TO THE DRAWINGS AND THE PROJECT MANUAL€¦ · CSP # 17-004 NEW TECHNOLOGY CENTER The Goose Creek Consolidated Independent School District (“GCCISD”) is requesting Competitive

NO. 5

TO THE DRAWINGS AND THE PROJECT MANUAL

PROJECT NAME: New Technology Center

CLIENT NAME: Goose Creek CISD

LOCATION: Baytown, Texas

PROJECT NUMBER: 1698-02

PROPOSAL DATE: Tuesday, February 14, 2017 at 2:00PM

ADDENDUM DATE: Monday, February 13, 2017

For additional information regarding this project, contact Cameron Mason at 800.687.1229.

THIS ADDENDUM INCLUDES:

Civil Items X Pages

Landscape Items X Pages

Structural Items X Pages

Architectural Items 1 Page

Foodservice Items X Pages

Plumbing Items X Pages

Mechanical Items X Pages

Electrical Items X Pages

Technology Items X Pages

AND ALL ATTACHED REVISED DRAWING REFERENCES IN THE ADDENDUM

Project Name: New Technology Center Client: Goose Creek CISD Baytown, Texas Project Number: 1698-02

Architectural Items For Addendum No. 5

Page 1 of 1

ARCHITECTURAL ITEMS FOR ADDENDUM NO. 5 NOTICE TO PROPOSERS:

A. This Addendum shall be considered part of the contract documents for the above-mentioned project as though it had been issued at the same time and incorporated integrally therewith. Where provisions of the following supplementary data differ from those of the original contract documents, this Addendum shall govern and take precedence.

B. Proposers are hereby notified that they shall make any necessary adjustments in their estimate on account of this Addendum. It will be construed that each Proposer’s proposal is submitted with full knowledge of all modifications and supplemental data specified therein. Acknowledge receipt of this addendum in the space provided on the proposal form. Failure to do so may subject Proposer to disqualification.

REFERENCE IS MADE TO THE DRAWINGS AND THE PROJECT MANUAL AS NOTED: PROJECT MANUAL:

AD No 5, Arch. Item 1: To the Project Manual, Section 00 0119, “CSP 17-004 RCSP,” Replace section in its entirety. Changes Highlighted. CLARIFICATION

AD No 5, Arch. Item 2: No Further RFI will be answered prior to Bid. DRAWINGS: END OF ADDENDUM

GOOSE CREEK CONSOLIDATED INDEPENDENT SCHOOL DISTRICT

PURCHASING DEPARTMENT

CSP # 17-004 NEW TECHNOLOGY CENTER

The Goose Creek Consolidated Independent School District (“GCCISD”) is requesting Competitive Sealed

Proposals from qualified offerors to provide services for the New Technology Center Project as identified

herein.

Competitive Sealed Proposals must be addressed to the Purchasing Department at the address listed below

and marked as follows:


Due no later than Tuesday, February 14th, 2017 AT 2:00 PM

Goose Creek CISD

Purchasing Department

4544 Interstate 10 East

Baytown, Texas 77521

ANY PROPOSAL RECEIVED AFTER THE TIME AND DATE STATED ABOVE WILL NOT BE

CONSIDERED. UNSIGNED PROPOSALS AND/OR PROPOSALS RECEIVED VIA FACSIMILE

OR EMAIL WILL NOT BE CONSIDERED. ALL RESPONSES MUST BE RECEIVED AT THE

ADDRESS SHOWN ABOVE. RESPONSES SENT/ DELIVERED TO ANY OTHER DISTRICT

ADDRESS WILL NOT BE CONSIDERED.

FAILURE TO COMPLY WITH SPECIFICATIONS MAY RESULT IN THE DISQUALIFICATION

OF YOUR PROPOSAL.

Offerors must provide all requested information; failure to comply with any portion of this solicitation will

be reflected in the evaluation process. The GCCISD reserves the right to accept or reject any Submission

or any part thereof or any combination of Submissions and to waive any or all formalities. All responses in

the Submission may be used by the GCCISD in the selection process. The GCCISD reserves the right to

verify the accuracy and completeness of all responses by utilizing any information available to the GCCISD

without regard to whether such information appears in the Submission.

Advertisement Dates: January 15, 2017

January 22, 2017

January 15, 2017

Joseph A. Villalba Jr. Date

Director of Purchasing & Warehouse Operations

Email: [email protected]

Phone: (281) 707-3869

mailto:[email protected]




I OVERVIEW

Pursuant to the provisions of Texas Government Code Chapter 2269, Subchapter D, as amended, it is the

intention of the Goose Creek Consolidated Independent School District (“GCCISD”) to select via the

Request for Competitive Sealed Proposal process a construction contractor for the New Technology Center

as generally described herein. Responses to this Request for Competitive Sealed Proposals (“CSP”) are

referred to herein as “proposals.” Entities submitting proposals are referred to as “Offerors.”

The architect for this project is Huckabee and Associates, Inc., located at 1800 Hughes Landing Boulevard,

Suite 701, The Woodlands, Texas 77380.

Offerors may obtain Contract Documents, including Project Manual by logging-in to the Architect’s Link

as indicated below. Drawings and specifications may be obtained electronically in PDF format at no charge

from the following location: Contract Documents will be posted after 12:00 noon on Monday, January 16,

2017 at www.huckabee-inc.com/Construction. Upon request a username and password will be issued for

electronic download.

In addition, Offerors may obtain Contract Documents from the Goose Creek CISD Planning and

Construction Department, located at 3401 N. Main Street, Baytown, Texas 77521. To obtain documents in

this manner, Offerors will be required to provide a refundable deposit check in the amount of TWO

HUNDRED AND 00/100 DOLLARS ($200.00) per set, made payable to the GCCISD. Each General

Contractor will only be allowed to pick up a maximum of three (3) sets of Contract Documents. Major

Subcontractors (including mechanical, electrical, etc) will be able to pick up a maximum of one (1) set upon

deposit of a refundable deposit check of the same amount indicated above, made payable to the GCCISD.

The deposit will be refunded upon return of the documents in clean unmarked and reusable condition within

ten (10) days after the opening of Proposals.

PROPOSALS MUST BE RECEIVED NO LATER THAN

2:00 PM ON TUESDAY, FEBRUARY 14, 2017

Any Proposal received after such time will not be considered and will be returned unopened. Proposals will

be received by:

Joseph A. Villalba Jr.

Director of Purchasing & Warehouse Operations

Goose Creek Consolidated Independent School District

4544 Interstate 10 East Baytown, Texas 77521

Proposal envelopes must be plainly marked on the outside as follows:

SEALED PROPOSAL – DO NOT OPEN

CSP #17-004 NEW TECHNOLOGY CENTER

PROPOSALS MUST BE SUBMITTED ON THE PROPOSAL FORM ATTACHED AS Error!

Reference source not found.. THIS REQUEST FOR CSP CONTAINS REQUIRED TERMS AND

DESCRIPTIVE INFORMATION ABOUT THE SERVICES. RESPONSES NOT MADE AS SET

FORTH IN THE REQUEST FOR CSP MAY BE DEEMED NON-RESPONSIVE AND MAY NOT BE

CONSIDERED.




For questions regarding this Request for CSP must be submitted in writing and addressed to:

Joseph A. Villalba Jr., Director of Purchasing & Warehouse Operations

Goose Creek Consolidated Independent School District

4544 Interstate 10 East Baytown, Texas 77521

Fax: (281) 421-3392 Email: [email protected]

Proposals are to include the information requested in Section V. Information to be Provided by General

Contractor Offerors of this CSP from the General Contractor in the sequence and format prescribed. In

addition to and separate from this information from the General Contractor, information is also requested

in Section VI. Information to be Provided Regarding NOC Infrastructure. Offerors submitting

proposals may provide supplementary materials further describing their capabilities and experience.

PRE-PROPOSAL CONFERENCE:

A pre-proposal conference for all bid packages will be held at the Facilities Management Complex

Building, 3401 North Main Street, Baytown, Texas 77521, on Friday, January 20, 2016 at 10:00 A.M.

Attendance is strongly encouraged by all Offerors.

Following the deadline for receipt, the GCCISD’s staff will receive, publicly open, and read aloud the

names of the Offerors and, if any are required to be stated, all prices stated in the proposals. Within forty-

five (45) days after the opening of the Proposals, the GCCISD shall evaluate and rank each Proposal

submitted in relation to the selected criteria set forth below. The GCCISD shall either select a construction

contractor from the respondents to this Request for Proposals or reject all proposals.

The recommended ranking shall be based on the data furnished by the Offerors in response to the Request

for CSP. The following is a list of criteria and weight for each criterion. Unless modified by addendum

prior to opening of the Proposals, the following listing of criteria and weight of criteria shall be utilized by

the GCCISD pursuant to Texas Government Code Chapter 2269, Subchapter D:

CRITERIA FOR SELECTION:

Consistent with Texas Government Code §2269.253, the following selection criteria and weighting will

be used for the selection process:

General Contractor General Information, 15 points total, consisting of:

o Firm Structure, 5 points

o Firm Stability, 5 points

o Subcontractor Information, 5 points

General Contractor Project Experience, 25 points total, consisting of:

o Relevant Past Experience, 10 points

o Unique Added Value, 10 points

o Safety Record, 5 points

General Contractor Project Management, 15 points total, consisting of:

o Project Approach, 4 points

o Strength of Proposed Project Team, 7 points

o Dispute Resolution, 4 points




General Contractor Base Bid Proposed Cost, 25 points total, consisting of:

o Base Bid Proposal Cost, 25 points

General Contractors NOC Infrastructure Project Experience, 20 points total, consisting of:

o Relevant Past Experience, 10 points

o Similar Completed Projects, 5 points

o Unique Added Value, 5 points

Please refer to Exhibit D for the scoring applicable to this CSP. This rubric will form the basis for analysis

of Applicant responses. The questions in Section V. and Section VI. (Scripted Format) will make up each

subsection of the scoring chart and are labeled in Exhibit D.

The District requires that all Applicant responses to the questions in Section V be clearly marked as the

response to the question asked. For example, when answering Question 1.3, you must clearly label your

response as the Answer to Question 1.3. The District will not consider any information that is not

properly labeled.

The questions in Section VI will be fill-in-the-blank responses to each question.

Applicants must submit one (1) original and three (3) copies of their response.

II COMMITMENTS OF THE GCCISD

1. The GCCISD reserves the right to withdraw this Request for CSP at any time and for any reason.

2. Receipt of response by the GCCISD or submission of a response to the GCCISD or selection of an

Offeror for the purposes of negotiating a contract; confers no rights to the Offeror, nor obligates the

GCCISD in any manner.

3. The GCCISD reserves the right to award or not award a contract. The GCCISD also will award the

Contract to the party or parties that the Board of Trustees of the GCCISD determines to be most

qualified and most responsive to this Request for CSP.

4. The GCCISD is under no obligation regarding this Request for CSP until a written contract is approved

and executed by all parties and funding of the Project occurs. The GCCISD’s draft forms of the

agreement are attached as Exhibits B and C.

5. The cost of developing a response is the sole responsibility of the Offeror. The GCCISD shall not

provide reimbursement of such cost, and shall not be liable for any response preparation cost for any

reason whatsoever.

III. INSTRUCTIONS TO OFFERORS

A. PROPOSAL FORM: The Proposal Form attached as Exhibit A must be filled out and signed by

the Offeror.

B. AGREEMENT: The Agreement between the Owner and Contractor shall consist of the following:

1. Standard Form of Agreement Between Owner and Contractor where the basis of payment is a

Stipulated Sum, attached as Exhibit B.

2. General Conditions of the Contract for Construction, AIA Document A201-2007, as modified

by the Owner attached as Exhibit C.




3. Plans and Specifications.

C. TIME: Offeror agrees to hold the proposal open for acceptance for 45 calendar days from the

proposal date.

D. WITHDRAWAL OF PROPOSALS: Offerors may request permission to withdraw a proposal

prior to the actual time for proposal opening. Such request must be made in person or in writing at

the same location designated to receive the proposal. The GCCISD will return the proposal

documents unopened at that time.

E. WAIVER: By submitting a proposal, each Offeror agrees to waive any claim it has or may have

against the GCCISD, its trustees, agents and employees, and any reference sources, arising out of

or in connection with the administration, evaluation, or recommendation of any proposal; waiver

of any requirements under the proposal documents; acceptance or rejection of any proposal; and

award of the proposal. The GCCISD shall have no contractual obligation to any Offeror, nor will

any Offeror have any property interest or other right in the proposal or contract being proposed

unless and until the contract is unconditionally executed and delivered by all parties, and all

conditions to be fulfilled by the Offeror have been fulfilled by the Offeror.

F. OTHER INFORMATION: The GCCISD believes the information included in this Request for

CSP is materially accurate, however, the GCCISD does not warrant this information to be free

from errors or omissions. Offerors are encouraged to inspect the premises prior to submitting a

response. Notwithstanding any provision to the contrary in the Project Manual, once the final

Contract Documents are executed; this CSP Document, CSP 17-004, shall not be considered part

of the final Contract Documents.

G. THE OFFEROR MUST SUBMIT THE FOLLOWING ITEMS:

1. Exhibit A: Proposal Form, signed by Offeror.

2. Responses to Information required by Section V. Information to be Provided by General

Contractor Offerors.

3. Responses to information required by VI. Information to be Provided Regarding NOC

Infrastructure Experience.

4. Exhibit E: Felony Conviction Notification, signed by Offeror.

5. Exhibit F: Non-Collusion Statement, signed by Offeror. 6. Purchasing Department Standard Documents.

IV. SCOPE OF WORK; SCHEDULE

The work includes, but is not limited to the following: A New Technology Center and Network

Operations Center (NOC) as indicated on the Drawings and in the Project Manual.

The estimated budget for this project is: $9,600,000.00




PROJECT CONSTRUCTION SCHEDULE:

Board Contract Approval: Monday, February 27, 2017

Notice to Proceed: Tuesday, February 28, 2017

Substantial Completion by: Wednesday, February 28, 2018

Final Completion by: Friday, March 30, 2018

The District is also requiring the Offeror to propose a separate cost of an accelerated schedule for a

substantial completion date of Dec 15, 2017 with a final completion date of Jan 12, 2018.

Costs for both construction timelines must be provided, for proposals to be considered.

OTHER REQUIRED DOCUMENTS:

The Offeror must complete and submit the Felony Conviction Notification Form and the Non-Collusion

Statement attached as Exhibit E and Exhibit F.

MINIMUM WAGE RATES:

The GCCISD has ascertained and adopted the Prevailing Wage Rates for School Construction Trades

(effective March 1, 2016) published in Chapter 2258 of the Texas Government Code. The wage rates are

attached as Exhibit G.

Successful Offerors shall pay at least the minimum wage rate set forth in such Schedule to all employees

and subcontractors performing work on this Project and in no event shall the successful Offeror pay less

than the rate adopted.

The scope of the work is more fully described in the Contract Documents available from Huckabee

Architects and/or the GCCISD.

TO THE EXTENT OF ANY CONFLICT BETWEEN THE TERMS OF THE PROPOSAL

DOCUMENTS (INCLUDING THE SPECIFICATIONS), AND THE TERMS OF THE OWNER-

MODIFIED AIA A101--2007 AND A201--2007 INCLUDED WITH THIS PROPOSAL, THE TERMS

OF THE OWNER-MODIFIED AIA A101 AND A201 SHALL CONTROL.

V. INFORMATION TO BE PROVIDED BY GENERAL CONTRACTOR OFFERORS

Please provide the following information in the sequence and format prescribed by this questionnaire.

Supplemental materials providing additional information may be provided in a separate format, but the

information requested below is to be provided in this format. Applicant’s responses to these questions will

be scored in accordance with the Scoring Rubric attached as Exhibit D.

1. General Contractor’s Firm Information

1.1 Name of Firm, Year founded:

1.2 Address of Principal Office, Phone and Fax:

1.3 Form of Business Organization (corporation, partnership, individual, joint venture, other?):

1.4 Primary Individual to Contact:

2. General Contractor’s Organization

2.1. How many years has your organization been in business in its current capacity?

2.2. How many years has your organization been in business under its present name? Under what other

or former names has your organization operated?




2.3. If your organization is a corporation, answer the following: Date of incorporation, State

incorporated, President's name, Vice-President's name(s), Secretary's name, and Treasurer's name.

2.4. If your organization is a partnership, answer the following: Date of organization, Type of

partnership (if applicable), and Name(s) of general partner(s).

2.5. If your organization is individually owned, answer the following: Date of organization, Name of

owner.

2.6. If the form of your organization is other than those listed above, describe it and name the

principals.

2.7. What is the dollar value of work done in the Houston area for the three-year period of 2014-2016,

and what percentage of your total work does this represent?

3. General Contractor’s Experience

3.1. Completed Work within the last five years: List up to the last five (5) similar projects constructed

by your organization; For each project, provide the name, nature of the project/function of the

building, size (SF), location, cost, contractual completion date, actual completion date, owner and

architect (and their phone numbers).

3.1.1. Project contacts listed in 3.1 and 3.2 may be contacted for references.

3.2. Current Work: List up to five (5) projects of similar size and scope currently under construction


building, size (SF), location, cost, contractual completion date, actual completion date, owner and

architect (and their phone numbers).

3.3. List the categories of work that your organization normally performs with its own forces. Would

you propose to do any work with your own forces?

3.4. List any subcontractors in which your organization has some ownership and list the categories of

work those subcontractors normally perform.

3.5. Claims and suits (If the answer to any of the questions below is yes, please provide details).

a. Has your organization ever failed to complete any work awarded?

b. Are there any judgments, claims, arbitration proceedings or suits, pending or outstanding

against your organization or its officers?

c. Has your organization filed or been involved in any lawsuits or requested arbitration with

regard to construction contracts within the last five years?

3.6. Within the last five years, has any officer or principal of your organization ever been an officer or

principal of another organization when it failed to complete a construction contract? (If the answer

is yes, please provide details.)

3.7. Describe your organization’s safety program and provide your worker’s compensation

Experience Modification Factor. List any safety awards your company has received.

4. General Contractor’s Financial Information

4.1. Attach an audited financial statement, including your organization's latest balance sheet and

income statement showing the following items:

a. Current assets (e.g., cash, joint venture accounts, accounts receivable, notes receivable,

accrued income, deposits, materials inventory, and prepaid expenses).

b. Non-current assets (e.g., net fixed assets, other assets).

c. Current liabilities (e.g., accounts payable, notes payable, accrued expenses, provision for

income taxes, advances, accrued salaries and accrued payroll taxes).

d. Non-current liabilities (e.g., notes payable).

e. Capital accounts and retained earnings (e.g., capital, capital stock, authorized and outstanding

shares par value, earned surplus, and retained earnings).

4.2. Name and address of firm preparing attached financial statement and date thereof.




4.3. Is the attached financial statement for the identical organization named under item 1 above? If not,

explain the relationship and financial responsibility of the organization whose financial statement

is provided (e.g., parent subsidiary).

4.4. Will the organization whose financial statement is attached act as guarantor of the contract for

construction?

4.5. Provide name, address and phone number of your financial institution.

4.6. Surety: Name of bonding company and name and address of agent.

5. General Contractor’s Personnel

5.1 Given the scope and schedule of the project, identify the personnel proposed, specifically the

Project Manager, Job Superintendent or Superintendent(s), Estimator and Field Operations

personnel proposed to work on the project. Provide a resume and references for each individual.

Prior to contracting with a General Contractor, the Goose Creek Consolidated Independent

School District may interview the Project Manager/Job Superintendent that will be assigned to the

project. Please reference these personnel to projects listed in items 3.1 and 3.2 and explain how

these personnel align with the proposed project.

5.2 Provide an organizational chart outlining all personnel that will be assigned to the project and their

responsibilities.

5.3 What do you bring to the project team (GCCISD, Architects and Contractor) that is unique? Please

answer in essay form.

5.4 What is your role in ensuring that the Architect, Owner and Contractor work as a team? How will

you resolve team conflict? Please answer in essay form.

VI. INFORMATION TO BE PROVIDED REGARDING NOC INFRASTRUCTURE

EXPERIENCE (Fill in the Blanks to Questions below)

Please provide the following information by filling in the blanks regarding NOC Infrastructure experience.

Supplemental materials providing additional information may be provided if needed. General Contractor

responses to these questions will be scored in accordance with the Scoring Rubric attached as Exhibit D.

1. NOC Infrastructure Experience of General Contractor’s Organization:

1.1. How many years has your organization been involved building Network Operating Centers

(NOC’s)?

1.2. What is the dollar value of NOC work done in the Houston area for the three-year period of

2014-2016 and what percentage of your total work does this represent?




1.3. Completed Work in the last five years: List up to the last five (5) similar projects consisting of

Network Operation Centers constructed by your organization. For each Project, provide name of

project, nature of project, function of building, size (SF), location, cost, completion date, owner

and architect (and their phone numbers). You may use additional pages if you wish. Contacts listed

in this section may be contacted for references.

1.4. Current Work: List up to three (3) projects of similar size and scope currently under construction


building, size (SF), location, cost, completion date, Owner and Architect (and their contact

information).

1.5. Claims and suits: (If the answer to any of the questions below is yes, please provide details).

1.5.1. Has your organization ever failed to complete any NOC work awarded?

1.5.2. Are there any judgments, claims, arbitration proceedings or suits, pending or outstanding

against your organization or its officers resulting from NOC work?

1.5.3. Has your organization filed or been involved in any lawsuits or requested arbitration with

regard to NOC work within the last five years?




2. Method of Selection:

A scoring chart is attached as Exhibit D. This chart will form the basis of the evaluation committee’s

analysis of Offeror responses. The questions that make up each subcategory of the Scoring Chart are

labeled.

The GCCISD requires that all Offeror responses be clearly marked as the response to each question asked.

For example, when answering Question 1-1, you must clearly label your response as the answer to Question

1-1. The GCCISD will not consider any information that is not properly labeled.

3. Execution:

The foregoing is true and correct. The GCCISD, or any authorized representative of the GCCISD, is

authorized by the undersigned to contact any firm, institution, or person listed above to obtain information

about our firm's services, financial condition, and any other information which the GCCISD might

determine as being desirable.

Offeror: _______________________________________

By: __________________________________________

(Signature)

__________________________________________

(Printed Name)

__________________________________________

(Title)




EXHIBIT A

PROPOSAL FORM: IDENTIFICATION OF OFFEROR AND ACCEPTANCE OF TERMS

IMPORTANT: A proposal, to be valid, must be manually signed in ink by an authorized person in the space

provided. By such signature, offeror agrees to strictly abide by the terms, conditions, and specifications set out in the

Request for Competitive Sealed Proposal.

1.1 TO: Goose Creek CISD Purchasing Department 4544 I-10 East Baytown, Texas 77521

1.2 SUBMITTED BY:

Address:

Phone: Fax: Date:

Email: Signature:

Printed Name: Title:

1.3 PROPOSAL: Undersigned agrees to complete the Work, for the LUMP SUM PROPOSAL amount of:

Proposal: Provide the construction of the New Technology Center including all site work, utilities, overall all

building envelope, finishes and all other construction related components and equipment of the Network

Operations Center (NOC). Refer to the project drawings and specifications for clarification of all items.

Dollars

(Amount written in words governs)

$_____________________________ (Amount in figures)

Accelerated Schedule Proposal: Provide the construction of the New Technology Center including all site

work, utilities, overall all building envelope, finishes and all other construction related components and

equipment of the Network Operations Center (NOC) for an accelerated schedule (with respect to Section IV)

of substantial completion date of Dec 15, 2017 with a final completion date of Jan 12, 2018. Refer to the

project drawings and specifications for clarification of all items.

Dollars

(Amount written in words governs)

$_____________________________ (Amount in figures)

1.4 UNIT PRICES: Offeror shall provide the following materials & systems at prices as stated below:

UNIT PRICING MATERIAL/SYSTEM UNITS COST/UNIT

Excavation (Dirt or Caliche) Cubic Yard $

Excavation (Rock) Cubic Yard $

Backfilling (On-Site) Cubic Yard $

Reinforcing Steel, Straight or Bent Pound $

Structural Concrete Cubic Yard $

Auger Cast Grout Piles — Complete including reinforcing, concrete, accessories and drilling

UNIT PRICING MATERIAL/SYSTEM UNITS COST/UNIT

24” Diameter Lineal Foot $




1.5 ALLOWANCES: Reference Section 01 2100-Allowances for amounts to be included in the LUMP SUM

PROPOSAL amount in paragraph 1.3 entitled “PROPOSAL” above.

1.6 ADDENDA: Undersigned acknowledges receipt of Addenda:

(Nos. & Dates)

Addendum No. _____ ___________________________________

Addendum No. _____ ___________________________________

Addendum No. _____ ___________________________________

Addendum No. _____ ___________________________________

Addendum No. _____ ___________________________________

Addendum No. _____ ___________________________________

Signature:




EXHIBIT B

AIA A101—2007, AS MODIFIED BY OWNER




EXHIBIT C

AIA A201---2007, AS MODIFIED BY OWNER




EXHIBIT D

SCORING RUBRIC




EXHIBIT E

FELONY CONVICTION NOTIFICATION

State of Texas Legislative Senate Bill No.1, Section 44.034, Notification of Criminal History, Subsection

(a) states “a person or business entity that enters into a contract with a school district must give advance

notice to the district if the person or an owner or operator of the business entity has been convicted of a

felony. The notice must include a general description of the conduct resulting in the conviction of a felony.”

Subsection (b) states “a school district may terminate a contract with a person or business entity if the

district determines that the person or business entity failed to give notice as required by Subsection (a) or

misrepresented the conduct resulting in the conviction. The district must compensate the person or business

entity for services performed before the termination of the contract.”

This notice is not required of a Publicly-held Corporation.

I, the undersigned agent for the firm named below, certify that the information concerning notification of

felony convictions has been reviewed by me and the following information furnished is true to the best of

my knowledge.

Vendor’s Name:

Authorized Company Official’s Name (Printed):

a. My firm is a publicly held corporation; therefore, this reporting requirement is not applicable:

Signature of Company Official

b. My firm is not owned nor operated by anyone who has been convicted of a felony.


c. My firm is owned or operated by the following individual(s) who has/have been convicted

of a felony:

Name of Felon(s)

Details of Conviction(s)





EXHIBIT F

ACKNOWLEDGMENT FORM - NON-COLLUSION STATEMENT

The undersigned affirms that they are duly authorized to execute this contract, that this company,

corporation, firm, partnership or individual has not prepared this submission in collusion with any other

proposer, and that the contents of this submission as to prices, terms or conditions of said submission have

not been communicated by the undersigned nor by any employee or agent to any other person engaged in

this type of business prior to the official opening of this submission.

Vendor:

Address:

Phone:_____________________________________ Fax:

Respondent (Signature):

Respondent (Print Name):

Position with Company:


Authorizing Submission:

Company Official (Print Name):

Official Position:




EXHIBIT G

PREVAILING WAGE RATE AS ADOPTED BY THE GCCISD BOARD OF TRUSTEES