Technical bid W-673 - GUVNL Office/Kutch Lignite... · 4 Security Deposit 5 % of Order value 5 Last date of receipt of tender ... Following are the checkpoint: 4.1 > General cleaning

GUJARAT STATE ELECTRICITY CORPORATION LTD. (Formerly known as Gujarat Electricity Board)

KUTCH LIGNITE THERMAL POWER STATION, SKV NAGAR, TAL: LAKHPAT, KUTCH - 370 601.

TENDER BOOKLET

TECHNICAL BID

Tender KLTPS- 38 , W-673, RFQ No-14405

Name of work: - Work of Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Issued to : Opened on :

GUJARAT STATE ELECTRICITY CORPORATION LTD.

KUTCH LIGNITE THERMAL POWER STATION

SKV NAGAR-KUTCH: 370601

INDEX

TECHNICAL BID

NAME OF WORK: Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Sr. No. Description.

01 Tender Notice (Technical Bid).

02 Scope of work.

03 Reference Schedule - B

04 List of documents required

05 Form-01

06 Form-02

07 Integrity Pack

08 General Instruction to Bidder (01)

09 General terms & conditions (001)

10 Labour Laws

11 General safety rules

Name of Firm

Tender fees no

EMD receipt no

GUJARAT STATE ELECTRICITY CORPORATION LTD

KUTCH LIGNITE THERMAL POWER STATION SKV NAGAR: PANANDHRO: 370 601

Online www.gseb.com; www.statetenders.com

TENDER NOTICE (Technical bid)

Sealed percentage rate tenders are invited for Overhauling of 415 V Raw water ACB and

modules with spares at KLTPS

1 Estimated cost Rs. 9,28,950.00

2 Tender fee (Non returnable) Rs. 750.00

3 Earnest Money Deposit Rs. 9290.00

4 Security Deposit

5 % of Order value

5 Last date of receipt of tender

15.11.2010 Up to 15:30 hrs.

6 Date of opening of tender

15.11.2010 onwards 16:00 hrs.

7 Time limit of work 2 months

8 Validity of tender

180 days from opening of Technical bid

Note:

The tender fee & EMD will be paid in cash or by Demand Draft in favor of Gujarat State Electricity

Corporation Ltd., payable at Dena Bank, SKV Nagar, Panandhro branch. Filled tender shall be accepted

by RPAD/speed post only. The technical bid & price bid should be kept in two separate sealed covers and

these two covers should be kept in main sealed cover. The tender will be opened in the presence of

contractors, who wish to remain present at the time of opening of tenders. Tender fee & EMD have to be

submitted along with technical bid, if not found offer will out rightly rejected. The undersigned reserves

the right to reject any or all tenders without assigning any reason thereof.

Details of tender fee & EMD paid (DD / MR No. & date) is invariably to be mentioned on the cover of

the tender. In absence, offer will be rejected.

Bidder has to submit tender fee / EMD in a separate cover duly super scribe with Tender Fee / EMD and

all three covers (Technical bid, Price bid and EMD/Tender fee covers) after keeping in the main cover

(Forth cover) duly super scribed with the required details such as Tender No, Description and details of

EMD/Tender Fee etc., is to be sent by RPAD/Speed Post

For & behalf of GSECL

M.C.Jain Chief Engineer (G.)

GSECL, KLTPS. SIGNATURE OF CONTRACTOR WITH SEAL & DATE

Gujarat State Electricity Corporation Limited

SCOPE OF WORK

Name of Work : “Overhauling of 415 V Raw water ACB and modules with spares at KLTPS

Scope of work includes :.

(1) Initially execute bonds – fulfill all formalities related with HR section(NOC) and safety section- carried out site survey for the work, if you required with EIC and start work within a week after dully supply.

(2) Includes General health checkup of MCC maintenance, overhauling, cleaning & checking as Following

are the checkpoint : 2.1 > General cleaning of complete cubicle by removing all draw out module. 2.2 > Checking of tightness of all Infinite bus bar, Vertical/Horizontal drop out, joints, I/C & O/G terminal with

torque wrench. 2.3 > Complete sealing of MCC to avoid entry of insects, lizards & mouse. 2.4 > Replacement of gasket with new leporine gasket. 2.5 > Replacement of door fixing missing/ damaged bolts. 2.6 > Re-termination of damaged lugs. 2.7 > Painting of the complete MCC Panel. 2.8 > After completion job, Measured IRV for infinite bus. 2.9 > Contractor should be Reported with individual feeder O/H work. (3) Includes Servicing & Overhauling of ACBs including renovation of ACB Cubicle: Rating: 800 A 3 Pole= 7 Nos (Raw water motor feeders) 1600 A 3 Pole= 5 Nos (Incomer and Bus coupler) 3.1 > Cleaning of dust, spider web, foreign particles etc. 3.2 > Checking of tightness of all infinite bus bar, vertical/horizontal drop out, joints I/C & O/G terminal with

torque wrench. 3.3 > Replacement of gasket with new leporine gasket with materials. 3.4 > Replacement of door fixing missing/damaged bolts with materials 3.5 > Removal of old grease from various parts 3.6 > Cleaning of Various parts with CRC - 2-26 ( CRC will be arranged by contractor) 3.7 > Check condition of arcing contact and gap between fixed and moving arcing contacts. Replacement of

arcing contacts and main contact if required. 3.8 > Check reset mechanism & tripping of breaker through push button 3.9 > Check tripping of ACB through protection release. 3.10 > Check and adjust freeness of DN or SR and voltmetric releases tripping mechanism. 3.11 > Check presence and proper tightening of hardware. 3.12 > Check presence of all circlips. 3.13 > Check condition and alignment of jaw contact with cradle terminals 3.14 > Replacement of damage parts if any (Spares provide by the agency as per schedule B1 (supply) 3.15 > Replacement of mechanical ON-OFF push button. 3.16 > Replacement of Electrical ON-OFF & trip indication. 3.17 > Replacement of Electrical trip Push button. 3.18 > Replacement of TNC Switch. 3.19 > Check control wiring and replace if required. 3.20 > Check and adjust gap between Hylam sheet and side plate. 3.21 > Check proper closing of all poles together. 3.22 > Check working of anti pumping device in case of EDO ACB 3.23 > Check alignment of SIC and it’s operation. 3.24 > Checking scrapping earth alignment 3.25 > Check condition of arc chutes. 3.26 > Check U/V release pick up and drop off. 3.27 > Check ACB tripping through shunt release. 3.28 > Check motor operation in case of EDO ACB 3.29 > Check closing coil operation in case of EDO ACB 3.30 > Check continuity and proper changeover of aux. contact block. 3.31 > Test protection release operation by secondary injection test kit.

3.32 > Set characteristics of protections for release as per the load. 3.33 > Check healthyness of CTs. 3.34 > Tightness checking of all hardware. 3.35 > Re-greasing as recommended in ACB service manual. 3.36 > Checking of Trip Time & Closing time of ACB. 3.37 > Measure IRV for infinite bus. 3.14 > Testing of protection relay and confirm the setting. (4) Includes General health checkup of MCC feeder, maintenance, overhauling, cleaning & checking as

Following are the checkpoint : 4.1 > General cleaning of draw out module. 4.2 > Checking of tightness of all power and control connection. 4.3 > Checking of healthiness of power contactor and other switchgear & replacement of the same if require

(Switchgear to be provided by you) All Consumable will arrange by the 4.4 > Replacement of door sealing gasket with new leporine gasket. 4.5 > Replacement of Electrical ON-OFF & trip indication. 4.6 > Replacement of Electrical ON-OFF & trip Push button. 4.7 > Re-termination of damaged lugs. (Lugs provided by you) 4.8 > Contractor should be Reported with individual feeder O/H work (5) Contractor should be ready & reach at site for the above work as & when outage of Bus permitted by

Shift Charge Engineer Unit-3 KLTPS (6) Contractor will arrange all tools-tackles, consumables etc required for subjected work of servicing & O/H. (7) The Contractor should follow all safety precautions during above subjected servicing & O/H . (8) The Contractor is fully responsible for any damage to materials/property of GSECL and recovery will be

made as per their present actual cost. (9) Note down Megger value before and after each and every work / activities before restore the

system/module. (10) Work should be start only after PTW (permit to work) issued by SCE # 3 / Incharge-Engineer of GSECL. (11) Warranty on repairing / servicing – 24 months from servicing / repairing.




Gujarat State Electricity Corporation Limited

Name of work : Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Ref- Schedule-B1 (Supply) 415 V ACB & MCC Spares

(1) 415 V ACB—CN-CS 800 AMP-(Raw water motor feeder) Description of works Qty UOM

01 ACB Spares type CN-CS 800 AMP Pole Assembly Cat. No. SL931920000

3 Nos.

02 ACB Spares type CN-CS 800 AMP Hylem Tube Cat. No. SL100590000

3 Nos.

03 ACB Spares type CN-CS 800 AMP Arcing Contact Moving Cat. No. SL938920000

1 Set

04 ACB Spares type CN-CS 800 AMP Arcing contact fix Cat .No. SL938910000

1 Set

05 ACB Spares type CN-CS 800 AMP Pole separator Cat. No. SL709170000

4 Nos.

06 ACB Spares type CN-CS 800 AMP Jaw contact Cat No. SL928600000

6 Nos.

07 ACB Spares type CN-CS 800 AMP Pole connector Cat No. SL612220000

3 Nos.

08 ACB Spares type CN-CS 800 AMP Trip Latch Assly. Cat. No. SL907150000

2 Nos.

09 ACB Spares type CN-CS 800 AMP Arc chutes Cat No. SL908550000

3 Nos.

10 ACB Spares type CN-CS 800 AMP Cradle term support Cat. No. SL500860000

3 Nos.

11 ACB Spares type CN-CS 800 AMP Cradle term Assly. Cat. No. SL918220000

6 Nos.

12 ACB Spares type CN-CS 800 AMP Insulating tube in Pillar Cat No.SL100670000

3 Nos.

13 ACB Spares type CN-CS 800 AMP Wire Harness Kit Cat. No. SL 946500000

1 Nos.

14 ACB Spares type CN-CS 800 AMP Shunt coil Cat. No. SL927180B00

3 Nos.

15 ACB Spares type CN-CS 800 AMP Closing coil Kit 220 V DC Cat. No. SL910800000

3 Nos.

16 ACB Spares type CN-CS 800 AMP Spring charging motor 220 V DC Cat. No. SL00347

1 Nos.

(2) 415 V ACB – CN-CS-1600 AMP ( 415 V MCC Incomer and Bus Coupler

Modules)


1 Nos.

02 ACB Spares type CN-CS 1600 AMP Hylem Tube Cat. No. SL 100590000

2 Nos.


1 Set


1 Set


2

Nos.

06 ACB Spares type CN-CS 1600 AMP Jaw contact 4 Nos.

Cat No. SL918160000 07 ACB Spares type CN-CS 1600 AMP Pole connector

Cat No. SL612220000 2 Nos.


1 Nos.


2 Nos.


2 Nos.


4 Nos


2 Nos.


1 Kit

Schedule-B 2 (Works)

Description of works Qty UOM

1 General health check up of 415 V MCC of Raw water P/H as per scope of work (sr no.1)

1 Nos.

2 Overhauling of 415 V Raw water ACBs including replacement of necessary spares as per scope of work (sr. no. 2)

12 Nos.

3 Overhauling of 415 v Raw water MCC modules and replacement of necessary spares as per scope of work ( sr.no. 3 )

Lot Lot

SIGNATURE OF CONTRACTOR WITH SEAL & DATE



LIST OF DOCUMENTS TO BE SUBMITTED ALONG WITH TECH. BID

Name of Work : Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

(1) Previous work order copies executed by the bidder during last 3 years. Work

completion / experience certificate for similar type of works executed in GEB /SEB

/Government / Semi-Government organizations.

(2) Solvency certificates from any nationalized bank for the amount more than 20 % of the

estimated cost.

(3) Copy of P.F. Code Number.

(4) Contractor's registration certificate. If any.

(5) B Copy of partnership deed in case of partnership firm or proprietorship declaration

in case of proprietary firm.

(6) Photo copy of receipt for payment of E.M.D.

(7) Service tax registration no. should be given before starting of the work.

(8) Labour licenses should be given before starting of the work.

(9) Income Tax returns if any.

(10) Submit license of electrical contractor from resp. Govt. authority.

(11) Latest authorization of L & T should be submitted with technical bid.




FORM-01

Name of Work Work of Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

I/we _____________________________________________________________

authorized signatory of M/s___________________________________________

hereby certify that M/s_______________________________________________

is not related with other firms who have submitted tenders for the same items under this

inquiry/Tender.

Seal of the firm Signature of the Tendered Place: With Designation Date:

FORM-02

Name of Work Work of Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

DEVIATION FROM BIDDER (IF ANY)

NOTE:-

1. GSECL does not bind to accept the deviation offered by bidder for evaluation of tender.

2. If there is any deviation from bidder, it should be clearly mentioned on this page.

3. Deviation mentioned on other page should not be considered and order will be placed according to

the tender documents.

4. If there is no any deviation from bidder, than it must be clearly mentioned in this

page “NO DEVIATION OFFERRED”

Signature of the Contractor

With seal

GUJARAT STATE ELECTRICITY CORPORATION LIMITED

INTEGRITY PACT

OUR ENDEAVAOUR

To create an environment where Business Confidence is built through Best Business Practices and is fostered in an atmosphere of trust and respect between providers of goods and services and their users for the ultimate benefit of society and the nation.

GSECL’S COMMITMENT

PARTY’S COMMITMENT

1 To maintain the highest ethical standards in business and professions.

1 Not to bring pressure recommendations from outside GSECL to influence its decision.

2 Ensure maximum transparency to the satisfaction of stakeholders.

2 Not to use intimidation, threat, inducement or pressure of any kind on GSECL or any of it’s employees under any circumstances.

3 To ensure to fulfill terms of agreement/contract and to consider objectively the view point of parties.

3 To be prompt and reasonable in fulfilling the contract, agreement, legal obligations.

4 To ensure regular and timely release of payments on due dates for work done.

4 To provide goods and/or services timely as per agreed quality and specifications at minimum cost to GSECL.

5 To ensure that no improper demand is made by employees or by any one on our behalf.

5 To abide by the general discipline to be maintained in our dealing.

6 To give maximum possible assistance to all the venders/ suppliers/service provider and other to enable them to complete the contract in time.

6 To be true and honest in furnishing information.

7 To provide all information to suppliers/contractor relating to contract/job which facilitate him to complete the contract/job successfully in time.

7 Not to divulge any information, business details available during the course of business relationship to others without the written consent of GSECL.

8 To ensure minimum hurdles to venders/suppliers/ contractors in completion of agreement/contract/ work order.

8 Not to enter in to carter/syndicate /understanding whether formal /non formal so as to influence the price.

Seal & signature (GSECL’s Authorized Signatory) Name Designation Date

Seal & signature (Party’s Authorized Signatory) Name Date


KLTPS, PANANDHRO – KUTCH. 370601

GENERAL INSTRUCTIONS TO THE BIDDERSGENERAL INSTRUCTIONS TO THE BIDDERSGENERAL INSTRUCTIONS TO THE BIDDERSGENERAL INSTRUCTIONS TO THE BIDDERS ---- (01)(01)(01)(01) 1. Contract means the documents forming tender and the subsequent agreement that may be entered

into.

2. Work or works means the work related to the subject mentioned in tender

3. Contractor means a firm or an individual undertaking these works or offers the rates for this work

4. The general rules and regulations of the GSECL for tender and contract for works will apply to the extent of the same and not modified herein. The contractor is deemed to have gone through and considered to be fully aware of the conditions mentioned therein.

5. Filled tender shall be accepted by RPAD/speed post only. The technical bid & price bid should be kept in two separate sealed covers and these two covers should be kept in main sealed cover. The tenders will be opened in the presence of bidders, who wish to remain present at the time of opening of tenders. Tender fee & EMD should have to be submitted along with technical bid, if not found offer will outrightly rejected. The Chief Engineer (G), KLTPS reserves the right to reject any or all tenders without assigning any reason thereof. Details of tender fee & EMD paid (DD / MR No. & date) is invariably to be mentioned on the cover of the tender. In absence, offer will be rejected. Bidder has to submit tender fee / EMD in a separate cover duly superscribe with Tender Fee / EMD and all three covers (Technical bid, Price bid and Tender fee / EMD covers) after keeping in the main cover (Forth cover) duly superscribed with the required details such as Tender No, Description and details of EMD/Tender Fee etc., is to be sent by RPAD/Speed Post to The office of Chief Engineer (G), The office of Chief Engineer (G), The office of Chief Engineer (G), The office of Chief Engineer (G), ADM Building, GSECL Colony, SKV Nagar, PaADM Building, GSECL Colony, SKV Nagar, PaADM Building, GSECL Colony, SKV Nagar, PaADM Building, GSECL Colony, SKV Nagar, Panandhro nandhro nandhro nandhro –––– 370 601, Dist: Kutch, Gujarat, India 370 601, Dist: Kutch, Gujarat, India 370 601, Dist: Kutch, Gujarat, India 370 601, Dist: Kutch, Gujarat, India.

6. Tender fee:Tender fee:Tender fee:Tender fee: Tender fee (Non-refundable) as notified in the tender notice should invariably be paid by way of DemandDemandDemandDemand Draft, otherwise offer will be ignored outrightly. Indian Postal orders (IPO’s) & Cheques are not acceptable. Demand Draft should be in the name of the “Gujarat State Electricity Corporation Limited”Gujarat State Electricity Corporation Limited”Gujarat State Electricity Corporation Limited”Gujarat State Electricity Corporation Limited”, Payable at Dena Bank (Branch code: 330 976) Panandhro branch. The envelope shall be addressed to the chief Engineer, KLTPS, Panandhro and the GSECL will not be responsible for the transit loss or misplacement. Alternatively, the bidders can pay the tender fee in CASH (Administrative office - Cash counter) and enclose the original Money receipt in the Tender fee / EMD cover. Demand Draft / Original Money fee receipt of Tender fee & EMD must be kept in the cover of Tender fee / EMD otherwise supplier’s offer is liable to be rejected.

7. Earnest Money Deposit:Earnest Money Deposit:Earnest Money Deposit:Earnest Money Deposit:

(a) The estimated cost of tender items is notified in the tender notice. Bidder has to pay EMD @1% of the estimated cost. The EMD is payable either in Cash or by Demand Draft in favour of the “Gujarat State Electricity Corporation Limited”, Payable at Dena Bank (Branch code: 330 976) Panandhro branch. It can also be furnished by way of an irrevocable Bank Guarantee from any Scheduled/Nationalized Bank in a standard format prescribed by the GSECL (Format given in this tender document). Cheques are not acceptable. CORPORATE BANK GUARANTEES not allowed.

(b)(b)(b)(b) Small Scale Industries will, however, be considered for exemption from payment of EMD subject to furnishing of the authenticated notary certified copy of the certificate of Registration with Small Scale Industries. The SSI certificate should indicate the manufacture of items offered under this tender. PrPrPrProvisional SSI Registration Certificates ovisional SSI Registration Certificates ovisional SSI Registration Certificates ovisional SSI Registration Certificates are not allowed....

All the “NSIC” & “SSI” Documents furnished along with the tender should have clear validity as per the tender and should invariably be renewed as per the norms of “NSIC” & “SSI” Otherwise you shall have to pay EMD and no exemption will be granted.

Government or Semi-Government Organizations, which are run departmentally & are not limited Companies, will be eligible for exemption from payment of E.M.D.

(c) No Interest will be allowed against payment of E.M.D. (d) Tenders submitted without Earnest Money Deposit by the firms, who are not eligible for any

exemption, will be rejected without entering in to further correspondence in this regard and no reference will also be made.

(e) EMD will be forfeited (i) if the tender, which it covers, is withdrawn during the validity of the offer and (ii) the successful bidder fails to furnish the security deposit in time.

(f) EMD of the unsuccessful bidders will be returned within 60 days of placement of the order and

when the bidder returns the original receipt of the EMD together with the advanced stamped receipt.

8. The bidder shall quote only certain percentage of rates above or below the estimated rates, i.e., bidder should quote either, say A% above the estimate or B% below the estimate for all the items. The bidder should not quote different percentage for different items. Tenders received with different percentage rates for different items shall be liable to be rejected. The bidder should quote only percentage higher/lower in figures as well as in words in Schedule-B. In case of not mentioning clearly above/below the estimate, the GSECL shall consider the quoted percentage below the estimate and the contractor must have to honour this, failing which suitable actions may be taken, considering this as dishonour and/or summary rejection of offer without assigning any reason thereof as deemed fit by Chief Engineer. The rate quoted should be inclusive of all taxes and expenses, if any. Nothing will be paid extra as a part of contract unless & until, it is specified in the tender documents by Gujarat State Electricity Corporation Ltd.

9. Revision of prices:Revision of prices:Revision of prices:Revision of prices:

Revision of prices or any commercial terms affecting the price after opening of technical bids shall not be considered and will be ignored.

10. Price Escalation:Price Escalation:Price Escalation:Price Escalation:

No price, escalation will be given till the completion of the work. The bidders must quote firm price only, during execution & extended period, without any escalation towards labour, material, fuel etc., till completion of work under contract and this is to be confirmed by bidder in technical bid envelope only. In case, if the bidder does not offer firm prices, his offer shall be rejected and the price bid envelope shall not be opened.

11. The percentage rates and price shall be written both in words & figures and the units in words. The tender documents shall be written legibly and free from erasure, over writings or conversions of figures. Corrections unavoidable shall be made by crossing out, initialing, dating and rewriting. Incase of any ambiguity or mistakes, the unit rates and prices which are favourable to GSECL shall be considered as final.

12. The rates quoted shall be firm and valid for 180 days for acceptance from the date of openingof technical bid.

13. Conditional tender is liable to be rejected. Withdrawal or insertion of conditions unilaterally after opening of tenders will not be permitted unless it is so desired by the GSECL.

14. Chief Engineer, KLTPS reserves the right to reject any or all tenders without assigning any reasons thereof.

15. Security Deposit :Security Deposit :Security Deposit :Security Deposit : (a) Security Deposit should be paid within 10 (ten) days after receipt of LOI/order. The successful

bidder whether SSI/NSIC/other units [non SSI/NSIC units] will be required to pay an amount

equivalent to 5% of the value of the order as a Security deposit for satisfactory execution of

the contract. Security deposit for satisfactory/successful execution is payable either in Cash /

D.D./ Bank Guarantees only. . . .

(b) Bank Guarantees from Scheduled / Nationalized Banks is also acceptable if the amount of

security deposit payable exceed Rs.5,000/-. The Bank Guarantees will be executed on the

standard form prescribed by the GSECL. In case of the Bank Guarantees furnished /

submitted, they should have a clear one time validity till the completion of the order in all

respect. Bank Guarantee for Interim period will not be allowed. If by any reasons the Work

period is extended then Contractor should undertake to renew the Bank Guarantee at least

one month before the expiry of the validity, failing which GSECL will be at liberty to encash the

same. CORPORATE BANK GUARANTEES are not allowed.

(c) The GSECL reserves the right to forfeit the SD in case of any breach of contract and in case of disputes. The decision of Chief Engineer, KLTPS shall be final, binding and acceptable to the contractor. If the contractor fails to start the work as stipulated, the EMD and the SD shall be forfeited.

(d) The security Deposit/ Bank guarantee covering execution of the contract will be released only on successful execution of contract and on receipt of the “NO Objection Certificate”NO Objection Certificate”NO Objection Certificate”NO Objection Certificate” from the Engineer In charge of the work.

16. Performance Guarantee (PGPerformance Guarantee (PGPerformance Guarantee (PGPerformance Guarantee (PG): ): ): ): if applicable to this contract then, (a) The successful bidder shall have to furnish PG. The Performance Guarantee for the tendered items wherever applicable shall be furnished in the form of D.D./Cash and by Bank Guarantee, valid for the period as per Technical Specifications and should have clear one time validity for the full period. (c) Performance Guarantee for an interim period will not be allowed. However, in case of expiry of PG before the said period the same should be got extended / renewed till the completion by the contractor at least one month before the expiry of the validity, failing which GSECL will be at liberty to encash the same, without entering into further correspondence, formalities, etc. in the matter. “NO STAGEWISE BANK GUARANTEES WILL BE ACCEPTABLE IN ANY CASE.”

17. Subletting of tender is not permitted without prior approval of GSECL.

18. GSECL reserves right to divide work to nos. of agencies.

19. The work will be awarded to each agency as per site requirement & as per instruction of EIC.

20. Technical Bids received will be opened if possible on the day and time indicated in the tender notice by an Officer nominated by the GSECL as representative in the presence of such of the bidders who wish to be present. Time and date for opening of price bids will be determined by the GSECL and intimated to only qualified bidders after the Technical Bid proposals are opened, analyzed as per post – qualification criteria mentioned in special note and all clarifications, if any, obtained from the bidder and verified by GSECL from the issuing authority if necessary.

21. The bidders shall submit their offer without any deviations to the Technical specifications, Commercial conditions and General Terms and Conditions of the contract & it will be presumed that the bidder agrees entirely with the specification and all other conditions of tender.

22. Tenders received after the time and date specified in tender notice will not be accepted. Once the offer is submitted by the bidder before due date of submission, the bidder shall not be allowed to submit revised / additional / modified offer even before due date and time of submission of tender. However if the date of submission of tender are extended by the GSECL due to any reason the bidder may submit if he wishes the revised / additional / modified offer before extended due date and time of submission.

23. The GSECL reserves the right to accept any tender irrespective of whether it is lowest or not or to reject all the tenders without assigning any reasons thereof. Tenders departing from the stipulated technical specifications, commercial conditions or the method of bidding in a radical manner are liable to be rejected

24. The bidder must visit the site before submitting the tender. The bidder shall be presumed to have carefully examined the conditions & specifications of work and to have fully acquainted themselves with all details of the site conditions, locations, materials, geological and weather characteristics, labour conditions and in general all the necessary information and data etc. pertaining to and need for the work

25. The bid submitted by bidders who are listed under declaration of ineligibility for corrupt or fraudulent practices issued by the Government, the list of Black listed contractors announced by GEB/GSECL, Govt. of Gujarat or its Public sector undertaking, shall be rejected.

26. Bidders must submit the schedule of quantities and rates and other schedules duly signed. Any tender not bearing signature of the bidder & with seal of company on all the documents accompanying the tender is liable to be rejected.

27. Tender shall remain open for acceptance for a period of 180 days from the date of opening of Technical bid and during this period no bidder shall be allowed to withdraw his tender. Any such withdrawal during the said period will entail forfeiture of the earnest money deposit submitted along with the tender and the GSECL may take further action like “no dealing” with such bidder in future tenders of GSECL or any company under GUVNL.

28. The Notice inviting tender, general instruction to bidders and all other documents of this tender shall form part of the contract

29. The information given in this specification is in good faith and meant to serve as a guide to the BIDDER. It is, therefore, imperative that BIDDER shall obtain and examine for himself all the data, information and particulars required for the satisfactory execution of the work under this enquiry. The submission of a bid by Bidder implies that he has fully read the specifications, bid drawing, Contractor Document and General Conditions of Contract and has made himself aware of the scope and the specifications for the work to be performed and local conditions and other features which have a bearing on the cost and execution of the work. The ENGINEER-IN- CHARGE (GSECL) shall not, therefore, after acceptance of the bid, pay any extra charges for any reason whatsoever.

30. PRICES AND RATESPRICES AND RATESPRICES AND RATESPRICES AND RATES Each page of the bid document shall be signed and dated in ink by the BIDDER as a token of having examined the same. Any correction in price and the rates entered in the Schedule of Price shall also be signed and dated by the BIDDER in ink, before submitting the bid. Non-compliance with these conditions will make the bid liable for rejection.

31. AAAACCEPTANCE / REJECTION OF BIDCCEPTANCE / REJECTION OF BIDCCEPTANCE / REJECTION OF BIDCCEPTANCE / REJECTION OF BID a. GSECL reserves the right to accept or reject any bid in whole or part and/or accept other than

the lowest bid without assigning any reasons. b. The bid is liable for rejection prima facie, if it is:

a. Not in the prescribed form. b. Not properly signed by the BIDDER. c. Not conforming to TENDER specification. d. Received after expiry of the due date and time.

e. Received by telex or telegram or fax or courier

32. SUBMISSION OF TENDERSUBMISSION OF TENDERSUBMISSION OF TENDERSUBMISSION OF TENDER The tender must reach to the office of Chief Engineer [Gen], GSECL, ADM office, S.K.V. Nagar, KLTPS,

Panandhro on or before due date and time of submission mentioned in tender notice. No tender shall be accepted/opened in any case received after due date and time of receipt of tender, irrespective of delay due to postal services or any other reasons, and the GSECL shall not take any responsibility for late receipt of tender. Any tender received after the due date and time of submission shall not be considered

33. Any clarification/queries asked by GSECL / GSECL's representative about tender/offer shall have to be furnished by the contractor; otherwise the offer of the firm will be liable to be rejected.

34. Tenders which do not fulfill all or any of the above conditions or incomplete in any respect, are liable to rejection





KLTPS, PANANDHRO – KUTCH. 370601

GENERAL TERMS & CONDITIONS - (001)

1. Contract means the documents forming tender and the subsequent agreement that may be entered into.

2. Work or works means the work related to the subject mentioned in tender.

3. Contractor means a firm or an individual undertaking these works or offers the rates for this work.

4. The general rules and regulations of the GSECL for tender and contract for works will apply to the extent of the same and not modified herein. The contractor is deemed to have gone through and considered to be fully aware of the conditions mentioned therein.

5. To sublet or to transfer the contract without prior approval of the GSECL shall be treated, as breach of contract and it shall be punishable by forfeiting the S.D. as well as termination of contract

6. The monthly payment to the labourers must be paid in the presence of Labour Welfare Officer, KLTPS. A copy of the same must be submitted along with monthly RA Bill, duly certified by the Labour Welfare Officer. The certificate should contain details of average no of labourers deployed, total wages/salaries paid and overtime amount separately

7. Execution of Agreement: Execution of Agreement: Execution of Agreement: Execution of Agreement: The successful bidder (contractor) will have to enter into an agreement with the GSECL before starting the work and the cost of the stamp paper will be borne by the contractor. The contractor will also have to execute indemnity bond on required value of stamp paper as per GSECL’s rules. The cost of stamp paper for indemnity bond will be born by the contractor

8. Taxes and Duties:Taxes and Duties:Taxes and Duties:Taxes and Duties:

All royalties, sales tax, toll tax, local tax, development charges, VAT, welfare cess and any other taxes including works contract tax etc., except Service Tax in respect of this contract and also any statutory variation in future towards above mentioned taxes & any other taxes if levied in future by statutory authority which are applicable to the this contract shall be payable by the contractor and GSECL will not entertain any claim whatsoever in this respect.

9. Service tax :Service tax :Service tax :Service tax :

The service tax, if applicable shall be reimbursed extra at actual on production of proof. The Bidder shall have to furnish attested copy of Registration Certificate issued by Excise Department mentioning Service Tax Registration Number and the same is to be shown in each invoice.

10. Statutory variation :Statutory variation :Statutory variation :Statutory variation :

Statutory variation on applicable taxes mentioned in order shall be admitted provided they take place during the contractual completion period subject to claim being supported by documentary evidence.

11. Income Tax:Income Tax:Income Tax:Income Tax:

Income tax & other taxes at the applicable rate will be deducted at source from your bill as per rules. Contractor has to submit all the invoices clearly mentioning PAN No. The contractor being exempted for Income tax shall submit the valid exemption certificate with bill.

12. Deductions :Deductions :Deductions :Deductions :

The GSECL will be entitled to deduct directly from the bills to be paid to the contractor any sum or sums payable by the contractor and which sum/sums the GSECL is required to recover as its own dues/recoveries as well as to pay as a principal employer on account of contractor’s default in respect of all liabilities referred to in above clauses.

13. Submission of Bill :Submission of Bill :Submission of Bill :Submission of Bill :

a) Bills (in triplicate) shall be submitted by the contractor for all works, executed at the frequency decided by the Engineer In charge (EIC).

b) Measurement is to be taken jointly in presence of the EIC. The running as well as final bill will be prepared based only on measurement sheet duly accepted & signed by party & our supervisor or engineer-in charge.

c) If the contractor does not submit the bill, within the time fixed, the EIC may depute a subordinate to measure the said work in the presence of the contractor or his duly authorised agent, whose countersignature in the measurement list shall be sufficient warrant and the EIC may prepare a bill which shall be binding to the contractor in all respect.

d) If contractor fails to depute his representative, the measurement taken by the EIC shall be treated as final and shall be binding to the contractor.

e) Other documents to be submitted with Bill (i) Along with the R.A Bill, the contractor should submit Material Account wherever

applicable duly approved by EIC. (ii) Proof of payment of provident fund and other statutory dues. (iii) Certificate issued by IRO/Labour Welfare officer. (Certifying average number of

labourers deployed during the month and total amount of wages and salaries paid to labourers) and No objection to release Payment of submitted bill.

14. The contractor shall not engage any sub-contractor without written prior permission of the Chief Engineer or the authorised officer of the GSECL. In no case the GSECL will be liable in any manner regarding any liability in respect of any contract labourer engaged by the sub-contractor and the liability of such contract labourer will solely rest with the principal contractor.

15. Payment:Payment:Payment:Payment: f) The GSECL shall not pay any advance(s) against this work including mobilization advance if

not otherwise included hereunder. g) The quantity mentioned in schedule-B is tentative and may vary widely with in the limit of

order/ approval; payment will be made for actual work done only. h) The payment shall be made as per GSECL rules which is

For Supply For Supply For Supply For Supply : 80% payment will be made against TRC within 30 days and balance 20% will be after acceptance of material & Completion of work within 60 days from the date of submission of bill. For Work For Work For Work For Work : within 60 days from the date of submission of bill.

i) Any delay in payment of bill shall not entail the contractor for any extra claim.

16. Penalty:Penalty:Penalty:Penalty:

(a) Any delay that may take place in supply and / or erection, testing and commissioning activities beyond contractual cut off date / stipulated period in the order shall be subjected to penalty (not liquidated damages) at the rate of 0.5% of the contract price / order price per week or part there of subject to maximum of 10% of the total contract value / order value (i.e. end cost including taxes and duties)

(b) The penalty for delay is over & above the charges deductable against performance guarantee and other dues/recoveries.

17. The contractor shall deploy the adequate number of experienced staff at site for daily supervision and for maintenance of various registers and records required under the law and contract. No payment by the GSECL for supervision shall be admissible

18. Staff Discipline: Staff Discipline: Staff Discipline: Staff Discipline: It is the responsibility of the contractor to ensure that his employees maintain strict discipline as regards security, methods of safe working etc., and not to cause any hindrance to smooth running of power station or in execution of duties by GSECL staff. Any lapse in this regard will be viewed seriously and contract is liable to be terminated. If any of his staff is found unsuitable or not behaving properly, the contractor shall have to remove him from the work-site on demand by GSECL. The contractor shall have to strictly observe the rules and conditions specified in the enclosed works contract booklet of the GSECL, which are not modified hereunder. To keep harmonious Industrial Relations amongst contract labourers is the sole responsibility of the contractor. Any breach of the same will be viewed seriously

19. Arbitration: Arbitration: Arbitration: Arbitration: If at any time any question, dispute, differences, shall arise between the GSECL or the Engineer-in-Charge and the contractor or any person claiming through him upon or in relation to or in connection with the matter herein before stipulated and specified to be referred to arbitration, either party may forthwith give to the other a months notice in writing of the existence of such question, dispute or differences whatsoever, which may at any time arise between the parties to this agreement, touching the agreement or subject matter thereof, arising out or in relation thereto and whether as to construction or otherwise, shall be referred to the decision of the sole Arbitrator appointed by the Chairman of GSECL for the purpose, who shall be a retired High Court Judge or a retired District and Sessions Judge, and upon the parties reference to the Arbitration act, 1940, as amended from time to time and the rules therein. The Arbitration proceedings shall be conducted at GSECLs head office, BARODA, or at such places as the sole arbitrator may determine. The award of the sole arbitrator (or umpire) shall be final and binding upon the parties upon every or any such reference the costs of and incidental to the reference and award respectively, shall be at the discretion of the arbitrator or umpire who may determine the amount thereof or direct the same to be taxed as between party, and the party shall direct by whom and in what manner the same shall be borne and paid, provided, however, that either party to the dispute shall in respect of any monetary claim, be entitled to receive from the other party by way of cost any time exceeding the percentage set out below, irrespective of the actual fees and expenses incurred by him. Work under contract shall continue during the arbitration proceedings and no payment, other than for matters in dispute due or payable by the purchaser, shall be withheld on account of such proceedings. The percentage above referred to in this clause is five percent on any such monetary award, which does not exceed Rs.10,000/-; three percent on the next or any part thereof; two percent on the next Rs.50,000/-, or any part thereof, and one percent on Rs.40,000/- or in case it exceeds Rs.1,00,000.

20. Labour Escalation: Labour Escalation: Labour Escalation: Labour Escalation: The contractor shall pay minimum wages to his labourers as per the Minimum Wages Act, 1948 and rules therein, as applicable from time to time, in pursuance to the state government notification. The

concerned contractor, after making such payment to his labourers, shall submit the details of the payment with the certification of Labour Welfare Officer/Industrial Relations Officer. However, no labour escalation will be payable by GSECL to the contractor as this is a firm price contract through out the period of contract.

21. The GSECL reserves the right to terminate this contract at any time during its currency without giving notice of termination or any reason thereof

22. In case of default, the work will be got done through other agency/agencies at the risk and cost of the original contractor, and the GSECL shall be entitled to recover such expenses from defaulting contractor by such methods as deemed fit. The contractor shall not, however, be entitled to terminate the contract or stop works undertaken by him before expiry of the contract period/extended period due to any reason whatsoever.

23. Under the contract, the contractor should either himself be present at the site or should nominate persons in writing, who must be available at site and who should be authorised to take decisions In absence of any responsible man of contractor at the time of any emergency, ad hoc decision of Engineer-in Charge will be binding on the contractor

24. The contractor is bound to execute the work for any item as per the instruction of the Engineer-in-Charge. On refusal to do so, the work will be carried out at the risk and cost of contractor by using the contractors tools and tackles, for which no compensation whatsoever shall be payable to the contractor

25. If any immovable articles/tools/equipment will be found stolen from the working place, the contractor would be held responsible and cost will be recovered from his bill.

26. For any conflict and ambiguity, the decision of the Chief Engineer (KLTPS) shall be final and binding on the contractor

27. Before starting the work, the contractor should contact Industrial Relation Officer/ Labour Welfare Officer for all formalities and obtaining the gate passes of his labourers and for other formalities

28. Office correspondence will be carried out in English language, and if at any time to facilitate the contractor, Gujarati translation may be furnished, if deemed fit. The English version will be the correct one and the same only will hold good for legal matters

29. The contractor should intimate to the office the name, cell no. and address of authorized and responsible representatives, so that our field officers can contact them when required in connection with the execution of the said works.

30. Contractor should take all risk insurance policies.

31. All safety measures as required to be adopted as per the Statutory Regulations and the Safety Rules of the Plant shall be strictly followed by the Contractor during the execution of the Contract. The Contractor shall set up a suitable safety organization of his own in this regard. The contractor shall ensure the safety of workers, material and structure including existing structures during execution of the contract. Safety measures shall be followed during operations of equipments/machinery being used. No separate payment shall be made for the safety measures and the quoted rates shall include the cost for all safety measures

32. In connection with the execution of the Contract, the Contractor shall comply with all applicable statutory Rules & Regulations including employment of labour at site

33. If the GSECL Engineer-in-Charge is not satisfied with the progress of work at site, he shall direct the Contractor to depute more numbers of supervisory personnel/workers to meet the completion schedules as per the Contract. Upon receiving such direction, Contractor shall deploy additional personnel within given time without any extra cost.

34. The GSECL may during the progress of work, order the removal of part or whole of the work executed, found not in accordance with the specifications/ instructions. No extra claims shall be entertained for re-executing or altering of such work

35. On acceptance of the tender the name (s) of the accredited representative (s) of the bidder who would be responsible for taking instructions from the Engineer-in-charge shall be communicated to the Engineer-in-charge.

36. The GSECL will not pay any extra charges or rate for any reasons in case the contractor claims, after acceptance of contract to have misjudged the site condition.

37. The contract or any part thereof shall not be subject to change without the written permission of the CHIEF ENGINEER or his authorized representatives from issuing authority of certificates / details.

38. In case of conflict/discrepancies among clauses of different specifications given in this document, the stringent specification shall be followed and under such circumstances, the decision of the EIC shall be final and binding to the CONTRACTOR.

39. Time is the essence of this Contract. The whole of works must be proceeded as described in these specifications and as directed by the EIC. No extra payment or relaxation in the rates will be permitted on account of this.

40. Start of Work:Start of Work:Start of Work:Start of Work: The contractor shall not enter upon or commence any portion of the work except with the written authority of Engineer, failing which the contractor shall have no claim to ask for measurement of or payment for work and shall be responsible for any claims or damages that may arise due to such

unauthorized commencement or entry. The contractor shall make all necessary arrangements at site to mobilize labour, supervisor as per schedule.

41. Work covered under this specification shall be completed in all respects, as stipulated under scope of work.

42. The rates quoted by BIDDER shall be based on his own knowledge and judgment of the conditions and hazards involved and shall not be based on any representations of the Engineer. No claim on this account shall be admitted by the GSECL.

43. Percentage quoted for Prices and rates shall be firm for the entire duration of the contract and any agreed extensions thereafter, without any escalation in prices.

44. During the execution of the work if it is found that the work is not progressing as per the scheduled programme, approved by the GSECL & planned by the contractor, due to the reasons attributable to the contractor, suitable action shall be taken as per GSECL providing rules. And the GSECL may also take such action as it may deem fit to ensure that the work is completed in time at risk and cost of the contractor.

45. Any clarification/queries asked by GSECL / GSECL's representative shall have to be furnished by the contractor.

46. Work to be executed to the satisfaction of the Engineer:Work to be executed to the satisfaction of the Engineer:Work to be executed to the satisfaction of the Engineer:Work to be executed to the satisfaction of the Engineer: The contractor shall proceed with the work with diligence and expedition and the whole of the work herein specified as well as the mode of execution shall be under the supervision and direction and shall be carried on to the entire satisfaction of the Engineer,.

47. Liability for accidents to personsLiability for accidents to personsLiability for accidents to personsLiability for accidents to persons a) The contractor or sub-contractor shall indemnify the GSECL against any claims which may be made under the workman's compensation Act, 1923, or any statutory modification or otherwise in respect of any damages or compensation payable in consequence of any accident or injury caused, by fault of contractor or sub-contractor and sustained by any workman or other person in the employment of the contractor or sub-contractor. In every case in which by virtue of the provisions of sub-section (1) of section 12 of the workman's Compensation Act, 1923, the GSECL is obliged to pay compensation to a workman employed by the contractor or sub-contractor in execution of the work, the GSECL will recover from the contractor the amount of compensation so paid, and without prejudice to the rights if the GSECL under sub-section (2) of section 12 of the said Act any such amount shall be paid by contractor within 30 days, failing which the GSECL shall be at liberty to recover such amount or any part thereof by deducting it from any some due by the GSECL to the contractor under this contract or otherwise. The GSECL shall not be bound to pay any claim made against either of them under section 12, sub-section (1) of its said Act, except on written request from the contractor and upon his giving to the GSECL full security for all costs for which the GSECL might become liable in consequence for entertaining such claim. b) The contractor and/or sub-contractor named in the contract shall indemnify the GSECL against all claims based upon injury or death to any person in the employ of the contractor or sub-contractor, or to third parties under paragraph (a) 2 or condition No.47 to the extent of any sums recovered under the insurance policy.

c) On the occurrence of an accident which results in the death of workman employed by the contractor or sub-contractor, which is so serious as to be likely to result in the death of any such workman, the contractor shall within 24 hours of happening of such accidents intimate in writing to the Engineer the fact or such accidents. The contractor or sub-contractor shall indemnify GSECL against all loss or damage sustained, by the GSECL resulting directly or indirectly from his failure to give intimation in the manner aforesaid including penalties or fine if any, payable by GSECL as a consequence of GSECL's failures, to give notice under workman's compensation Act or otherwise to confirm to the provisions of the said Act in regard to such accident.

d) The contractor will be responsible for complying with all rules and regulations and labour land applicable to him and the GSECL will not be responsible for any lapses committed by them. If there is any claim from any Govt. Authority pertaining to the contractor the same amount will be deducted from the contractor's bill.

48. Inspection of WorksInspection of WorksInspection of WorksInspection of Works The Engineer or his duly authorized agent shall have at all time full power to inspect the works, wherever in progress,

49. RecoveriesRecoveriesRecoveriesRecoveries Recoveries due from the contractor, up to the end of the month previous to the one in which the bill is prepared shall be made from bills approved by payment every month or at other periods when the bills are prepared, for the various items in the following order of priorities and extents. i) Deduction on account of security deposit in full together with shortage, if any, to be made good. ii) Penalty in full, if levied.

iii) Expenditure, if any, incurred by the GSECL on Contractor's behalf in labour or materials in full. iv) Charges for services such as water etc. in full. v) Other recoveries. (If any)

50. Speed of workSpeed of workSpeed of workSpeed of work The contractor shall at all times maintain the speed of work to confirm to the latest operative progress schedule but the Engineer may at any time with sufficient notice in writing direct the contractor to slow down any part or the whole of the work for any reason (which shall not be question whatsoever, and the contractor shall comply with such orders of the Engineer. The compliance of the orders shall not entitle the contractor to any claim or compensation.

51. Contract document and matters to be treated as confidentialContract document and matters to be treated as confidentialContract document and matters to be treated as confidentialContract document and matters to be treated as confidential All documents, correspondence, decision and other matter concerning the contract shall be considered as of confident and restricted nature by the contractor and he shall not divulge or allow access there to any unauthorized persons of any kind.

52. Measurements to be provisional and subject to correctionMeasurements to be provisional and subject to correctionMeasurements to be provisional and subject to correctionMeasurements to be provisional and subject to correction Every measurement for running payment on account of work, done or supplies made shall be subject to adjustment or final measurements. In case of disagreement between such intermediate and final measurements, the latter shall prevail.

53. PPPPererererforma returnsforma returnsforma returnsforma returns The contractor shall maintain Performa, charts and details regarding machinery equipments materials, labour personnel and other matters as may be specified by the Engineer. He shall further, submit returns of Performa and details as may be specified by the Engineer from time to time.

54. Performance Guarantee (PG):Performance Guarantee (PG):Performance Guarantee (PG):Performance Guarantee (PG): if applicable to this contract then,

(a) The successful bidder shall have to furnish PG.

(b) The Performance Guarantee for the tendered items wherever applicable shall be furnished in the

form of D.D./Cash and by Bank Guarantee, valid for the period as per Technical Specifications and

should have clear one time validity for the full period.

(c)Performance Guarantee for an interim period will not be allowed. However, in case of expiry of PG before the said period the same should be got extended / renewed till the completion by the contractor at least one month before the expiry of the validity, failing which GSECL will be at liberty to encash the same, without entering into further correspondence, formalities, etc. in the matter. “NO STAGEWISE BANK GUARANTEES WILL BE ACCEPTABLE IN ANY CASE.”

55. Security Deposit :Security Deposit :Security Deposit :Security Deposit : (a) Security Deposit should be paid within 10 (ten) days after receipt of LOI/order. The successful

bidder whether SSI/NSIC/other units [non SSI/NSIC units] will be required to pay an amount

equivalent to 5% of the value of the order as a Security deposit for satisfactory execution of

the contract. Security deposit for satisfactory/successful execution is payable either in Cash /

D.D./ Bank Guarantees only. . . .

(b) Bank Guarantees from Scheduled / Nationalized Banks is also acceptable if the amount of

security deposit payable exceed Rs.5,000/-. The Bank Guarantees will be executed on the

standard form prescribed by the GSECL. In case of the Bank Guarantees furnished /

submitted, they should have a clear one time validity till the completion of the order in all

respect. Bank Guarantee for Interim period will not be allowed. If by any reasons the Work

period is extended then Contractor should undertake to renew the Bank Guarantee at least

one month before the expiry of the validity, failing which GSECL will be at liberty to encash the

same. CORPORATE BANK GUARANTEES are not allowed.

(c) The GSECL reserves the right to forfeit the SD in case of any breach of contract and in case of

disputes. The decision of Chief Engineer, KLTPS shall be final, binding and acceptable to the

contractor. If the contractor fails to start the work as stipulated, the EMD and the SD shall be

forfeited.

(d) The security Deposit/ Bank guarantee covering execution of the contract will be released only

on successful execution of contract and on receipt of the “NO Objection Certificate”NO Objection Certificate”NO Objection Certificate”NO Objection Certificate” from the

Engineer In charge of the work.






PO :: SKV NAGAR :: 370 601

DIST :: KUTCH

TERMS AND CONDITIONS REGARDING INDUSTRIAL LAWS AND OTHER RELATED MATTERS:

1. Wages to be paid, time of payment, etc., by the contractor:

The payment shall be disbursed in presence of the GSECL representative during the working hours in the factory

premises and the contractor shall get the entries certified in the register of wages by the representative of the

GSECL. Any default will result in cancellation of contract forthwith. The contractor shall give his telephone

number, address to the GSECL, so that in case of labour unrest etc., the contractor can be contacted. The contractor

shall arrange to have his office outside the factory premises and the contractor shall keep himself present

throughout the working hours. It is absolutely necessary that the contractor either himself and/or a fully authorised

representative having full power or authority concerning the contract shall have to remain present at KLTPS. He

must also contact Executive Engineer (WTP) daily at 08.00 hours, so that necessary instruction can be passed on to

him. Also, he must be available during working hours (general shift) and during failure of any equipment at any

time, so that he can be immediately contacted for any emergency work. The contractor and/or his authorised

representative shall not leave KLTPS without specific permission from the Executive Engineer (WTP). If the

period of absence from KLTPS is more than three days, an alternative arrangement shall be made and to be

informed to the sectional head in writing.

2. Labour Laws:

The labour laws applicable and amended from time to time have to be followed scrupulously. A few of them for

information are as under:

i).Person below the age of eighteen years shall not be employed for the works

ii).No female worker shall be employed in the night shift between 19:00 hrs to 06:00 hrs.

iii).Contractor shall maintain a valid labour license under the Contract Labour (Regulation & Abolition) Act for

employing necessary manpower to be required by him. In the absence of such license, the contract shall be liable to

be terminated without assigning any reasons thereof.

iv).The contractor shall, at his own expense, comply with all labour laws and keep the GSECL indemnified in

respect thereof. Some of the major liabilities under various labour and industrial laws, which the contractor shall

comply with, are as under:

a. Payment of contribution of employees (contract labour) as well as employer’s (contractor’s) contribution towards

provident fund, family pension scheme, deposit linked insurance scheme, administration charges, inspection

charges, etc., at the rates applicable from time to time by the Government of Gujarat/Government of India or other

statutory authorities.

b.Payment of deposit in respect of each contract labour at the rate as revised by the Government from time to time

with the Office of the Commissioner of Labour as per the Contract Labour (R&A) Act.

c.License fee as prescribed under the Contract Labour (R&A) Act and rules framed therein, depending upon the

number of workers employed by the contractor.

d.Paid leave facility and wages as per the provision of the Factories Act at the rate of one day for every 20 days of

working.

e.Identity cards as prescribed under the Factories Act or by the Thermal power station with photograph affixed

thereon, for identification.

f.Payment of retrenchment compensation, notice pay and other liabilities as per Industrial Disputes Act, 1947. Any

payment to the contractor’s employees arising out of any claim or disputes under the Industrial Disputes Act, 1947

or any other labour laws.

g. Payment of compensation in case of accidental injury, under Workmen’s

Compensation Act.

h. Provision of crèche if the female labour employed is more than 30.

i. Maternity leave as per the provision of the Maternity Benefits Act.

The above are some of the major liabilities of the contractor in addition to other liabilities prescribed

under the various labour laws in force from time to time by the statutory authorities, like State

Government/Government of India, which the contractor shall have to comply with.

3. Provident Fund and Family Pension Scheme:

The contractor shall submit along with his bill (month-wise) a statement regarding deductions against Employees

Provident Fund (EPF) and Family Pension Scheme (FPS) in respect of each concerned employee at the rate of 10%,

or at the rates made applicable by the government from to time, of wages. The contractor’s contribution and the

worker’s contribution towards PF and FPS shall be deposited by the contractor with the Regional Provident Fund

Commissioner, Ahmedabad, or to the authority prescribed under the Act along with the other charges.

4. Deposit Linked Insurance Scheme:

The contractor shall have to deposit 0.50% (half percent) or the rate applicable from time to time of the wages in

respect of employees who are members of the PF, as the contribution to the Deposit Linked Insurance Scheme, with

the Regional Provident Fund Commissioner, Ahmedabad.

5. Minimum Wages Act:

The contractor shall pay prevailing minimum wages as applicable from time to time to the labourers engaged by

him as per the Minimum Wages Act, in presence of the GSECL’s officer or representative.

6. E.S.I. Act:

The contractors shall comply with the provisions of E.S.I. Act wherever applicable as per the prevailing provisions

of the Act and as amended from time to time.

7. Administrative Charges:

Administrative charges for maintaining Provident Fund account shall be deposited by the contractor with the

Regional Provident Fund Commissioner, Ahmedabad, at the rates applicable.

8. Paid Leave Facility:

Paid leave facility at the rate of one day for every twenty days of actual work by the contract labour shall be

provided by the contractor to his workers. He shall maintain leave records/verified and approved/certified by the

authorised officer of the GSECL.

9. Safety:

The contractor shall strictly observe all safety rules and provide safety equipment to the contract labourers as per

the Factories Act, 1948, and whatever amendments made from time to time to avoid any chance of accident. The

contractor shall strictly observe all instructions of Safety Officer and Factory Inspector to avoid any chance of

accident.

10. Workmen’s Compensation Fund and Employer’s Liability Insurance:

Insurance shall be affected for all the contract employees engaged in the performance of this contract. If any of the

work is sublet after due permission in writing from the GSECL, the contractor shall require the sub-contractor to

provide workmen’s compensation and employer’s liability insurance for the later employees, unless such

employees are covered under the contractor’s insurance. It shall be the liability of contractor for employees of his

sub-contractor.

11. Compliance to Security Matters:

The power station being a restricted/prohibited area, all the formalities as required by the Security and Vigilance

staff of GSECL should be complied with, to whom the contractor should contact S.O.

12. Submission of Returns & Maintenance of Records:

The contractor shall submit the returns under the Contract Labour Act, Payment of Bonus Act, Payment of Gratuity

Act etc. and shall have to maintain all up-to-date records/registers in respect his employees as prescribed under

various Labour Laws and produce the same as and when demanded by GSECL’s or Govt.’s appropriate authorities.

13. Contractor to Indemnify the GSECL:

The contractor shall indemnify and keep indemnified the GSECL and every member, officer and employees of the

GSECL, including Engineer-in-Charge and his staff, against all actions, proceedings, claims, demands, costs and

expenses whatsoever arising out of or in connection with the matters referred in above clauses and elsewhere and

against all actions, claims, demands, costs and expenses which may be made against the GSECL, by any

workman/employee of the contractor or sub-contractor or any other person under any laws, rules or regulations

having the force of law, including, but not limited to, claims against the owner under Workmen’s Compensation

Act, 1970. The GSECL shall not be liable for or in respect of or in consequence of any accident or injury to any

workman or other person in the employment of the contractor. The contractor shall indemnify and keep

indemnified

The GSECL against all such damages and compensation and against all claims, demands, proceeding costs, charges

and expenses whatsoever in respect thereof or in relation thereto.

The contractor shall also indemnify GSECL in all respect against any liability due to breach of legal provisions

contained in any of the Labour Laws.

The Contractor shall also indemnify GSECL for injury or damage to third party other than employees of the

GSECL, contractor or sub-contractor.

14. As a contractor, the contractor shall be responsible and liable to pay difference

in wages, if any, and/or observe the revised service conditions that may be

awarded by the Honourable Industrial Tribunal effective from the date directed

in the award.

15. The contractor must be maintaining regular labour record and should be paying all acquired benefits to labour force

and contractor should obtain certificates to this effect from Labour welfare officer.

16. Any other rules and regulations, conditions etc. that are in force at present and

that may be framed by the GSECL from time to time in connection with the

contract will be binding and acceptable to the contractor.

17. The contractor will make arrangements at his own cost to insure all men, materials and equipment employed for

this work. The GSECL will not be responsible for any loss or damage either to the contractor’s personnel or his

equipment.

18. Dispute, if any, taking place between the contractor and labourers must be intimated to Labour Welfare Officer,

KLTPS, immediately.

19. The contractor must insure all the labourers before starting the works.

20. Any casualty will also have to be borne by the contractor for the period the contract continues.






PO-S.K.VARMA NAGAR, PANANDHRO-KUTCH-370601

“GENERAL SAFETY RULES / NORMS” TO BE OBSERVED BY THE CONTRACTORS.

All the contractors working at Kutch Lignite Thermal Power Station shall have to strictly observe the

following Safety Rules. Concerned Contractors are responsible for informing & observance of these rules

by their supervisors/employees/labours as well as the supervisors/ employees/ labours of agencies/ sub-

Contractors engaged, if any, by them for the work contract awarded to them. Prior to commencement of

the work, Contractor shall have to submit a written assurance on their letterhead to the concerned

Sectional Head / Engineer-in-charge that they have thoroughly gone through these Rules, have educated

their employees / employees of their sub contractor and will strictly observe the said Rules while

execution of work under work contract awarded to them. They will have to indemnify the Corporation for

any loss or damage / accident / injury to the Corporation’s property / employee or employee of their own

in default of non - observing these rules.

01 Persons to be employed for carrying out the work shall possess required qualification, are fully trained

and conversant for works to be done. All persons should have gate pass. Register consisting the full

details i.e. address, ph no, nearest relative, of all persons to be maintained. During the work execution,

one trained & competent supervisor should always remain present at site.

02 The contractor shall take all the required safety measures prior to commencement of work on

dangerous substances, machineries or area at which cautionary notice is displayed and obtain “Line

Clear” or “Work Permit” through the concerned Department / Section.

03 Prior to carrying out welding, gas cutting, furnace heating or any other hot work job, remove all the

inflammable material lying at or nearby worksite or cover it properly by suitable protective covering.

Also, special care shall be taken before carrying out such job & see that all possible contributing

factors to set fire shall be removed / vanished prior to commencement of the work. Advance intimation

shall be given to concerned section / fire section to commence the work in fire prone areas. They

should also keep ready all the First Aid Fire Extinguishers / equipments & fire extinguishing media /

material like sand / water buckets or other appropriate equipment at such place.

04 While carrying out work in confined space or inside vessel, obtain necessary “Confined Space /

Vessel Entry Permit” from concerned department prior to commencement of the work.

For lighting in such areas, only 24-volt (ISI certified & with proper guard) hand lamp shall be used. For taking care of the persons working inside the confined space / vessel, a supervisor / person capable to keep continuous

watch on person(s) working inside, assist them incase of emergency or arrange to get immediate outside help, shall remain

present at entry point. Use full body safety belt without failed.

While working inside sewage, trench or in-depth, a person to warn outsiders / entrants / passers etc

shall remain available near entry point or the entry point shall be cordoned by a barricaded tape with a

cautionary notice. After completion of the works, all the lids / covers / grills / grits opened, shall be re-

fixed / re-placed in the original position as it were prior to commencement of the work and leave the

work place in safe condition in all respect, so as to prevent accident to fellow workers.

05 The contractor shall see that he / his persons do not work on or block (by stacking material, spare parts,

tools-tackles, equipments etc), any passages / walkways / gangways / aisles / staircases / ladders / lifts

or any other approaches / roads leading to plans or its auxiliaries, on which there is traffic movements

or possible traffic movements in case of emergency. Such passages are meant for safe escape in the

event of emergency. If it is utmost necessary to carry out work in such area with blocking of passage,

prior permission of Competent Authority or the Engineer-In-Charge shall be obtained. To demarcate /

declare the area as “UNSAFE”, cordon it using barricading tape & display suitable caution notice or

keep a person to restrict / divert the traffic on this route through other safe passage.

06 Prior to use power / electrically operated hand tools / equipments / machines / gadgets like welding

machine, hand grinder, hand drill etc, ensure for its safe operation & use it only if it is found safe to

use. Do not use defective, unsafe or improperly maintained equipments.

The electrical power supply required to run such equipments shall not be taken directly at their own

but shall be obtained through concerned Electrical Maintenance Departments or their authorized

persons or under their observations / guidance only. The Electrical Section shall provide temporary

electrical connection up to contractor’s Mains Board on which it is compulsory to install mains switch,

ELCB & fuses of adequate capacity. All such equipments shall invariably be earthed adequately to

prevent electrical shock, sparking, short circuit etc. Power cord to be used shall be of adequate

capacity, without any joint & shall consist of earth wire also. Hence, it is necessary to use adequate

capacity 3-wire power cord for single & 5-wire power cord for three phase power connections. The

plugs, receptacles, pins, holders etc shall be of adequate capacity & safe to use.

All electrical & mechanical equipments / tools-tackles viz. welding machine, cutting

machine, Grinder, Drill, Chain Pulley Blocks, Hook chooks etc required to be used during

work execution shall be of standard make & bear ISI certification mark on it.

The consumables like welding electrodes, grinding wheels / discs etc which has

specific prescribed life span shall not be used in any case if its expiry date is over.

It is compulsory to use standard make Personal Protective Equipments (P.P.Es.) as per the job

requirement. Do not work without use of required P.P.Es. Contractor is responsible to provide standard

make (ISI approved) Personal Protective Equipments / Safety Gadgets suitable to give sufficient

protection against hazards involved in their work / job to their staff, as per the job requirement and

insist / enforce their staff to put on the same while at works. The ongoing work is liable to be stopped at any time if your staff found working without P.P.Es. Following is the list of

various P.P.Es. to be used for various works / worksites.

List of safety equipments

01 Industrial Safety Helmet. For protection of head against falling objects or during fall

of person from height.

02 Safety Goggles (Grinding,

Welding, Punk, Panorama etc).

For protection of eyes against flying particles / dust,

chemical splash, spark, arc, flashover etc.

03 Face shield (Half or full). For protection of face against flying particles / dust,

chemical splash, spark, arc, flashover etc.

04 Earplug / Ear muffs. For ear / hearing system protection while working in high

noise level area.

05 Apron (Rubber / PVC / Asbestos /

Leather / Cotton).

For body protection against chemicals, oils, sharp edged

objects, heat, hot objects etc.

06 Gloves (Rubber / PVC, Asbestos,

Leather, Electrical shock proof).

For protection of hands against chemicals, oils, sharp edged

objects, heat, hot metals/objects, electricity etc.

07 Safety shoes/ Leather / Asbestos

shoes, Gum Boots etc.

For protection of leg/feet against falling objects, sharp

edged objects, heat, hot metals/objects, electricity etc..

08 Safety Belt(full body hardness ) /

Rope / Life line / Fall prevention

system etc.

For fall prevention while working at heights or in depth,

working in vessel or in confined space.

09 Dust Respirator / Scarf. Protection of respiratory system against dust.

10 ChemicalCartridge Respirator Protection against chemical fume / vapor etc.

11 Canister Gas mask. Protection against toxic/poisonous fumes/gases.

07

12 Air supply respirators. Working in oxygen deficient zone.

08 Before using lifting machines / tackles (like C.P.Bs., Hook chooks, winch, forklift, mobile crane, EOT

crane etc) & its attachments (like D-shackles, slings, U-clamps, Eye bolts or any fixtures), it shall be

checked and used only if found safe to use. Also, ensure that these are tested, examined & certified in

form no.10 by Competent Person as per the Factory act-1948 & Gujarat Factories Rules and its validity

do not expire. Further, it shall be fixed properly and firmly prior to lifting the weight. Test certificate of

all Lifting machines used by Contractor to be submitted to concerned Engineer & Safety Officer before

commencement of work.

09 Scaffoldings to be used for working at height shall be of adequate size & capacity. Obtain the work

permit when working at height. While climbing on such scaffolding or working on any structure at

height, use of full body safety belt & Helmet is compulsory. It is also necessary to fasten chinstraps of

the helmet.

10 Contractor or their employee shall not interfere in day-to-day routine plant activities / works except the

work assigned to them, shall not loiter in the areas other than their work jurisdiction, as well as shall

not temper / operate / touch the machineries/equipments/auxiliaries with which they are not concerned.

Also, the contractor shall strictly instruct their staff for not to sit or take rest at/near/below running

plants, auxiliaries, systems or any place which is risky, hazardous & prone to accident.

11 The cylinders containing poisonous / toxic or inflammable / explosive gas like Oxygen, Acetylene,

LPG, Hydrogen, Ammonia, Chlorine, CO2 etc shall be handled safely taking due care. To handle / shift

such cylinders a special trolley /cage meant for it must be used but in no case it should be rolled.

12 On completion of the work, cotton waste, spilled oil / grease, pieces of welding rod & other waste

material shall be removed from work site and the area shall be left safe, neat & clean.

13 In case of any injury / accident while working, it shall immediately be reported to Safety Department

through concerned Sectional Head / Engineer. The prescribed Form No. 21 & ANNEXURE may be

obtained from concerned section or Safety Officer.

In case of any electrical accident, it shall immediately be reported to Safety Department through

concerned Sectional Head / Engineer. The prescribed Electrical accident form no. A as per

electricity act-2003 & Form No. 21 & ANNEXURE as per Gujarat Factories rules shall be filled

up by concerned department with written consent of contractor. The Form may be obtained from

concerned section or Safety Officer.

For any incident occurred but have no injury to any persons should also reported as per GSECL format

and informed to safety officer as Near Miss Incident.

14 In all risky job, before start the work contractor should obtain General Safety Work Permit through

concerned section from safety dept in well advance.

15 For performance evaluation of contractor safety factors of work accident, fire incident & near miss

accident will be considered. Steps can be taken to review the job assignment up to cancellation for

negligence.

16 In case of noticing smoke or fire during their work execution, they shall make immediate efforts to

extinguish / control it and simultaneously inform the Fire Brigade on intercom phone No. 222 or

221,WLL Mobile No:90990 69658. Shift the casualty to nearby hospital after rendering first aid in

case of accident.

17 No women or young person shall be allowed to clean, lubricate or adjust any part of a prime mover or

of any transmission machinery while the prime mover or transmission machinery is in motion.

Examination or operation of motion machinery shall be made or carried out only by a specially trained

adult male worker wearing tight fitting clothing as per section 22 of factories act 1948.

18 No women or young person shall be employed or permitted to work in Lead-compound area like

battery room etc. as per schedule VI of GFR 1963.

19 All the relevant labour and industrial laws shall also be followed compulsorily.

20 It is felt necessary to deploy safety officers / Safety supervisors by contractors / Agencies involved in

carrying out hazardous activities / operations inside TPS to have better and constant supervision in

terms of Health Safety and Environment activities.

21 If any worker working in a factory contravenes any of the provision of section 111 of Factories act or

of any rule or order made thereunder, he shall be punishable with imprisonment for a term which may

extend to three months, or with fine may extend to Rs.100/-(One Hundred rupees only), or with

both.

22 List of PPEs Should be submitted by Contractor before commencement of work to concerned HOD’s

and Safety Officer.

Safety Clearances will be issued by Safety Officer after physical verification of PPEs as per Specified

job works.

23 Over & above these, contractor shall have to follow all the safety requirements / rules & regulations /

norms and legal provisions laid down in various statutes. Particularly the provisions of The Factories

Act-1948 & The Gujarat State Factories Rules-1963 (Amended up to date), The Electricity Act-2003 &

rules shall be followed strictly. The contractor shall also obey the rules / regulations / instructions of

the local Competent Authority for safety requirements.

24 The above rules shall be scrupulously followed and where required, they may contact the Safety

Officer in case of any ambiguity or needs further guidance in this regard.

25 For performance evaluation of contractor, safety factors of work accident, fire incident & near miss

accident will be considered. Steps can be taken to review the job assignment up to cancellation for

negligence.


M.C.Jain

Chief Engineer (G.)

GSECL, KLTPS.

SIGNATURE OF CONTRACTOR

WITH SEAL & DATE



TENDER BOOKLET

PRICE BID

Tender KLTPS- 38 , W-673 , RFQ No-14405

Name of work: - Work of Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Issued to : Opened on :



SKV NAGAR-KUTCH: 370601

INDEX

Price BID

NAME OF WORK: Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Sr. No. Description.

01 Tender Notice (Price Bid).

03 Schedule - B

Name of Firm

Tender fees no

EMD receipt no


KUTCH LIGNITE THERMAL POWER STATION SKV NAGAR: PANANDHRO: 370 601

Online www.gseb.com; www.statetenders.com

TENDER NOTICE (Price bid)

Sealed percentage rate tenders are invited for Overhauling of 415 V Raw water ACB and

modules with spares at KLTPS

1 Estimated cost Rs. 9,28,950.00

2 Tender fee (Non returnable) Rs. 750.00

3 Earnest Money Deposit Rs. 9290.00

4 Security Deposit

5 % of Order value

5 Last date of receipt of tender

15.11.2010 Up to 15:30 hrs.

6 Date of opening of tender

15.11.2010 onwards 16:00 hrs.

7 Time limit of work 2 months

8 Validity of tender

180 days from opening of Technical bid

Note:

The tender fee & EMD will be paid in cash or by Demand Draft in favor of Gujarat State Electricity

Corporation Ltd., payable at Dena Bank, SKV Nagar, Panandhro branch. Filled tender shall be accepted

by RPAD/speed post only. The technical bid & price bid should be kept in two separate sealed covers and

these two covers should be kept in main sealed cover. The tender will be opened in the presence of

contractors, who wish to remain present at the time of opening of tenders. Tender fee & EMD have to be

submitted along with technical bid, if not found offer will out rightly rejected. The undersigned reserves

the right to reject any or all tenders without assigning any reason thereof.

Details of tender fee & EMD paid (DD / MR No. & date) is invariably to be mentioned on the cover of

the tender. In absence, offer will be rejected.

Bidder has to submit tender fee / EMD in a separate cover duly super scribe with Tender Fee / EMD and

all three covers (Technical bid, Price bid and EMD/Tender fee covers) after keeping in the main cover

(Forth cover) duly super scribed with the required details such as Tender No, Description and details of

EMD/Tender Fee etc., is to be sent by RPAD/Speed Post




GUJARAT STATE ELECTRICITY CORPORATION LTD KUTCH LIGNITE THERMAL POWER STATION

SKV NAGAR: PANANDHRO: 370 601 PRICE BID

Name of work : Overhauling of 415 V Raw water ACB and modules with spares at KLTPS.

Schedule-B1 (Supply) 415 V ACB & MCC Spares

(1) 415 V ACB—CN-CS 800 AMP-(Raw water motor feeder) Description of works Qty UOM Rate Amount


3 Nos. 18400 55200


3 Nos. 450 1350


1 Set 2250 2250


1 Set 2250 2250


4 Nos. 650 2600


6 Nos. 2800 16800

07 ACB Spares type CN-CS 800 AMP Pole connector Cat No. SL612220000

3 Nos. 150 450


2 Nos. 400 800


3 Nos. 2650 7950


3 Nos. 950 2850


6 Nos. 1650 9900


3 Nos. 300 900


1 Nos. 2050 2050

14 ACB Spares type CN-CS 800 AMP Shunt coil Cat. No. SL927180B00

3 Nos. 1950 5850

15 ACB Spares type CN-CS 800 AMP Closing coil Kit 220 V DC Cat. No. SL910800000

3 Nos. 2500 7500

16 ACB Spares type CN-CS 800 AMP Spring charging motor 220 V DC Cat. No. SL00347

1 Nos. 14300 14300

(2) 415 V ACB – CN-CS-1600 AMP ( 415 V MCC Incomer and Bus Coupler

Modules) 01 ACB Spares type CN-CS 1600 AMP Pole Assembly

Cat. No. SL938860000 1 Nos. 30900 30900


2 Nos. 450 900


1

Set

2250

2250


1 Set 2250 2250


2 Nos. 650 1300


4 Nos. 3600 14400

07 ACB Spares type CN-CS 1600 AMP Pole connector 2 Nos. 150 300

Cat No. SL612220000 08 ACB Spares type CN-CS 1600 AMP Trip Latch Assly.

Cat. No. SL907150000 1 Nos. 400 400


2 Nos. 3150 6300


2 Nos. 1150 2300


4 Nos 2350 9400


2 Nos. 300 600


1 Kit 2050 2050

Total of Schedule B1 of Rs. 206350.00

Schedule-B 2 (Works)

Description of works Qty UOM Rate Amount (Rs.)

1 General health check up of 415 V MCC of Raw water P/H as per scope of work (sr no.2)

1 Nos. 1,95,000 1,95,000

2 Overhauling of 415 V Raw water ACBs including replacement of necessary spares as per scope of work (sr. no. 3)

12 Nos. 22,300 2,67,600

3 Overhauling of 415 v Raw water MCC modules and replacement of necessary spares as per scope of work ( sr.no. 4 )

Lot Lot 2,60,000 2,60,000

Total of Schedule B2 of Rs 7,22,600.00 Total of Schedules (B1 + B2) Rs. 9,28,950=00

1. Quantity shown in schedule B1 is tentative and payment will be made as per actual

consumption/execution during work and after 60 days from submission of Bill. 2. On work part the bidder should clearly specify whether the service tax is inclusive or

exclusive. If nothing is specified by the bidder the rate quoted by the bidder will be considered as inclusive of service tax and nothing will be paid extra. Service tax will be reimbursed only on submission of documentary proof.

3. On supply part Excise duty, VAT/CST against “C” form and Insurance will be paid extra if mentioned under schedule -B.

P & F and Freight are inclusive in above rates. 4. FOR: KLTPS main store. 5. General terms and condition (001) and General Instructions to the bidder (01) are

applicable to this tender. Clause No: 08, 09 and 15 of General terms and conditions (001) are not applicable to

this contract. For & behalf of GSECL


GSECL, KLTPS.

I/We am/are agree to carry-out above work at ______ % above ( in words_ ______________ ) OR at _____ % below ( in words ___________________)

than an estimated amount

Signature of contractor (With Seal/stamp & date)