Upload
others
View
2
Download
0
Embed Size (px)
Citation preview
Project Controls in
a Pandemic Era
The Speaker
• Certified Project Management Professional. (PMP)• Certified Occupational Safety and Health Administration (OSHA)• Risk Management Professional (RMP)• Scheduling Professional (PMI-SP)• Earned Value Professional (EVP)• Forensic Planning• Claims Analysis • Authorized Primavera Trainer, User & admin.• Member of CMAA “Construction Management Association of America”• Member of the Egyptian syndicate of engineers • Member in EPPMA “Engineering Planning & Project Management Association “• M.Sc., Project Management (candidate) – Liverpool University, UK.• D.PM. Diploma of Project Management - Ain Shams , Egypt • B.Sc., Architecture - Ain Shams University, Egypt
Ahmed Khashaba, PMPSenior Manager, Project Controls System (PCS)
Project Controls in a Pandemic Era
• What is a pandemic ?• Pandemic Impacts
How a pandemic affects the construction projects
01
• Identifying Risks• Manage the Risks
Identifying, managing the construction risks during a pandemic
02Recommended actions before, during and after a pandemic
03
How a pandemic affects the construction
projectswww.thebig5constructegypt.com
01
How a pandemic affects the construction projects
A pandemic is the global outbreak of a disease
The most recent is the COVID-19 which began as an epidemic in China, before making its way around the world in a matter of months and becoming a pandemic as declared by the World Health Organization on March 12, 2020.
01What is a pandemic ?
How a pandemic affects the construction projects
Broadly speaking
COVID-19 is having a massive impact on construction projects, but the legal implications vary from country to country, and contract to contract.
At this stage, COVID-19 is not rendering projects altogether impossible to complete. But it is slowing them down, causing delayand disruption, even if only because supply chains have been severally disrupted. Many projects have even stopped, usually with the intention to resume work at a later date.
A number of governments have also ordered that certain businesses stop working. However, the construction industry has generally not been the subject of ordered shutdowns.
01Pandemic Impacts
How a pandemic affects the construction projects
More specific …
In addition to physical wellness, contractors are considering mental health, too, because employers report anxiety among workers as one of the top issues brought on by the coronavirus.
In an informal Construction Dive survey, 70% of respondents noted “employee anxiety” as their top concern, above material shortages and the prospect of government shutdowns.
01Pandemic Impacts
How a pandemic affects the construction projects
Construction is a people business built on healthy relationships and partnerships. Human capital risk management holds that employees are the primary asset of companies. Companies that truly care for workers yield a sustainable competitive advantage from building a caring culture.
A crisis is the best time to reinforce these beliefs.
01Pandemic Impacts Employee Anxiety
The Rising Anxiety, Fear & Uncertainty
How a pandemic affects the construction projects
It’s becoming increasingly difficult to obtain essential materials from the overseas suppliers they rely on—especially those in China, where quarantines, curfewsand other public health measures by the Chinese government has reduced its manufacturing sector to roughly 30% of its usual capacity.
Just as COVID-19’s impact to industries was unequal, supply chain recovery times will be unequal as well.
01Pandemic Impacts Material Shortages
Supply Chain has been disproportionately impacted by the crisis.
How a pandemic affects the construction projects
01Pandemic Impacts Shutdowns
The pandemic has caused business closures, city curfews, travel bans, financial market upheavals and manufacturing shutdowns in major global economic hubs.
Employers reduce the number of working hours as well as the salary of a worker during this pandemic period
Managing the construction risks during
a pandemicwww.thebig5constructegypt.com
02
Managing the construction risks during a pandemic
Most factors influencing construction time and cost overruns
Even the most carefully planned project can run into trouble. No matter how well you plan, your project can always encounter unexpected problems
Cost saving and time performance are usually essential to all parties who are involved in a construction project, that is owner, contractor, subcontractor
02
Managing the construction risks during a pandemic
02Reduce working
hours employee absence
Shortage of material
Social distancing Force MajeureStop of work
Time & Cost
Supply Chain
Curfew & Shutdown
Anxiety
Delay in Payment Health
Precautions
Contractual Issues
Lowproductivity
LowperformanceClose
borders
Stay at HomeLDs
Recommended actions before, during and after a
pandemicwww.thebig5constructegypt.com
03
Recommended Actions
03
Action 01: Identify and Assess Relevant Local and Government Restrictions on Construction Activities
Initially, we should consult appropriate legal counsel and carefully examine the local government orders to identify restrictions on construction activities and only proceed accordingly.
Recommended Actions
03Action 02: Identify and Assess Relevant Contractual Provisions
We should carefully examine the construction contract to identify key provisions implicated by the pandemic. While standard contract forms are widely used, the forms often are modified and standard terms and conditions frequently are changed based upon negotiations. Crucial provisions such as those addressing force majeure, notice time limits, compensable costs resulting from delays, risk allocation and damages limitations may be significantly different and therefore each contract should be carefully reviewed and analyzed.
Recommended Actions
03Action 03: Communicate and Work with the Contractor to Identify, and Mitigate Project Impacts
The project management should communicate with critical contractors, designers, and suppliers to assess the actual and potential impacts on contract performance and discuss how to potentially mitigate project disruptions, in an effort to achieve the overriding objective – complete the project as soon as possible within or as close as possible to the budgeted costs. The pandemic may impact design and construction contracts in a variety of ways, including impacts to supply chains, contractor workforces, designer personnel, and the availability of government inspectors.
The contractor should taking appropriate site health and safety measures, including WHO and local guidelines as to distancing, cleansing, disinfecting, etc., and that sites are being properly manned and managed considering current circumstances.
The project management should request updated schedules from the contractor and consider setting flexible contract completion dates. Prioritizing and/or accelerating certain work areas and delaying others, as well as planning to recover delays once the pandemic restrictions are lifted.
Conclusion
“STAY SAFE, Be Productive ”
Thank You …
Ahmed Khashaba
Q & A Time