under regulation 215 in relation to a building or place of public entertainment and an occupancy permit applies to the building or place of public entertainment, it is a condition of the occupancy permit that each essential safety measure specified in the maintenance determination must—
(a) be inspected and tested as specified in the maintenance determination; and
(b) be maintained as specified in the maintenance determination so that the essential safety measure achieves the level of performance specified in the maintenance determination.
196 Compliance with AS 1851—2012 taken to be compliance with earlier standards
(1) This regulation applies in relation to an occupancy permit which specifies the frequency and type of inspection, testing and maintenance required for an essential safety measure in a building or place of public entertainment.
(2) Despite sections 40 and 51 of the Act, if an occupancy permit specifies that the essential safety measure must be maintained in accordance with AS 1851—2005 Maintenance of fire protection systems and equipment published on 5 September 2005, as in force and as issued from time to time, or an equivalent standard published before 5 September 2005, compliance with AS 1851—2012 is taken to be compliance with the frequency and type of inspection, testing and maintenance requirements specified in the occupancy permit (if applicable).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
172
(3) If the owner of the building or place of public entertainment, in accordance with subregulation (2), complies with AS 1851—2012 in relation to the essential safety measure, instead of the frequency and type of inspection, testing and maintenance required for the essential safety measure specified in the occupancy permit, the owner must continue to comply with AS 1851—2012 in relation to the essential safety measure.
Division 4—Display and inspection requirements for occupancy permits
197 Display of occupancy permit at approved location
(1) This regulation applies to—
(a) Class 1b, 2, 3, 5, 6, 7 and 8 buildings constructed on or after 1 July 1994; and
(b) Class 9 buildings; and
(c) places of public entertainment.
(2) An owner of a building or place of public entertainment must ensure that a copy of any current occupancy permit in relation to that building or place is displayed and kept displayed at an approved location within the building or place.
Penalty:10 penalty units.
198 Approved location for display of permit
(1) Subject to subregulation (3), the relevant building surveyor must ensure that a location approved within a building for the purposes of regulation 197 is in a prominent position and is accessible to the occupants of the building.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
173
(2) The relevant building surveyor must ensure that a location approved within a place of public entertainment for the purposes of regulation 197 is in a prominent position and is accessible to the public.
(3) In a building of a class of building referred to in regulation 281, the location approved for the purposes of regulation 197 may be in an area to which access is available only with the authorisation of the owner of the building.
199 Owner to make permit available for inspection
(1) This regulation applies to—
(a) Class 1b, 2, 3, 5, 6, 7 and 8 buildings constructed on or after 1 July 1994; and
(b) Class 9 buildings; and
(c) places of public entertainment.
(2) An owner of a building or place of public entertainment must ensure that a copy of any current occupancy permit is available at that building or place for inspection by the municipal building surveyor or chief officer at any time on request.
Penalty:10 penalty units.
Division 5—Certificates of final inspection200 Form of certificate of final inspection
A certificate of final inspection must be in the form of Form 17.
201 Relevant building surveyor to notify chief officer of issue of certificates of final inspection
(1) If a certificate of final inspection is issued in relation to a building or building work involving the transmission signal of an alarm required, under these Regulations or any previous
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
174
corresponding regulations, to be connected to a fire station or other alarm monitoring service, the relevant building surveyor must notify the chief officer within 10 days after issuing the certificate that—
(a) the certificate has been issued; and
(b) the required connection has been made.
(2) If a certificate of final inspection is issued and the chief officer was a reporting authority in relation to the application for the relevant building permit, the relevant building surveyor must notify the chief officer of the issue of the certificate within 10 days after issuing the certificate.
Division 6—Records202 Keeping of occupancy permit records
(1) For the purposes of section 75 of the Act, a council must keep the documents relating to occupancy permits in any manner specified by the Keeper of Public Records until—
(a) the building in relation to which the permit is given is demolished or removed from the allotment; or
(b) the occupancy permit is cancelled.
(2) For the purposes of section 75 of the Act, a council must keep documents relating to a temporary approval for 3 years after the earlier of the following—
(a) the end of the period for which the temporary approval applies;
(b) the temporary approval is cancelled.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
175
203 Documents to be given to council
The following documents are prescribed for the purposes of section 73(1A) of the Act—
(a) a notice given to the relevant building surveyor under section 25A(2) of the Act;
(b) a notice given to the relevant building surveyor under section 25AB(2) of the Act;
* * * * *
(d) a record of inspection of building work made under section 35A(1) of the Act;
(e) a determination made by the relevant building surveyor under regulation 111(3);
(f) a notice served on the relevant building surveyor under section 84(1) of the Act;
(g) a notice given to the relevant building surveyor under section 85(1) of the Act;
(h) a determination of the relevant building surveyor under section 87(1) of the Act;
(i) a determination or order of the Building Appeals Board;
(j) a determination of the relevant building surveyor that a performance solution complies with a performance requirement of the BCA together with any computations or reports relied on by the relevant building surveyor in making the determination;
Reg. 203(a) amended by S.R. No. 75/2018 reg. 13(1).
Reg. 203(b) amended by S.R. No. 75/2018 reg. 13(2).
Reg. 203(c) revoked by S.R. No. 75/2018 reg. 13(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
176
(k) a determination of the municipal building surveyor or a private building surveyor exercising the functions of a municipal building surveyor under regulation 64(1);
(l) a document setting out any requirement of the relevant building surveyor under regulation 116 to take precautions to protect the safety of the public;
(m) any test carried out in accordance with regulation 120(1);
(n) a complete record of pile-driving operations under regulation 127;
(o) a report and consent of a reporting authority referred to in regulation 187;
(p) any exemption from, or consent to partial compliance with, certain requirements of these Regulations relating to a building or building work that has been given by the municipal building surveyor or a private building surveyor exercising the functions of a municipal building surveyor under regulation 229(2) or 231(2) or by the relevant building surveyor under regulation 233(3) or 234(2);
(q) any document required by the relevant building surveyor under clause 2(1) of Schedule 2 to the Act.
204 Prescribed time to give council other documents
For the purposes of section 73(1A) of the Act, the prescribed time is 7 days after the issue or amendment of the occupancy permit or temporary approval (as the case requires).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
177
205 Information to be supplied to council
In addition to the requirements of section 73 of the Act, the relevant building surveyor must within 7 days—
(a) after issuing a certificate of final inspection, give to the relevant council a copy of the certificate; and
(b) after issuing an occupancy permit or a certificate of final inspection, give to the relevant council the approved dates of the inspections carried out of the mandatory notification stages of building work carried out on the building or land.
Penalty: 10 penalty units.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
178
Part 14—Places of public entertainment206 Prescribed classes of buildings or places
(1) For the purposes of the definition of place of public entertainment in section 3(1) of the Act—
(a) the following are prescribed classes of buildings—
(i) Class 9b buildings with an area greater than 500 m2;
(ii) prescribed temporary structures; and
(b) places with an area greater than 500 m2 are a prescribed class of places unless—
(i) the place is used for the purposes of conducting an event or activity which is organised and controlled by a community-based organisation; and
(ii) the number of persons in the place at any one time during the event or activity does not exceed 5000.
Example
A place used for a public market conducted by a Rotary club would not fall within the class of places prescribed under paragraph (b) if the number of persons in the place at any one time did not exceed 5000.
(2) For the purposes of this regulation community-based organisation means a body, whether or not it is a corporate body, that—
(a) is not established primarily for the purposes of profit or gain; and
(b) does not distribute any part of any profit or gain made in the conduct of its activities to any member of the organisation; and
Example to reg. 206(1)(b) amended by S.R. No. 180/2018 reg. 9.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
179
(c) operates in a community wholly for—
(i) a philanthropic or benevolent purpose, including the promotion of art, culture, science, religion, education or charity; or
(ii) any sporting or recreational purpose, including the benefiting of any sporting or recreational club or association.
207 Prescribed temporary structures
For the purposes of the definition of prescribed temporary structure in section 3(1) of the Act, the following are prescribed classes of temporary structures, if those structures do not form part of a building other than a temporary structure or temporary building—
(a) tents, marquees or booths with a floor area greater than 100 m2;
(b) seating stands for more than 20 persons;
(c) stages or platforms (including sky borders and stage wings) exceeding 150 m2 in floor area;
(d) prefabricated buildings with an area exceeding 100 m2 and that are not placed directly on the ground surface.
208 Exemption from permit for temporary structures
(1) For the purposes of section 16(6) of the Act, building work is exempted to the extent it relates to a temporary structure prescribed by regulation 207.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
180
(2) A temporary structure prescribed by regulation 207 is exempt from these Regulations, other than regulations 210 and 212.
Note
If a prescribed temporary structure is used for the purpose of providing public entertainment it must have an occupancy permit under Division 2 of Part 5 of the Act and meet the requirements of the Authority under that permit.
209 Prescribed place of public entertainment
For the purposes of section 53(2) of the Act, the sportsgrounds and spectator stands known as Kardinia Park, Geelong, is a prescribed place of public entertainment.
210 Conditions on occupancy permits
Without limiting the conditions to which an occupancy permit may be subject, an occupancy permit for a place of public entertainment may be issued subject to conditions relating to—
(a) the engagement of safety officers tobe in attendance at the place of public entertainment to provide for the safety of the public; and
(b) the safety training qualifications that must be held by any person engaged as a safety officer; and
(c) the responsibilities of a safety officer, including—
(i) the operation of fire safety elements, equipment and systems; and
(ii) the establishment and operation of evacuation procedures; and
(iii) the safety of barriers and exits; and
(iv) the control of the use of naked flame in theatrical productions; and
Reg. 209 amended by S.R. No. 40/2019 reg. 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
181
(d) the exclusion of the public from unsafe areas; and
(e) the keeping, testing and storage of flammable material or explosive items and equipment in a safe manner, to the extent that this is not required by any other Act or regulations; and
(f) the ignition of fireworks and the discharge of pistols or other shooting devices in a safe and responsible manner, to the extent that this is not required by any other Act or regulations; and
(g) the location and designation of passageways and exits; and
(h) the availability of public toilet facilities and the condition of those facilities.
211 Safety officer qualifications
(1) For the purposes of regulation 210(b), the Authority or the chief officer may publish a list of safety training qualifications that may be held by a person engaged as a safety officer on the website of the Authority or the chief officer.
(2) The relevant building surveyor must have regard to the qualifications published under subregulation (1) when determining the safety training qualifications that must be held by a person engaged as a safety officer for the purposes of complying with a condition imposed under regulation 210.
212 Structural design of prescribed temporary structures
Prescribed temporary structures must be designed in accordance with engineering principles to provide for their structural safety and the safety of the public and other persons using them.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
182
Part 15—Maintenance of buildings and places of public entertainment
Division 1—Maintenance of essential safety measures
Subdivision 1—General213 Application of this Division
(1) Subject to subregulation (2), this Division applies to—
(a) a Class 1b, 2, 3, 5, 6, 7, 8 or 9 building; and
(b) a Class 4 part of a building; and
(c) a place of public entertainment.
(2) This Division does not apply to a smoke alarm installed in a sole-occupancy unit in a Class 1b or 2 building or a Class 4 part of a building.
214 Definitions in this Division
In this Division—
essential safety measure means—
(a) a safety measure specified in column 2 of the table in each Part of Schedule 8 that is required by or under the Act or these Regulations to be provided in relation to a building or place of public entertainment; or
(b) any other item that is required by or under the Act or these Regulations to be provided in relation to a building or place of public entertainment for the safety of persons in the event of fire and that is designated by the relevant
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
183
building surveyor as an essential safety measure; or
(c) any other item that is an essential safety measure within the meaning of regulation 1202 of the Building Interim Regulations 2017 as in force immediately before its revocation; or
(d) any other measure (including an item of equipment, form of construction or safety strategy) required for the safety of persons using a building or place of public entertainment required to be provided in relation to that building or place by or under the Act, or any previous corresponding Act, before 1 July 1994;
maintenance determination means—
(a) a determination made by a relevant building surveyor under regulation 215; or
(b) a maintenance determination within the meaning of regulation 1202 of the Building Interim Regulations 2017 as in force immediately before its revocation;
maintenance schedule means—
(a) a maintenance schedule prepared by the municipal building surveyor or a private building surveyor that complies with regulation 222; or
(b) a maintenance schedule within the meaning of regulation 1202 of the Building Interim Regulations 2017 as in force immediately before its revocation.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
184
Subdivision 2—Maintenance determinations215 Maintenance determinations for essential safety
measures in buildings and places of public entertainment
(1) This regulation applies if an essential safety measure is required to be provided or altered in a building or place of public entertainment by—
(a) a building permit that does not require an occupancy permit; or
(b) an emergency order or a building order under Part 8 of the Act.
(2) The relevant building surveyor must determine and specify in the determination the following—
(a) the essential safety measure that is the subject of the determination;
(b) the level of performance that the essential safety measure must achieve to fulfil its purpose;
(c) the frequency and type of inspection, testing and maintenance required for the essential safety measure.
(3) A determination under subregulation (2) must—
(a) be in writing in the form approved by the Authority; and
(b) be given to the owner of the building or place of public entertainment—
(i) with the certificate of final inspection, if the essential safety measure is required under a building permit; or
(ii) without delay after it is made, if the essential safety measure is required under an emergency order or a building order under Part 8 of the Act; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
185
(c) be given to the relevant council with a report under section 120(2)(a) of the Act, if the essential safety measure is required under an emergency order or a building order under Part 8 of the Act.
216 Owner must comply with maintenance determination
(1) This regulation applies if a maintenance determination is issued in relation to a building or place of public entertainment to which an occupancy permit does not apply.
(2) The owner of the building or place of public entertainment must ensure that each essential safety measure that is the subject of a maintenance determination in relation to that building or place—
(a) performs at the level to fulfil its purpose specified in the maintenance determination; and
(b) is inspected, tested and maintained in accordance with the requirements specified in the maintenance determination.
Penalty: 20 penalty units.
217 Compliance with AS 1851—2012 taken to be compliance with earlier standards
(1) This regulation applies in relation to a maintenance determination that specifies the frequency and type of inspection, testing and maintenance required for an essential safety measure in a building or place of public entertainment.
(2) Despite regulation 216, if a maintenance determination specifies that the essential safety measure must be maintained in accordance with AS 1851—2005 Maintenance of fire protection
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
186
systems and equipment published on 5 September 2005, as in force and as issued from time to time, or an equivalent standard published before 5 September 2005, compliance with AS 1851—2012 is taken to be compliance with the frequency and type of inspection, testing and maintenance requirements specified in the maintenance determination (if applicable).
(3) If the owner of the building or place of public entertainment, in accordance with subregulation (2), complies with AS 1851—2012 in relation to the essential safety measure, instead of the frequency and type of inspection, testing and maintenance required for the essential safety measure specified in the maintenance determination, the owner must continue to comply with AS 1851—2012 in relation to the essential safety measure.
Subdivision 3—Maintenance schedules218 Relevant building surveyor must prepare or update
maintenance schedule for an existing building or place of public entertainment
(1) This regulation applies if an essential safety measure is specified in relation to a building or place of public entertainment in—
(a) an occupancy permit under regulation 194; or
(b) a maintenance determination under regulation 215.
(2) The relevant building surveyor must prepare or update a maintenance schedule so that it complies with regulation 222 in relation to the building or place of public entertainment.
Reg. 218(1) amended by S.R. No. 180/2018 reg. 10(1).
Reg. 218(1)(a) substituted by S.R. No. 180/2018 reg. 10(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
187
(3) The owner of a building or place of public entertainment must provide to the relevant building surveyor who must prepare or update a maintenance schedule under subregulation (2) relating to that building or place all the documents referred to in regulation 225 that relate to essential safety measures in the building or place within 7 days after a request of the relevant building surveyor to provide those documents.
Penalty: 10 penalty units.
219 Owner of building or place of public entertainment may apply for maintenance schedule
(1) The owner of a building or place of public entertainment may apply to the municipal building surveyor or a private building surveyor to request the municipal building surveyor or private building surveyor to prepare a maintenance schedule that complies with regulation 222 in relation to the building or place.
(2) If the municipal building surveyor or a private building surveyor agrees to prepare a maintenance schedule that complies with regulation 222 in relation to a building or place of public entertainment, the owner of the building or place must provide to the municipal building surveyor or private building surveyor all documents referred to in regulation 225 relating to essential safety measures for the building or place.
220 Building surveyor may prepare maintenance schedule
The municipal building surveyor or a private building surveyor may prepare a maintenance schedule in relation to a building or place of public entertainment that complies with regulation 222 if the owner of the building or place has applied in accordance with
Reg. 219(2) amended by S.R. No. 40/2019 reg. 19.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
188
regulation 219 to the municipal building surveyor or private building surveyor for such a maintenance schedule to be prepared.
221 Building surveyor must give owner copy of maintenance schedule
The municipal building surveyor or private building surveyor who prepares or updates a maintenance schedule in relation to a building or place of public entertainment under regulation 218 or 220 must give a copy of the maintenance schedule to the owner of the building or place without delay.
222 Maintenance schedules
(1) For the purposes of regulation 218, a maintenance schedule must list all essential safety measures specified in an occupancy permit or a maintenance determination relating to a building or a place of public entertainment and the maintenance requirements for those essential safety measures.
(2) For the purposes of regulation 220, a maintenance schedule must list—
(a) all essential safety measures required to be provided for a building or place of public entertainment constructed before 1 July 1994 by or under the Act or these Regulations or any previous corresponding Act or regulations; and
(b) all essential safety measures specified in an occupancy permit or maintenance determination that relates to a building or place of public entertainment and the maintenance requirements specified in the occupancy permit or maintenance determination.
Reg. 222(1) substituted by S.R. No. 180/2018 reg. 11.
Reg. 222(2) substituted by S.R. No. 40/2019 reg. 20.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
189
(3) The essential safety measures and related maintenance requirements must be listed in chronological order according to the date on which each essential safety measure was required to be provided by or under the Act or these Regulations or any previous corresponding Act or regulations.
(4) A maintenance schedule under this regulation must be prepared in a form approved by the Authority.
(5) In this regulation maintenance requirements in relation to an essential safety measure consist of—
(a) the level of performance that the essential safety measure must achieve to fulfil its purpose; and
(b) the frequency and type of inspection, testing and maintenance required for the essential safety measure.
Subdivision 4—Reporting and records223 Owner must prepare annual essential safety
measures report
(1) The owner of a building or place of public entertainment in respect of which an essential safety measure is required to be provided for the building or place by an occupancy permit or a maintenance determination must ensure that an annual essential safety measures report is prepared in accordance with regulation 224 within 28 days before each anniversary of the relevant anniversary date.
Penalty:20 penalty units.
(2) The owner of a building or place of public entertainment that was constructed before 1 July 1994, in respect of which an essential safety
Reg. 223(1) amended by S.R. No. 40/2019 reg. 21(1).
Reg. 223(2) amended by S.R. No. 40/2019 reg. 21(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
190
measure was required to be provided for the building or place by the Act or these Regulations or any previous corresponding Act or regulations, must ensure that an annual essential safety measures report is prepared in accordance with regulation 224 within 28 days before 13 June 2018 and each anniversary of that date.
Penalty:20 penalty units.
(3) Subregulation (2) does not apply in relation to any essential safety measure in respect of which an annual report is required to be prepared under subregulation (1).
(4) In this regulation—
anniversary date means the earlier of the following dates—
(a) the date of issue of the first occupancy permit or amendment to an occupancy permit that required that an essential safety measure be provided for the building or place of public entertainment;
(b) the date of making of the first maintenance determination which required that an essential safety measure be provided for the building or place of public entertainment.
224 Contents and form of annual essential safety measures report
For the purposes of regulation 223, the annual essential safety measures report for a building or place of public entertainment must—
(a) be in a form approved by the Authority; and
(b) be signed by the owner of the building or place; and
Reg. 223(4) def. of anniversary date amended by S.R. No. 40/2019 reg. 21(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
191
(c) state the address of the building or place; and
(d) include the details of any inspection report made under section 227E of the Act in relation to an essential safety measure for the building or place; and
(e) if applicable, state that the owner of the building or place, in accordance with regulation 196 or 217, is complying with AS 1851—2012 in relation to an essential safety measure required to be provided for the building or place, instead of the frequency and type of inspection, testing and maintenance required for the essential safety measure specified in the relevant occupancy permit or the maintenance determination (as the case requires); and
(f) state that the owner has taken all reasonable steps to ensure that each essential safety measure for the building or place—
(i) is operating and has been maintained in a state that enables the essential safety measure to fulfil its purpose; and
(ii) has been inspected, tested and maintained in accordance with the Act and these Regulations.
225 Records relating to essential safety measures must be made available
An owner of a building or place of public entertainment must ensure that the following documents relating to the building or place are available for inspection at that building or place within 24 hours after a request by the municipal building surveyor or chief officer to inspect the documents—
Reg. 224(d) amended by S.R. No. 40/2019 reg. 22(1).
Reg. 224(e) amended by S.R. No. 40/2019 reg. 22(2).
Reg. 224(f) amended by S.R. No. 40/2019 reg. 22(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
192
(a) all annual essential safety measures reports prepared under these Regulations, or any previous corresponding regulations, within 10 years before the request; and
(b) all maintenance schedules in relation to the essential safety measures for the building or place; and
(c) all maintenance determinations requiring an essential safety measure to be provided for the building or place; and
(d) the records of all inspections, testing and maintenance (including repairs) of any essential safety measure for the building or place.
Penalty: 20 penalty units.
226 Maintenance responsibility of owner of building or place of public entertainment
(1) The owner of a building or place of public entertainment must ensure that any essential safety measure required to be provided in relation to the building or place by or under the Act or any previous corresponding Act is maintained in a state which enables the essential safety measure to fulfil its purpose.
Penalty: 20 penalty units.
(2) An owner of a building or place of public entertainment does not commit an offence under subregulation (1) if—
(a) the essential safety measure is subject to a maintenance determination; or
(b) the building or place is subject to an occupancy permit which imposes a condition on the occupier to maintain the essential
Reg. 225(b) amended by S.R. No. 40/2019 reg. 23.
Reg. 225(c) amended by S.R. No. 40/2019 reg. 23.
Reg. 225(d) amended by S.R. No. 40/2019 reg. 23.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
193
safety measure and the owner occupies the building or place.
227 Essential safety measures not to be removed from approved locations
The owner of a building or place of public entertainment must ensure that any essential safety measure required to be provided in relation to the building or place by or under this Act or any previous corresponding Act is not removed from its approved location except for the purpose of inspection or testing of, or the carrying out of maintenance on, that essential safety measure.
Penalty:20 penalty units.
Division 2—Maintenance of exits and paths of travel relating to buildings or places of
public entertainment228 Maintenance of exits and paths of travel by
occupiers of buildings or places of public entertainment
The occupier of a Class 1b, 2, 3, 5, 6, 7, 8 or 9 building or place of public entertainment must ensure that—
(a) all exits in the building or place; and
(b) any paths of travel to exits in the building or place; and
(c) any paths of travel on the allotment from exits in the building or place to a road—
required to be provided in relation to that building or place are kept readily accessible, functional and clear of obstructions so that egress from the building or place is maintained.
Penalty: 20 penalty units.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
194
Part 16—Existing buildings
Division 1—Change of use of existing buildings229 Change of use
(1) A person must not change the use of a building or place of public entertainment unless the building or place of public entertainment complies with the requirements of these Regulations applicable to the new use.
Penalty:20 penalty units.
(2) Despite subregulation (1), the municipal building surveyor may exempt a building or place of public entertainment from compliance with any of these Regulations applicable to the new use.
(3) In deciding whether to grant an exemption under subregulation (2) the municipal building surveyor must take into account—
(a) the structural adequacy of the building or place of public entertainment; and
(b) the requirements necessary to make reasonable provision for—
(i) the amenity of the building or place and the safety and health of people using the building or place; and
(ii) avoiding the spread of fire to or from any adjoining building.
(4) An exemption granted under subregulation (2) must be in the form of Form 18.
(5) This regulation applies in addition to any other requirements in the Act or these Regulations that apply because of the change of use of a building or place of public entertainment.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
195
230 Private building surveyor may exercise functions of municipal building surveyor under regulation 229
A private building surveyor may exercise the functions of the municipal building surveyor under regulation 229 in the case of a building or place of public entertainment for which the private building surveyor has been appointed to issue an occupancy permit.
Division 2—Subdivision of existing buildings231 Subdivision of existing building
(1) Subject to regulation 233, if an existing building, whenever constructed, is subdivided, each building resulting from the subdivision must be brought into conformity with these Regulations.
Penalty:20 penalty units.
(2) Despite subregulation (1), the municipal building surveyor may exempt a building from all or any of the requirements of subregulation (1).
(3) In deciding whether to grant an exemption under subregulation (2) the municipal building surveyor must take into account—
(a) the structural adequacy of any building to which the exemption applies; and
(b) the requirements necessary to make reasonable provision for—
(i) the amenity of any building and the safety and health of people using any building to which the exemption applies; and
(ii) avoiding the spread of fire to or from any adjoining building.
(4) An exemption granted under subregulation (2) must be in the form of Form 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
196
232 Private building surveyor may exercise functions of municipal building surveyor under regulation 231
A private building surveyor may exercise the functions of the municipal building surveyor under regulation 231 in the case of building work for which the private building surveyor has been appointed to issue a building permit.
Division 3—Alterations233 Alteration to existing building
(1) Building work to alter an existing building must comply with these Regulations.
(2) Subject to regulations 234 and 236, if the proposed alterations to an existing building, together with any other alterations completed or permitted within the previous 3 years, relate to more than half the original volume of the building, the entire building must be brought into conformity with these Regulations.
(3) Despite subregulations (1) and (2) and subject to subregulation (6), the relevant building surveyor may consent to partial compliance of building work or an existing building with subregulation (1) or (2).
(4) In determining whether to consent to partial compliance with subregulation (1) or (2) in respect of any alteration to a building, the relevant building surveyor must take into account—
(a) the structural adequacy of the building; and
(b) the requirements necessary to make reasonable provision for—
(i) the amenity of the building and the safety and health of people using the building; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
197
(ii) avoiding the spread of fire to or from any adjoining building.
(5) Any consent to partial compliance under subregulation (3) must be in the form of Form 18.
(6) If any part of the alteration is an extension to an existing building, the relevant building surveyor may only consent to partial compliance in respect of the extension if the floor area of the extension is not greater than the lesser of—
(a) 25% of the floor area of the existing building; and
(b) 1 000 m2.
234 Alterations affecting exits and paths to exits
(1) If a proposed alteration to an existing building other than a Class 1 or 10 building would adversely affect any exit or path of travel to an exit, the building must comply with Section D of the BCA Volume One.
(2) The relevant building surveyor may consent to partial compliance of a building with subregulation (1).
(3) In determining whether to consent to partial compliance with subregulation (1), the relevant building surveyor must take into account the requirements necessary to make reasonable provision for—
(a) the amenity of the building; and
(b) the safety and health of people using the building.
(4) Any consent to partial compliance under subregulation (2) must be in the form of Form 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
198
235 Extension of non-complying external wall
Despite anything to the contrary in these Regulations, a single storey external wall (including any openings) of a Class 1 building may be extended, once, a maximum of 6 m measured horizontally in similar construction without the extension of the wall complying with performance requirement P2.3.1 of the BCA Volume Two.
236 Application of requirements in the BCA Volume One relating to access to buildings for persons with disabilities
(1) Subject to subregulation (4), if an existing building is to contain a new part that must comply with an access provision, any affected part of the building must be brought into conformity with that access provision.Note
This provision aligns the operation of these Regulations (which incorporates the BCA Volume One) with the Disability (Access to Premises — Buildings) Standards 2010 of the Commonwealth. The Disability (Access to Premises−Buildings) Standards 2010 apply the requirements of the Access Code contained in those Standards (being building requirements relating to access to buildings and associated facilities and services for persons with a disability), not only to new parts of buildings but also to the affected parts of buildings that contain new parts. Affected parts of buildings may be in buildings that pre-date the commencement on 1 May 2011 of the access provisions in the BCA Volume One or they may be in buildings constructed after 1 May 2011.
(2) An access provision that was not in force immediately before 1 May 2011 does not apply to building work carried out under a building permit in respect of which an application was made before 1 May 2011, whether the permit was issued before or after 1 May 2011.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
199
(3) Despite anything to the contrary in the BCA Volume One, an access provision does not apply to—
(a) a new part of an existing Class 1b building if the Class 1b building—
(i) has less than 4 bedrooms that are used for rental accommodation; and
(ii) was constructed before 1 May 2011, or in respect of which an application for a building permit for construction was made before 1 May 2011; or
(b) a new part of an existing Class 2 building if the Class 2 building was constructed before 1 May 2011, or in respect of which an application for a building permit for construction was made before 1 May 2011; or
(c) the internal parts of a sole-occupancy unit in a Class 2 building; or
(d) a Class 4 building; or
(e) a Class 10 building or a new part of a Class 10 building that is associated with—
(i) a Class 1a building; or
(ii) a Class 4 part of a building.
(4) Despite anything to the contrary in the BCA Volume One and subject to regulation 234—
(a) an access provision does not apply to an affected part of an existing building if—
(i) parts of the existing building are leased to different persons; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
200
(ii) one of the persons is responsible for building work to be carried out in respect of the new part of the building; and
(iii) the new part of the building is leased to that person; and
(b) the deemed-to-satisfy provision in Table E3.6b in the BCA Volume One requiring a passenger lift, which travels more than 12 metres, to have a lift floor dimension of not less than 1400 mm x 1600 mm does not apply if the passenger lift—
(i) is an existing passenger lift; and
(ii) is located in a new part or an affected part of an existing building; and
(iii) has a lift floor dimension of not less than 1100 mm x 1400 mm; and
(c) the deemed-to-satisfy provisions in F2.4(c) and F2.4(e) in the BCA Volume One do not apply to an existing accessible sanitary compartment or an existing sanitary compartment suitable for a person with a disability to the extent that the requirements require a sanitary compartment to comply with AS 1428.1—2009 Design for access and mobility Part 1: General requirements for access—New building work published on 27 November 2009, as incorporated for the time being by the BCA Volume One, if the existing sanitary compartment—
(i) is located in a new part or an affected part of an existing building; and
Reg. 236(4)(c) amended by S.R. No. 40/2019 reg. 24.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
201
(ii) complies with AS 1428.1—2001 Design for access and mobility Part 1: General requirements for access—New building work published on 5 June 2001.
(5) In this regulation—
access provision means—
(a) a performance requirement—
(i) that is contained in Section D, Part E3 or Part F2 of the BCA Volume One; and
(ii) in respect of which there is an equivalent performance requirement contained in the Access Code within the meaning of the Disability (Access to Premises−Buildings) Standards 2010 of the Commonwealth; andNote
The Disability (Access to Premises−Buildings) Standards 2010 of the Commonwealth is available from the Australian Government Federal Register of Legislation website at www.legislation.gov.au.
(iii) to the extent that the performance requirement relates to the provision of access to buildings, and facilities and services within buildings, for persons with disabilities; and
(b) a provision of a document applied, adopted or incorporated by reference in a performance requirement referred to in paragraph (a);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
202
affected part in relation to an existing building that is to contain a new part means—
(a) the principal pedestrian entrance of the building; and
(b) any part of the building that is necessary to provide a continuous accessible path of travel from the principal pedestrian entrance to the proposed new part;
new part in relation to an existing building means a part of that building that is to be altered, including an extension to the building, in respect of which an application for a building permit is made on or after 1 May 2011.
Note
Under section 160B of the Act, a person may apply on the ground of unjustifiable hardship to the Building Appeals Board for a determination that an access provision does not apply, or applies with specified modifications or variations, to a building or land.
Division 4—General237 Small live music venue classification
(1) The BCA Volume One applies as if, in Schedule 3, for paragraph (c)(iii) of the definition of Assembly building, there were substituted—
"(iii) a sports stadium, sporting or other club—
but not including a small live music venue; or".
(2) The BCA Volume One applies as if, in Schedule 3, after the definition of Sitework, there were inserted—
"Small live music venue means the whole or the only part of a Class 6 building that has a rise in storeys of no more than 2—
Reg. 237(1) amended by S.R. No. 40/2019 reg. 25(1).
Reg. 237(2) amended by S.R. No. 40/2019 reg. 25(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
203
(a) in which live music entertainment is provided to the public; and
(b) that has a floor area not greater than 500 m2.".
(3) The BCA Volume One applies as if, at the foot of the definition of Class 6 in clause A6.6, there were inserted—"Note
A Class 6 building or part of a Class 6 building in which people assemble for entertainment purposes remains a Class 6 building or part of a Class 6 building if it is a small live music venue—see the definition of Assembly building in the BCA Volume One."
Reg. 237(3) amended by S.R. No. 40/2019 reg. 25(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
204
Part 17—Building product accreditation
Division 1—Definitions238 Definitions
In this Part—
building product includes construction method, design, component or system connected with building work;
Committee means the Building Regulations Advisory Committee.
Division 2—Accreditation persons and bodies239 Prescribed persons and bodies to accredit building
products
For the purposes of sections 14 and 15 of the Act, the following persons and bodies are prescribed as accreditation persons or bodies—
(a) the Australian Building Codes Board;
(b) a person or body authorised by the Australian Building Codes Board.
240 Definition of Certificate of Accreditation in the BCA
(1) The BCA Volume One applies as if, in Schedule 3, in the definition of Certificate of Accreditation, for "a State or Territory accreditation authority" there were substituted "the Building Regulations Advisory Committee".
(2) The BCA Volume Two applies as if, in Schedule 3, in the definition of Certificate of Accreditation, for "a State or Territory accreditation authority" there were substituted "the Building Regulations Advisory Committee".
Reg. 240(1) amended by S.R. No. 40/2019 reg. 26(1).
Reg. 240(2) amended by S.R. No. 40/2019 reg. 26(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
205
Division 3—Accreditation by Committee241 Application of Division
This Division does not apply to a building product that complies with the relevant deemed-to-satisfy provisions of the BCA.
242 Application for accreditation
(1) A person may apply to the Committee to have a building product accredited under this Division.
(2) An application for accreditation must be in the form of Form 19.
(3) An application must be accompanied by—
(a) the fee prescribed in regulation 244(1); and
(b) if required by the Committee, any one or more of the following—
(i) an appraisal of the building product from an organisation or person that is recognised by the Committee as competent to make the appraisal, including details of the appraiser's qualifications and experience;
(ii) an appraisal of the building product from an organisation or person nominated by the Committee addressing any matter relating to the properties and performance of a building product requested by the Committee;
(iii) a report from an Accredited Testing Laboratory or a Registered Testing Authority showing that the building product has been submitted to the tests listed in the report and setting out the results of those tests and any other relevant information that demonstrates
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
206
the suitability of the building product for its proposed purpose;
(iv) any installation manual produced for the building product;
(v) any other information or document required by the Committee.
243 Information in application to remain confidential
(1) A person must not disclose, except to the extent necessary to carry out functions or exercise powers under this Part, any information obtained by that person from an application for accreditation unless the disclosure is authorised in writing by the person who made the application.
Penalty:10 penalty units.
(2) A person does not commit an offence under subregulation (1) by disclosing information—
(a) that is contained in the register under regulation 251 at the time of disclosure; or
(b) that has been published in the Government Gazette under regulation 245 or 248 before the disclosure.
244 Accreditation fees
(1) The fee for accreditation of a building product under this Division is 138·31 fee units.
(2) All fees paid under this Division must be paid into the Building account of the Victorian Building Authority Fund.
245 Certificate of accreditation
(1) If the Committee accredits a building product under this Division, the Authority must issue a certificate of accreditation to the applicant.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
207
(2) A certificate of accreditation must set out the following—
(a) the name of the building product;
(b) a description of the building product;
(c) a description of the purpose and use of the building product;
(d) any regulation in relation to which the building product is accredited;
(e) any condition to which the accreditation is subject;
(f) the name and address of the holder of the accreditation;
(g) the number of the certificate of accreditation;
(h) the date of issue of the certificate of accreditation;
(i) any other information that the Committee considers appropriate.
(3) The Authority must cause to be published in the Government Gazette notice of any accreditation of a building product under this Division as soon as practicable after that accreditation.
(4) The notice of accreditation must contain the information set out in subregulation 245(2).
246 Revocation of accreditation
(1) The Committee may at any time revoke an accreditation under this Division if it finds that—
(a) the accreditation has been obtained by fraud, misrepresentation or concealment of facts; or
(b) the performance of the building product the subject of the accreditation—
(i) is unsatisfactory; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
208
(ii) differs or fails to achieve the level of performance for which the building product was accredited; or
(c) the regulation in relation to which the building product was accredited has been amended or revoked.
(2) If the Committee determines to revoke an accreditation, the Authority must notify the holder of the certificate of accreditation in writing of the decision of the Committee.
247 Holder may request revocation of accreditation
(1) The holder of a certificate of accreditation may, in writing, at any time request the Committee to revoke the accreditation.
(2) The Committee must revoke an accreditation under this Division on receipt of a request made under subregulation (1).
248 Notice of revocation of accreditation
(1) The Authority must cause to be published in the Government Gazette notice of any revocation of an accreditation under this Division as soon as practicable after that revocation.
(2) A notice that an accreditation has been revoked must include the following—
(a) the name of the building product;
(b) a description of the building product;
(c) the number of the certificate of accreditation;
(d) a statement to the effect that the accreditation of the building product has been revoked by the Committee;
(e) the date of the revocation;
(f) any other information the Committee considers appropriate.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
209
249 Accreditation ceases to have effect on revocation
An accreditation under this Division ceases to have effect on its revocation.
250 Offence to falsely claim product accredited
A person or body must not knowingly claim that a building product is accredited under this Division if the building product is not accredited under this Division.
Penalty:20 penalty units.
Division 4—Register and records251 Register of accredited products
(1) The Authority must keep a register of all building products accredited under Division 3.
(2) The register must contain the following information—
(a) in relation to each accredited building product—
(i) the name of the building product;
(ii) a description of the building product;
(iii) a description of the purpose and use of the building product;
(iv) any regulation in relation to which the building product is accredited;
(v) any condition to which the accreditation is subject;
(vi) the name and address of the holder of the accreditation;
(vii) the number of the certificate of accreditation;
(viii) the date of issue of the certificate of accreditation;
Reg. 251(2) substituted by S.R. No. 40/2019 reg. 27.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
210
(b) in relation to each formerly accredited building product—
(i) the name of the building product;
(ii) the number of the certificate of accreditation;
(iii) the date of issue of the certificate of accreditation;
(iv) the date of revocation of the accreditation;
(c) any other information that the Committee considers appropriate.
(2A) The information referred to in subregulation (2)(b) is not required to be contained in the register until 1 January 2020.
(3) The Authority must update the register as soon as is practicable after the Committee revokes an accreditation under Division 3.
(4) The Authority must make the register available without charge for inspection by any person during normal office hours.
(5) The Authority may publish the information on the register on the Authority's website.
252 Records
The Authority must keep—
(a) all documents considered by the Committee in relation to an accreditation under Division 3 until the accreditation is revoked; and
(b) copies of all certificates of accreditation issued by the Authority.
Reg. 251(2A) inserted by S.R. No. 40/2019 reg. 27.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
211
Part 18—Building practitioners
Division 1—Registration* * * * *
254 Information to accompany application for registration
For the purposes of section 170A(e) of the Act, an application for registration under section 170 of the Act must be accompanied by the following information—
(a) any evidence or proof of identity of the applicant that is required by the Authority;
(b) a certified copy of each licence or registration to carry out building work outside of Victoria (if any);
(c) the usual place of business of the applicant;
(d) the business postal address of the applicant;
(e) the telephone number of the applicant;
(f) if the applicant is a natural person—
(i) any information about the applicant's work or employment history and experience in the building industry inside or outside Victoria, including any technical referee report, that is required by the Authority; and
(ii) a certified copy of any academic qualifications for the purposes of section 171(1)(a) of the Act; and
(iii) the residential address of the applicant;
Reg. 253 revoked by S.R. No. 75/2018 reg. 14.
Reg. 254 substituted by S.R. No. 75/2018 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
212
(g) if the applicant is a body corporate—
(i) the ACN or ARBN of the body corporate; and
(ii) the name of each director of the body corporate; and
(iii) the registration number of each nominee director of the body corporate;
(h) if the applicant carries on business, or intends to carry on business, as a building practitioner as a member of a partnership—
(i) the name of the partnership; and
(ii) the usual place of business of the partnership; and
(iii) the name of each member of the partnership; and
(iv) the registration number of each member of the partnership (if applicable); and
(v) the address of each member of the partnership;
(i) a certified copy of any other document being relied on by the applicant in support of the application.
254A Other financial probity criteria
For the purposes of section 171E(1)(i) of the Act, the person must disclose whether they were an officer of a body corporate at any time within the period of 2 years immediately before the body corporate was subject to external administration within the meaning of section 5-15 of Schedule 2 to the Corporations Act.
Reg. 254A inserted by S.R. No. 40/2019 reg. 28.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
213
255 Certificate of registration
The prescribed information for the purposes of section 171G(2)(c) of the Act is—
(a) the name of the registered person; and
(b) the registration number of the registered person; and
(c) the category and class of registration; and
(d) any condition that applies to the registration; and
(e) the commencement date of the registration; and
(f) the expiry date of the registration.
256 Condition of registration
For the purposes of section 171H(1)(a) of the Act, it is a prescribed condition of registration that a building practitioner must not allow another person to use the building practitioner's certificate issued to the building practitioner under section 171G of the Act.
256A Authority to be advised of nominee director changes
(1) For the purposes of section 175C(a) of the Act the prescribed information is—
(a) the name and registration number of the person who has ceased to be a nominee director; and
(b) the day on which the person ceased to be a nominee director.
(2) For the purposes of section 175C(b) of the Act the prescribed information is—
(a) the name and registration number of any new nominee director appointed and the day on which the appointment was made; and
Reg. 255 substituted by S.R. No. 75/2018 reg. 15.
Reg. 256 amended by S.R. No. 75/2018 reg. 16.
Reg. 256A inserted by S.R. No. 75/2018 reg. 17.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
214
(b) the name and registration number of any person who has ceased to be appointed as a nominee director and the day on which the appointment ceased.
Division 1A—Register of Building Practitioners
256B The Register of Building Practitioners
For the purposes of section 175(2) of the Act, the Register of Building Practitioners must include the following information relating to a person who is a registered building practitioner—
(a) the registration number of the person;
(b) any condition that applies to the registration of the person;
(c) the residential address of the person;
(d) the usual place of business of the person;
(e) the business postal address of the person;
(f) the telephone number of the person;
(g) if the person is a body corporate—
(i) the name of each nominee director of the body corporate; and
(ii) the name of each director of the body corporate;
(h) if the person carries on business as a building practitioner as a member of a partnership—
(i) the name of the partnership; and
(ii) the usual place of business of the partnership; and
Pt 18 Div. 1A (Heading and regs 256B, 256C) inserted by S.R. No. 75/2018 reg. 18.
Reg. 256B inserted by S.R. No. 75/2018 reg. 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
215
(iii) the name of each member of the partnership; and
(iv) the registration number of each member of the partnership (if applicable); and
(v) the address of each member of the partnership;
(i) the commencement date of the registration;
(j) the expiry date of the registration;
(k) whether the registration is in force, suspended, surrendered or cancelled;
(l) if the registration is suspended—
(i) the date the registration was suspended; and
(ii) the reason the registration was suspended; and
(iii) the date the registration ceased to be suspended (if applicable);
(m) the date the registration was surrendered (if applicable);
(n) if the registration is cancelled—
(i) the date the registration was cancelled; and
(ii) the reason the registration was cancelled.
256C Publication of information on Register of Building Practitioners
(1) For the purposes of section 175D(1) of the Act, the prescribed information in relation to a person who is a registered building practitioner is—
(a) the name of the person; and
(b) the registration number of the person; and
Reg. 256C inserted by S.R. No. 75/2018 reg. 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
216
(c) the category and class of registration of the person; and
(d) any condition on the registration of the person; and
(e) the business postal address of the person; and
(f) the telephone number of the person; and
(g) the name of each nominee director, if the person is a body corporate; and
(h) if the person carries on business as a building practitioner as a member of a partnership—
(i) the name of the partnership; and
(ii) the name of each member of the partnership; and
(iii) the registration number of each member of the partnership (if applicable); and
(iv) the usual place of business of the partnership; and
(i) the commencement date of the registration; and
(j) the expiry date of the registration; and
(k) whether the registration is in force, suspended, surrendered or cancelled; and
(l) if the registration is suspended—
(i) the date the registration was suspended; and
(ii) the reason the registration was suspended; and
(iii) the date the registration ceased to be suspended (if applicable); and
(m) the date the registration was surrendered (if applicable); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
217
(n) if the registration is cancelled—
(i) the date the registration was cancelled; and
(ii) the reason the registration was cancelled.
(2) For the purposes of section 175D(2) of the Act, the prescribed information in relation to a person who is a registered building practitioner is—
(a) details of any criminal sanction imposed on the person; and
(b) details of any disciplinary sanction imposed on the person.
Division 2—Prescribed qualifications and classes of building practitioner
257 Prescribed classes of building practitioner
For the purposes of section 171 of the Act, each class of building practitioner in respect of a category of building practitioner is the class set out in Part 2 of Schedule 9.
258 Prescribed qualifications
(1) For the purposes of section 171(1)(a)(i) of the Act, the prescribed qualifications for registration of a category or a class of building practitioner are any—
(a) degree, diploma, certificate, accreditation, authority, training or examination set out in Part 3 of Schedule 9 for the category or class of building practitioner; and
(b) practical experience set out in Part 3 of Schedule 9 for that category or class of building practitioner.
Reg. 257 amended by S.R. No. 75/2018 reg. 19(1).
Reg. 258(1) amended by S.R. No. 75/2018 reg. 19(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
218
(2) In this regulation practical experience—
(a) includes compliance with any supervision requirements during the obtaining of that experience; and
(b) must have been obtained in the 7 years before the application for registration was made.
259 Building surveyor work
(1) A person who is registered in the class of building surveyor (unlimited) is authorised to carry out the work set out in column 3 of item 1 of the Table in Schedule 10.
(2) A person who is registered in the class of building surveyor (limited) is authorised to carry out the work set out in column 3 of item 2 of the Table in Schedule 10.
260 Building inspector work
(1) A person who is registered in the class of building inspector (unlimited) is authorised to carry out the work set out in column 3 of item 1 of the Table in Schedule 11.
(2) A person who is registered in the class of building inspector (limited) is authorised to carry out the work set out in column 3 of item 2 of the Table in Schedule 11.
261 Domestic builder work
A person who is registered in a class of domestic builder set out in column 2 of the Table in Schedule 12 is authorised to carry out the domestic building work set out in column 3 of that Table corresponding to that class of domestic builder.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
219
Division 3—Requirements for advertising and written statements
262 Advertisements or written statements by registered building practitioners
For the purposes of section 169H(c) of the Act, the name and registration number of the registered building practitioner must be clearly legible in the advertisement or statement.
263 Advertisements or written statements by partnerships
For the purposes of section 169I(c) of the Act, the name and registration number of the registered building practitioner must be clearly legible in the advertisement or statement.
Division 3A—Probity and discipline
263A Authority must be notified of probity matters
(1) A relevant person must notify the Authority in writing within 14 days after any of the following occurs—
(a) the person is convicted or found guilty of an offence referred to in regulation 263B;
(b) the person is convicted or found guilty (whether in Victoria or outside Victoria) of any offence involving fraud, dishonesty, drug trafficking or violence
Pt 18 Div. 3 (Heading and regs 262, 263) substituted by S.R. No. 75/2018 reg. 20.
Reg. 262 substituted by S.R. No. 75/2018 reg. 20.
Reg. 263 substituted by S.R. No. 75/2018 reg. 20.
Pt 18 Div. 3A (Heading and regs 263A–263C) inserted by S.R. No. 75/2018 reg. 20.
Reg. 263A inserted by S.R. No. 75/2018 reg. 20.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
220
that is punishable by imprisonment for 6 months or more;
(c) the person is convicted or found guilty of an offence under any law regulating building work or building practitioners;
(d) the person has any registration, licence, approval, certificate or other authorisation as a building practitioner suspended or cancelled for any reason other than a failure by the person to renew the registration, licence, approval, certificate or other authorisation;
(e) the person is convicted or found guilty of an offence against—
(i) section 53, 55, 55A, 56, 58 or 60 of the Trade Practices Act 1974 of the Commonwealth; or
(ii) section 29, 33, 34, 35, 36, 50, 151, 157, 158 or 168 of the Australian Consumer Law (Victoria); or
(iii) section 29, 33, 34, 35, 36, 50, 151, 157, 158 or 168 of Schedule 2 to the Competition and Consumer Act 2010 of the Commonwealth;
(f) the person becomes subject to an order of a court or VCAT under the following enactments that has not been complied with within the period required by the court or VCAT—
(i) the Act or these Regulations; or
(ii) the Domestic Building Contracts Act 1995 or the regulations under that Act;
(g) the person is disqualified from managing corporations under Part 2D.6 of the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
221
Corporations Act;
(h) an insurer declines, cancels, or imposes special conditions in relation to, the provision of professional indemnity insurance, public liability insurance or any other indemnity insurance in relation to the person in relation to work as a building practitioner in Victoria or in an equivalent occupation in the building and construction industry in another State or Territory;
(i) the person has outstanding—
(i) any judgment debt for an amount recoverable by an insurer under a policy of insurance for domestic building work referred to in section 137A or 137B of the Act that is not satisfied within the period required for satisfaction of that debt; or
(ii) any judgment debt for an amount owed to the Authority as a debt due under this Act that has not been satisfied within the period required for satisfaction of that debt; or
(iii) any judgment debt for an amount payable in relation to a domestic building dispute that is not satisfied within the period required for satisfaction of that debt; or
(iv) any amount payable under any dispute resolution order (within the meaning of the Domestic Building Contracts Act 1995) or VCAT order requiring the payment of an amount in relation to a domestic building dispute that is
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
222
not paid within the period required for compliance with that order; or
(v) any unpaid adjudicated amount due to be paid under the Building and Construction Industry Security of Payment Act 2002 if—
(A) the period for making an adjudication review application under that Act in relation to that amount has expired; and
(B) the person has not made an adjudication review application in relation to that amount within that period.
Penalty: 10 penalty units.
(2) A relevant person must notify the Authority in writing without delay after—
(a) the person becomes an insolvent under administration; or
(b) the person becomes an externally administered body corporate within the meaning of the Corporations Act; or
(c) the person is convicted or found guilty of an offence against section 32 of the Occupational Health and Safety Act 2004; or
(d) the person is convicted or found guilty (whether in Victoria or outside Victoria) of an indictable offence involving fraud, dishonesty, drug trafficking or violence; or
(e) the person ceases to be covered by the required insurance; or
(f) the person becomes an excluded person.
Penalty: 10 penalty units.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
223
(3) In this regulation—
relevant person means—
(a) a registered building practitioner; or
(b) a director of a registered body corporate; or
(c) a member of a partnership, which includes a person who carries on business as a building practitioner, other than that person.
263B Grounds for disciplinary action
The prescribed provisions for the purposes of section 179(1)(a)(iii) of the Act are sections 21(1), 23(1), 24(1), 25(1), 25(2), 26(1), 27(1) and 28(1) of the Occupational Health and Safety Act 2004.
263C Grounds for immediate suspension
(1) The prescribed provisions for the purposes of section 180(b)(i) of the Act are sections 172(1)(a) and (b) of the Act.
(2) The prescribed provision for the purposes of section 180(b)(iii) of the Act is section 32 of the Occupational Health and Safety Act 2004.
Division 4—General264 Notice of suspension or cancellation of registration
For the purposes of section 183A of the Act—
(a) a notice of suspension of registration must be in the form of Form 20; and
(b) a notice of cancellation of registration must be in the form of Form 21.
Reg. 263B inserted by S.R. No. 75/2018 reg. 20.
Reg. 263C inserted by S.R. No. 75/2018 reg. 20.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
224
265 Professional standards
A registered building practitioner must—
(a) perform work as a building practitioner in a competent manner and to a professional standard; and
(b) immediately inform a client in writing if a conflict of interest arises or appears likely to arise between the building practitioner and that client; and
(c) receive remuneration for services as a building practitioner solely by the professional fee or other benefits specified in the contract of engagement or by the salary and other benefits payable by the building practitioner's employer.
266 Duplicate certificate fee
For the purposes of section 171J(a)(ii) of the Act, the prescribed fee for a duplicate building practitioner's certificate is 2·75 fee units.
267 Period for which private building surveyor may not act
The prescribed period for the purposes of section 79(1)(b) of the Act is one year.
Division 5—Exemptions for certain building practitioners
268 Relevant building surveyor exempt from section 24A in relation to certain types of building work
When issuing a permit for building work referred to in section 24B(3) of the Act, a relevant building surveyor is not required to be satisfied that the building work is to be carried out by a
Reg. 266 amended by S.R. No. 75/2018 reg. 21.
Reg. 268 substituted by S.R. No. 75/2018 reg. 22.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
225
builder who is a registered building practitioner as required under section 24B(3)(a) of the Act if the building work is to be carried out by a builder who is solely engaged in the business of constructing Class 10 buildings other than a Class 10b structure constructed for the purpose of displaying a sign.
269 Relevant building surveyor exempt from section 24(6) and (7) of the Act in relation to certain building permit applications
A relevant building surveyor is exempt from section 24(6) and (7) of the Act in relation to an application for a building permit—
(a) to construct a Class 10 building; or
(b) to carry out building work on an allotment in a planning scheme other than a planning scheme specified in Schedule 13.
* * * * *
Reg. 269 revoked by S.R. No. 75/2018 reg. 23, new reg. 269 inserted by S.R. No. 180/2018 reg. 12.
Reg. 270 revoked by S.R. No. 75/2018 reg. 23.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
226
Part 19—Appeals and reviews271 Appeal periods
(1) For the purposes of section 146(1)(a) of the Act, the prescribed appeal period is—
(a) in the case of an appeal against the refusal of a permit, an amendment, an application or an approval—30 days after the day the applicant is notified of the refusal; or
(b) in the case of an appeal against the deemed refusal of a permit or an application—30 days after the day the permit or application is deemed under the Act to have been refused; or
(c) in the case of an appeal against the imposition of a condition on a permit or an approval—30 days after the day the permit is given or the approval is issued; or
(d) in the case of an appeal against the amendment of a permit or an approval—30 days after the day the owner of the building or land to which the permit relates is notified of the amendment; or
(e) in the case of an appeal against a requirement of a reporting authority or relevant building surveyor to give more information about a permit application or to amend a permit application—30 days after the day the applicant is notified of the requirement; or
(f) in the case of an appeal against a refusal by a person or body to make a determination or exercise a discretion under a condition of a permit—30 days after the day the applicant is notified of the refusal; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
227
(g) in the case of an appeal against a decision to issue a permit that differs from, or fails to implement, a reporting authority's recommendations in a report on the application for the permit—30 days after the day the reporting authority receives notification of the issue of the permit from the relevant building surveyor; or
(h) in the case of an appeal against a direction to fix building work under Division 2 of Part 4 of the Act—7 days after the day the person is given the written direction under section 37C(b) or 37D(2) of the Act; or
(i) in a case of an appeal against the cancellation of an approval under section 71 of the Act—30 days after the day the owner of the building or land concerned is notified of the cancellation; or
(j) in a case of an appeal against the refusal of the Authority to consent to the termination of a building surveyor's appointment under section 81(1) of the Act—30 days after the day the owner or the relevant building surveyor (as the case requires) is notified of the Authority's refusal; or
(k) in the case of an appeal against the refusal of the Authority to consent to the proposed appointment of a private building surveyor or municipal building surveyor under section 81(4) of the Act—30 days after the day the owner or the private building surveyor or municipal building surveyor (as the case requires) is notified of the Authority's refusal; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
228
(l) in the case of an appeal against a determination under section 87(1) of the Act as to the appropriateness of protection work—14 days after the day the owner and the adjoining owner is given notice of the determination; or
(m) in the case of an appeal against a declaration made under section 89(1) of the Act—30 days after the day the owner or the adjoining owner (as the case requires) is given notice of the declaration; or
(n) in the case of an appeal against a requirement made under section 87 of the Act to give more information—14 days after the day the owner is asked to give more information under section 87(2)(a) of the Act; or
(o) in the case of an appeal against a decision to serve a building notice on an owner—30 days after the day the building notice is served on the owner; or
(p) in the case of an appeal against the making of an emergency order or a building order—30 days after the day the order is served on the person to whom it is directed; or
(q) in the case of an appeal against the imposition of a condition on an emergency order or a building order—30 days after the day the order is served on the person to whom it is directed; or
(r) in the case of an appeal against a refusal to amend or cancel an emergency order or a building order—30 days after the day the owner is notified of the refusal or the day the relevant building surveyor is deemed to have refused to amend or cancel the order; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
229
(s) in the case of an appeal against a requirement that an order made under the Act be fully complied with—30 days after the day the owner is notified of the requirement; or
(t) in the case of an appeal against a decision of the Authority under section 42 or 43 of the Building and Construction Industry Security of Payment Act 2002—30 days after the day the Authority makes the decision; or
(u) in the case of an appeal against a failure by a person or body to make a decision, a determination, an approval, a cancellation or an amendment or to exercise a discretion within a reasonable time—60 days after the request was made to the person or body to make the decision, determination, approval, cancellation or amendment or to exercise the discretion; or
(v) in the case of an appeal against any other decision, determination, declaration or approval or exercise of discretion by a person or body—30 days after the day notification is given of the decision, determination, declaration or approval or exercise of discretion; or
(w) in any other case—30 days after the day of the event in relation to which the appeal is brought.
(2) If an appeal period prescribed under this regulation begins on the day on which a person is notified under the Act or these Regulations but the notice has not been so given, the prescribed appeal period for the purposes of section 146(1)(a) of the Act is—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
230
(a) 37 days after the day of the event that required that notification to be given; or
(b) any longer period that the Building Appeals Board considers appropriate in the circumstances.
272 Appeal, referral and application fees
(1) The fees for making an appeal, a referral or an application to the Building Appeals Board in a matter relating to a Class 1 or 10 building are—
(a) for an appeal under—
(i) section 138, 138A, 140, 141 or 142 of the Act—23·04 fee units; or
(ii) section 139, 144 or 144A of the Act—13·82 fee units; or
(b) for a referral under—
(i) section 150 of the Act—13·82 fee units; or
(ii) section 151, 152, 153, 154, 155, 156, 157 or 158 of the Act—23·04 fee units; or
(c) for an application under—
(i) section 159 of the Act—23·04 fee units; or
(ii) section 160 of the Act—8·29 fee units; or
(iii) section 164 of the Act—13·82 fee units.
(2) The fees for making an appeal, a referral or an application to the Building Appeals Board in a matter relating to a building other than a Class 1 or 10 building are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
231
(a) for an appeal under—
(i) section 138, 138A, 140, 141 or 142 of the Act—46.1 fee units; or
(ii) section 139, 144 or 144A of the Act—23·04 fee units; or
(b) for a referral under—
(i) section 150 of the Act—23·04 fee units; or
(ii) section 151, 152, 153, 154, 155, 156, 157 or 158 of the Act—46·1 fee units; or
(c) for an application under—
(i) section 159 of the Act—46.1 fee units; or
(ii) section 160 of the Act—18·43 fee units; or
(iii) section 164 of the Act—23·04 fee units.
(3) The fees for making an application to the Building Appeals Board are—
(a) for an appeal under section 160A of the Act—18·43 fee units; or
(b) for an appeal under section 160B of the Act—41·89 fee units.
273 Fees for fast track appeals
(1) The fee for making a request to the Building Appeals Board under section 147(1) of the Act is 36·88 fee units.
(2) For the purposes of section 147(3)(b) of the Act, the additional prescribed fee is 14·75 fee units per hour or part of an hour.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
232
274 Refund of fees by Authority
(1) The Authority may refund, from the Building account of the Victorian Building Authority Fund, in whole or in part, any fee paid to the Building Appeals Board under this Part if the appeal, request, application or referral does not proceed.
(2) The Building Appeals Board must refund from the Victorian Building Authority Fund any fee paid for a request under regulation 273(1) if the request is refused.
275 Review period
The period within which an application for review by VCAT under section 25J of the Act must be lodged is—
(a) 60 days after the day that the applicant is notified of the decision to be reviewed; or
(b) if the application is for the review of a failure to make a decision within a reasonable time—67 days after the day a request was made to the Authority to make that decision.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
233
Part 20—Infringement notices276 Authorised officers
The prescribed office or class of officers for the purposes of the definition of authorised officer in section 254 of the Act are—
(a) the Chief Executive Officer or a VBA inspector, for offences against regulations 41(1), 41(2), 197(2), 199(2), 216(2), 218(3), 223(1), 223(2), 225, 226(1), 227 and 228; and
(b) the chief officer, for offences against regulations 199(2), 216(2), 223(1), 223(2), 225, 226(1), 227 and 228; and
(c) the municipal building surveyor, for offences against regulations 41(1), 41(2), 147C, 147L(2), 147M(2), 147N(2), 147O(2), 147V(1), 147X(3), 147ZC, 147ZJ(4), 197(2), 199(2), 216(2), 218(3), 223(1), 223(2), 225, 226(1), 227 and 228.
277 Prescribed offences
The prescribed offences for the purposes of the definition of prescribed offence in section 254 of the Act are offences against regulations 41(1), 41(2), 147C, 147L(2), 147M(2), 147N(2), 147O(2), 147V(1), 147X(3), 147ZC, 147ZJ(4), 197(2), 199(2), 216(2), 218(3), 223(1), 223(2), 225, 226(1), 227 and 228.
278 Prescribed penalties
The prescribed penalty for the purposes of section 255(3) of the Act is—
(a) 5 penalty units in the case of a place of public entertainment; and
(b) 2 penalty units in any other case.
Reg. 276(a) amended by S.R. No. 75/2018 reg. 24.
Reg. 276(c) amended by S.R. Nos 75/2018 reg. 24, 116/2019 reg. 12.
Reg. 277 amended by S.R. Nos 75/2018 reg. 24, 116/2019 reg. 13.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
234
Part 21—Exemptions279 Exemptions from building regulations
A building or building work specified in column 2 of the Table in Schedule 3 is exempt from the regulations specified in column 3 of that Table corresponding to that building or building work.
280 Exemption for Class 10 buildings on farm land
(1) The relevant council may exempt a Class 10 building that is to be constructed on farm land and used for farming purposes from all or any of the requirements of these Regulations.
(2) If the relevant council grants an exemption from all of these Regulations under subregulation (1), a building permit and certificate of final inspection under the Act are not required for that building.
281 Exemptions relating to building surveyors for certain buildings
Sections 23, 30, 47 and 73 of the Act do not apply to a relevant building surveyor in relation to the following classes of buildings—
(a) premises that are used or intended to be used for the provision of residential accommodation by—
(i) a community service established under section 44 of the Children, Youth and Families Act 2005; or
(ii) a registered community service within the meaning of that Act that is situated on Crown land or land in relation to which the Secretary to the Department of Health and Human Services or the Director of Housing is registered as proprietor;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
235
(b) premises that are used or intended to be used as—
(i) a remand centre within the meaning of the Children, Youth and Families Act 2005; or
(ii) a secure welfare service within the meaning of that Act; or
(iii) a youth justice centre within the meaning of that Act;
(iv) a youth residential centre within the meaning of that Act; or
(c) premises that are used or intended to be used as—
(i) a prison established under section 10 of the Corrections Act 1986; or
(ii) a community corrections centre established under Part 9 of that Act;
(d) premises that are used or intended to be used as a residential institution within the meaning of the Disability Act 2006;
(e) premises that are used or intended to be used as a residential service within the meaning of the Disability Act 2006;
(f) premises that are used or intended to be used as a courthouse by a court;
(g) premises that are used or intended to be used as a police station;
(h) premises that are used or intended to be used as a designated mental health service within the meaning of the Mental Health Act 2014;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
236
(i) premises that are used or intended to be used as a youth refuge or a women's refuge operated with funding provided by the Secretary to the Department of Health and Human Services for the purpose of providing a refuge.
* * * * *
Reg. 282 revoked by S.R. No. 38/2018 reg. 282(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
237
Part 22—Transitional and savings provisions283 Registration of building practitioners not affected
by revocation of Building Interim Regulations 2017
The revocation of the Building Interim Regulations 2017 does not affect the registration under Part 11 of the Act of any building practitioner who was registered or taken to be registered under that Part immediately before that revocation.
284 Domestic builder (manager)
(1) Despite the revocation of the Building Interim Regulations 2017, a person registered under Part 11 of the Act in the category of builder, class of domestic builder (manager) immediately before 1 July 2017 and to whom regulation 2046(2) of the Building Interim Regulations 2017 as in force immediately before its revocation applied, continues to be registered under Part 11 of the Act in that class of domestic builder until 30 June 2022.
(2) For the purposes of subregulation (1), the relevant qualifications set out in the table in Schedule 7 of the Building Interim Regulations 2017, as in force before being substituted by regulation 15 of the Building Amendment Regulations 2017, are taken to be the prescribed qualifications for the category of builder, class of domestic builder (manager), until 30 June 2022.
285 Appointment of private building surveyor
Section 78(1A) of the Act does not apply in relation to domestic building work—
(a) to be carried out under a major domestic building contract entered into by a builder before 1 September 2016; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
238
(b) in respect of which a builder acts or proposes to act as a domestic builder before 1 September 2016.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
239
Part 23—Revocation of temporary fees286 Revocation of regulations prescribing fees
The following regulations are revoked on 1 July 2020—
(a) regulation 18;
(b) regulation 36;
(c) regulation 45;
(d) regulation 52;
(e) regulation 244;
(f) regulation 266;
(g) regulation 272;
(h) regulation 273.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
240
Schedule 1—RevocationsRegulation 4
Table
S.R. No. Title
31/2017 Building Interim Regulations 2017
65/2017 Building Amendment Regulations 2017
81/2017 Building Further Amendment Regulations 2017
87/2017 Building Amendment (Macedon Ranges Siting Requirements and Other Matters) Regulations 2017
136/2017 Building Amendment (Powers of Entry and Other Matters) Regulations 2017
26/2018 Building Amendment (National Construction Code Amendment and Siting Requirements) Regulations 2018
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
241
Schedule 2—Duties and responsibilities of an owner-builder
Regulation 19
1 Understanding the restrictions imposed by the Act and these Regulations on the carrying out of domestic building work, including those referred to in section 16 of the Act, which include that building work must be carried out under a building permit.
2 Understanding the process of applying to the municipal building surveyor, or appointing a private building surveyor under Part 6 of the Act, to obtain a building permit and understanding the circumstances under which the relevant building surveyor must not issue a building permit.
3 Ensuring building work is inspected as required by the Act and these Regulations.
4 Understanding the requirement for, and knowing when to apply for and obtain, an occupancy permit or certificate of final inspection.
5 Understanding the requirement for entering a major domestic building contract when engaging a domestic builder to undertake certain building work.
6 Understanding the requirement to engage a building practitioner registered under Part 11 of the Act to carry out certain building work if required by the Act and these Regulations.
7 Understanding the requirement to engage licensed or registered practitioners, other than building practitioners registered under Part 11 of the Act, to undertake forms of regulated work, such as plumbing or electrical work.
8 Understanding the processes available to resolve domestic building work disputes under the Domestic Building Contracts Act 1995.
9 Undertaking relevant planning and preparation for carrying out building work.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
242
10 Complying with site safety requirements, including development, communication, monitoring and maintenance of site safety plans, and any relevant requirement under the Occupational Health and Safety Act 2004 and the regulations under that Act, for carrying out building work.
11 Supervising the carrying out of all building work and ensuring that it complies with the Act and these Regulations.
12 Ensuring building work is undertaken in accordance with the requirements of any relevant environmental laws.
13 Understanding when directions to fix building work can be made and when and how enforcement of safety and building standards can be undertaken in relation to domestic building work subject to a certificate of consent.
14 Arranging any required protection works.
15 Interpreting plans, drawings and specifications relating to the building work.
16 Setting out and preparing the building site according to plans and specifications.
17 Understanding requirements for the sale of an owner-built home under section 137B of the Act, including the requirement to obtain insurance for the building work carried out by the owner-builder.
18 Ensuring knowledge of and obtaining insurance to cover any loss, damage or injury to the owner-builder or others incurred in connection with the carrying out of the building work.
19 Ensuring knowledge of warranties implied into a contract for the sale of an owner-built home under section 137C of the Act.
20 Any other duty or responsibility of an owner-builder imposed by the Act, these Regulations, the Domestic Building Contracts Act 1995 or the regulations made under that Act.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
243
Schedule 3—Exemptions for building work and buildings
Regulations 23, 185, 279
Table
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
1 Construction of a freestanding Class 10a building that—
(a) has a floor area not exceeding 10 m2; and
(b) is no more than 3 m in height or, if situated within 1 m of a boundary, is no more than 24 m in height; and
(c) if appurtenant to a building of another Class on the same allotment, is located no further forward on the allotment than the front wall of the building to which it is appurtenant; and
(d) if it is not appurtenant to a building of another Class on the same allotment, is the only Class 10a building on the allotment and is set back at least 9 m from the front street alignment and at least 2 m from each side street alignment; and
(e) is not constructed of masonry.NoteThe consent of a service authority may be required to construct a Class 10a building 10 m2 or less in an area over an easement vested in that authority under another Act or within 1 m laterally of any works of a water
All Parts
Sch. 3 amended by S.R. Nos 75/2018 reg. 25, 40/2019 reg. 29, 116/2019 reg. 14.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
244
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
supply authority.
2 Demolition of a freestanding Class 10 building that—
(a) is not constructed of masonry; and(b) does not exceed 40 m2 in floor
area; and(c) will not adversely affect the safety
of the public or occupiers of the building; and
(d) is not work carried out on, or in connection with, a building included on the Heritage Register within the meaning of the Heritage Act 2017.
NoteThis building work may require approval from the Executive Director within the meaning of the Heritage Act 2017 under that Act.Certain building work that does not require a building permit may require a planning permit under the Planning and Environment Act 1987.
All Parts
3 Repair, renewal or maintenance of a part of an existing building, if the building work—
(a) will not adversely affect the structural soundness of the building, and does not include—(i) an increase or decrease in the
floor area or height of the building;
(ii) underpinning or replacement of footings; or
All Parts
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
245
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
(iii) the removal or alteration of any element of the building that is contributing to the support of any other element of the building; and
(b) is done using materials commonly used for the same purpose as the material being replaced; and
(c) will not adversely affect the safety of the public or occupiers of the building; and
(d) will not adversely affect an essential safety measure relating to the building.
NoteCertain building work that does not require a building permit may require a planning permit under the Planning and Environment Act 1987 or may be in a heritage overlay and be required to be maintained using particular materials.If the contract price for the carrying out of domestic building work is more than $5000 (or any higher amount fixed by the regulations made under the Domestic Building Contracts Act 1995), the builder is required to enter into a major domestic building contract with the owner under the Domestic Building Contracts Act 1995.
4 Alterations to a building, if the building work—
(a) will not adversely affect the structural soundness of the building, and does not include—
(i) an increase or decrease in the
Parts 3 to 19
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
246
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
floor area or height of the building; or
(ii) underpinning or replacement of footings; or
(iii) the removal or alteration of any element of the building that is contributing to the support of any other element of the building; and
(b) will not project beyond the street alignment; and
(c) will not adversely affect the safety of the public or occupiers of the building; and
(d) is not work carried out on, or in connection with, a building included on the Heritage Register within the meaning of the Heritage Act 2017; and
(e) is not work in relation to, and will not adversely affect, an essential safety measure relating to the building.
NoteCertain building work that does not require a building permit may require a planning permit under the Planning and Environment Act 1987 or may be in a heritage overlay and be required to be maintained using particular materials.If the contract price for the carrying out of domestic building work is more than $5000 (or any higher amount fixed by the regulations made under the Domestic Building Contracts Act 1995), the builder is required to enter into a major domestic building contract with the owner under the Domestic
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
247
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
Building Contracts Act 1995.
5 Any building that is not of a Class listed in clauses A6.1 to A6.10 of the BCA Volume One and clauses A6.1 to A6.10 of the BCA Volume Two.
All Parts
6 A building used only temporarily for the duration of building work for—
(a) construction purposes; or(b) display purposes.
All Parts
7 Temporary structures other than those to which regulation 207, item 20 or item 21 applies.
All Parts
8 A swimming pool or spa that is not capable of containing water to a depth of greater than 300 mm.
All Parts
* * * * *10 A fence (other than a fence forming part
of a safety barrier for a swimming pool or spa or a fence forming part of an outdoor play space associated with a children's service)—
(a) not exceeding 2 m in height; and(b) not exceeding 15 m in height
when within 3 m of a street (which is not a lane, footway, alley or right of way) alignment and which is not constructed of masonry, concrete or similar material; and
(c) not exceeding 12 m in height when within 3 m of a street (which is not a lane, footway,
All Parts except reg. 89(1) and Schedule 6
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
248
alley or right of way) alignment and which is constructed of masonry, concrete or similar material; and
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
(d) not exceeding 1 m in height above the footpath when within 9 m of a point of intersection of street alignments.
11 A chain wire fence surrounding a tennis court.
All Parts
12 A Class 10b structure constructed for the purpose of displaying a sign if that structure is—
(a) less than 3 m from a street alignment and does not exceed 1 m in height above ground level; or
(b) not less than 3 m from a street alignment and does not exceed—
(i) a height of 8 m above ground level; and
(ii) 6 m2 in display area.
All Parts
13 Any mast, pole, antenna, aerial or similar Class 10b structure—
(a) attached to a building and which does not exceed a height of 3 m above the highest point of the attachment to the building; or
(b) not attached to a building and which does not exceed a height of 8 m above ground level.
All Parts
14 Any facility (within the meaning of paragraph (b) of the definition of facility in section 7 of the Telecommunications Act 1997 of the Commonwealth) and construction or demolition of such a
Parts 3 to 19 except Part 5
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
249
facility by a carrier (within the meaning of that section).
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
15 Any retaining wall less than 1 m in height that is not associated with other building work or with protection of adjoining property.
Parts 3 to 19 except regulation 119
16 A pergola that—(a) is not more than 36 m in height;
and(b) in the case of a pergola that is
appurtenant to a Class 1 building, is located no further forward on the allotment than 2·5 m forward of the front wall of that building; and
(c) in any other case, is located no further forward on the allotment than the front wall of that building to which it is appurtenant; and
(d) has a floor area not exceeding 20 m2.
Parts 3 to 19
17 Installation of a wood or solid fuel household heating appliance.NoteInstallation of a wood or solid fuel burning heater is plumbing work and must be carried out by a licensed plumber.
Parts 3 to 19
18 A relocatable building that is a movable unit within the meaning of the Housing Act 1983 that is constructed for a community service and is to be used or intended to be used to provide temporary accommodation on a non-profit basis if—
(a) the building has a floor area not exceeding 30 m2; and
Parts 3 to 19
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
250
(b) the building is located no further forward on the allotment than the front wall of the building to which it is appurtenant; and
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
(c) the building or building work will not adversely affect the structural soundness of that, or any other building; and
(d) the building or building work will not adversely affect the safety of the public or the occupiers of the building; and
(e) the building is set back from an allotment boundary not less than 1 m; and
(f) the building does not exceed a height of 36 m; and
(g) the building work will not involve construction over an easement vested in a service authority from whom a report and consent is required under regulation 130.
19 A relocatable building used as a school or TAFE institute within the meaning of the Education and Training Reform Act 2006 if—
(a) the building has a floor area not exceeding 300 m2; and
Parts 3 to 19
(b) the building or building work will not adversely affect the structural soundness of that, or any other building; and
(c) the building or building work will not adversely affect the safety of the public or the occupiers of the building.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
251
20 Assembling, erecting or installing a relocatable swimming pool or a relocatable spa.
Parts 3 to 9, 10 to 19
Column 1
Item
Column 2
Description of building or building work exempted from building permit and occupancy permit
Column 3Building regulations that building or building work exempted from
21 Assembling, erecting or installing a swimming pool or spa barrier that is relocatable around a relocatable swimming pool or relocatable spa.
Parts 3 to 9, 10 to 19
22 Replacement or alteration of any part of a barrier for a swimming pool or spa if the building work is being carried out to rectify the non-compliance of the barrier with the applicable barrier standard identified in an inspection carried out by a swimming pool and spa inspector unless the building work involves—
(a) replacement or alteration of sections, parts or components of the barrier that when combined, comprise more than 50% of the existing length of the barrier; or
(b) replacement or alteration of posts or footings of the barrier; or
(c) the use of materials in the barrier that are not commonly used for the same purpose as the material being replaced in the barrier; or
(d) an increase or decrease in the length of the barrier, or the size of the area enclosed by the barrier; or
(e) replacement or alteration of any part of a retaining wall that forms part of the barrier.
Parts 3 to 9, 10 to 19
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
252
Schedule 4—FormsFORM 1
Regulation 24
Building Act 1993
Building Regulations 2018
APPLICATION FOR A BUILDING PERMIT
To (Building surveyor)
From
*Owner/*Agent of owner
*ACN/*ARBN
Postal address of applicant
Postcode
Address for serving or giving of documents
Postcode
Indicate if the applicant is a lessee or licensee of Crown land to which this application applies †
Contact person Telephone
Lessee responsible for building work
Indicate if a lessee of the building, of which parts are leased by different persons, is responsible for the alterations to a part of the building leased by that lessee †
*Ownership details (if applicant is agent of owner)
Name of owner(s) [insert full name(s)]
*ACN/*ARBN
Postal address
Postcode
Contact person Telephone
Sch. 4 Form 1 substituted by S.R. No. 75/2018 reg. 26.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
253
Property details
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district Allotment area (for new dwellings only) m2
Land owned by the Crown or a public authority †
Builder
Name Telephone
*ACN/*ARBN
*Building practitioner registration no.
Postal address Postcode
[If the builder is carrying out domestic building work under a major domestic building contract, attach an extract of the major domestic building contract showing the names of the parties to the contract in relation to the proposed building work and a copy of the certificate of insurance (if applicable).]
*Natural person for service of directions, notices and orders (if builder is a body corporate)
Name Telephone
Postal address Postcode
Building practitioner or architect engaged to prepare documents for this permit
[List any building practitioner or architect engaged to prepare documents forming part of the application for this permit.]
Name Category/class Registration no.
Name Category/class Registration no.
Nature of building work
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
254
Construction of a new building †
Demolition of a building †
Extension to an existing building †
Re-erection of a building †
Construction of swimming poolor spa †
Other [give description] †
Alterations to an existing building †
Removal of a building †
Change of use of an existing building †
Construction of swimming pool or spa barrier †
Proposed use of building
*Owner-builder
I intend to carry out the work as an owner-builder. [Yes/No]
Owner builder certificate of consent no. (if applicable)
Cost of building work
Is there a contract for the building work? [Yes/No]
If yes, state the contract price $
If no, state the estimated cost of the building work (including the cost of labour and materials) and attach details of the method of estimation $
Stage of building work
If application is to permit a stage of the work—
Extent of stage
Cost of work for this stage $
Signature
Signature of applicant
Date
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
255
FORM 2Regulation 37(1)
Building Act 1993
Building Regulations 2018
BUILDING PERMIT
Issued to
*Owner/*Agent of owner
*ACN/*ARBN
Postal address
Postcode
Address for serving or giving of documents
Postcode
Contact person Telephone
*Ownership details (if person issued with permit is not the owner)
Owner
*ACN/*ARBN
Postal address
Postcode
Contact person Telephone
Property details [include title details as and if applicable]
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Sch. 4 Form 2 substituted by S.R. No. 75/2018 reg. 26.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
256
Builder
Name Telephone
*ACN/*ARBN
*Building practitioner registration no.
Postal address Postcode
*This builder is specified under section 24B[state precise subsection] of the Building Act 1993 for the building work to be carried out under this permit.
*Natural person for service of directions, notices and orders (if builder is a body corporate)
Name Telephone
Postal address Postcode
Building practitioner or architect engaged to prepare documents for this permit
[List any building practitioner or architect engaged to prepare documents forming part of the application for this permit.]
Name Category/class Registration no.
Name Category/class Registration no.
*Details of domestic building work insurance
Name of builder Name of issuer or provider
Policy number Policy cover $
*Details of relevant planning permit
Planning permit no. Date of grant of planning permit
Nature of building work
Construction of a *new building/*extension/*alteration/*change of use/*demolition/*removal/*re-erection of a building
*Storeys contained
*Rise in storeys (for Class 2-9 building only)
*Effective height
*Type of construction
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
257
Version of BCA applicable to permit
Stage of building work permitted Cost of building work $
Total floor area of new building work in m2
Building classification
Part of building BCA Classification
Part of building BCA Classification
*Performance solution
A performance solution was used to determine compliance with the following performance requirements of the BCA that relate to the building to which this permit applies:
Relevant performance requirement Details of performance solution
[Insert details of performance solution(s) including applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
*Building Appeals Board determinations and orders
The following determinations and orders of the Building Appeals Board (the BAB) relate to the building work to which this permit applies:
Date of determination or order Determination or order
Section of the Building Act 1993 under which application to BAB made
[Insert details of determination or order including applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
258
*Prescribed reporting authorities
The following bodies are prescribed reporting authorities for the purposes of the application for this permit in relation to the matters set out below:
Reporting authority
Matter reported on or consented to
Regulation no.
*Combined allotment determination
A determination has been made under regulation 64(1) in relation to the building work that is the subject of this permit.
*Subdivision of existing building
This building permit authorises building work that involves the subdivision of an existing building.
An exemption has been issued under regulation 231 in relation to the building work that is the subject of this permit.
*Exemption from, or consent to partial compliance with, certain requirements
The following exemption from, or a consent to partial compliance with, certain requirements of the Building Regulations 2018 was granted or given under regulation 229(2), 231(2), 233(3) or 234(2) of the Building Regulations 2018 in relation to the building work to which this permit applies:
Part or whole of building or place of public entertainment or building work exempt from, or given consent to partial compliance with, requirements of the Building Regulations 2018 Nature and scope of exemption
[Specify the relevant regulation/ BCA performance requirement which the building, place of public entertainment or building work is exempt from or may partially comply with]
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
259
Protection work
Protection work *is/*is not required in relation to the building work proposed in this permit.
Inspection requirements
The mandatory notification stages are
[insert mandatory stages].
Occupation or use of building
An *occupancy permit/*certificate of final inspection is required prior to the occupation or use of this building.
If an occupancy permit is required, the permit is required for the *whole/*part of the building in relation to which the building work is carried out.
Commencement and completion
This building work must commence by [insert commencement date].
If the building work to which this building permit applies is not commenced by this date, this building permit will lapse unless an extension is applied for and granted by the relevant building surveyor before this date under regulation 59 of the Building Regulations 2018.
This building work must be completed by [insert completion date].
If the building work to which this building permit applies is not completed by this date this building permit will lapse, unless an extension is applied for and granted by the relevant building surveyor before this date under regulation 59 of the Building Regulations 2018.
*Conditions
This permit is subject to the following conditions
[insert conditions].
Relevant building surveyor
Name: [insert full name]
*ACN/*ARBN
Address:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
260
Email:
Building practitioner registration no.:
*Municipal district/*council name:
*Designated building surveyor:
*Name: [insert full name] Building practitioner registration number:
Permit no.: Date of issue of permit:
Signature:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
261
FORM 3Regulation 56
Building Act 1993
Building Regulations 2018
NOTICE OF IMMINENT LAPSE OF BUILDING PERMIT—COMMENCEMENT OF WORK
TO:
Applicant for building permit [insert full name]
of [insert address of service of the applicant]
Building permit details
Building permit number:
Commencement date of building work:
Date issued:
A copy of the relevant building permit is attached to this notice.
Property to which building permit relates
Property details [include title details as and if applicable]
Registered proprietor
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
262
FROM:
I am the relevant building surveyor appointed in relation to the issue of the building permit.
In accordance with regulation 56 of the Building Regulations 2018, I am required to give the applicant for the building permit described above notice of the imminent lapse of the building permit because it is 30 days before the commencement date of the building work and an inspection of the first mandatory notification stage of the work has not been carried out.
The building work to which the building permit described above applies must commence by [insert commencement date specified in building permit] or any extension granted to this date by the relevant building surveyor under regulation 59 of the Building Regulations 2018.
If the building work to which the building permit described above applies is not commenced by the commencement date, including any extension to that date, the building permit described above will lapse.
A building permit that has lapsed is no longer in force for the purposes of the Building Act 1993 and the Building Regulations 2018.
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Signature:
Date:
* Delete whichever is inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
263
FORM 4Regulation 57
Building Act 1993
Building Regulations 2018
NOTICE OF IMMINENT LAPSE OF BUILDING PERMIT—COMPLETION OF WORK
TO:
Applicant for building permit [insert full name]
of [insert address of service of the applicant]
Building permit details
Building permit number:
Completion date of building work:
Date issued:
A copy of the relevant building permit is attached to this notice.
Property to which building permit relates
Property details [include title details as and if applicable]
Registered proprietor
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
264
FROM:
I am the relevant building surveyor appointed in relation to the issue of the building permit.
In accordance with regulation 57 of the Building Regulations 2018, I am required to give the applicant for the building permit described above notice of the imminent lapse of the building permit because it is 30 days before the completion date of the building work and an inspection of the final mandatory notification stage of the work has not been carried out.
The building work to which the building permit described above applies must be completed by [insert completion date specified in building permit] or any extension granted to this date by the relevant building surveyor under regulation 59 of the Building Regulations 2018.
If the building work to which the building permit described above applies is not completed by the completion date including any extension to that date, the building permit described above will lapse.
A building permit that has lapsed is no longer in force for the purposes of the Building Act 1993 and the Building Regulations 2018.
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Signature:
Date:
* Delete whichever is inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
265
FORM 5Regulation 64(3)
Building Act 1993
Building Regulations 2018
DETERMINATION THAT COMBINED ALLOTMENT IS ONE ALLOTMENT
Given to
Owner of allotment 1 in combined allotment:
Telephone:
Email:
Postal address:
Postcode:
Owner of *allotment 2/*adjoining land in combined allotment:
Telephone:
Email:
Postal address:
Postcode:
[insert details of any other owners if more than 2 pieces of land in combined allotment]
Details of land in combined allotment to which this determination applies
Allotment 1, property details [include title details as and if applicable]
Owner
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Sch. 4 Form 5 amended by S.R. No. 75/2018 reg. 27(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
266
*Allotment 2/*adjoining land property details [include title details as and if applicable]
Owner
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
[insert details of any additional allotments or land to which the application applies]
DETERMINATION
I am the *municipal building surveyor/*private building surveyor and I have determined that the combined allotment to which this determination applies can be treated as one allotment for the purposes of the Building Act 1993 and the Building Regulations 2018.
In making this determination I have considered the matters set out in regulation 64(2) of the Building Regulations 2018 and make the following statements:
(1) The proposed building work to be carried out on the combined allotment is [insert description of proposed building work].
(2) I am satisfied that the proposed building work will not adversely impact on the structural adequacy of any existing building on the combined allotment for the following reason(s) [insert reasons].
(3) I am satisfied that reasonable provision will be made for the amenity of any building on the combined allotment for the following reason(s) [insert reasons].
(4) I am satisfied that reasonable provision will be made for the safety and health of people using any building on the combined allotment for the following reason(s) [insert reasons].
(5) I am satisfied that reasonable provision will be made for avoiding the spread of fire to or from any adjoining building on the combined allotment for the following reason(s) [insert reasons].
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
267
Made by *municipal building surveyor/*private building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Related building permit no. (if issued before determination made):
Signature:
Date:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
268
FORM 6Regulation 111(4)
Building Act 1993
Building Regulations 2018
DETERMINATION THAT PROTECTION WORK IS REQUIRED
Issued to
Owner (referred to throughout this determination as the Owner)
Telephone
Postal address
Postcode
*Agent of owner
Telephone
Postal address
Postcode
Property subject to building permit application (referred to throughout this determination as the Owner's property)
Property details [include title details as and if applicable]
Registered proprietor
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Building permit application details (referred to throughout this determination as the Owner's building permit application)
Applicant
Date of application
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
269
Nature of building work
Construction of a new building †
Demolition of a building †
Extension to an existing building †
Re-erection of a building †
Construction of swimming poolor spa †
Other †
Alterations to an existing building †
Removal of a building †
Change of use of an existing building †
Construction of swimmingpool or spa barrier †
Details of each adjoining property (referred to throughout this determination as an adjoining property)
[list each adjoining property, include title details as and if applicable]
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
MATTERS CONSIDERED IN MAKING THIS DETERMINATION
In making this determination I have considered the following matters set out in regulation 112 of the Building Regulations 2018:
Allotment plan provided to me under regulation 25
†
Allotment plan provided to me under regulation 26
†
Specifications describing materials and methods to be used in the proposed building work
†
Any certificate under section 238 of the Building Act 1993 from the engineer who designed the building
Demolition required as part of the proposed building work †
Excavation required as part of the proposed building work †
Any proposed building work in relation to party walls and retaining walls †
Any certificate under section 238 of the Building Act 1993 from an independent engineer who is a registered building practitioner in the category of engineer, class of engineer (civil), certifying that the structural design of the building work complies with that Act and the Building
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
270
work who is a registered building practitioner in the category of engineer, class of engineer (civil)
†
The nature and likely extent of any damage or other adverse effect on the stability or otherwise of an
adjoining property that may be caused by the proposed buildingwork
†
Regulations 2018 †
Other matters that I consider appropriate to determine the need for protection work †
DETERMINATION
1. I am the relevant building surveyor appointed on [insert date] under Part 6 of the Building Act 1993 by or on behalf of the Owner in relation to the Owner's building permit application.
2. I am required by the Building Regulations 2018 to determine if protection work is required for any adjoining property as a result of building work proposed in the Owner's building permit application.
3. I have determined that the Owner must carry out protection work in respect of each adjoining property identified in this determination in accordance with Part 7 of the Building Act 1993 and Part 7 of the Building Regulations 2018.
4. The proposed building work that gives rise to the need for protection work is [insert description of all building work proposed in the Owner's building permit application which poses a risk of significant damage to an adjoining property identified above].
5. This determination triggers the protection work process set out in Part 7 of the Building Act 1993, which is supported by Part 7 of the Building Regulations 2018.
Made by relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
271
*Municipal district/*council name:
Related building permit no. (if known):
Date of issue of determination:
Signature:
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
272
FORM 7Regulation 113
Building Act 1993
Building Regulations 2018
PROTECTION WORK NOTICE
To
Adjoining owner
Postal address
Postcode
Relevant building surveyor
Postal address
Postcode
Contact person Telephone
Adjoining owner's property details (the adjoining property)
Number Street/road City/suburb/town
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
From
*Owner/*agent
Name of owner [insert full name]
*ACN/*ARBN
Postal address
Postcode
Contact person Telephone
Sch. 4 Form 7 amended by S.R. No. 40/2019 reg. 30(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
273
Owner's property details
Number Street/road City/suburb/town
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
*Name of agent
*ACN/*ARBN
Postal address
Postcode
Contact person Telephone
NOTICE
In accordance with section 84 of the Building Act 1993, I give notice of my intention to carry out the following building work on my property and request your agreement to the proposed protection work which affects your adjoining property.
In accordance with section 85 of the Building Act 1993, and subject to sections 90 and 91 of that Act, you will be taken to have agreed to the protection works proposed in this notice if you do not respond within 14 days after this notice is served on you.
A response to this notice must be in the form of Form 8 of the Building Regulations 2018, include the information in that form, and be given to the owner and the relevant building surveyor whose details are set out in this notice.
Details of proposed building work
[insert details including details about damage etc. that may be caused to adjoining property]
Details of proposed protection work
[insert the nature, location, time and duration of the proposed protection work, including the extent to which access to the adjoining property will be required for the purpose of undertaking the proposed protection work]
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
274
Information about protection of an adjoining owner under the Building Act 1993 in relation to proposed protection work
In accordance with section 92 of the Building Act 1993, at any time after this notice is given to the adjoining owner, the relevant building surveyor must make available to the adjoining owner, on request, for inspection, without charge, any plans, drawings and specifications of the proposed building work in the possession or control of the relevant building surveyor. The relevant building surveyor's name and contact details are on page 1 of this notice.
If the proposed protection work is agreed to by the adjoining owner or determined as being appropriate by the relevant building surveyor under section 87(1) of the Building Act 1993 or by the Building Appeals Board under section 141 of the Building Act 1993 (as the case requires), the owner must—
(a) before the commencement of any protection work—
(i) ensure that a contract of insurance is in force in accordance with section 93 of the Building Act 1993 against damage by the protection work to the adjoining property and other liabilities described in that section; and
(ii) make a full and adequate survey of the adjoining property in accordance with section 94 of the Building Act 1993; and
(b) pay to an adjoining owner all costs and expenses necessarily incurred by the adjoining owner in assessing proposed protection work and in supervising the carrying out of protection work in relation to an adjoining property in accordance with section 97 of the Building Act 1993; and
(c) compensate an adjoining owner or an adjoining occupier for inconvenience, loss or damage suffered by the adjoining owner or adjoining occupier in connection with the carrying out of protection work in accordance with section 98 of the Building Act 1993 or an order of the Building Appeals Board under section 159 of that Act.
Signature
Signature of *owner/*owner's agent
Date
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
275
FORM 8Regulation 114
Building Act 1993
Building Regulations 2018
PROTECTION WORK RESPONSE NOTICE
To
*Owner/*owner's agent
Postal address
Postcode
Address of owner's property on which building work is to be carried out
Number Street/road City/suburb/town
Relevant building surveyor
Postal address
Postcode
From
*Adjoining owner/*adjoining owner's agent
Postal address
Postcode
Contact person Telephone
Address of my adjoining property
Number Street/road City/suburb/town
Response from adjoining owner
In accordance with section 85 of the Building Act 1993, I am responding to the notice served on me by the owner under section 84 of that Act and—
(a) agree to the proposed protection work †
(b) disagree with the proposed protection work †
(c) request the following further information †
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
276
Signature
Signature of *adjoining owner/*adjoining owner's agent
Date
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
277
FORM 9Regulation 115(a)
Building Act 1993
Building Regulations 2018
NOTICE OF DETERMINATION UNDER SECTION 87 OF THE ACT
To
*Owner/*owner's agent
Postal address
Postcode
Address of owner's property on which building work is to be carried out
Number Street/road
City/suburb/town
Relevant building surveyor
Postal address
Postcode
And to
*Adjoining owner/*adjoining owner's agent
Postal address
Postcode
Contact person Telephone
Address of adjoining property
Number Street/road City/suburb/town
DETERMINATION
1. I am the relevant building surveyor appointed on [insert date] under Part 6 of the Building Act 1993 by or on behalf of the owner, [insert full name of owner of the property on which building work is being carried out].
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
278
2. On [insert date] I received from the adjoining owner a notice under section 85(1)(b) of the Building Act 1993 (the adjoining owner's notice).
3. In the adjoining owner's notice, the adjoining owner *disagreed with the proposed protection work/*required more information to be given to enable the proposal for protection work to be considered by me. I attach a copy of the adjoining owner's notice to this determination.
4. As a result of the adjoining owner's notice, I am required by the Building Act 1993 to examine the owner's proposal for protection work.
5. I received the owner's proposal for protection work under section 84 of the Building Act 1993 on [insert date] (the owner's proposal for protection work). I attach the owner's proposal for protection work to this determination.
6. In making this determination, I have examined the owner's proposal for protection work.
*7. Before making this determination, I requested the following additional information from the owner under section 87(2)(a) of the Building Act 1993 [specify relevant information]. I received this information on [insert date].
*8. On [insert date], I made a copy of the additional information (referred to in paragraph 7 above) available to the adjoining owner.
*9. In determining the appropriateness or otherwise of the owner's proposal for protection work, I made the following inquiries under section 87(3) of the Building Act 1993 [specify any relevant inquiry made].
10. After considering all matters required of me under the Building Act 1993 and the Building Regulations 2018, I determine the owner's proposal for protection work is *appropriate/*not appropriate.
Made by relevant building surveyor
Name: [insert full name]
Address:
Email:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
279
Building practitioner registration no.:
*Municipal district/*council name:
Related building permit no. (if known):
Date determination made:
Signature:
Rights of appeal under section 141 of the Building Act 1993
An owner required to carry out protection work or an adjoining owner may appeal to the Building Appeals Board against—
(a) a determination under section 87 of the Building Act 1993 as to the appropriateness of the work; or
(b) a declaration under section 89 of the Building Act 1993; or
(c) a failure, within a reasonable time, or refusal to make that determination or declaration; or
(d) a request under section 87 of the Building Act 1993 to give more information.
Appeal period
For the purposes of section 146 of the Building Act 1993, the prescribed appeal period for an appeal against a determination by the relevant building surveyor under section 87(1) of the Building Act 1993 is 14 days from the day the owner and the adjoining owner are given notice of the determination.
A determination by the relevant building surveyor under section 87(1) of the Building Act 1993, does not take effect until—
(a) the end of the prescribed appeal period of 14 days, if there is no appeal; or
(b) the decision is affirmed on appeal.
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
280
FORM 10Regulation 178
Building Act 1993
Building Regulations 2018
EMERGENCY ORDER
This emergency order is made under section 102 of the Building Act 1993.
*WARNING: THIS ORDER HAS BEEN SERVED IN ACCORDANCE WITH SECTION 236(4A) OF THE BUILDING ACT 1993. UNDER SECTION 236(7) OF THAT ACT, IT IS AN OFFENCE FOR A PERSON TO REMOVE OR DEFACE THIS ORDER WITHOUT THE PRIOR CONSENT OF THE RELEVANT BUILDING SURVEYOR, THE RELEVANT COUNCIL OR THE VICTORIAN BUILDING AUTHORITY. THE MAXIMUM PENALTY FOR THIS OFFENCE IS 500 PENALTY UNITS FOR A NATURAL PERSON AND 2500 PENALTY UNITS FOR A BODY CORPORATE.
TO:
The *owner/*occupier/*builder/*person or class of person [insert full name or describe class of person]
Of [insert address for service on the owner, occupier, builder or person or class of person]
*AND TO:
Any other person or class of person [insert full name or describe class of person]
Of [insert address for service on person or class of person]
Sch. 4 Form 10 amended by S.R. Nos 180/2018 reg. 13(1), 40/2019 reg. 30(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
281
FROM:
I am the municipal building surveyor of [insert name of municipal district].
The municipal building surveyor is authorised to cause an emergency order to be served on the *owner/*occupier/*builder of the *building/*land/*place of public entertainment to which this order applies under Division 1 of Part 8 of the Building Act 1993.
LOCATION OF THE *BUILDING/*LAND/*PLACE OF PUBLIC ENTERTAINMENT TO WHICH THIS ORDER APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
ORDER:
I, being the municipal building surveyor, order that:
*1. By [insert time] on [insert date], the *owner/*occupier of [insert description and address of building, land or place of public entertainment] must evacuate the *building/*land/*place of public entertainment.
*2. By [insert time] on [insert date], [specify the person or class of person served with this order] must vacate the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment].
Note: This order may only be made if order 1 is made.
*3. At [insert time] on [insert date], entry into the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition].
*4. At [insert time] on [insert date], use of the *building/*land/*place of public entertainment [insert description and address of building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition] for [specified prohibited use].
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
282
*5. At [insert time] on [insert date], occupation of the *building/ *land/ *place of public entertainment [insert description and address of relevant building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition].
*6. The *owner/*occupier of the place of public entertainment [insert description and address of place of public entertainment] must not conduct nor allow the conduct of a public entertainment at this place of public entertainment.
*7. The *owner/*occupier of the place of public entertainment [insert description and address of place of public entertainment] must immediately cease to conduct *all/*specified public entertainment [specify public entertainment to be ceased if applicable] at this place of public entertainment.
*8. By [insert time] on [insert date], the *owner/*occupier must stop building work on the *building/*land/*place of public entertainment [insert description and address of building, land or place of public entertainment] that is [insert description of building work that must stop].
*9. By [insert time] on [insert date], the *owner/*occupier of [insert description and address of building, land or place of public entertainment] must carry out the following building work or other work [insert detailed description of building work or other work required to be carried out by this order] to make the *building/ *land/*place of public entertainment safe.
*10. By [insert time] on [insert date], the *owner/*occupier of [insert description and address of building, land or place of public entertainment] must carry out the following building work or other work [insert detailed description of building work or other work required to be carried out by this order] to secure the *building/ *land/*place of public entertainment from access.
*11. By [insert time] on [insert date], the owner must cause the *building/*land/*place of public entertainment [insert description and address of relevant building, land or place of public entertainment] to be inspected by [name of specified person].
*12. By [insert time] on [insert date], the *owner/*builder must cause [specified material] used in the *building/*land/*place of public entertainment [insert description and address of building, land or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
283
place of public entertainment] to be tested by [name of specified person].
*13. By [insert time] on [insert date], the *owner/*builder must cause [insert the building product or material] used in the building [insert description and address of building] to be destructively tested by a prescribed testing authority.
14. The *owner/*builder must provide the results of the destructive testing to *the municipal building surveyor/*[name and address of other person authorised by the municipal building surveyor to receive the results] within [specified time] after the prescribed testing authority completes the destructive testing.
*INSPECTION DETAILS:
*The date and time of any inspection of the *building/*land/*place of public entertainment carried out by me, as the municipal building surveyor, are:
Time of inspection:
Date of inspection:
[list any inspections carried out by municipal building surveyor]
*The date and time of any inspection of the *building/*land/*place of public entertainment relied on by me as the municipal building surveyor for the purpose of making this order, and the name and qualifications of the person or persons who conducted the inspection, are:
Time of inspection:
Date of inspection:
Name of person/persons:
Qualification(s) of person/persons:
*Building practitioner registration no. of person/persons:
[List details of any inspections relied on by the municipal building surveyor]
REASON(S) WHY THIS EMERGENCY ORDER WAS MADE:
In accordance with section 102 of the Building Act 1993, I am of the opinion that this order is necessary because of a—
*Danger to life arising out of the condition of the *building/*land/*place of public entertainment
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
284
[state reason(s) why the condition of the building, land or place of public entertainment causes a danger to life]
*Danger to life arising out of the use of the *building/*land/*place of public entertainment
[state reason(s) why the use of the building, land or place of public entertainment causes a danger to life]
*Danger to life arising out of a proposed use of the *building/*land/ *place of public entertainment
[state reason(s) why a proposed use of the building, land or place of public entertainment may cause a danger to life]
*Danger to property arising out of the condition of the *building/*land/ *place of public entertainment
[state reason(s) why the condition of the building, land or place of public entertainment causes a danger to property]
*Danger to property arising out of the use of the *building/*land/*place of public entertainment
[state reason(s) why the use of the building, land or place of public entertainment causes a danger to property]
*Danger to property arising out of a proposed use of the *building/ *land/*place of public entertainment
[state reason(s) why a proposed use of the building, land or place of public entertainment causes a danger to property]
EMERGENCY ORDER MADE AND SERVED BY:
The municipal building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
Municipal district:
Signature:
Emergency order no.:
Date of making:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
285
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
286
FORM 11Regulation 180
Building Act 1993
Building Regulations 2018
BUILDING NOTICE
This building notice is served under section 106 of the Building Act 1993.
*WARNING: THIS NOTICE HAS BEEN SERVED IN ACCORDANCE WITH SECTION 236(4A) OF THE BUILDING ACT 1993. UNDER SECTION 236(7) OF THAT ACT, IT IS AN OFFENCE FOR A PERSON TO REMOVE OR DEFACE THIS NOTICE WITHOUT THE PRIOR CONSENT OF THE RELEVANT BUILDING SURVEYOR, THE RELEVANT COUNCIL OR THE VICTORIAN BUILDING AUTHORITY. THE MAXIMUM PENALTY FOR THIS OFFENCE IS 500 PENALTY UNITS FOR A NATURAL PERSON AND 2500 PENALTY UNITS FOR A BODY CORPORATE.
TO:
The owner [insert full name]
Of [insert address for service on the owner]
FROM:
*I am the private building surveyor appointed to carry out functions under the Building Act 1993 in relation to the *building/*land/*place of public entertainment which is the subject of this notice.
*I am the municipal building surveyor of [insert name of municipal district].
I am authorised to cause a building notice to be served on you, as owner of the *building/*land/*place of public entertainment to which this notice applies, under Division 2 of Part 8 of the Building Act 1993.
Sch. 4 Form 11 amended by S.R. Nos 180/2018 reg. 13(2), 40/2019 reg. 30(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
287
LOCATION OF THE *BUILDING/*LAND/*PLACE OF PUBLIC ENTERTAINMENT TO WHICH THIS NOTICE APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
*INSPECTION DETAILS:
*The date and time of an inspection of the *building/*land/*place of public entertainment carried out by myself as the relevant building surveyor was:
Time of inspection:
Date of inspection:
[list any inspections carried out by the relevant building surveyor]
*The date and time of an inspection relied on by myself as the relevant building surveyor for the purpose of serving this notice, and the name and qualifications of the person or persons who conducted the inspection, are:
Time of inspection:
Date of inspection:
Name of person/persons:
Qualification(s) of person/persons:
*Building practitioner registration no. of person/persons:
[list details of any inspections relied on by the relevant building surveyor]
REASON(S) WHY THIS NOTICE WAS SERVED:
In accordance with section 106 of the Building Act 1993, I am of the opinion that the following *circumstance/*circumstances exist(s):
*Building work carried out without a building permit being issued and in force under the Building Act 1993
The following building work has been carried out on the *building/*land/ *place of public entertainment without a building permit as required by the Building Act 1993
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
288
[insert description here of building work carried out on the relevant building, land or place of public entertainment without a building permit, including details of when this building work was carried out]
*Building work carried out in contravention of a building permit
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of a building permit.
The particulars of the relevant building permit are:
Building permit no.:
Date of issue of building permit:
The building work that contravenes the building permit is: [insert description of relevant building work and state reason(s) why the building work does not comply with the building permit identified above]
A copy of the relevant building permit is attached to this order.
*Building work has been carried out in contravention of the Building Act 1993
The following building work has been carried out on the *building/*land/ *place of public entertainment in contravention of the Building Act 1993:
[insert description of relevant building work and state reason(s) why this building work does not comply with the Building Act 1993, using specific references to the section(s) of that Act that have been breached by the building work]
*Building work carried out in contravention of the Building Regulations 2018 (this includes building work carried out in contravention of the Building Code of Australia)
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of the Building Regulations 2018.
[insert description of relevant building work and state reason(s) why building work does not comply with the Building Regulations 2018, using specific references to the regulation(s) that have been breached by the building work, including clauses of the BCA if applicable]
*Use of building or place of public entertainment in contravention of the Building Act 1993
The use of the *building/*place of public entertainment contravenes the Building Act 1993.
[state reason(s) why use or uses of the building or place of public entertainment do not comply with the Building Act 1993, using specific
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
289
references to the section(s) of that Act that have been breached by the use or uses]
*Use of *building/*place of public entertainment in contravention of the Building Regulations 2018
The use of the *building/*place of public entertainment contravenes the Building Regulations 2018.
[state reason(s) why the use or uses of the building or place of public entertainment do not comply with the Building Regulations 2018, using specific references to the regulation(s) that have been breached by the use or uses]
*Safety or emergency services, installations or equipment have not been maintained in accordance with the occupancy permit and the Building Regulations 2018
The following safety or emergency service(s), installation(s) or equipment have not been maintained in accordance with the occupancy permit and the Building Regulations 2018.
[insert description of each safety or emergency service, installation or equipment that has not been maintained, using specific references to the regulation(s) or the requirement(s) in the occupancy permit that the emergency service, installation or equipment has not been maintained in accordance with].
*Building/*place of public entertainment unfit for occupation or use as a place of public entertainment
*The building is unfit for occupation.
*The place of public entertainment is unfit for occupation or for use as a place of public entertainment.
[state reason(s) why the building or place of public entertainment is unfit for occupation or for use as a place of public entertainment]
*Danger to life, safety or health from *building/*land/*place of public entertainment
The *building/*land/*place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the *building/*land/*place of public entertainment or to any property.
[state reason(s) why the building, land or place of public entertainment or building work on the building, land or place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the building, land or place of public entertainment or to any property]
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
290
*Danger to life, safety or health from building work
Building work on the *building/*land/*place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the *building/*land/*place of public entertainment or to any property.
[state reason(s) why building work on the building, land or place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the building, land or place of public entertainment or to any property]
*Failure to comply with a direction to fix building work under Division 2 of Part 4 of the Building Act 1993
There has been a failure to comply with a direction to fix building work under Division 2 of Part 4 of the Building Act 1993.
[state reason(s) why the building surveyor issuing this notice believes the direction has not been complied with]
A copy of the relevant direction is attached to this notice.
SHOW CAUSE PROCESS:
Under section 108 of the Building Act 1993, you are required to show cause within 30 days of the date of service of this notice—
*why entry, use, or occupation of the *building/*land/*place of public entertainment should not be prohibited.
*why you should not be required to evacuate the *building/*land/*place of public entertainment.
*why you should not be required to carry out the building work, protection work or work required by the Building Regulations 2018 identified in this notice in relation to the *building/*land/*place of public entertainment.
[insert description of building work, protection work or other work that may be required by a building order to remedy the circumstances identified in this notice]
Specified period for making representations:
[insert specified period for making representations]
Specified manner for making representations:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
291
The manner for making representations in response to the matters contained in this notice is [insert specifics of the relevant building surveyor's preferred manner for receiving representations in response to this notice].
BUILDING NOTICE SERVED BY:
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Building notice no.:
Date of making:
Signature:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
292
FORM 12Regulation 182(1)
Building Act 1993
Building Regulations 2018
BUILDING ORDER (GENERAL)
This building order is made under section 111 of the Building Act 1993.
*WARNING: THIS ORDER HAS BEEN SERVED IN ACCORDANCE WITH SECTION 236(4A) OF THE BUILDING ACT 1993. UNDER SECTION 236(7) OF THAT ACT, IT IS AN OFFENCE FOR A PERSON TO REMOVE OR DEFACE THIS ORDER WITHOUT THE PRIOR CONSENT OF THE RELEVANT BUILDING SURVEYOR, THE RELEVANT COUNCIL OR THE VICTORIAN BUILDING AUTHORITY. THE MAXIMUM PENALTY FOR THIS OFFENCE IS 500 PENALTY UNITS FOR A NATURAL PERSON AND 2500 PENALTY UNITS FOR A BODY CORPORATE.
TO:
The *owner/*occupier/*any person/*class of person [insert full name or describe class of person]
Of [insert address for service of owner, occupier or person or class of person]
*AND TO:
Any other person or class of person [insert full name or describe class of person]
Of [insert address for service on person or class of person]
FROM:
*I am the private building surveyor appointed to carry out functions under the Building Act 1993 in relation to the *building/*land/*place of public entertainment which is the subject of this building order.
*I am the municipal building surveyor of [insert name of municipal district].
Sch. 4 Form 12 amended by S.R. Nos 180/2018 reg. 13(3), 40/2019 reg. 30(4).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
293
I am authorised to make a building order under section 111 of the Building Act 1993.
LOCATION OF THE *BUILDING/*LAND/*PLACE OF PUBLIC ENTERTAINMENT TO WHICH THIS NOTICE APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
ORDER:
I, as the relevant building surveyor, order that:
*1. By [insert time] on [insert date], the *owner/*occupier of the [insert description and address of building/land/place of public entertainment] MUST evacuate the *building/*land/*place of public entertainment.
*2. By [insert time] on [insert date], any person or class of person served with this order must vacate the *building/*land/*place of public entertainment [insert description and address of building, land or place of public entertainment].
*3. At [insert time] on [insert date], entry into the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition] unless permitted by the municipal building surveyor.
*4. At [insert time] on [insert date], use of the *building/*land/*place of public entertainment [insert description and address of building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition] for [specified prohibited use] unless permitted by the municipal building surveyor.
*5. At [insert time] on [insert date], occupation of the *building/*land/ *place of public entertainment [insert description and address of relevant building, land or place of public entertainment] by [specify person or class of person served with this order] is prohibited for a period of [insert period of time of prohibition] unless permitted by the municipal building surveyor.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
294
*6. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following building work [insert detailed description of building work required to be carried out by this order].
*7. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following protection work [insert detailed description of protection work required to be carried out by this order].
*8. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following other work as required by the Building Regulations 2018 in relation to the *building/*land/*place of public entertainment [insert detailed description of other work required to be carried out by the Building Regulations 2018, including the BCA. Include references to the relevant regulation and/or clauses of the BCA].
*9. By [insert time] on [insert date], the owner must cause the *building/*land/*place of public entertainment [insert description and address of relevant building, land or place] to be inspected by [name of specified person].
*10. By [insert time] on [insert date], the *owner/*builder must cause [describe specified material] used in the *building/*land/*place of public entertainment [insert description and address of building, land or place of public entertainment] to be tested by [name of specified person].
*11. By [insert time] on [insert date], the *owner/*builder must arrange for [insert the building product or material] used in the building [insert description and address of building] to be destructively tested by a prescribed testing authority.
12. The *owner/*builder must provide the results of the destructive testing to *the relevant building surveyor/*[name and address of other person authorised by the relevant building surveyor to receive the results] within [specified time] after the prescribed testing authority completes the destructive testing.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
295
REASON(S) WHY THIS ORDER WAS MADE:
In accordance with section 111 of the Building Act 1993, I am of the opinion that the following *circumstance/*circumstances exist(s):
*Building work was carried out without a building permit being issued and in force under the Building Act 1993
The following building work has been carried out on the *building/*land/ *place of public entertainment without a building permit as required by the Building Act 1993:
[insert description here of building work carried out on the relevant building, land or place of public entertainment without a building permit]
*Building work carried out in contravention of a building permit
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of a building permit.
The particulars of the relevant building permit are—
Building permit no.:
Date of issue of building permit:
The building work that contravenes the permit is [describe work].
[state reason(s) for why the building work does not comply with the building permit identified immediately above]
A copy of the relevant building permit is attached to this order.
*Building work has been carried out in contravention of the Building Act 1993
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of the Building Act 1993.
The building work that contravenes the Building Act 1993 is [describe work].
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
296
[state reason(s) why building work does not comply with the Building Act 1993, using specific references to the section(s) of that Act that have been breached by the building work]
*Building work has been carried out in contravention of the Building Regulations 2018 (this includes building work carried out in contravention of the Building Code of Australia)
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of the Building Regulations 2018.
The building work that contravenes the Building Regulations 2018 is [describe work].
[state reason(s) why building work does not comply with the Building Regulations 2018, using specific references to the regulation(s) that have been breached by the building work, including clauses of the BCA if applicable]
*The use of the building or place of public entertainment contravenes the Building Act 1993
The use of the *building/*place of public entertainment as a [insert description of use] contravenes the Building Act 1993.
[state reason(s) why use or uses of the building or place of public entertainment do not comply with the Building Act 1993, using specific references to the section(s) of that Act that have been breached by the use or uses]
*The use of the building or place of public entertainment contravenes the Building Regulations 2018
The use of the *building/*place of public entertainment as a [insert description of use] contravenes the Building Regulations 2018.
[state reason(s) why the use or uses of the building or place of public entertainment do not comply with the Building Regulations 2018, using specific references to the regulation(s) that have been breached by the use or uses]
*Safety or emergency services, installations or equipment have not been maintained in accordance with the occupancy permit and the Building Regulations 2018
Safety or emergency services, installations or equipment in the *building/ *land/*place of public entertainment have not been maintained in accordance with the occupancy permit and the Building Regulations 2018.
[detail the safety or emergency services, installations or equipment that have not been maintained, and identify the requirement in the occupancy
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
297
permit or the Building Regulations 2018 that each safety or emergency service, installation or equipment has not been maintained in accordance with]
*Building or place of public entertainment is unfit for occupation
*The building is unfit for occupation.
*The place of public entertainment is unfit for occupation or for use as a place of public entertainment.
[state reason(s) why the building or place of public entertainment is unfit for occupation or for use as a place of public entertainment]
*A building or place of public entertainment is a danger to life, safety or health
The *building/*land/*place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the *building/*land/*place of public entertainment or to any property.
[state reason(s) why the building, land or place is a danger to the life, safety or health of any member of the public or of any person using the building, land or place of public entertainment or to any property]
*Building work is a danger to life, safety or health
Building work on the *building/*land/*place of public entertainment is a danger to the life, safety or health of any member of the public or of any person using the *building/*land/*place of public entertainment or to any property.
[state reason(s) why building work on the building, land or place is a danger to the life, safety or health of any member of the public or of any person using the building, land or place of public entertainment or to any property]
DETAILS OF RELEVANT BUILDING NOTICE:
Date of service of building notice:
Due date for making representations as specified in the building notice:
A copy of the relevant building notice is attached to this building order.
At the date of making this order, the due date for the owner to make representations has now expired.
*Representations were made by the owner. After considering these representations, I am of the opinion that, for the reasons set out in this order, the making of this building order is warranted.
*Representations were not made by the owner.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
298
*INSPECTION DETAILS:
*The date and time of any inspection of the *building/*land/*place of public entertainment carried out by myself as the relevant building surveyor was—
Time of inspection:
Date of inspection:
[list any inspections carried out by the relevant building surveyor]
*The date and time of any inspection relied on by myself as the relevant building surveyor for the purpose of making this order, and the name and qualifications of the person or persons who conducted the inspection are—
Time of inspection:
Date of inspection:
Name of person/persons:
Qualification(s) of person/persons:
*Building practitioner registration no. of person/persons:
[list details of any inspections relied on by the relevant building surveyor]
BUILDING ORDER MADE BY:
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Building order no.:
Signature:
Date of making:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
299
FORM 13Regulation 182(2)
Building Act 1993
Building Regulations 2018
BUILDING ORDER TO STOP BUILDING WORK
This building order is made under section 112 of the Building Act 1993.
TO:
The owner [insert full name]
Of [insert address for service on the owner]
OR
TO:
Other person [insert name of person other than the owner required by this building order to stop building work]
Of [insert address for service on person named immediately above]
FROM:
*I am the private building surveyor appointed to carry out functions under the Building Act 1993 in relation to the *building/*land/*place of public entertainment which is the subject of this building order.
*I am the municipal building surveyor of [insert name of municipal district].
I am authorised by section 112 of the Building Act 1993 to make this building order.
LOCATION OF THE *BUILDING/*LAND/*PLACE OF PUBLIC ENTERTAINMENT TO WHICH THIS ORDER APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Sch. 4 Form 13 amended by S.R. No. 40/2019 reg. 30(5).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
300
STOP WORK ORDER:
I, as the relevant building surveyor, order that:
*1. By [insert time] on [insert date], the owner must stop the following building work on the *building/*land/*place of public entertainment located at [insert address]: [insert description of building work that must stop].
*2. By [insert time] on [insert date], [insert name of person other than owner who is subject to this stop work order] must stop the following building work on the *building/*land/*place of public entertainment located at [insert address]: [insert description of building work that must stop].
*EXEMPT BUILDING WORK:
The following building work or part of the building work is exempt from this stop work order:
[Specify building work that is exempt from the stop work order if the relevant building surveyor considers that it is necessary for the exempt work to be carried out and the reasons for the exemption *in the interests of the safety or security of the building, land or place of public entertainment on which the building work is being carried out/*in the interests of the safety or health of any member of the public/*to prevent a nuisance to members of the public or occupiers of nearby properties.]
*INSPECTION DETAILS:
*The date and time of any inspection/s of the *building/*land/*place of public entertainment carried out by myself as the relevant building surveyor was—
Time of inspection:
Date of inspection:
[list any inspections carried out by the relevant building surveyor]
*The date and time of any inspection relied on by myself as the relevant building surveyor for the purpose of making this order, and the name and qualifications of the person or persons who conducted the inspection are—
Time of inspection:
Date of inspection:
Name of person/persons:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
301
Qualification(s) of person/persons:
*Building practitioner registration no. of person/persons:
[list details of any inspections relied on by the relevant building surveyor]
REASON(S) WHY THIS ORDER WAS MADE:
In accordance with section 112 of the Building Act 1993, I am of the opinion that—
*Building work contravenes the Building Act 1993
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of the Building Act 1993. The building work that contravenes the Building Act 1993 is [describe work].
[state reason(s) why the building work does not comply with the Building Act 1993, using specific references to the section(s) of that Act that have been breached by the building work]
*Building work contravenes the Building Regulations 2018
Building work has been carried out on the *building/*land/*place of public entertainment in contravention of the Building Regulations 2018.
The building work that contravenes the Building Regulations 2018 is [describe work].
[state reason(s) why the building work does not comply with the Building Regulations 2018, using specific references to the regulation(s) that have been breached by the building work, including clauses of the BCA where applicable]
*Building work is a danger to life, safety or health
Building work is a danger to the life, safety or health of any member of the public or of any person using the *building/*land/*place of public entertainment or to any property.
The building work that is a danger to life, safety or health is [describe work].
[state reason(s) why the building work is a danger to the life, safety or health of any member of the public or of any person using the building, land or place of public entertainment or to any property]
*Building work affects the support of any adjoining property
Building work affects the support of any adjoining property.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
302
[state reason(s) why the building work is affecting the stability of any adjoining property, including details of the location of the adjoining property affected]
BUILDING ORDER TO STOP BUILDING WORK MADE BY:
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Building order to stop building work no.:
Date of making:
Signature:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
303
FORM 14Regulation 182(3)
Building Act 1993
Building Regulations 2018
BUILDING ORDER—MINOR WORK
This building order is made under section 113 of the Building Act 1993.
TO:
The owner [insert full name]
Of [insert address for service of the owner]
FROM:
*I am the private building surveyor appointed to carry out functions under the Building Act 1993 in relation to the *building/*land/*place of public entertainment which is the subject of this building order.
*I am the municipal building surveyor of [insert name of municipal district].
I am authorised by section 113 of the Building Act 1993 to make this building order.
LOCATION OF THE *BUILDING/*LAND/*PLACE OF PUBLIC ENTERTAINMENT TO WHICH THIS ORDER APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Sch. 4 Form 14 amended by S.R. No. 40/2019 reg. 30(5).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
304
ORDER:
I, as the relevant building surveyor, order that:
*1. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following building work as required by the Building Regulations 2018 [insert detailed description of work required to be carried out by the Regulations, including the BCA. Include references to the relevant regulation(s) and/or clauses of the BCA].
*2. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following protection work [insert detailed description of protection work required to be carried out by this order, including details of adjoining property that will receive the benefit of this work].
*3. By [insert time] on [insert date], the owner of the *building/*land/ *place of public entertainment [insert description and address of building, land or place of public entertainment] MUST carry out the following other work as required by the Building Regulations 2018 in relation to the *building/*land/*place of public entertainment [insert detailed description of other work required to be carried out by the Regulations, including the BCA. Include references to the relevant regulation(s) and/or clauses of the BCA].
INSPECTION DETAILS:
*The date and time of any inspection/s of the *building/*land/*place of public entertainment carried out by myself as the relevant building surveyor was—
Time of inspection:
Date of inspection:
[list any inspections carried out by the relevant building surveyor]
*The date and time of any inspection/s relied on by myself as the relevant building surveyor for the purpose of making this order, and the name and qualifications of the person or persons who conducted the inspection are—
Time of inspection:
Date of inspection:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
305
Name of person/persons:
Qualification(s) of person/persons:
*Building practitioner registration no. of person/persons:
[list details of any inspections relied on by the relevant building surveyor]
REASON(S) WHY THIS ORDER WAS MADE:
In accordance with section 113 of the Building Act 1993, I am of the opinion that—
*The work required by this order is of a minor nature.
*Building work of a minor nature is required to be carried out
The building work required by this order is [describe work].
[state reason(s) why building work of a minor nature is required to be carried out]
*Protection work of a minor nature is required to be carried out
The protection work required by this order is [describe work].
[state reason(s) why protection work of a minor nature is required to be carried out]
*Other work of a minor nature is required to be carried out
The other work required by this order is [describe work].
[state reason(s) why the other work is required to be carried out]
BUILDING ORDER MADE BY:
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
Signature:
Building order no.:
Date made:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
306
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
307
FORM 15Regulation 186(1)
Building Act 1993
Building Regulations 2018
APPLICATION FOR OCCUPANCY PERMIT
To
Relevant building surveyor
Name Class Registration no.
From
This application is made by the *owner/*agent of the owner of the property.
Name of applicant *ACN/*ARBN
Telephone
Contact person (if applicant not a natural person)
In accordance with *section 42/*section 54 of the Building Act 1993, I apply for an occupancy permit for the *building/*place of public entertainment situated at—
Property details
Number Street/road City/suburb/town
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Nature of Application
New building †
Alteration to an existing building †
Place of public entertainment †
Other †
Amendment to existing occupancy permit †
Change of use of an existing building †
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
308
*Building permit details
Permit no.
*Building practitioners and architects who were engaged in the building work
Name Category/Class Registration no.
Name Category/Class Registration no.
Use applied for
Part of building Proposed use BCA Class of building
Part of building Proposed use BCA Class of building
To conduct public entertainment †
Certificates of compliance
Copies of compliance certificates for plumbing work and electrical work are attached in accordance with regulation 186(2)(b).
*Signature of owner
Print name:
Date:
*Signature of agent of owner
Print name:
Date:
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
309
FORM 16Regulation 192
Building Act 1993
Building Regulations 2018
OCCUPANCY PERMIT
This occupancy permit must be displayed in the following approved location:
[insert details of location]
Property details
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Building permit details
Building permit number
Version of BCA applicable to building permit
*Building details
[complete this portion only if an occupancy permit is required under Division 1 of Part 5 of the Building Act 1993]
*Building to which permit applies Permitted use BCA Class ofbuilding
Maximum permissible floor live Maximum number of people to beload accommodated
Storeys contained Rise in storeys (for Class 2-9buildings)
Effective height Type of construction
*Part of building to which permit applies Permitted use BCA Class ofbuilding
Sch. 4 Form 16 amended by S.R. No. 40/2019 reg. 30(6).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
310
Maximum permissible floor live Maximum number of people to beload accommodated
*Places of public entertainment
[complete this portion only if an occupancy permit is required under Division 2 of Part 5 of the Building Act 1993]
Class 9b building having an area greater than 500 m2
† Place with an area greater than 500 m2
†
Prescribed temporary structure
† Kardinia Park Precinct †
Public entertainment to be conducted
Period of operation of this permit
*Exemption from, or consent to partial compliance with, certain building requirements
The following exemption from, or a consent to partial compliance with, certain requirements of the Building Regulations 2018 was granted under regulation 229(2), 231(2), 233(3) or 234(2) of the Building Regulations 2018:
Part or whole of building or place of public entertainment or building work exempt from, or given consent to partial compliance with, requirements of the Building Regulations 2018
Nature and scope of exemption
[specify the relevant regulation/BCA Performance Requirement which the building, place of public entertainment or building work is exempt from or may partially comply with]
*Performance solution
A performance solution was used to determine compliance with the following performance requirements of the BCA that relate to the building or place of
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
311
public entertainment to which this permit applies: [list matters not referenced on the relevant building permit]
Relevant performance requirement Details of performance solution
[insert details of performance solution including, applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
*Building Appeals Board determinations and orders
The following determinations and orders of the Building Appeals Board (BAB) relate to the *building/*place of public entertainment to which this permit applies: [list matters not referenced on the relevant building permit]
Date of determination or order Determination or order
Section of Building Act 1993 under which application to BAB made
[insert details of determination or order including applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
*Reporting authorities
The following bodies are reporting authorities for the purposes of the application for this permit in relation to the matters set out below:
Reporting authority
Matter reported on or consented to
Relevant regulation no.
*Conditions to which this permit is subject
Occupation is subject to the following conditions—
(1) Essential safety measures
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
312
The following essential safety measures must be inspected, tested and maintained in accordance with the maintenance requirements set out in the following table—
Essential safety measures required to be provided for the building or place of public entertainment
Provision of the Building Regulations 2018 applicable to installation and operation of essential safety measure
The level of performance that each essential safety measure must achieve to fulfil its purpose
The frequency and type of maintenance required for each essential safety measure
The frequency and type of testing and inspections required for each essential safety measure
*(2) Other conditions
*Combined allotment determination
A determination has been made under regulation 64(1) of the Building Regulations 2018 in relation to the building to which this permit applies.
*Subdivision of existing building
The building to which this occupancy permit relates was created by the subdivision of an existing building.
An exemption granted in accordance with regulation 231 exempts the building from compliance with certain provisions of the Building Regulations 2018. This exemption was granted by *a municipal building surveyor/*the private building surveyor on [insert date], and a copy of this exemption is available by request from the relevant council in accordance with regulation 51.
Suitability for occupation
At the date this occupancy permit is issued, the *building/*place of public entertainment to which this permit applies is suitable for occupation.
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
313
Building practitioner registration no.:
*Municipal district/*council name:
Occupancy Permit no. Date of issue:
Date of final inspection:
Signature:
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
314
FORM 17Regulation 200
Building Act 1993
Building Regulations 2018
CERTIFICATE OF FINAL INSPECTION
Property details
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Building permit details
Building permit number
Version of BCA applicable to building permit
Description of building work
Part of building Permitted use BCA Class ofbuilding
Part of building Permitted use BCA Class ofbuilding
*Exemption from, or consent to partial compliance with, certain building requirements
The following exemption from, or a consent to partial compliance with, certain requirements of the Building Regulations 2018 was granted under regulation 229(2), 231(2), 233(3) or 234(2) of the Building Regulations 2018.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
315
Part or whole of building or place of public entertainment or building work exempt from, or given consent to partial compliance with, requirements of the Building Regulations 2018 Nature and scope of exemption
[specify the relevant regulation/ BCA Performance Requirement which the building, place of public entertainment or building work is exempt from or may partially comply with]
*Performance solution
A performance solution was used to determine compliance with the following Performance Requirements of the BCA that relate to the building to which this permit applies: [list matters not referenced on the relevant building permit]
Relevant performance requirement Details of performance solution
[insert details of performance solution including, applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
*Building Appeals Board determination and orders
The following determinations and orders of the Building Appeals Board (BAB) relate to the building to which this permit applies: [list matters not referenced on the relevant building permit]
Date of determination or order Determination or order
Section of Building Act 1993 under which application to BAB made
[insert details of determination or order including, applicable materials, systems, methods of building, procedures, specifications and other relevant requirements]
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
316
Maintenance determination
A maintenance determination *is/*is not required to be prepared in accordance with regulation 215 of the Building Regulations 2018.
*Combined allotment determination
A determination has been made under regulation 64(1) of the Building Regulations 2018 in relation to the building work to which this certificate applies.
*Directions to fix building work
All directions to fix building work under Part 4 of the Building Act 1993 have been complied with.
Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Certificate no.: Date of issue:
Signature:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
317
FORM 18Regulations 229(4), 231(4), 233(5), 234(4)
Building Act 1993
Building Regulations 2018
EXEMPTION FROM, OR CONSENT TO PARTIAL COMPLIANCE WITH, REQUIREMENTS IN REGULATIONS
TO:
Owner
Telephone
Postal address
Postcode
*Agent of owner
Telephone
Postal address
Postcode
*Details of relevant building permit
Building permit no. Date of issue of building permit
Property details [include title details as and if applicable]
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
318
FROM:
1. I am the *municipal building surveyor of [insert name of municipal district]/*relevant building surveyor for building permit [insert building permit number].
2. I am authorised under regulation *229(2)/*231(2)/*233(3)/*234(2) of the Building Regulations 2018 to *exempt/*consent to partial compliance of a *building/*place of public entertainment/*certain building work from requirements in the Building Regulations 2018 and grant this *exemption/*consent accordingly.
*3. The *building/*place of public entertainment/*building work to which this *exemption/*consent applies is [insert details of building or place of public entertainment].
*4. The proposed building work to which this *exemption/*consent applies is [insert description of proposed building work] (the building work).
5. The following part or whole of the *building/*place of public entertainment/*building work is *given consent to partially comply with/*exempted from compliance with the following requirements in the Building Regulations 2018—
(a) [insert in (a) the part or parts of the building or place of public entertainment or building work exempted from, or given consent to partial compliance with, the Building Regulations 2018]
(b) [insert in (b) the nature of the scope of exemption from or consent to partial compliance with a requirement of the Building Regulations 2018 and specify the relevant regulation or BCA Performance Requirement etc.]
*6. Description of how the structural adequacy of the *building/*place of public entertainment was taken into account when granting this *exemption/*consent [insert description].
7. Description of the requirements necessary to make reasonable provision for the amenity of the *building/*place of public entertainment subject to this *exemption/*consent that were taken into account [insert description].
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
319
8. Description of the requirements necessary to make reasonable provision for the safety and health of people using the *building/*place of public entertainment that were taken into account [insert description].
*9. Description of the requirements necessary to make reasonable provision for avoiding the spread of fire to or from any adjoining building that were taken into account [insert description].
Note
Items numbered 6 and 9 do not apply to a determination under regulation 234(2) of the Building Regulations 2018.
*Municipal building surveyor/*Relevant building surveyor
Name: [insert full name]
Address:
Email:
Building practitioner registration no.:
*Municipal district/*council name:
Date of *grant of exemption/*consent to partial compliance:
Related building permit no. [if issued before exemption granted or consent given]
Signature:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
320
FORM 19Regulation 242(2)
Building Act 1993
Building Regulations 2018
APPLICATION FOR BUILDING PRODUCT ACCREDITATION
To
Building Regulations Advisory Committee
From
Applicant:
Name: [insert full name]
*ACN/*ARBN:
Postal address:
Postcode:
Contact person: Telephone:
Email:
*If applicant making application on behalf of the owner of a building product:
I have been authorised by the owner of the building product to make this application on the owner's behalf.
†
A copy of the authorisation from the owner to make this application is attached to this form.
†
*Owner of building product [if different from applicant]
Name: [insert full name]
*ACN/*ARBN:
Postal address:
Postcode:
Contact person: Telephone:
Email:
Sch. 4 Form 19 amended by S.R. No. 40/2019 reg. 30(7).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
321
Nature of application
This application is for:
Building product †
Construction method connected with building work †
Design connected with building work †
Component connected with building work †
System connected with building work †
Note
Regulation 238 of the Building Regulations 2018 defines building product to include construction method, design, component or system connected with building work.
Details of building product
Name of building product:
Description of building product:
Purpose and use of building product:
Method of installation or use:
Interaction of building product with other components and materials in building work:
BCA performance requirements that building product intended to comply with:
Column 1 Column 2 Column 3
The performance requirements that are relevant to the building product, as determined in accordance with clauses A.2.2(3) and A2.4(3) of the BCA Volume One or clauses A.2.2(3) and A2.4(3) of the BCA Volume Two are [insert performance requirements]—
The deemed-to-satisfy provisions relevant to the performance requirements identified in column 1 are [insert deemed-to-satisfy clauses]—
The relevant deemed-to-satisfy provisions identified in column 2 that the building product does not comply with are [insert relevant deemed-to-satisfy clauses]—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
322
Means of demonstrating compliance with BCA requirements
This application for accreditation demonstrates that the building product meets the following performance requirement(s) of the BCA by the following means:
Column 1 Column 2
Performance requirements relevant to the building product, as determined in accordance with clauses A.2.2(3) and A2.4(3) of the BCA Volume One or clauses A.2.2(3) and A2.4(3) of the BCA Volume Two are [insert performance requirements]—
Evidence to demonstrate compliance of the building product with the performance requirements in column 1 [insert specific piece of evidence and explain how it shows compliance of the building product with the relevant performance requirement]—
Documentation or information accompanying application
The application is accompanied by the following—
Appraisal of building product †
Appraiser's qualifications and curriculum vitae †
Test report(s) from Accredited Testing Laboratory or Registered Testing Authority
†
Technical/installation manual for the building product †
Other information or documentation required by the Committee
†
Signature
I certify that the information and content contained in this application is complete and correct.
Signature of *applicant/*authorised agent of applicant:
Date:
* Delete if inapplicable† Tick if applicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
323
FORM 20Regulation 264(a)
Building Act 1993
Building Regulations 2018
NOTICE OF SUSPENSION OF REGISTRATION UNDER SECTION 183A
I [insert name] give notice that on [insert date] my registration as a building practitioner in the category of [insert registration category] class of [insert registration class] was suspended by the Victorian Building Authority (VBA) with respect to the work I am carrying out for you. My registration will be suspended from [insert date].
Under section 183A of the Building Act 1993, I am required to give you notice of the suspension of my registration.
Under section 185 of the Building Act 1993, I have the right to apply for an internal review of the VBA's decision to suspend my registration. In reviewing the decision, the VBA may choose to affirm, amend or substitute the decision.
Under section 186 of the Building Act 1993, I also have the right to apply for a review of the decision to suspend my registration directly to the Victorian Civil and Administrative Tribunal (VCAT). VCAT may then choose to affirm, amend or substitute the decision.
If I apply for an internal review or a review by VCAT, the suspension of my registration is stayed until a decision is made unless my registration was immediately suspended under section 180A of the Act.
Signature
Date
Sch. 4 Form 20 amended by S.R. No. 75/2018 reg. 27(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
324
FORM 21Regulation 264(b)
Building Act 1993
Building Regulations 2018
NOTICE OF CANCELLATION OF REGISTRATION UNDER SECTION 183A
I [insert name] give notice that on [insert date] my registration as a building practitioner in the category of [insert registration category] class of [insert registration class] was cancelled by the Victorian Building Authority (VBA). My registration will be cancelled from [insert date].
Under section 183A of the Building Act 1993, I am required to give you notice of the cancellation of my registration.
Under section 185 of the Building Act 1993, I have the right to apply for an internal review of the VBA's decision to cancel my registration. In reviewing the decision, the VBA may choose to affirm, amend or substitute the decision.
Under section 186 of the Building Act 1993, I also have the right to apply for a review of the decision to cancel my registration directly to the Victorian Civil and Administrative Tribunal (VCAT). VCAT may then choose to affirm, amend or substitute the decision. If I apply for a review, the cancellation of my registration is stayed until a decision is made.
If I apply for an internal review or a review by VCAT, the suspension of my registration is stayed until a decision is made unless my registration was immediately suspended under section 180A of the Act.
Signature
Date
Sch. 4 Form 21 amended by S.R. No. 75/2018 reg. 27(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
325
FORM 22Regulation 147P(1)
Building Act 1993
Building Regulations 2018
APPLICATION TO REGISTER A SWIMMING POOL OR SPAOwnership details
Name of owner of the land (the property) on which the swimming pool or spa is located:
Postal address:
Telephone number:
Email address:
Property details: [include title details as and if applicable]
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Type of swimming pool or spa: [please tick]:
Permanent swimming pool
Permanent spa
Relocatable swimming pool
Relocatable spa
For permanent swimming pools and permanent spas, the approximate date that the swimming pool or spa was constructed:
[please provide copies of any relevant building permit if available and/or any other information or documentation that provides evidence of when the swimming pool or spa was constructed]
For relocatable swimming pools and relocatable spas, the date that the relocatable swimming pool or relocatable spa was erected:
Is there any other building work that has altered or resulted in changes to the barrier since the swimming pool or spa was constructed or erected?
[if yes, please provide details and copies of any relevant building permit or other documentation]
Sch. 4 Form 22 inserted by S.R. No. 116/2019 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
326
Signature
Signature of applicant
Date
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
327
FORM 23Regulations 147Y(4), 147ZB(2)
Building Act 1993
Building Regulations 2018
CERTIFICATE OF POOL AND SPA BARRIER COMPLIANCE
Issued to:
1. Name of owner of the land (the property) on which the swimming pool or spa is located:
2. Postal address:
3. Telephone number:
4. Email address:
Property details:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Type of swimming pool or spa: [please tick]
Permanent swimming pool
Permanent spa
Relocatable swimming pool
Relocatable spa
5. Date of construction of the swimming pool or spa:
6. Applicable barrier standard:
7. The applicable barrier standard applies under: [please tick]
Division 2 of Part 9A of the Building Regulations 2018
relevant deemed to satisfy provisions of the BCA
a performance solution in accordance with the BCA
8. Date(s) of inspection(s) of the swimming pool or spa barrier:
Sch. 4 Form 23 inserted by S.R. No. 116/2019 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
328
Certification of compliance
Following inspection of the *swimming pool barrier/*spa barrier on the date(s) referred to in item 8 of this certificate, I certify that the barrier complies with the applicable barrier standard.
Signature of *relevant building surveyor/*swimming pool and spa inspector/*municipal building surveyor:
Date:
9. I confirm that I *did/*did not carry out building work on the barrier to address identified non-compliance of the barrier prior to certifying the barrier's compliance with the applicable barrier standard.
Inspector details
10. Name of registered building practitioner:
11. *ACN/*ARBN
12. Address:
13. Email:
14. Building practitioner registration no.:
15. *Municipal district/*council name:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
329
FORM 24Regulation 147ZI(1)
Building Act 1993
Building Regulations 2018
CERTIFICATE OF POOL AND SPA BARRIER NON-COMPLIANCE
Issued to:
1. Name of owner of the land (the property) on which the swimming pool or spa is located:
2. Postal address:
3. Telephone number:
4. Email address:
Property details:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
Type of swimming pool or spa: [please tick]
Permanent swimming pool
Permanent spa
Relocatable swimming pool
Relocatable spa
5. Date of construction of the swimming pool or spa:
6. Applicable barrier standard:
7. The applicable barrier standard applies under: [please tick]
Division 2 of Part 9A of the Building Regulations 2018
relevant deemed to satisfy provisions of the BCA
a performance solution in accordance with the BCA
Sch. 4 Form 24 inserted by S.R. No. 116/2019 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
330
8. Date(s) of inspection(s) of the swimming pool or spa barrier:
Certification of non-compliance
Following inspection of the *swimming pool/*spa barrier on the date(s) referred to in item 8 of this certificate, I certify that the barrier does not comply with the applicable barrier standard.
This certificate of pool and spa barrier non-compliance has been issued because:
in my opinion the barrier cannot or will not be made compliant with the applicable barrier standard within 60 days; or
a written notice was provided to the owner in accordance with regulation 147ZG(1) or 147ZH(1) of the Building Regulations 2018 and the barrier was not made compliant within the time period specified in that notice; or
in my opinion the barrier non-compliance poses a significant and immediate risk to life or safety; or
in my opinion the barrier is non-compliant with the applicable barrier standard in one or more ways specified in regulation 147ZF(c) of the Building Regulations 2018.
List of non-compliant items (required):
Column 1
Item number
Column 2
Items/components of swimming pool or spa barrier that are non-compliant with the applicable barrier standard[insert ways in which barrier is non-compliant with the applicable barrier standard]
Column 3Rectification work required[set out the building work required to make the barrier compliant with the applicable barrier standard]
1
2
3
4
5
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
331
Column 1
Item number
Column 2
Items/components of swimming pool or spa barrier that are non-compliant with the applicable barrier standard[insert ways in which barrier is non-compliant with the applicable barrier standard]
Column 3Rectification work required[set out the building work required to make the barrier compliant with the applicable barrier standard]
6
[More rows may be added as required]
Any additional comments:
Signature of swimming pool and spa inspector:
Date:
Inspector details:
9. Name of swimming pool and spa inspector:
10. *ACN/*ARBN
11. Address:
12. Email:
13. Building practitioner registration no.:
14. *Municipal district/*council name:
* Delete if inapplicable
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
332
FORM 25Regulation 147ZK(2)
Building Act 1993
Building Regulations 2018
BARRIER IMPROVEMENT NOTICE
Served on:
Name of owner of the land on which the swimming pool or spa is located [insert full name]
Of [insert address for service on the owner]
FROM:
I am the municipal building surveyor of the municipal district of [insert name of relevant council].
I am authorised to cause a barrier improvement notice to be served on you, as owner of the land to which this notice applies under regulation 147ZK of the Building Regulations 2018.
LOCATION OF THE LAND TO WHICH THIS NOTICE APPLIES:
Number Street/road City/suburb/town Postcode
Lot/s LP/PS Volume Folio
Crown allotment Section Parish County
Municipal district
REASON WHY THIS NOTICE WAS SERVED:
A certificate of pool and spa barrier non-compliance was lodged with [insert name of the relevant council] on [insert date] in relation to a swimming pool or spa located on the land described above.
A copy of the certificate of pool and spa barrier non-compliance is attached. This certificate lists the matters identified in respect of which the barrier was determined not to comply with the applicable barrier standard.
ACTION REQUIRED:
You are required to bring the matters listed in the certificate of pool and spa barrier non-compliance into compliance with the applicable barrier standard,
Sch. 4 Form 25 inserted by S.R. No. 116/2019 reg. 15.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
333
and to lodge a certificate of pool and spa barrier compliance with the [insert name of relevant council] by [insert date].
A failure to lodge the required certificate of pool and spa barrier compliance by [insert date] is an offence under regulation 147V(1) of the Building Regulations 2018. As a prescribed offence, a failure to comply with this notice may result in the issuing of a building infringement notice which carries a prescribed penalty of 2 penalty units.
Municipal building surveyor
Name: [insert full name]
Name of council: [insert name of relevant council]
Address:
Email:
Building practitioner registration no.:
Signature:
Barrier improvement notice no.:
Date made:
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
334
Schedule 5—Prescribed matters reported onby prescribed reporting authorities
Regulation 31
Part 1—Prescribed matters reported on by chief officer
Column 1
Item
Column 2Prescribed matters to be reported on by chief officer
Column 3Regulation reference
The following fire safety matters if those matters do not meet the deemed-to-satisfy provisions of the BCA—
reg. 129(1)
1 fire hydrants;
2 fire control centres or fire control rooms;
3 fire precautions during construction;
4 fire mains;
5 control valves;
6 booster assemblies;
7 open space and perimeter vehicular access to the extent it relates to emergency vehicles;
8 fire indicator panels;
9 fire services controls in passenger lift cars.The following bushfire safety matters if those matters do not meet the requirements of regulation 160 or 161—
reg. 162(1)
10 static water supply for fire fighting purposes;
11 emergency vehicle access.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
335
Part 2—Prescribed matters reported on by relevant council
Column 1
Item
Column 2Prescribed matters to be reported on by relevant council
Column 3Regulation reference
1 Setback from a street alignment not complying with reg. 73
reg. 73(2)
2 Setback from a street alignment not complying with reg. 74
reg. 74(4)
3 Building height not complying with reg. 75 reg. 75(4)
4 Site coverage not complying with reg. 76 reg. 76(4)
5 Permeable surfaces not complying with reg. 77
reg. 77(3)
6 Car parking spaces not complying with reg. 78
reg. 78(6)
7 Side or rear boundary setbacks not complying with reg. 79
reg. 79(6)
8 Walls or carports on boundaries not complying with reg. 80
reg. 80(6)
9 Building setbacks not complying with reg. 81 (daylight to existing habitable room windows)
reg. 81(6)
10 Building setbacks not complying with reg. 82 (solar access to north-facing habitable room windows)
reg. 82(5)
11 Building design not complying with reg. 83 (overshadowing of recreational private open space)
reg. 83(3)
12 Window or raised open space not complying with reg. 84 (overlooking)
reg. 84(9)
13 Building design not complying with reg. 85 (daylight to habitable room windows)
reg. 85(3)
14 Private open space for a building not complying with reg. 86
reg. 86(3)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
336
Column 1
Item
Column 2Prescribed matters to be reported on by relevant council
Column 3Regulation reference
15 Siting of a Class 10a building, that is appurtenant to a building of another class, that does not comply with reg. 87
reg. 87(2)
16 Front fence height not complying with reg. 89
reg. 89(3)
17 Fence setback from side or rear boundary not complying with reg. 90
reg. 90(2)
18 Length or height of side or rear boundary fence not complying with reg. 91
reg. 91(5)
19 A fence within 9 m of an intersection of street alignments and exceeding height of 1 m above footpath
reg. 92(2)
20 Fence setback not complying with reg. 94 (daylight to existing habitable room window)
reg. 94(6)
21 Fence setback not complying with reg. 95 (solar access to north-facing habitable room windows)
reg. 95(3)
22 Fence design not complying with reg. 96 (overshadowing of recreational private open space)
reg. 96(3)
23 A mast, pole, aerial, antenna, chimney, flue or service pipe not complying with reg. 97(1)
reg. 97(2)
24 Projections beyond street alignment reg. 109(1) and (2)
25 Precautions over a street alignment reg. 116(4)
26 Installation or alteration of a septic tank system, or construction of a building over an existing septic tank system
reg. 132(1)
27 Point of discharge of stormwater reg. 133(2)
28 Buildings above or below certain public facilities
reg. 134(2)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
337
Column 1
Item
Column 2Prescribed matters to be reported on by relevant council
Column 3Regulation reference
29 Construction of buildings on land liable to flooding
reg. 153(2)
30 Building on designated land or designated works
reg. 154(1)
Part 3—Prescribed matter reported on by relevant service authority
Column 1
Item
Column 2Prescribed matter to be reported on by relevant service authority
Column 3Regulation reference
1 Construction of building over an easement vested in the service authority
reg. 130(1)
Part 4—Prescribed matter reported on by relevant electricity supply authority
Column 1
Item
Column 2Prescribed matter to be reported on by relevant electricity supply authority
Column 3Regulation reference
1 Provision of substations reg. 131(1)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
338
Schedule 6—Planning schemesRegulations 74(1), 75(1), 76(1), 76A(1), 77(1), 79(1), 80(2), 86(1), 89(1)
Table
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
1 Alpine Planning Scheme General Residential Zone (GRZ)
2 Ararat Planning Scheme General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
3 Ballarat Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
4 Banyule Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
5 Bass Coast Planning Scheme
General Residential Zone (GRZ)
6 Baw Baw Planning Scheme
General Residential Zone (GRZ)
7 Bayside Planning Scheme Mixed Use Zone (MUZ)Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
Sch. 6 amended by S.R. No. 100/2018 reg. 5.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
339
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
8 Benalla Planning Scheme General Residential Zone (GRZ)
9 Boroondara Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
10 Brimbank Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
11 Campaspe Planning Scheme
General Residential Zone (GRZ)
12 Cardinia Planning Scheme General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
13 Casey Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)
14 Central Goldfields Planning Scheme
General Residential Zone (GRZ)
15 Colac Otway Planning Scheme
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
16 Corangamite Planning Scheme
General Residential Zone (GRZ)
17 Darebin Planning Scheme Residential Growth Zone (RGZ)General Residential Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
340
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
(GRZ)Neighbourhood Residential Zone (NRZ)
18 East Gippsland Planning Scheme
General Residential Zone (GRZ)
19 Frankston Planning Scheme
General Residential Zone (GRZ)
20 Gannawarra Planning Scheme
General Residential Zone (GRZ)
21 Glen Eira Planning Scheme
Mixed Use Zone (MUZ)Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
22 Glenelg Planning Scheme General Residential Zone (GRZ)
23 Golden Plains Planning Scheme
General Residential Zone (GRZ)
24 Greater Bendigo Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)
25 Greater Dandenong Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
26 Greater Geelong Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
341
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
27 Greater Shepparton Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
28 Hepburn Planning Scheme
General Residential Zone (GRZ)
29 Hindmarsh Planning Scheme
General Residential Zone (GRZ)
30 Hobsons Bay Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)
31 Horsham Planning Scheme
General Residential Zone (GRZ)
32 Hume Planning Scheme General Residential Zone (GRZ)
33 Indigo Planning Scheme General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
34 Kingston Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
35 Knox Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
342
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
Zone (NRZ)
36 Latrobe Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
37 Macedon Ranges Planning Scheme
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
38 Manningham Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
39 Mansfield Planning Scheme
Mixed Use Zone (MUZ)General Residential Zone (GRZ)
40 Maribyrnong Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
41 Maroondah Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
42 Melbourne Planning Scheme
Residential Growth Zone (RGZ)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
343
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
43 Melton Planning Scheme Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
44 Mildura Planning Scheme General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
45 Mitchell Planning Scheme General Residential Zone (GRZ)
46 Moira Planning Scheme General Residential Zone (GRZ)
47 Monash Planning Scheme Mixed Use Zone (MUZ)Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
48 Moonee Valley Planning Scheme
General Residential Zone (GRZ)
49 Moorabool Planning Scheme
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
50 Moreland Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
344
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
51 Mornington Peninsula Planning Scheme
General Residential Zone (GRZ)
52 Mount Alexander Planning Scheme
General Residential Zone (GRZ)
53 Moyne Planning Scheme General Residential Zone (GRZ)
54 Murrindindi Planning Scheme
General Residential Zone (GRZ)
55 Nillumbik Planning Scheme
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
56 Northern Grampians Planning Scheme
General Residential Zone (GRZ)
57 Port Phillip Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
58 Pyrenees Planning Scheme
General Residential Zone (GRZ)
59 Queenscliffe Planning Scheme
General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
60 South Gippsland Planning Scheme
General Residential Zone (GRZ)
61 Southern Grampians Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
345
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
62 Stonnington Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
63 Strathbogie Planning Scheme
General Residential Zone (GRZ)
64 Surf Coast Planning Scheme
General Residential Zone (GRZ)
65 Swan Hill Planning Scheme
General Residential Zone (GRZ)
66 Towong Planning Scheme General Residential Zone (GRZ)
67 Wangaratta Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
68 Warrnambool Planning Scheme
Mixed Use Zone (MUZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
69 Wellington Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
70 Whitehorse Planning Residential Growth Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
346
Column 1Item
Column 2Name of planning scheme
Column 3Name of zone
Scheme (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
71 Whittlesea Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
72 Wodonga Planning Scheme
General Residential Zone (GRZ)
73 Wyndham Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)
74 Yarra Planning Scheme General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
75 Yarra Ranges Planning Scheme
Residential Growth Zone (RGZ)General Residential Zone (GRZ)Neighbourhood Residential Zone (NRZ)
76 Yarriambiack Planning Scheme
General Residential Zone (GRZ)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
347
Schedule 7—Planning schemes applying to allotments containing homes destroyed
in the 2009 bushfiresRegulation 159(b)
1 Alpine Planning Scheme
2 Baw Baw Planning Scheme
3 Cardinia Planning Scheme
4 Casey Planning Scheme
5 Greater Bendigo Planning Scheme
6 Horsham Planning Scheme
7 Indigo Planning Scheme
8 Latrobe Planning Scheme
9 Macedon Ranges Planning Scheme
10 Mitchell Planning Scheme
11 Mount Alexander Planning Scheme
12 Murrindindi Planning Scheme
13 Nillumbik Planning Scheme
14 Wellington Planning Scheme
15 Whittlesea Planning Scheme
16 Yarra Ranges Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
348
Schedule 8—Essential safety measuresRegulation 214
Part 1—Building fire integrityColumn 1Item
Column 2Safety measure
1 Building elements required to satisfy prescribed fire-resistance levels
2 Materials and assemblies required to have fire hazard properties
3 Elements required to be non-combustible, provide fire protection, compartmentation or separation
4 Wall-wetting sprinklers (including doors and windows required in conjunction with wall-wetting sprinklers)
5 Fire doors (including sliding fire doors and their associated warning systems) and associated self-closing, automatic closing and latching mechanisms
6 Fire windows (including windows that are automatic or permanently fixed in the closed position)
7 Fire shutters
8 Solid core doors and associated self-closing, automatic closing and latching mechanisms
9 Fire-protection at service penetrations through elements required to be fire-resisting with respect to integrity or insulation, or to have a resistance to the incipient spread of fire
10 Fire protection associated with construction joints, spaces and the like in and between building elements required to be fire-resisting with respect to integrity and insulation
11 Smoke doors and associated self-closing, automatic closing and latching mechanisms
12 Proscenium walls (including proscenium curtains)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
349
Part 2—Means of egressColumn 1Item
Column 2Safety measure
1 Paths of travel to exits
2 Discharge from exits (including paths of travel from open spaces to the public roads to which they are connected)
3 Exits (including fire-isolated stairways and ramps, non fire-isolated stairways and ramps, stair treads, balustrades and handrails associated with exits, and fire-isolated passageways)
4 Smoke lobbies to fire-isolated exits
5 Open access ramps or balconies for fire-isolated exits
6 Doors (other than fire or smoke doors) in a required exit, forming part of a required exit or in a path of travel to a required exit, and associated self-closing, automatic closing and latching mechanisms
Part 3—SignsColumn 1Item
Column 2Safety measure
1 Exit signs (including direction signs)
2 Signs warning against the use of lifts in the event of fire
3 Warning signs on sliding fire doors and doors to non-required stairways, ramps and escalators
4 Signs, intercommunication systems, or alarm systems on doors of fire-isolated exits stating that re-entry to a storey is available
5 Signs alerting persons that the operation of doors must not be impaired
6 Signs required on doors, in alpine areas, alerting people that they open inwards
7 Fire order notices required in alpine areas
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
350
Part 4—LightingColumn 1Item
Column 2Safety measure
1 Emergency Lighting
Part 5—Fire fighting services and equipmentColumn 1Item
Column 2Safety measure
1 Fire hydrant system (including on-site pump set and fire-service booster connection)
2 Fire hose reel system
3 Sprinkler system
4 Portable fire extinguishers
5 Fire control centres (or rooms)
Part 6—Air-handling systemsColumn 1Item
Column 2Safety measure
1 Smoke hazard management systems—(a) automatic air pressurisation systems for
fire-isolated exits;(b) zone smoke control system;(c) automatic smoke exhaust system;(d) automatic smoke-and-heat vents
(including automatic vents for atriums);(e) air-handling systems that do not form part
of a smoke hazard management system and which may unduly contribute to the spread of smoke;
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
351
Column 1Item
Column 2Safety measure
(f) miscellaneous air-handling systems serving more than one fire compartment to which Sections 5 and 6 of AS/NZS 1668.1 The use of ventilation and air conditioning in buildings—Part 1: Fire and smoke control in buildings, as in force or as re-issued or as published from time to time;
(g) other air-handling systems.
2 Car park mechanical ventilation system
3 Atrium smoke control system (see item 1(d) for smoke and heat vents)
Part 7—Automatic fire detection and alarm systems
Column 1Item
Column 2Safety measure
1 Smoke and heat alarm system
2 Smoke and heat detection system
3 Atrium fire detection and alarm system
Part 8—Occupant warning systemsColumn 1Item
Column 2Safety measure
1 Sound system and intercom system for emergency purposes
2 Building occupant warning system
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
352
Part 9—LiftsColumn 1Item
Column 2Safety measure
1 Stretcher facilities in lifts
2 Emergency lifts
3 Passenger lift fire service controls
Part 10—Standby power supply systemColumn 1Item
Column 2Safety measure
1 Standby power supply system
Part 11—Building clearance and fire appliances
Column 1Item
Column 2Safety measure
1 Open space around large isolated buildings
2 Vehicular access around large isolated buildings
Part 12—Mechanical ventilation and hot, warm and cooling water systems
Column 1Item
Column 2Safety measure
1 Mechanical ventilation systems incorporating cooling tower systems (other than a system serving only a single sole-occupancy unit in a Class 2 or 3 building or a Class 4 part of a building)
2 Mechanical ventilation systems incorporating hot and warm water systems (other than a system serving only a single sole-occupancy unit in a Class 2 or 3 building or a Class 4 part of a building)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
353
Schedule 9—Prescribed classes of buildingpractitioners and prescribed qualifications
Regulations 257 and 258
Part 1—Preliminary1 Definitions
(1) In this Schedule—
RTO means a training organisation registered under Division 4 of Part 4.3of the Education and Training Reform Act 2006 or a vocational education and training organisation registered under section 17 of the National Vocational Education and Training RegulatorAct 2011 of the Commonwealth;
unit of competency has the same meaning as in Part 4.1 of the Education and Training Reform Act 2006.
(2) In this Schedule, a code or number in brackets is a reference to the code or number by which a unit of competency is known.
Part 2—Prescribed classes of registration2 Category of building surveyor
The classes of building practitioner in respect of the category of building surveyor are the following classes—
(a) class of building surveyor (unlimited);
(b) class of building surveyor (limited).
3 Category of building inspector
The classes of building practitioner in respect of the category of building inspector are the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
354
following classes—
(a) class of building inspector (unlimited);
(b) class of building inspector (limited);
(c) class of building inspector (pool safety).
4 Category of engineer
The classes of building practitioner in respect of the category of engineer are the following classes—
(a) class of engineer (civil);
(b) class of engineer (mechanical);
(c) class of engineer (electrical);
(d) class of engineer (fire safety).
5 Category of draftsperson
The classes of building practitioner in respect of the category of draftsperson are the following classes—
(a) class of building design (architectural);
(b) class of building design (interior);
(c) class of building design (services).
6 Category of builder
The classes of building practitioner in respect of the category of builder are the following classes—
(a) class of commercial builder (unlimited);
(b) class of commercial builder (limited to the construction of low rise building work);
Sch. 9 cl. 3(b) amended by S.R. No. 116/2019 reg. 16(1).
Sch. 9 cl. 3(c) inserted by S.R. No. 116/2019 reg. 16(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
355
(c) class of commercial builder (limited to the construction of medium rise building work);
(d) class of commercial builder (limited to the construction of shade structures work);
(e) class of commercial builder (limited to the erection of signs work);
(f) class of commercial builder (limited to the installation of blinds and awnings work);
(g) class of commercial builder (limited to non-structural fit-out work);
(h) class of commercial builder (limited to steel erection work);
(i) class of commercial builder (limited to structural fit-out work);
(j) class of commercial builder (limited to structural landscaping work);
(k) class of commercial builder (limited to waterproofing work);
(l) class of domestic builder (unlimited);
(m) class of domestic builder (limited to the construction of non-habitable building structures);
(n) class of domestic builder (limited to the construction of gates and fences);
(o) class of domestic builder (limited to the construction of retaining walls);
(p) class of domestic builder (limited to the construction of swimming pools and spas);
(q) class of domestic builder (limited to the construction of private bushfire shelters);
(r) class of domestic builder (limited to the construction of shade structures);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
356
(s) class of domestic builder (limited to the construction of structural landscaping);
(t) class of domestic builder (limited to bathroom, kitchen and laundry renovation);
(u) class of domestic builder (limited to earthworks and excavation work);
(v) class of domestic builder (limited to footings and slab work);
(w) class of domestic builder (limited to framing);
(x) class of domestic builder (limited to bricklaying and blocklaying);
(y) class of domestic builder (limited to external wall cladding);
(z) class of domestic builder (limited to roof tiling);
(za) class of domestic builder (limited to waterproofing);
(zb) class of domestic builder (limited to door and window replacement and installation);
(zc) class of domestic builder (limited to site works involved in relocating a dwelling);
(zd) class of domestic builder (limited to re-stumping and re-blocking);
(ze) class of domestic builder (limited to cabinet making, joinery and stair construction);
(zf) class of domestic builder (limited to carpentry);
(zg) class of domestic builder (limited to the erection of poles, masts and antennas);
(zh) class of domestic builder (limited to sheet plastering);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
357
(zi) class of domestic builder (limited to solid plastering and rendering);
(zj) class of domestic builder (limited to floor finishing and covering);
(zk) class of domestic builder (limited to glazing work);
(zl) class of domestic builder (limited to insulation work);
(zm) class of domestic builder (limited to painting and decorating);
(zn) class of domestic builder (limited to floor and wall tiling work);
(zo) class of domestic builder (limited to attaching external fixtures);
(zp) class of demolisher (low rise);
(zq) class of demolisher (medium rise);
(zr) class of demolisher (unlimited).
7 Category of person responsible for a building project
The class of building practitioner in respect of the category of person responsible for a building project or any stage of a building project is the class of project manager (domestic).
8 Category of person who erects or supervises the erection of prescribed temporary structures
The classes of building practitioner in respect of the category of person who erects or supervises the erection of prescribed temporary structures are the following classes—
(a) class of temporary structures (limited to scaffolding stages and towers);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
358
(b) class of temporary structures (limited to tents and marquees).
Part 3—Prescribed qualifications9 Class of building surveyor (unlimited)
The prescribed qualifications for registration in the class of building surveyor (unlimited) are—
(a) the successful completion of—
(i) a Bachelor of Building Surveying from Holmesglen Institute; or
(ii) a Bachelor of Building Surveying from Victoria University; and
(b) at least 3 years of practical experience.
10 Class of building surveyor (limited)
The prescribed qualifications for registration in the class of building surveyor (limited) are—
(a) the successful completion of—
(i) a Bachelor of Building Surveying from Holmesglen Institute; or
(ii) a Bachelor of Building Surveying from Victoria University; or
(iii) an advanced diploma of building surveying (CPC60115) from an RTO; and
(b) at least 2 years of practical experience.
11 Class of building inspector (unlimited)
The prescribed qualifications for registration in the class of building inspector (unlimited) are—
(a) the successful completion of—
(i) a Bachelor of Building Surveying from Holmesglen Institute; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
359
(ii) a Bachelor of Building Surveying from Victoria University; and
(b) at least 2 years of practical experience.
12 Class of building inspector (limited)
The prescribed qualifications for registration in the class of building inspector (limited) are—
(a) the successful completion of—
(i) a Bachelor of Building Surveying from Holmesglen Institute; or
(ii) a Bachelor of Building Surveying from Victoria University; or
(iii) an advanced diploma of building surveying (CPC60115) from an RTO; and
(b) at least 2 years of practical experience.
12A Class of building inspector (pool safety)
The prescribed qualifications for registration in the class of building inspector (pool safety) are—
(a) the successful completion of a course in swimming pool and spa barrier inspection approved by the Authority from a Registered Training Organisation; and
(b) at least 6 months of practical experience.
13 Class of engineer (civil)
The prescribed qualifications for registration in the class of engineer (civil) are—
(a) the successful completion of—
(i) a Bachelor of Civil Engineering (Honours) from Deakin University; or
(ii) a Bachelor of Engineering (Civil) (Honours) from Federation University; or
Sch. 9 cl. 12A inserted by S.R. No. 116/2019 reg. 17.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
360
(iii) a Bachelor of Civil Engineering (Honours) from La Trobe University; or
(iv) a Bachelor of Engineering (Honours) in the field of Civil Engineering from Monash University; or
(v) a Bachelor of Engineering (Civil and Infrastructure) (Honours) from RMIT University; or
(vi) a Bachelor of Engineering (Civil) (Honours) from Swinburne University of Technology; or
(vii) a Master of Engineering (Civil) from The University of Melbourne; or
(viia) a Master of Engineering (structural) from The University of Melbourne; or
(viii) a Bachelor of Engineering (Civil Engineering) (Honours) from Victoria University; or
(ix) registration as a civil engineer on the National Engineering Register (NER); and
(b) at least 3 years of practical experience.
14 Class of engineer (mechanical)
The prescribed qualifications for registration in the class of engineer (mechanical) are—
(a) the successful completion of—
(i) a Bachelor of Mechanical Engineering (Honours) from Deakin University; or
(ii) a Bachelor of Engineering (Mechanical) (Honours) from
Sch. 9 cl. 13(a)(viia) inserted by S.R. No. 75/2018 reg. 28(1).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
361
Federation University; or
(iii) a Bachelor of Engineering (Honours) in the field of Mechanical Engineering from Monash University; or
(iv) a Bachelor of Engineering (Mechanical Engineering) (Honours) from RMIT University; or
(v) a Bachelor of Engineering (Mechanical) (Honours) from Swinburne University of Technology; or
(vi) a Master of Engineering (Mechanical) from The University of Melbourne; or
(vii) a Bachelor of Engineering (Mechanical Engineering) (Honours) from Victoria University; or
(viii) a current certificate of registration as a mechanical engineer on the National Engineering Register (NER); and
(b) at least 3 years of practical experience.
15 Class of engineer (electrical)
The prescribed qualifications for registration in the class of engineer (electrical) are—
(a) the successful completion of—
(i) a Bachelor of Electrical and Electronics Engineering (Honours) from Deakin University; or
(ii) a Bachelor of Engineering (Electrical Engineering) (Honours) from RMIT University; or
(iii) a Bachelor of Engineering (Electrical and Electronic) (Honours)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
362
from Swinburne University of Technology; or
(iv) a Master of Engineering (Electrical) from The University of Melbourne; or
(v) a Bachelor of Engineering (Electrical and Electronic Engineering) (Honours) from Victoria University; or
(vi) a current certificate of registration as an electrical engineer on the National Engineering Register (NER); and
(b) at least 3 years of practical experience.
16 Class of engineer (fire safety)
The prescribed qualifications for registration in the class of engineer (fire safety) are—
(a) the successful completion of—
(i) a Graduate Certificate in Performance-Based Building and Fire Codes from Victoria University, and any prescribed qualification for registration in the class of engineer (civil) or the class of engineer (mechanical) or the class of engineer (electrical); or
(ii) a Master of Engineering (Building Fire Safety and Risk Engineering) from Victoria University; or
(iii) a current certificate of registration as a fire safety engineer on the National Engineering Register (NER); and
(b) at least 3 years of practical experience.
17 Class of building design (architectural)
The prescribed qualifications for registration in the class of building design (architectural) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
363
(a) the successful completion of an advanced diploma of building design (architectural) (22268VIC) from an RTO; and
(b) at least 2 years of practical experience.
18 Class of building design (interior)
(1) The prescribed qualifications for registration in the class of building design (interior) are—
(a) the successful completion of—
(i) an advanced diploma of interior design (MSF60113) from an RTO, including the required units of competency; or
(ii) an advanced diploma of building design (22268VIC) from an RTO; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the required units of competency are—
(a) select and instruct consultants and contractors (MSFID6007); and
(b) investigate legal requirements for design (MSFFDT5014); and
(c) design for large scale commercial or institutional interiors (MSFID6003); and
(d) specify structural elements, systems and services for interior spaces (MSFID5004); and
(e) use CAD applications to complete models and documentation for interior design projects (MSFID5014); and
(f) monitor and manage small business operations (BSBSMB405); and
(g) identify materials, construction techniques and methods used in building interiors
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
364
(MSFID4007); and
(h) work safely (MSMWHS200).
19 Class of building design (services)
(1) The prescribed qualifications for registration in the class of building design (services) are—
(a) the successful completion of—
(i) an advanced diploma of engineering technology (mechanical) (22228VIC) from an RTO, including the required units of competency; or
(ii) an advanced diploma of engineering technology (electrical) (UEE62111) from an RTO, including the required units of competency; or
(iii) an advanced diploma of engineering (MEM60112) from an RTO, including the required units of competency; or
(iv) a diploma of fire systems design (CPC50509) from an RTO; and
(b) at least 2 years of practical experience.
(2) For the purposes of subclause (1)(a)(i), the required units of competency are—
(a) perform mechanical engineering design drafting (MEM09157A); and
(b) perform computations (MEM12024A); and
(c) produce an engineering drainage design of pipes and culverts (VU21131); and
(d) produce an engineering design for a stormwater reticulation scheme (VU21132); and
(e) produce an engineering design for a sewerage reticulation scheme (VU21133);
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
365
and
(f) produce engineering drawings for a stormwater reticulation scheme (VU21143); and
(g) generate design solutions (VU21154); and
(h) design fluid power controlled engineering systems (VU21202); and
(i) apply hydraulic principles in engineering (VU21203); and
(j) apply pneumatic principles in engineering (VU21204); and
(k) design pressure sewerage systems (VU21248); and
(l) design sewerage pumping station systems (VU21249).
(3) For the purposes of subclause (1)(a)(ii), the required units of competency are—
(a) prepare engineering drawings using manual drafting and CAD for electrotechnology/ utilities applications (UEENEEE190A); and
(b) prepare electrotechnology/utilities drawings using manual drafting and CAD equipment and software (UEENEEE191A); and
(c) provide advice on effective and energy efficient lighting products (UEENEEG181A).
(4) For the purposes of subclause (1)(a)(iii), the required units of competency are—
(a) perform mechanical engineering design drafting (MEM09157A); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
366
(b) produce basic engineering detail drawings (MEM09204A); and
(c) evaluate thermal loads in heating, ventilation, air-conditioning and refrigeration (MEM23129A); and
(d) contribute to the design of a commercial refrigeration system (MEM23144A); and
(e) contribute to the design of industrial refrigeration systems (MEM23146A); and
(f) contribute to the design of hydronic systems (MEM23147A); and
(g) contribute to the design of commercial and industrial exhaust systems (MEM23149A); and
(h) contribute to the design of heating systems (MEM23150A); and
(i) contribute to the design of heat exchanger systems (MEM23153A).
20 Class of commercial builder (unlimited)
The prescribed qualifications for registration in the class of commercial builder (unlimited) are—
(a) the successful completion of—
(i) a Bachelor of Construction Management and Economics from Holmesglen Institute; or
(ia) a Bachelor of Construction Management (Honours) from Deakin University; or
(ii) a Bachelor of Construction Management (Honours) from Victoria University; or
(iii) a Bachelor of Applied Science (Construction Management) from
Sch. 9 cl. 20(a)(ia) inserted by S.R. No. 75/2018 reg. 28(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
367
RMIT University; or
(iv) an advanced diploma of building and construction (management) (CPC60212) from an RTO; and
(b) at least 3 years of practical experience.
21 Class of commercial builder (limited to the construction of low rise building work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to the construction of low rise building work) are—
(a) the successful completion of—
(i) a Bachelor of Construction Management and Economics from Holmesglen Institute; or
(ia) a Bachelor of Construction Management (Honours) from Deakin University; or
(ii) a Bachelor of Construction Management (Honours) from Victoria University; or
(iii) a Bachelor of Applied Science (Construction Management) from RMIT University; or
(iv) a diploma of building and construction (building) (CPC50210) from an RTO, including the required units of competency; and
(b) at least 3 years of practical experience.
(2) For the purposes of this clause, the required units of competency are—
(a) apply building codes and standards to the construction process for large building
Sch. 9 cl. 21(1)(a)(ia) inserted by S.R. No. 75/2018 reg. 28(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
368
projects (CPCCBC6001B); and
(b) apply structural principles to the construction of large, high rise and complex buildings (CPCCBC6014A).
22 Class of commercial builder (limited to the construction of medium rise building work)
The prescribed qualifications for registration in the class of commercial builder (limited to the construction of medium rise building work) are—
(a) the successful completion of—
(i) a Bachelor of Construction Management and Economics from Holmesglen Institute; or
(ia) a Bachelor of Construction Management (Honours) from Deakin University; or
(ii) a Bachelor of Construction Management (Honours) from Victoria University; or
(iii) a Bachelor of Applied Science (Construction Management) from RMIT University; or
(iv) an advanced diploma of building and construction (management) (CPC60212) from an RTO; and
(b) at least 3 years of practical experience.
23 Class of commercial builder (limited to the construction of shade structures work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to the construction of shade structures work) are—
Sch. 9 cl. 22(a)(ia) inserted by S.R. No. 75/2018 reg. 28(2).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
369
(a) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) arrange building applications and approvals (CPCCBC4026A).
24 Class of commercial builder (limited to the erection of signs work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to the erection of signs work) are—
(a) the successful completion of the required units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the required units of competency are—
(a) select and prepare a construction contract (CPCCBC4003A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) read and interpret plans and specifications (CPCCBC4012B); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
370
(d) arrange building applications and approvals (CPCCBC4026A); and
(e) erect and dismantle restricted height scaffolding (CPCCCM2008B); and
(f) work safely on scaffolding higher than 2 metres (CPCCCM2010); and
(g) operate elevated work platforms up to 11 metres (CPCCCM3001); and
(h) work safely around electrical sources, services and assets (CPCCCM3003); and
(i) carry out concreting to simple forms (CPCCCO2013A); and
(j) apply basic levelling procedures (CPCCCM2006); and
(k) identify construction work hazards and select risk control strategies (CPCCWHS3001).
25 Class of commercial builder (limited to the installation of blinds and awnings work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to the installation of blinds and awnings work) are—
(a) the successful completion of a certificate in blinds, awnings, security screens and grilles (MSF30913) from an RTO, including the required units of competency and the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
371
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) arrange building applications and approvals (CPCCBC4026A); and
(e) read and interpret plans and specifications (CPCCBC4012B).
(3) For the purposes of this clause, the required units of competency are—
(a) install metal structures and features (AHCLSC308); and
(b) install exterior blinds and awnings (MSFBA3002); and
(c) perform minor maintenance (MSTGN2005).
26 Class of commercial builder (limited to non-structural fit-out work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to non-structural fit-out work) are—
(a) the successful completion of—
(i) a certificate in shopfitting (CPC30116) from an RTO, including the additional units of competency; or
(ii) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; or
(iii) a certificate in carpentry and joinery (CPC32011) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
372
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) arrange building applications and approvals (CPCCBC4026A).
27 Class of commercial builder (limited to steel erection work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to steel erection work) are—
(a) the successful completion of a certificate in rigging (CPC30711) from an RTO, including the required unit of competency and the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
373
(d) read and interpret plans and specifications (CPCCBC4012B); and
(e) apply structural principles to commercial low rise constructions (CPCCBC4011B); and
(f) arrange building applications and approvals (CPCCBC4026A).
(3) For the purposes of this clause, the required unit of competency is perform advanced structural steel erection (CPCCRI3014A).
28 Class of commercial builder (limited to structural fit-out work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to structural fit-out work) are—
(a) the successful completion of—
(i) a certificate in shopfitting (CPC30116) from an RTO, including the additional units of competency; or
(ii) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; or
(iii) a certificate in carpentry and joinery (CPC32011) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
374
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) apply building codes and standards to the construction process for medium rise building projects (CPCCBC5001B); and
(e) arrange building applications and approvals (CPCCBC4026A).
29 Class of commercial builder (limited to structural landscaping work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to structural landscaping work) are—
(a) the successful completion of—
(i) a certificate in landscape construction (AHC30916) from an RTO, including the additional units of competency; or
(ii) a diploma of landscape design (AHC50616) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
Sch. 9 cl. 29(1)(a)(ii) amended by S.R. No. 75/2018 reg. 28(3).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
375
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) read and interpret plans and specifications (CPCCBC4012B); and
(e) arrange building applications and approvals (CPCCBC4026A).
30 Class of commercial builder (limited to waterproofing work)
(1) The prescribed qualifications for registration in the class of commercial builder (limited to waterproofing work) are—
(a) a certificate in construction waterproofing (CPC31411) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) identify construction work hazards and select risk control strategies (CPCCWHS3001); and
(b) select and prepare a construction contract (CPCCBC4003A); and
(c) produce labour and material schedules for ordering (CPCCBC4005A); and
(d) read and interpret plans and specifications (CPCCBC4012B); and
(e) arrange building applications and approvals (CPCCBC4026A).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
376
31 Class of domestic builder (unlimited)
The prescribed qualifications for registration in the class of domestic builder (unlimited) are—
(a) the successful completion of—
(i) a Bachelor of Construction Management and Economics from Holmesglen Institute; or
(ii) a Bachelor of Construction Management (Honours) from Deakin University; or
(iii) a diploma of building and construction (building) (CPC50210) from an RTO; and
(b) at least 3 years of practical experience.
32 Class of domestic builder (limited to the construction of non-habitable building structures)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of non-habitable building structures) are—
(a) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
377
(d) identify construction work hazards and select risk control strategies (CPCCWHS3001).
33 Class of domestic builder (limited to the construction of gates and fences)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of gates and fences) are—
(a) the successful completion of—
(i) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(ii) a certificate in bricklaying and blocklaying (CPC30111) from anRTO, including the required units of competency and the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required units of competency are—
(a) lay masonry walls and corners (CPCCBL3005A); and
(b) lay multi-thickness walls and piers (CPCCBL3006A).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
378
34 Class of domestic builder (limited to the construction of retaining walls)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of retaining walls) are—
(a) the successful completion of a certificate in landscape construction (AHC30916) from an RTO, including the required units of competency and the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required units of competency are—
(a) erect timber structures and features (AHCLSC304); and
(b) implement a retaining wall project (AHCLSC307).
35 Class of domestic builder (limited to the construction of swimming pools and spas)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of swimming pools and spas) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
379
(a) the successful completion of a certificate in swimming pool and spa building (CPC40808) from an RTO, including the additional unit of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional unit of competency is arrange building applications and approvals (CPCCBC4026A).
36 Class of domestic builder (limited to the construction of private bushfire shelters)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of private bushfire shelters) are—
(a) the successful completion of a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
37 Class of domestic builder (limited to the construction of shade structures)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of shade structures) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
380
(a) the successful completion of a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
38 Class of domestic builder (limited to the construction of structural landscaping)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to the construction of structural landscaping) are—
(a) the successful completion of a certificate in landscape construction (AHC30916) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) read and interpret plans and specifications (CPCCBC4012B); and
(d) select and prepare a construction contract (CPCCBC4003A).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
381
39 Class of domestic builder (limited to bathroom, kitchen and laundry renovation)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to bathroom, kitchen and laundry renovation) are—
(a) the successful completion of a certificate in cabinet making (MSF31113) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
40 Class of domestic builder (limited to earthworks and excavation work)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to earthworks and excavation work) are—
(a) the successful completion of a certificate in civil construction plant operations (RII30815) from an RTO, including the required units of competency and the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) produce labour and material schedules for ordering (CPCCBC4005A); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
382
(b) read and interpret plans and specifications (CPCCBC4012B); and
(c) arrange building applications and approvals (CPCCBC4026A).
(3) For the purposes of this clause, the required units of competency are—
(a) apply the principles of earthworks construction (RIIMPO402D); and
(b) conduct earthworks (RIICRC306D); and
(c) carry out excavation (CPCCCM2002A); and
(d) install trench support (RIICCM210D).
41 Class of domestic builder (limited to footings and slab work)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to footings and slab work) are—
(a) the successful completion of a certificate in concreting (CPC30313) from an RTO, including the additional unit of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional unit of competency is arrange building applications and approvals (CPCCBC4026A).
42 Class of domestic builder (limited to framing)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to framing) are—
(a) the successful completion of a certificate in carpentry (CPC30211) from an RTO, including the required units of competency and the additional units of competency; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
383
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required units of competency are—
(a) construct ceiling frames (CPCCCA3005B); and
(b) construct pitched roofs (CPCCCA3007C); and
(c) erect roof trusses (CPCCCA3006B).
43 Class of domestic builder (limited to bricklaying and blocklaying)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to bricklaying and blocklaying) are—
(a) the successful completion of a certificate in bricklaying and blocklaying (CPC30111) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
384
(c) select and prepare a construction contract (CPCCBC4003A).
44 Class of domestic builder (limited to external wall cladding)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to external wall cladding) are—
(a) the successful completion of a certificate in carpentry (CPC30211) from an RTO, including the required unit of competency and the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required unit of competency is install exterior cladding (CPCCCA3017B).
45 Class of domestic builder (limited to roof tiling)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to roof tiling) are the successful completion of—
(a) a certificate in roof tiling (CPC30812) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
385
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
46 Class of domestic builder (limited to waterproofing)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to waterproofing) are—
(a) the successful completion of a certificate in construction waterproofing (CPC31411) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
47 Class of domestic builder (limited to door and window replacement and installation)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to door and window replacement and installation) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
386
(a) the successful completion of—
(i) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; or
(ii) a certificate in joinery (CPC31912) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
48 Class of domestic builder (limited to site works involved in relocating a dwelling)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to site works involved in relocating a dwelling) are—
(a) the successful completion of—
(i) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; or
(ii) a certificate in civil foundations (RII31215) from an RTO, including the required units of competency and the additional units of competency; and
(b) at least 2 years of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
387
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this regulation, the required units of competency are—
(a) conduct earthworks (RIICRC306D); and
(b) construct underpinning (RIICFW301D).
49 Class of domestic builder (limited to re-stumping and re-blocking)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to re-stumping and re-blocking) are—
(a) the successful completion of a certificate in civil foundations (RII31215) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
388
50 Class of domestic builder (limited to cabinet making, joinery and stair construction)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to cabinet making, joinery and stair construction) are—
(a) the successful completion of—
(i) a certificate in cabinet making (MSF31113) from an RTO, including the additional units of competency and the required unit of competency; or
(ii) a certificate in joinery (CPC31912) from an RTO, including the additional units of competency; or
(iii) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required unit of competency is install furnishing products (MSFFM3006).
51 Class of domestic builder (limited to carpentry)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to carpentry) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
389
(a) the successful completion of a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; and
(b) at least 3 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
52 Class of domestic builder (limited to the erection of poles, masts and antennas)
(1) The prescribed qualification for registration in the class of domestic builder (limited to the erection of poles, masts and antennas) are—
(a) the successful completion of the required units of competency from an RTO; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the required units of competency are—
(a) produce labour and material schedules for ordering (CPCCBC4005A); and
(b) read and interpret plans and specifications (CPCCBC4012B); and
(c) install a terrestrial antenna (ICTRFN202); and
(d) install a satellite antenna (ICTRFN201); and
(e) arrange building applications and approvals (CPCCBC4026A).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
390
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
53 Class of domestic builder (limited to sheet plastering)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to sheet plastering) are—
(a) the successful completion of a certificate in wall and ceiling lining (CPC31211) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
391
type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
54 Class of domestic builder (limited to solid plastering and rendering)
(1) The prescribed qualification for registration in the class of domestic builder (limited to solid plastering and rendering) are—
(a) the successful completion of a certificate in solid plastering (CPC31011) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
392
55 Class of domestic builder (limited to floor finishing and covering)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to floor finishing and covering) are—
(a) the successful completion of a certificate in flooring technology (MSF30813) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
56 Class of domestic builder (limited to glazing work)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to glazing work) are—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
393
(a) the successful completion of a certificate in glass and glazing (MSF30413) from an RTO, including the additional units of competency; and
(b) at least 2 years of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
57 Class of domestic builder (limited to insulation work)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to insulation work) are—
(a) the successful completion of a certificate in wall and ceiling lining (CPC31211) from an RTO, including the additional units of competency and the required units of competency; and
(b) at least one year of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
394
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
(3) For the purposes of this clause, the required units of competency are—
(a) install bulk insulation and pliable membrane products (CPCCPB3014); and
(b) install acoustic and thermal environmental protection systems (CPCCPB3015A); and
(c) install ceiling insulation products (CPCCPB3027).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
58 Class of domestic builder (limited to painting and decorating)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to painting
Sch. 9 cl. 57(3)(a) substituted by S.R. No. 75/2018 reg. 28(4).
Sch. 9 cl. 57(3)(c) amended by S.R. No. 75/2018 reg. 28(5).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
395
and decorating) are—
(a) the successful completion of a certificate in painting and decorating (CPC30611) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
59 Class of domestic builder (limited to floor and wall tiling work)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to floor and wall tiling work) are—
(a) the successful completion of a certificate in wall and floor tiling (CPC31311) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
396
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
60 Class of domestic builder (limited to attaching external fixtures)
(1) The prescribed qualifications for registration in the class of domestic builder (limited to attaching external fixtures) are—
(a) the successful completion of—
(i) a certificate in carpentry (CPC30211) from an RTO, including the additional units of competency; or
(ii) a certificate in blinds, awnings, security screens and grilles (MSF30913) from an RTO, including the additional units of competency; and
(b) at least one year of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
397
(2) For the purposes of this clause, the additional units of competency are—
(a) arrange building applications and approvals (CPCCBC4026A); and
(b) produce labour and material schedules for ordering (CPCCBC4005A); and
(c) select and prepare a construction contract (CPCCBC4003A).
Note
Under regulation 7 of the Domestic Building Contracts Regulations 2017, if this type of building work is undertaken in isolation under a contract, it is not considered domestic building work to which the Domestic Building Contracts Act 1995 applies. However registration under Part 11 of the Act to carry out this type of building work is required if this work and another type of building work listed under regulation 7 of the Domestic Building Contracts Regulations 2017 are to be carried out under the same contract because that work is then considered to be domestic building work for the purposes of the Domestic Building Contracts Act 1995.
61 Class of demolisher (low rise)
The prescribed qualifications for registration in the class of demolisher (low rise) are—
(a) the successful completion of a certificate in demolition (CPC30413) from an RTO; and
(b) at least 2 years of practical experience.
62 Class of demolisher (medium rise)
The prescribed qualifications for registration in the class of demolisher (medium rise) are—
(a) the successful completion of a certificate in demolition (CPC30413) from an RTO; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
398
(b) at least 2 years of practical experience.
63 Class of demolisher (unlimited)
The prescribed qualifications for registration in the class of demolisher (unlimited) are—
(a) the successful completion of a certificate in demolition (CPC41013) from an RTO; and
(b) at least 3 years of practical experience.
64 Class of project manager (domestic)
The prescribed qualifications for registration in the class of project manager (domestic) are—
(a) the successful completion of—
(i) a Bachelor of Construction Management and Economics from Holmesglen Institute; or
(ii) a Bachelor of Construction Management (Honours) from Deakin University; or
(iii) a Graduate Diploma of Construction Management from Swinburne University of Technology; or
(iv) a diploma of building and construction (management) (CPC50308) from an RTO; and
(b) at least 2 years of practical experience.
65 Category of quantity surveyor
The prescribed qualifications for registration in the category of quantity surveyor are—
(a) the successful completion of—
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
399
(i) a Bachelor of Applied Science (Construction Management) from RMIT University; or
(ii) a Bachelor of Construction Management (Honours) from Deakin University; or
(iii) a Bachelor of Construction Management and Economics from Holmesglen Institute; and
(b) at least 2 years of practical experience.
66 Class of temporary structures (limited to scaffolding stages and towers)
(1) The prescribed qualifications for registration in the class of temporary structures (limited to scaffolding stages and towers) are at least 2 years of practical experience and—
(a) an intermediate scaffolding licence issued under the Occupational Health and Safety Regulations 2017; or
(b) the successful completion of the required unit of competency from an RTO.
(2) For the purposes of this clause, the required unit of competency from an RTO is identify construction work hazards and select risk control strategies (CPCCWHS3001).
67 Class of temporary structures (limited to tents and marquees)
(1) The prescribed qualifications for registration in the class of temporary structures (limited to tents and marquees) are—
(a) the successful completion of the required unit of competency from an RTO; and
(b) 2 years of practical experience.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
400
(2) For the purposes of this clause, the required unit of competency from an RTO is identify construction work hazards and select risk control strategies (CPCCWHS3001).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
401
Schedule 10—Work authorised to be carriedout by a registered building surveyor
Regulation 259
Table
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised work
1 Category of building surveyor, class of building surveyor (unlimited)
Performance of all the functions that a building surveyor is authorised or required to perform under the Act and these Regulations, for all classes of building of unlimited height or floor area including the following—
(a) issuing building permits and temporary approvals as applicable under the Act;
(b) arranging and undertaking inspections of building work to determine compliance with the Act, these Regulations and the building permit;
(c) taking actions authorised under the Act and these Regulations to ensure building work complies with the Act, these Regulations and the building permit, including issuing—
(i) building notices; and(ii) building orders; and(iii) directions to fix building work under
section 37A of the Act;(d) approving the use and occupation of
buildings in accordance with the Act and these Regulations, including issuing occupancy permits and certificates of final inspection;
(e) carrying out the functions of a municipal building surveyor if the building surveyor—
(i) has been appointed as a municipal building surveyor in accordance with section 213 of the Act; or
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
402
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised work
(ii) is deemed to be a municipal building surveyor under section 215 of the Act; or
(iii) is acting as a delegate of a municipal building surveyor under section 216B of the Act, but only to the extent of carrying out the functions set out in the instrument of delegation;
(f) issuing certificates of compliance stating that proposed building work in the nature of design work complies with the Act and these Regulations;
(g) in relation to building work that has been inspected personally by that building surveyor, issuing certificates of compliance stating that the building work complies with the Act and these Regulations.
2 Category of building surveyor, class of building surveyor (limited)
Performance of all the functions that a building surveyor is authorised or required to perform under the Act and these Regulations, for all classes of building up to 3 storeys in height with a maximum floor area of 2000 m2 including the following—
(a) issuing building permits and temporary approvals as applicable under the Act;
(b) undertaking inspections of building work to determine compliance with the Act, these Regulations and the building permit;
(c) taking actions authorised under the Act and these Regulations to ensure building work complies with the Act, these Regulations and the building permit, including issuing—
(i) building notices; and(ii) building orders; and(iii) directions to fix building work under
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
403
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised work
section 37A of the Act;
(d) approving the use and occupation of buildings in accordance with the Act and these Regulations, including issuing occupancy permits and certificates of final inspection;
(e) carrying out the functions of a municipal building surveyor if the building surveyor is acting as a delegate or a municipal building surveyor under section 216B of the Act, but only to the extent of carrying out the functions set out in the instrument of delegation;
(f) issuing certificates of compliance stating that proposed building work in the nature of design work complies with the Act and these Regulations;
(g) in relation to building work that has been inspected personally by that building surveyor, issuing certificates of compliance stating that the building work complies with the Act and these Regulations.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
404
Schedule 11—Work authorised to be carriedout by a registered building inspector
Regulation 260
Table
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised work
1 Category of building inspector, class of building inspector (unlimited)
Performance of all the functions that a building inspector is authorised or required to perform under the Act and these Regulations, for all classes of building of unlimited height or floor area including the following—
(a) undertaking inspections of building work to determine compliance with the Act, these Regulations and the building permit at the request of the relevant building surveyor;
(b) issuing oral directions to fix building work under Division 2 of Part 4 of the Act if authorised by the relevant building surveyor;
(c) in relation to building work that has been inspected personally by that building inspector, issuing certificates of compliance under regulation 123 stating that the building work complies with the Act and these Regulations.
2 Category of building inspector, class of building inspector (limited)
Performance of all the functions that a building inspector is authorised or required to perform under the Act and these Regulations for all classes of buildings (excluding buildings with basements) of up to 3 storeys in height with a maximum floor area of 500 m2 or for all classes of buildings (including buildings with basements) of up to 3 storeys in height with a maximum floor area of up to 2000 m2 including the following—
(a) undertaking inspections of building work to determine compliance with the Act, these
Sch. 11 amended by S.R. No. 116/2019 reg. 18.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
405
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised work
Regulations and the building permit at the request of the relevant building surveyor;
(b) issuing directions to fix building work under Division 2 of Part 4 of the Act where authorised by the relevant building surveyor;
(c) in relation to building work that has been inspected personally by that building inspector, issuing certificates of compliance under regulation 123 stating that the building work complies with the Act and these Regulations.
3 Category of building inspector, class of building inspector (pool safety)
Performance of all of the functions that a swimming pool and spa inspector is authorised or required to perform under the Act and Part 9A of these Regulations including the following—
(a) undertaking inspections of swimming pool and spa barriers to determine compliance with the applicable barrier standard;
(b) issuing certificates of pool and spa barrier compliance;
(c) issuing certificates of pool and spa barrier non-compliance;
(d) lodging certificates of pool and spa barrier non-compliance with the relevant council.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
406
Schedule 12—Domestic building work authorised to be carried out by
registered domestic buildersRegulation 261
Table
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
1 Category of builder, class of domestic builder (unlimited)
The carrying out of all components of domestic building work.
2 Category of builder, class of domestic builder (limited to the construction of non-habitable building structures)
The carrying out of domestic building work associated with the construction of the following Class 10 buildings which are above ground and free standing in structure—
(a) a private garage;(b) a carport;(c) a separate single storey garage associated
with another building if the garage contains no more than 3 vehicle spaces;
(d) a shed;(e) a cabana;(f) a gazebo;(g) a shade structure.
Work in this class does not include the following work—
(a) the construction of retaining walls that are not part of the non-habitable building;
(b) the construction of external bathrooms, kitchens or laundries.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
407
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
3 Category of builder, class of domestic builder (limited to the construction of gates and fences)
The carrying out of domestic building work associated with the following work—
(a) the construction and dismantling of all types of fencing of any type of material, including associated manual and automatic gates;
(b) the construction of safety barriers for swimming pools and spas.
4 Category of builder, class of domestic builder (limited to the construction of retaining walls)
The carrying out of domestic building work associated with the construction of retaining walls of any material that do not form part of another building.
5 Category of builder, class of domestic builder (limited to the construction of swimming pools and spas)
The carrying out of domestic building work associated with the construction of swimming pools and spas and the construction of appropriate safety barriers for those swimming pools or spas.Work in this class does not include the following work—
(a) the construction of retaining walls;(b) the construction of shade structures;(c) the maintenance and general repair of
swimming pools and spas;(d) water chemistry.
6 Category of builder, class of domestic builder (limited to the construction of private bushfire shelters)
The carrying out of domestic building work associated with the construction of private bushfire shelters.
7 Category of builder, class of domestic builder (limited to the construction of shade structures)
The carrying out of domestic building work associated with the construction of shade structures.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
408
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
8 Category of builder, class of domestic builder (limited to the construction of structural landscaping)
The carrying out of domestic building work associated with the following work—
(a) the construction of the following—(i) retaining walls of any material,
that do not form part of another building;
(ii) gates;
(iii) fences (excluding swimming pool and spa safety barriers);
(iv) gazebos;(v) driveways;(vi) paths;(vii) external stairs and ramps;(viii) cabanas;(ix) pergolas;(x) decks;(xi) ornamental ponds, water
features and other structural ornamentation;
(b) drainage associated with work in paragraph (a);
(c) irrigation associated with work in paragraph (a);
(d) paving associated with work in paragraph (a).
9 Category of builder, class of domestic builder (limited to bathroom, kitchen and laundry renovation)
The carrying out of domestic building work associated with renovating bathrooms, kitchens and laundries that do not extend beyond the existing external walls, floor or ceiling of a home, including any site works, work requirements to gain access to the site, the removal of site impediments and the replacement of walls.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
409
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
10 Category of builder, class of domestic builder (limited to earthworks and excavation work)
The carrying out of domestic building work associated with the removal of earth, soil, rock and grass roots to excavation lines and levels to form a hole or trench, including site preparation work, the consideration of soil types and classifications and site drainage requirements for—
(a) structural supports; or(b) walls or floors of a building; or(c) structural landscaping work; or
(d) site preparation works including—(i) the consideration of soil types and
classifications; and(ii) site drainage requirements.
11 Category of builder, class of domestic builder (limited to footings and slab work)
The carrying out of domestic building work associated with the selection and placement of footing systems for—
(a) structural supports; or(b) walls or floors of a building; or(c) structural landscaping work; or(d) the construction and installation of
reinforced or bulk concrete footing and structural elements for buildings; or
(e) formwork; or(f) falsework; or(g) underpinning.
12 Category of builder, class of domestic builder (limited to framing)
The carrying out of domestic building work associated with the following work—
(a) fabricating, erecting and bracing wall frames (load bearing and non-load bearing);
(b) erection and replacement of roof trusses.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
410
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
13 Category of builder, class of domestic builder (limited to bricklaying and blocklaying)
The carrying out of domestic building work associated with the following work—
(a) construction of internal or external walls, isolated piers, arches, fireplaces and chimneys;
(b) concrete rendering to buildings and masonry fixtures;
(c) rammed earth or form cell construction;(d) mud brick footings to houses.
14 Category of builder, class of domestic builder (limited to external wall cladding)
The carrying out of domestic building work associated with applying the following types of external wall cladding to homes—
(a) weatherboards (timber or vinyl);(b) manufactured board or sheet panels;(c) lightweight aerated autoclaved concrete
panels.
15 Category of builder, class of domestic builder (limited to roof tiling)
The carrying out of domestic building work associated with the following work—
(a) initial tiling of roofs;(b) the repair and renovation of existing tiled
roofs;(c) re-pointing, sarking, cutting, bedding and
pointing of roof tiles.
16 Category of builder, class of domestic builder (limited to waterproofing)
The carrying out of domestic building work associated with waterproofing and the application, installation and repair of membranes or systems that may be applied to the interior, exterior, below ground and remedial areas of a home, except swimming pools and spas.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
411
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
17 Category of builder, class of domestic builder (limited to door and window replacement and installation)
The carrying out of domestic building work associated with selection, setting out, installation, removal or replacement of windows and doors.
18 Category of builder, class of domestic builder (limited to site works involved in relocating a dwelling)
The carrying out of domestic building work associated with relocating a home, consisting of—
(a) preparation of the new site; and(b) work associated with joining sections of
the home, and(c) repairing and replacing materials as a
result of the relocation of the home.Work in this class does not include transportation of a home or part of a home.
19 Category of builder, class of domestic builder (limited to re-stumping and re-blocking)
The carrying out of domestic building work associated with sub-floor works and the levelling and supporting of existing structures to ensure they have solid foundations.
20 Category of builder, class of domestic builder (limited to cabinet making, joinery and stair construction)
The carrying out of domestic building work associated with the following work—
(a) the manufacture, assembly and installation of joinery and joinery products, including cabinets, cupboards, shelving and fitments;
(b) cabinet-making work, including constructing cabinets and components of cabinets on site and making adjustments when required;
(c) constructing stairs.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
412
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
21 Category of builder, class of domestic builder (limited to carpentry)
The carrying out of domestic building work involving carpentry work associated with the alteration and repair of homes, carports, garages, pergolas, decks, verandas and similar structures.Work in this class also includes the domestic building work authorised to be carried out by the following classes of domestic builder—
(a) class of domestic builder (limited to the construction of non-habitable building structures);
(b) class of domestic builder (limited to the construction of gates and fences);
(c) class of domestic builder (limited to bathroom, kitchen and laundry renovation);
(d) class of domestic builder (limited to framing);
(e) class of domestic builder (limited to external wall cladding);
(f) class of domestic builder (limited to door and window replacement and installation);
(g) class of domestic builder (limited to cabinet making, joinery and stair construction).
22 Category of builder, class of domestic builder (limited to the erection of poles, masts and antennas)
The carrying out of domestic building work associated with the erection of poles, masts and antennas attached to a home if the pole, mast or antenna—
(a) exceeds a height of 3 m above the highest point of its attachment to the home; or
(b) exceeds a height of 8 m above ground level.
23 Category of builder, The carrying out of domestic building work
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
413
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
class of domestic builder (limited to sheet plastering)
associated with sheet plastering, including the cutting and fixing of interior wall boards.
24 Category of builder, class of domestic builder (limited to solid plastering and rendering)
The carrying out of domestic building work associated with the following solid plastering work—
(a) the application of plaster or render to interior or exterior surfaces;
(b) the restoration and renovation of solid plaster;
(c) the installation of associated cornices and decorative moulds.
25 Category of builder, class of domestic builder (limited to floor finishing and covering)
The carrying out of domestic building work associated with—
(a) the installation of non-structural flooring; and
(b) floor coverings including timber, timber veneers, parquetry, cork, carpet and vinyl.
Work in this class does not include fixing floor tiles.
26 Category of builder, class of domestic builder (limited to glazing work)
The carrying out of domestic building work involving the installation of glass, acrylic or other like materials in prepared openings, such as windows, door panels, screens, fences, balustrades or partitions.
27 Category of builder, class of domestic builder (limited to insulation work)
The carrying out of domestic building work involving installing insulation into ceilings, external walls and floors and around pipe and duct work, including the selection of appropriate types of insulation material for such installations.
28 Category of builder, class of domestic builder (limited to painting and decorating)
The carrying out of domestic building work involving—
(a) preparation of surfaces for the application of paint; and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
414
Column 1
Item
Column 2Category/prescribed class of building practitioner
Column 3
Authorised domestic building work
(b) the application of paint or other substances for protective, decorative or technical purposes; and
(c) colour matching.
29 Category of builder, class of domestic builder (limited to floor and wall tiling work)
The carrying out of domestic building work involving affixing tiles for functional or decorative use on the internal or external surfaces of a home, including a swimming pool or spa, which includes waterproofing the tiling.
30 Category of builder, class of domestic builder (limited to attaching external fixtures)
The carrying out of domestic building work involving the installation of external fixtures such as blinds, awnings, security screens, insect screens and balustrades.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
415
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Regulation 269
1 Cardinia Planning Scheme
2 Casey Planning Scheme
3 Hume Planning Scheme
4 Melton Planning Scheme
5 Mitchell Planning Scheme
6 Whittlesea Planning Scheme
7 Wyndham Planning Scheme
════════════
Sch. 13 inserted by S.R. No. 180/2018 reg. 14.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
416
Endnotes1 General information
See www.legislation.vic.gov.au for Victorian Bills, Acts and current Versions of legislation and up-to-date legislative information.
The Building Regulations 2018, S.R. No. 38/2018 were made on 27 March 2018 by the Governor in Council under sections 7, 9, 15A, 261 and 262 of, and Schedule 1 to, the Building Act 1993, No. 126/1993 and came into operation on 2 June 2018: regulation 3.
The Building Regulations 2018 will sunset 10 years after the day of making on 27 March 2028 (see section 5 of the Subordinate Legislation Act 1994).
INTERPRETATION OF LEGISLATION ACT 1984 (ILA)
Style changes
Section 54A of the ILA authorises the making of the style changes set out in Schedule 1 to that Act.
References to ILA s. 39B
Sidenotes which cite ILA s. 39B refer to section 39B of the ILA which provides that where an undivided regulation, rule or clause of a Schedule is amended by the insertion of one or more subregulations, subrules or subclauses the original regulation, rule or clause becomes subregulation, subrule or subclause (1) and is amended by the insertion of the expression "(1)" at the beginning of the original regulation, rule or clause.
Interpretation
As from 1 January 2001, amendments to section 36 of the ILA have the following effects:
• Headings
All headings included in a Statutory Rule which is made on or after 1 January 2001 form part of that Statutory Rule. Any heading inserted in a Statutory Rule which was made before 1 January 2001, by a Statutory Rule made on or after 1 January 2001, forms part of that Statutory Rule. This includes headings to Parts, Divisions or Subdivisions in a Schedule; Orders; Parts into which an Order is divided; clauses; regulations; rules; items; tables; columns; examples; diagrams; notes or forms. See section 36(1A)(2A)(2B).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
417
• Examples, diagrams or notes
All examples, diagrams or notes included in a Statutory Rule which is made on or after 1 January 2001 form part of that Statutory Rule. Any examples, diagrams or notes inserted in a Statutory Rule which was made before 1 January 2001, by a Statutory Rule made on or after 1 January 2001, form part of that Statutory Rule. See section 36(3A).
• Punctuation
All punctuation included in a Statutory Rule which is made on or after 1 January 2001 forms part of that Statutory Rule. Any punctuation inserted in a Statutory Rule which was made before 1 January 2001, by a Statutory Rule made on or after 1 January 2001, forms part of that Statutory Rule. See section 36(3B).
• Provision numbers
All provision numbers included in a Statutory Rule form part of that Statutory Rule, whether inserted in the Statutory Rule before, on or after 1 January 2001. Provision numbers include regulation numbers, rule numbers, subregulation numbers, subrule numbers, paragraphs and subparagraphs. See section 36(3C).
• Location of "legislative items"
A "legislative item" is a penalty, an example or a note. As from 13 October 2004, a legislative item relating to a provision of a Statutory Rule is taken to be at the foot of that provision even if it is preceded or followed by another legislative item that relates to that provision. For example, if a penalty at the foot of a provision is followed by a note, both of these legislative items will be regarded as being at the foot of that provision. See section 36B.
• Other material
Any explanatory memorandum, table of provisions, endnotes, index and other material printed after the Endnotes does not form part of a Statutory Rule. See section 36(3)(3D)(3E).
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
418
2 Table of AmendmentsThis publication incorporates amendments made to the Building Regulations 2018 by statutory rules, subordinate instruments and Acts.
–––––––––––––––––––––––––––––––––––––––––––––––––––––––––––––
Building Regulations 2018, S.R. No. 38/2018Date of Making: 27.3.18Date of Commencement: Reg. 282(2) on 2.6.18: reg. 3Note: Reg. 282(2) revoked reg. 282 on 1.7.18
Building Amendment Regulations 2018, S.R. No. 75/2018Date of Making: 13.6.18Date of Commencement: Regs 11, 24, 25, 27 on 13.6.18: reg. 3(1);
regs 5–10, 12–23, 26, 28 on 1.7.18: reg. 3(2)
Building Amendment (Garden Area and Siting Requirements) Regulations 2018, S.R. No. 100/2018
Date of Making: 10.7.18Date of Commencement: 10.7.18
Building Further Amendment Regulations 2018, S.R. No. 180/2018Date of Making: 23.10.18Date of Commencement: 23.10.18
Building Amendment Regulations 2019, S.R. No. 40/2019Date of Making: 4.6.19Date of Commencement: Regs 5, 6, 9–30 on 4.6.19: reg. 3(1); regs 7, 8 on
1.7.19: reg. 3(2)
Building Amendment (Swimming Pool and Spa) Regulations 2019, S.R. No. 116/2019
Date of Making: 26.11.19Date of Commencement: 1.12.19: reg. 3
–––––––––––––––––––––––––––––––––––––––––––––––––––––––––––––
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
419
3 Amendments Not in OperationThis publication does not include amendments made to the Building Regulations 2018 by the following Statutory Rules.
–––––––––––––––––––––––––––––––––––––––––––––––––––––––––––––
Building Regulations 2018, S.R. No. 38/2018Date of Making: 27.3.18Date of Commencement: Reg. 286 on 2.6.18: reg. 3Note: Reg. 286 revokes regs 18, 36, 45, 52, 244, 266,
272, 273 on 1.7.20
–––––––––––––––––––––––––––––––––––––––––––––––––––––––––––––
At the date of this publication, the following provisions amending the Building Regulations 2018 were Not in Operation:
Amending Statutory Rule/s:
Building Regulations 2018, S.R. No. 38/2018
286 Revocation of regulations prescribing fees
The following regulations are revoked on 1 July 2020—
(a) regulation 18;
(b) regulation 36;
(c) regulation 45;
(d) regulation 52;
(e) regulation 244;
(f) regulation 266;
(g) regulation 272;
(h) regulation 273.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
420
4 Explanatory detailsFee Units
These Regulations provide for fees by reference to fee units within the meaning of the Monetary Units Act 2004.
The amount of the fee is to be calculated, in accordance with section 7 of that Act, by multiplying the number of fee units applicable by the value of a fee unit.
The value of a fee unit for the financial year commencing 1 July 2019 is $14.81. The amount of the calculated fee may be rounded to the nearest 10 cents.
The value of a fee unit for future financial years is to be fixed by the Treasurer under section 5 of the Monetary Units Act 2004. The value of a fee unit for a financial year must be published in the Government Gazette and a Victorian newspaper before 1 June in the preceding financial year.
Penalty Units
These Regulations provide for penalties by reference to penalty units within the meaning of section 110 of the Sentencing Act 1991. The amount of the penalty is to be calculated, in accordance with section 7 of the Monetary Units Act 2004, by multiplying the number of penalty units applicable by the value of a penalty unit.
The value of a penalty unit for the financial year commencing 1 July 2019 is $165.22.
The amount of the calculated penalty may be rounded to the nearest dollar.
The value of a penalty unit for future financial years is to be fixed by the Treasurer under section 5 of the Monetary Units Act 2004. The value of a penalty unit for a financial year must be published in the Government Gazette and a Victorian newspaper before 1 June in the preceding financial year.
——
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
421
Table of Applied, Adopted or Incorporated Matter
The following table of applied, adopted or incorporated matter was included in S.R. No. 38/2018 in accordance with the requirements of regulation 5 of the Subordinate Legislation Regulations 2014.
In this table—
AS 1851—2005 means AS 1851—2005 Maintenance of fire protection systems and equipment, published by Standards Australia on 5 September 2005, as amended on 26 July 2006 and 23 May 2008;
AS 1851—2012 means AS 1851—2012 Routine service of fire protection systems and equipment, published by Standards Australia on 3 December 2012, as amended on 16 November 2016;
AS 3959—2009 means AS 3959—2009 Construction of buildings in bushfire-prone areas, published by Standards Australia on 10 March 2009, as amended on 16 November 2009, 15 February 2011 and 11 November 2011;
BCA means the Building Code of Australia;
BCA Volume One means Volume One of the National Construction Code 2016 including any variations or additions in the Appendix Victoria set out in the Appendices to that Volume;
BCA Volume Two means Volume Two of the National Construction Code 2016 including any Victoria additions set out in Appendix A to that Volume;
Building Code of Australia means the Building Code of Australia comprising—
(a) Volume One of the National Construction Code 2016 including any variations or additions in the Appendix Victoria set out in the Appendices to that Volume; and
(b) Volume Two of the National Construction Code 2016 including any Victoria additions set out in Appendix A to that Volume;
National Construction Code 2016 means the National Construction Code 2016 published by the Australian Building Codes Board on 1 May 2016, as amended on 12 March 2018.
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
422
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 5 (definition of AS 1851—2012)
AS 1851—2012 Routine service of fire protection systems and equipment, published by Standards Australia on 3 December 2012, as amended on 16 November 2016
The whole
Regulation 5 (definition of AS 3959)
AS 3959—2009 as incorporated for the time being by the BCA
The whole
Regulation 5 (definition of BCA)
Building Code of Australia The whole
Regulation 5 (definition of BCA Volume One)
Building Code of Australia Volume One
Regulation 5 (definition of BCA Volume Two)
Building Code of Australia Volume Two
Regulation 5 (definition of bushfire attack level)
AS 3959—2009 as incorporated for the time being by the BCA
The whole
Regulation 5 (definition of fire performance requirement)
BCA Volume One Performance requirement BP1.1, DP2, DP3, DP4 or DP6 (to the extent that it relates to fire safety)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
423
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Performance requirement CP1, CP2, CP3, CP4, CP5, CP6, CP7, CP8, CP9, DP5, EP1.1, EP1.2, EP1.3, EP1.4, EP1.5, EP1.6, EP2.1 or EP2.2
BCA Volume Two Performance requirement P2.1.1, P2.3.1 or P2.3.2 (to the extent that it relates to fire safety for a Class 1b building or a Class 10 building not associated with a Class 1a building)
Regulations 10, 11, 12 and 13
BCA The whole
Regulation 29(b) BCA Volume One Clause A2.2
BCA Volume Two Clause 1.2.2
Regulations 38 and 44(1)(j)
BCA The whole
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
424
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulations 74, 75, 76, 77, 79, 80, 86, 89 and Schedule 6
Alpine Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Ararat Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the schedule to that Zone and the General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Ballarat Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the schedule to that Zone and the Residential Growth Zone and General Residential Zone and the provisions of
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
425
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
the Planning Scheme (including the planning scheme maps) identifying those Zones
Banyule Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Bass Coast Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
426
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Baw Baw Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Bayside Planning Scheme made under the Planning and Environment Act 1987
Mixed Use Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Benalla Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
427
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Boroondara Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Brimbank Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and Neighbourhood Residential Zone and the schedules to those Zones and General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
428
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Campaspe Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Cardinia Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Casey Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
429
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Central Goldfields Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Colac Otway Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedule to that Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Corangamite Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
430
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Darebin Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and the schedules to that Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
East Gippsland Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Frankston Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
431
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Gannawarra Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Glen Eira Planning Scheme made under the Planning and Environment Act 1987
Mixed Use Zone and Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
432
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Glenelg Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Golden Plains Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Greater Bendigo Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and the General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
433
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Greater Dandenong Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Greater Geelong Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
434
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Greater Shepparton Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the schedule to that Zone and Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Hepburn Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
435
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Hindmarsh Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Hobsons Bay Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Horsham Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
436
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Hume Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Indigo Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Kingston Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and Residential Growth Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
437
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Knox Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Latrobe Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and the schedules to that Zone and General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
438
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Macedon Ranges Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the schedules to that Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Manningham Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
439
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Mansfield Planning Scheme made under the Planning and Environment Act 1987
Mixed Use Zone and the schedule to that Zone and the General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Maribyrnong Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Maroondah Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
440
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Melbourne Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Melton Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
441
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Mildura Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the schedule to that Zone and the General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Mitchell Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
442
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Moira Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Monash Planning Scheme made under the Planning and Environment Act 1987
Mixed Use Zone and Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Moonee Valley Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
443
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Moorabool Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and General Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Moreland Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the schedules to those Zones and Neighbourhood Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
444
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Mornington Peninsula Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedule to that Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Mount Alexander Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Moyne Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
445
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Murrindindi Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Nillumbik Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Northern Grampians Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
446
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Port Phillip Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and Residential Growth Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Pyrenees Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Queenscliffe Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and Neighbourhood Residential Zone and the schedules to
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
447
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
South Gippsland Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Southern Grampians Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
448
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Stonnington Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Strathbogie Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Surf Coast Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
449
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Swan Hill Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Towong Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Wangaratta Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
450
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Warrnambool Planning Scheme made under the Planning and Environment Act 1987
Mixed Use Zone and the schedules to that Zone and the General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Wellington Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and Neighbourhood Residential Zone and the schedules to those Zones and the General Residential Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
451
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Whitehorse Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and Neighbourhood Residential Zone and the schedules to those Zones and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Whittlesea Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and the Residential Growth Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
452
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying those Zones
Wodonga Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Wyndham Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Yarra Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the schedules to that Zone and the provisions of the Planning Scheme
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
453
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
(including the planning scheme maps) identifying that Zone
Yarra Ranges Planning Scheme made under the Planning and Environment Act 1987
Residential Growth Zone and Neighbourhood Residential Zone and the schedules to those Zones and General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying those Zones
Yarriambiack Planning Scheme made under the Planning and Environment Act 1987
General Residential Zone and the provisions of the Planning Scheme (including the planning scheme maps) identifying that Zone
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
454
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 117(1) AS 2601—2001 The demolition of structures, published by Standards Australia on 13 September 2001
The whole
Regulation 121 BCA Volume One Performance requirement BP1.1, DP2, DP3, DP4 or DP6 (to the extent that it relates to fire safety)Performance requirement CP1, CP2, CP3, CP4, CP5, CP6, CP7, CP8, CP9, DP5, EP1.1, EP1.2, EP1.3, EP1.4, EP1.5, EP1.6, EP2.1 or EP2.2
BCA Volume Two Performance requirement P2.1.1, P2.3.1 or P2.3.2 (to the extent that it relates to fire safety for a Class 1b building or a Class 10 building not associated with a Class 1a building)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
455
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 124(1) BCA The whole
Regulation 125(1) BCA Volume One Clause A2.2(a)(v)
Regulation 125(2) BCA Volume Two Clause 1.2.2(a)(iii)
Regulation 128(1) BCA Volume One Performance requirement BP1.1
BCA Volume Two Performance requirement P2.1.1
AS 2082—2007 Timber—Hardwood—Visually stress-graded for structural purposes, published by Standards Australia on 7 December 2007
The whole
AS 2858—2008 Timber—Softwood—Visually stress-graded for structural purposes, published by Standards Australia on 30 June 2008
The whole
AS/NZS 1748—2011 Timber—Solid—Stress-graded for structural purposes Part 1: General requirements, jointly published by Standards Australia and Standards New Zealand on 24 February 2011 as amended on 31 October 2012.
The whole
Statutory rule Title of applied, adopted or Matter in
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
456
provision incorporated document applied, adopted or incorporated document
AS 1613—2005 Timber—Colours for marking F-grades, published by Standards Australia on 13 September 2005
The whole
Regulation 128(2) AS 1720.1—2010 Timber structures—Part 1: Design methods, published by Standards Australia on 21 June 2010 as amended on 7 December 2010 and 13 August 2015.
The whole
Regulation 129 BCA The whole
Regulation 137(b) AS 1926.1—1993 Swimming pool safety—Part 1: Fencing for swimming pools, published by Standards Australia on 26 July 1993, as amended on 12 June 2000
The whole
Regulation 145(2) BCA Volume Two Part 3.7.2
Regulation 145(3) BCA Volume One Specification E2.2a
Regulations 146(2) and 147(2)
BCA Volume One Clause E1.5
Regulation 147(4) BCA Volume One Clause E1.4
Clause G4.4
Part E4
AS 2444—2001 Portable fire extinguishers and fire blankets—Selection and location, published by Standards Australia on 9 November 2001
The whole
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
457
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Practice Note 2008-13 issued by the Building Commission in November 2008
The whole
Regulation 147(5) BCA Volume One Clause E1.4
Clause G4.4
Part E4
Practice Note 2008-13 issued by the Building Commission in November 2008
The whole
Regulation 151 BCA Volume One Performance requirement BP1.1
BCA Volume Two Performance requirement P2.1.1
Regulation 152(1) BCA The whole
Regulation 152(2) BCA Volume One Clause A1.1
Regulation 152(3) BCA Volume Two Clause 1.1.1
Regulation 158(1) BCA Volume One Clause A1.1
Regulation 158(2) BCA Volume One Part G5
Regulation 159(b) and Schedule 7, item 1
Alpine Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
458
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 159(b) and Schedule 7, item 2
Baw Baw Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 3
Cardinia Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 4
Casey Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 5
Greater Bendigo Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
459
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 159(b) and Schedule 7, item 6
Horsham Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 7
Indigo Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 8
Latrobe Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 9
Macedon Ranges Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
460
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 159(b) and Schedule 7, item 10
Mitchell Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 11
Mount Alexander Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 12
Murrindindi Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 13
Nillumbik Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
461
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 159(b) and Schedule 7, item 14
Wellington Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 15
Whittlesea Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 159(b) and Schedule 7, item 16
Yarra Planning Scheme made under the Planning and Environment Act 1987
Clause 44.06 Bushfire Management Overlay (including the planning scheme maps) identifying that overlay
Regulation 160(1)(a) AS 3959—2009 as incorporated for the time being by the BCA
The whole
Regulation 163 (note)
BCA Volume Two P2.3.5
Regulation 164(1) BCA Volume One Clause A1.1
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
462
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 164(2) BCA Volume Two Clause 1.1.1 and clause O2.3(d)Performance requirement P2.3.5(e) and Application at the foot of performance requirement P2.3.5
Regulation 165 BCA Volume Two Performance requirement P2.3.5
Regulation 196(2) AS 1851—2005 The whole
AS 1851—2012 The whole
Regulation 196(3) AS 1851—2012 The whole
Regulation 203(j) BCA The whole
Regulation 217(2) AS 1851—2005 The whole
AS 1851—2012 The whole
Regulation 217(3) AS 1851—2012 The whole
Regulation 224(e) AS 1851—2012 The whole
Regulation 234(1) BCA Volume One Section D
Regulation 235 BCA Volume Two Performance requirement P2.3.1
Regulation 236(4) BCA Volume One Table E3.6b
F2.4(c)
F2.4(e)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
463
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
AS 1428.1—2009 Design for access and mobility Part 1: General requirements for access—New building work, published by Standards Australia on 27 November 2009, as amended on 26 November 2010, as incorporated by the BCA Volume One
The whole
AS 1428.1—2001 Design for access and mobility Part 1: General requirements for access—New building work, published by Standards Australia on 5 June 2001
The whole
Regulation 236(5) (definition of access provision)
BCA Volume One Section DPart E3 and F2
Access Code within the meaning of the Disability (Access to Premises — Buildings) Standards 2010 of the Commonwealth
The whole
Regulation 237(1), 237(2)
BCA Volume One Clause A1.1
Regulation 237(3) BCA Volume One Clause A3.2
Regulation 240(1) BCA Volume One Clause A1.1
Regulation 240(2) BCA Volume Two Clause 1.1.1
Regulation 241 BCA The whole
Schedule 3, Item 5 BCA Volume One Clause A3.2
BCA Volume Two Clause 1.3.2
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
464
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Schedule 4, Form 19 BCA Volume One Clause A0.7
BCA Volume Two Clause 1.0.7
Schedule 5, Part 1 BCA The whole
Schedule 8, Part 6, Item 1(f)
AS/NZS 1668.1—2015 The use of ventilation and air conditioning in buildings—Part 1: Fire and smoke control in buildings, jointly published by Standards Australia and Standards New Zealand on 14 December 2015
Sections 5 and 6
——Table of Applied, Adopted or Incorporated Matter
The following table of applied, adopted or incorporated matter was included in S.R. No. 75/2018 in accordance with the requirements of regulation 5 of the Subordinate Legislation Regulations 2014.
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 12 of the Building Amendment Regulations 2018 which amends regulation 147 of the Building Regulations 2018
AS 3745—2010 Planning for emergencies in facilities published by Standards Australia Ltd on 25 November 2010, as amended on 1 May 2014
The whole
——
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
465
Table of Applied, Adopted or Incorporated Matter
The following table of applied, adopted or incorporated matter was included in S.R. No. 100/2018 in accordance with the requirements of regulation 5 of the Subordinate Legislation Regulations 2014.
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 5 of the Building Amendment (Garden Area and Siting Requirements) Regulations 2018 which amends Schedule 6 to the Building Regulations 2018
Banyule Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Boroondara Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Cardinia Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Colac Otway Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the Schedule to that Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Darebin Planning Scheme made under the Planning and
Neighbourhood Residential Zone and the provisions of the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
466
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Environment Act 1987
Planning Scheme
(including planning scheme maps) identifying that Zone
Indigo Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Kingston Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Latrobe Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Manningham Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the Schedule to that Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Maribyrnong Planning Scheme made under the Planning and
Neighbourhood Residential Zone and the provisions of the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
467
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Environment Act 1987
Planning Scheme
(including planning scheme maps) identifying that Zone
Melton Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Nillumbik Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Port Phillip Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the Schedules to that Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Southern Grampians Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Wangaratta Planning Scheme made under the Planning and
Neighbourhood Residential Zone and the provisions of the
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
468
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Environment Act 1987
Planning Scheme
(including planning scheme maps) identifying that Zone
Warrnambool Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Whittlesea Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
Yarra Planning Scheme made under the Planning and Environment Act 1987
Neighbourhood Residential Zone and the provisions of the Planning Scheme (including planning scheme maps) identifying that Zone
——
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
469
Table of Applied, Adopted or Incorporated Matter
The following table of applied, adopted or incorporated matter was included in S.R. No. 180/2018 in accordance with the requirements of regulation 5 of the Subordinate Legislation Regulations 2014.
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulations 12 and 14 of the Building Further Amendment Regulations 2018 which insert regulation 269 and Schedule 13 into the Building Regulations 2018
Cardinia Planning Scheme made under the Planning and Environment Act 1987Casey Planning Scheme made under the Planning and Environment Act 1987Hume Planning Scheme made under the Planning and Environment Act 1987Melton Planning Scheme made under the Planning and Environment Act 1987Mitchell Planning Scheme made under the Planning and Environment Act 1987Whittlesea Planning Scheme made under the Planning and Environment Act 1987Wyndham Planning Scheme made under the Planning and Environment Act 1987
The whole
The whole
The whole
The whole
The whole
The whole
The whole
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
470
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 5(a) of the Building Amendment Regulations 2019 which amends regulation 5(1) of the Building Regulations 2018 (definition of AS 3959)
AS 3959:2018 Construction of buildings in bushfire-prone areas published by Standards Australia on 14 November 2018
The whole
Regulation 5(b) and (c) of the Building Amendment Regulations 2019 which amend regulation 5(1) of the Building Regulations 2018 (definitions of BCA Volume One, BCA Volume Two)
BCA Volume OneBCA Volume Two
Schedule 1
Regulation 6(1) of the Building Amendment Regulations 2019 which amends regulation 29(b) of the Building Regulations 2018
BCA Volume OneBCA Volume Two
Clause A5.1Clause A5.2
Regulation 10 of the Building Amendment Regulations 2019 which amends regulation 125(1) and (2) of the Building Regulations 2018
BCA Volume OneBCA Volume Two
Clause A5.2(1)(e)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
471
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 11(1) of the Building Amendment Regulations 2019 which amends regulation 145(2)(a) of the Building Regulations 2018
BCA Volume Two Part 3.7.5
Regulation 11(3) of the Building Amendment Regulations 2019 which amends regulation 145(3) of the Building Regulations 2018
BCA Volume One Clause 5 of Specification E2.2a
Regulation 12 of the Building Amendment Regulations 2019 which amends regulation 152(2) and (3) of the Building Regulations 2018
BCA Volume OneBCA Volume Two
Schedule 3
Regulation 13 of the Building Amendment Regulations 2019 which amends regulation 158(1) of the Building Regulations 2018
BCA Volume One Schedule 3
Regulation 14(1) of the Building Amendment Regulations 2019 which amends regulation 164(1) of the Building Regulations 2018
BCA Volume One Schedule 3
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
472
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 14(2) of the Building Amendment Regulations 2019 which amends regulation 164(2)(a) of the Building Regulations 2018
BCA Volume Two Schedule 3
Regulation 14(3) of the Building Amendment Regulations 2019 which amends regulation 164(2)(b) of the Building Regulations 2018
BCA Volume Two Clause O2.7(f)
Regulation 14(4) of the Building Amendment Regulations 2019 which amends regulation 164(2)(c) of the Building Regulations 2018
BCA Volume Two Performance requirement P2.7.6(e)
Regulation 14(5) of the Building Amendment Regulations 2019 which amends regulation 164(2)(d) of the Building Regulations 2018
BCA Volume Two Performance requirement P2.7.6
Regulation 15 of the Building Amendment Regulations 2019 which amends regulation 165 of the Building Regulations
BCA Volume Two Performance requirement P2.7.6
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
473
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
2018
Regulation 25(1) of the Building Amendment Regulations 2019 which amends regulation 237(1) and (2) of the Building Regulations 2018
BCA Volume One Schedule 3
Regulation 25(2) of the Building Amendment Regulations 2019 which amends regulation 237(3) of the Building Regulations 2018
BCA Volume One Clause A6.6
Regulation 26 of the Building Amendment Regulations 2019 which amends regulation 240(1) and (2) of the Building Regulations 2018
BCA Volume OneBCA Volume Two
Schedule 3
Regulation 29 of the Building Amendment Regulations 2019 which amends item 5 of the Table in Schedule 3 to the Building Regulations 2018
BCA Volume OneBCA Volume Two
Clauses A6.1 to A6.10
Regulation 30(7) of the Building Amendment Regulations 2019 which amends
BCA Volume OneBCA Volume Two
Clauses A2.2(3) and A2.4(3)
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
474
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Form 19 in Schedule 4 to the Building Regulations 2018
——Table of Applied, Adopted or Incorporated Matter
The following table of applied, adopted or incorporated matter was included in S.R. No. 116/2019 in accordance with the requirements of regulation 5 of the Subordinate Legislation Regulations 2014.
Statutory rule provision
Title of applied, adopted or incorporated document
Matter in applied, adopted or incorporated document
Regulation 11 of the Building Amendment (Swimming Pool and Spa) Regulations 2019 which inserts new regulation 147C into the Building Regulations 2018
AS 1926.1-1993 Swimming Pool Safety Part 1: Fencing for swimming pools published by Standards Australia Ltd on 26 July 1993, as amended in June 2000
The whole
Schedule 13—Planning schemes that have an approved infrastructure contributions plan
Building Regulations 2018S.R. No. 38/2018
475