Upload
others
View
2
Download
0
Embed Size (px)
Citation preview
JUDICIAL INTERPRETATIONS ON THE PHRASE ‘REGULARLY AND
DILIGENTLY’ IN CONSTRUCTION INDUSTRY
LEE SHIAU MEI
UNIVERSITI TEKNOLOGI MALAYSIA
JUDICIAL INTERPRETATIONS ON THE PHRASE ‘REGULARLY AND
DILIGENTLY’ IN CONSTRUCTION INDUSTRY
LEE SHIAU MEI
A project report submitted in partial fulfillment of the
requirements for the award of the degree of
Master of Science (Construction Contract Management)
Faculty of Built Environment
Universiti Teknologi Malaysia
JULY 2007
iv
ACKNOWLEDGEMENTS
A debt of gratitude is owed to many individuals who have given me the
benefit of their unconditional help, tolerance and knowledge in writing and
completing this master project. First of all, I would like to express my highest
gratitude to my supervisor, Encik Norazam Othman for his guidance, advice and
support in order to complete this master project.
Next, my special thanks are due to all the lecturers for the course of Master
of Science (Construction Contract Management), for their patient and kind advice
during the process of completing the master project.
Not forgetting my dearest parents, brothers and sister, a token of appreciation
goes to them for giving full support. Lastly, I would like to express my special
thanks my fellow classmates, who have in their own way helped me a great deal
throughout the preparation and production stages of this master project.
v
ABSTRACT
Construction contracts usually impose an express duty on the contractor to
complete the works by a specified date or within a specific period. Many standard
forms of contract include an express obligation for the contractor to proceed
regularly and diligently with the works. Failure by the contractor to comply entitles
the employer to determine the contractor’s employment. However, there is a great
deal of uncertainty as to the exact circumstances in which a contractor could be said
to be failing to proceed regularly and diligently with the works. The employer’s
liability to terminate on failure to proceed regularly and diligently emphasizes the
importance of understanding its meaning. Hence, this research intends to identify
judicial interpretations on the phrase ‘regularly and diligently’ in construction
industry. This research was carried out mainly through documentary analysis of law
journals and law reports. Results show that there are 11 judicial interpretations for
the phrase ‘regularly and diligently’ in construction industry. Most of the cases
interpreted the phrase ‘regularly and diligently’ by considering on the quantity of
resources on site, by referring to the words itself, by schedule of works, etc. The
words may convey the actions and characters (style of the actions) of the contractor
on site in order to proceed regularly and diligently with the works. There are many
interpretations on the phrase ‘regularly and diligently’ in construction industry.
Ultimately therefore, there is absolutely no easy answer. The contractor would be
wise to remember that they must always carry out their works cautiously and always
fulfil the contractual requirements to avoid determination by the employer under the
contract.
vi
ABSTRAK
Kontrak pembinaan lazimnya mengenakan tanggungjawab yang nyata
terhadap kontraktor untuk menyiapkan kerja dalam jangka masa yang ditetapkan.
Banyak borang kontrak standard memperuntukkan kewajipan nyata bagi kontraktor
untuk melaksanakan kerja dengan mengikut aturan dan tekun. Kegagalan kontraktor
untuk meneruskan kerja dengan mengikut aturan dan tetap akan mengakibatkan
penamatan pengambilan kerja kontraktor oleh majikan. Namun demikian, terdapat
banyak ketidakpastian dalam menentukan keadaan sebenar dimana kontraktor gagal
meneruskan kerja dengan mengikut aturan dan tekun. Liabiliti majikan untuk
menamatkan pengambilan kerja kontraktor atas alasan gagal meneruskan kerja
dengan mengikut aturan dan tekun mencerminkan kepentingan memahami frasa ini.
Oleh itu, kajian ini bertujuan untuk mengenalpasti tafsiran hakim terhadap frasa
‘mengikut aturan dan tekun’ dalam industri pembinaan. Kajian ini dijalankan
melalui analisis dokumen, iaitu laporan dan jurnal undang-undang. Kajian ini
menunjukkan bahawa terdapat 11 tafsiran hakim terhadap frasa ‘mengikut aturan
dan tekun’ dalam industri pembinaan. Kebanyakan kes menafsir frasa ‘mengikut
aturan dan tekun’ dengan mempertimbangkan kuantiti sumber di tapak bina, merujuk
kepada perkataan tersebut, jadual kerja dan sebagainya. Perkataan tersebut
menyampaikan kelakuan dan sifat kontraktor di tapak bina untuk melaksanakan
kerja secara mengikut aturan dan tekun. Terdapat banyak tafsiran terhadap frasa
‘mengikut aturan dan tekun’ dalam industri pembinaan. Jadi, tiada jawapan yang
senang dalam konteks ini. Kontraktor diingatkan bahawa sentiasa berwaspada
semasa melaksanakan kerja dan memenuhi semua tuntutan kontrak agar tidak
ditamatkan kerja oleh majikan di bawah kontrak.
vii
TABLE OF CONTENTS
CHAPTER TITLE PAGE
DECLARATION ii
DEDICATION iii
ACKNOWLEDGEMENTS iv
ABSTRACT v
ABSTRAK vi
TABLE OF CONTENTS vii
LIST OF TABLES xi
LIST OF FIGURES xii
LIST OF ABBREVIATIONS xiii
LIST OF CASES xv
LIST OF APPENDICES xxii
1 INTRODUCTION 1
1.1 Background Studies 1
1.2 Problem Statement 4
1.3 Objective of Research 7
1.4 Scope of Research 7
1.5 Importance of Research 8
1.6 Research Process and Methods of Approach 8
1.6.1 Initial Study 8
1.6.2 Data Collection 9
1.6.3 Data Analysis and Interpretation 10
1.6.4 Completion 10
viii
CHAPTER TITLE PAGE
2 OBLIGATIONS OF THE CONTRACTOR 12
2.1 Introduction 12
2.2 Obligations of the Contractor 12
2.2.1 Obligation to Complete 13
2.2.2 Obligation as to Design and Quality of
Materials and Work
16
2.2.2.1 Design and Suitability 16
2.2.2.2 Materials 17
2.2.2.3 Workmanship 19
2.2.2.4 Work to Satisfaction of
Architect/Engineer
20
2.2.3 Obligation as to Progress 20
2.2.4 Obligation as to Cost 22
2.2.5 Obligation as to Defects and Defective
Materials
23
2.3 Time for Performance 23
2.3.1 Contract Provisions Relating to Time 24
2.3.1.1 Express Conditions 24
2.3.1.2 Commencement and Progress of
Works
25
2.3.1.3 Implied Provisions 28
2.3.1.4 Completion of the Works 29
2.3 Determination of the Contract 29
2.3.1 Common Law Determination 30
2.3.2 Contractual Determination 32
2.3.2.1 Determination by the Employer 33
2.3.2.2 Determination by the Contractor 35
2.4 Conclusion 36
ix
CHAPTER TITLE PAGE
3 INTERPRETATIONS FOR THE PHRASE
‘REGULARLY AND DILIGENTLY’
38
3.1 Introduction 38
3.2 Term of the Contract 39
3.2.1 Classification of Terms 39
3.2.1.1 Express Terms 40
3.2.1.2 Implied Terms 41
3.3 Interpretation of the Contracts 43
3.3.1 Rules of Interpretation of the Contracts 44
3.3.1.1 Literal Interpretation 44
3.3.1.2 The Contra Proferentum
Principle
45
3.3.1.3 The Ejusdem Generis Rule 46
3.4 Contractual Provision 46
3.4.1 JKR 203A (Rev 10/83) Form 47
3.4.2 JKR 203N Form 49
3.4.3 PAM 1998 Form 50
3.4.4 PAM 1998 Sub-Contract Form 51
3.5 Interpretations for the Phrase ‘Regularly and Diligently’ 52
3.5.1 Generally 53
3.5.2 Interpretations for the Phrase ‘Regularly and
Diligently’ from the Literature Review
53
3.5.3 Summary 64
3.6 Conclusion 71
4 JUDICIAL INTERPRETATIONS ON THE PHRASE
‘REGULARLY AND DILIGENTLY’ IN
CONSTRUCTION INDUSTRY
72
4.1 Introduction 72
4.2 Judicial Interpretations on the Phrase ‘Regularly and
Diligently’ in Construction Industry
73
4.3 Conclusion 124
x
CHAPTER TITLE PAGE
5 CONCLUSION AND RECOMMENDATIONS 126
5.1 Introduction 126
5.2 Summary of Research Findings 126
5.3 Problem Encountered during Research 132
5.4 Future Researches 132
5.5 Conclusion 133
REFERENCES 135
BIBLIOGRAPHY 140
APPENDICES 143
xi
LIST OF TABLES
TABLE NO TITLE PAGE
3.1 Interpretations for the Phrase ‘Regularly and
Diligently’ from the Literature Review
65
5.1 Judicial Interpretations on the Phrase ‘Regularly
and Diligently’ in Construction Industry
127
xiii
LIST OF ABBRIEVATIONS
AC Law Reports Appeal Cases
All ER All England Law Reports
ALJ Australian Law Journal
ALR Australian Law Reports
ALJR Australian Law Journal Reports
App Cas Appeal Cases
B Beavan
B & S Best and Smith’s Reports
Build LR Building Law Reports
CA Court of Appeal
CB Common Bench Reports
Ch Chancery
Ch App Chancery Appeal
Ch D The Law Reports, Chancery Division
CIDB Construction Industry Development Board
CLD Construction Law Digest
DC Divisional Court, England
Const LJ Construction Law Journal
Const LR Construction Law Reports
CP Law Reports, Common Pleas
CPD Law Reports, Common Pleas Division
DLR Dominion Law Reports
Exch Exchequer Reports
Eq Equity Case
xiv
EWHC High Court of England and Wales Decisions
FC Federal Court
F & F Foster & Finlayson’s Reports
H & N Hurlstone & Norman’s Exchequer Reports
HL House of Lords
HKC Hong Kong Cases
HKLR Hong Kong Law Reports
IEM The Institution of Engineers, Malaysia
IR Irish Reports
JKR Jabatan Kerja Raya
KB King Bench
LGR Local Government Reports
LJKB (QB) Law Journal Reports, King’s (Queen’s) Bench
Lloyd’s Rep Lloyd’s List Reports
LR Law Reports
LT Law Times Reports
JP Justice of the Peace / Justice of the Peace Reports
MLJ Malayan Law Journal
NS Nova Scotia
NZLR New Zealand Law Reports
PAM Pertubuhan Arkitek Malaysia
PWD Public Work Department
PD Probate, Divorce and Admiralty Division of High Court
QB Queen Bench
TCC Technology and Construction Court
SLR Singapore Law Reports
Stark Starkie’s Nisi Prius Reports
WLR Weekly Law Reports
WR Weekly Reports
xv
LIST OF CASES
CASES PAGE
Abdul Razak Valibhoy v. Abdul Rahim Valibhoy [1995] 2 SLR
555
43
Abrams v. Ancliffe [1978] 2 NZLR 420 22
Aisla Craig Fishing Co Ltd v. Malvern Fishing Co [1983] 1 All
ER 101
45
Arterial Drainage Co Ltd v. Ratbangan River Drainage Board
[1880] 6 LR Ir 513
33, 34
Amherst v. James Walker [1983] Ch 305 (CA) 28
Baker v. Gray [1856] 17 CB 462 34
BCL Installations Ltd (formerly Barnard Contracts) Ltd v.
Balfour Beatty Water Engineering Ltd [1999] CA
113, 119, 122,
129
Bentsen v. Taylor, Sons & Co (No 2) [1983] 2 QB 274 40
Billyark v. Leyland Construction Co Ltd [1968] 1 All ER 783,
[1968] 1 WLR 471
18
Bottoms v. York Corpn [1892] 2 Hudson’s BC (4th Edn) 208,
(10th Edn) 270, CA (Eng)
14
Bower v. Chapel-en-le-Frith RDC [1910] 75 JP 122 18
Bramall & Ogden v. Sheffield City Council [1983] 29 BLR 73 45
Brown v. Bateman [1867] LR 2 CP 272 33
Brunswick Construction Ltd v. Nowlan [1974] 21 BLR 127, 49
DLR (3d) 93
23
Cammell Laird & Co Ltd v. Manganese Bronze and Brass Co
Ltd [1934] AC 402, HL
18
xvi
CASES PAGE
Carr v. J A Berriman Pty Ltd [1953] 27 ALJ 273 13
Charnock v. Liverpool Corporation [1968] 1 WLR 1498 (CA) 28
Cobert Ltd v. H Kumar [1992] 59 BLR 89 13
Cork Corpn v. Rooney [1881] 7 LR Ir 191 33
Corudace v. London Borough of Lambeth [1986] 33 BLR 20
(CA)
25
Davies v. Swansea Corpn [1853] 8 Exch 808 33
Duncan v. Blundell [1820] 3 Stark 6 18, 19
D B Bradley (Cable Jointing) Ltd v. Jefro Mechanical Services
[1988] 6-CLD-07-19
35
Faber Union (Hong Kong) Ltd v. Alabama Building
Construction Ltd [1973-1976] HKC 113
34
Francis v. Cockrell [1870] LR 5 QB 501 18
Fook Kwong Construction Co v. The District Officer, Islands
[1979] HKLR 165 (HK)
23
Garett v. Salisbury and Dorset Junction Rly Co [1866] LR 2 Eq
358
34
Gloucestershire Country Council v. Richardson (t/a W J
Richardson & Son) [1969] 1 AC 480, [1968] 2 All ER 1181,
HL
19
Greater London Council v. Cleveland Bridge and Engineering
Company Ltd [1986] 34 BLR 50
28, 59
Hamid Abdul Rashid, Dr v. Jurusan Malaysia Consultants
(sued as a firm) [1997] 3 MLJ 546
43
Hampshire County Council v. Stanley Hugh Leach Ltd [1992] 8
Const LJ 174
64
Harmer v. Cornelius [1858] 5 C.B. (N.S.) 236 19
Hancock v. B W Brazier (Anerley) Ltd [1966] 1 All ER 901,
[1966] 1 WLR 1317 , CA (Eng)
18, 19
Hiap Tian Soon Construction Pte Ltd and Another v. Hola
Development Pte Ltd and Another [2003] 1 SLR 667
96, 128
Hoeing v. Issacs [1952] 2 All ER 176 31
xvii
CASES PAGE
Hollier v. Rambler Motors (AMC) Ltd [1972] 1 All ER 399 45
Hooker Constructions Pty Limited v. Chris’s Engineering
Contracting Co. [1970] ALR 821
82
Hunt v. Bishop [1853] 8 Exch 675 34
Hunt v. South Eastern Rly Co [1875] 45 LJQB 87, HL 34
Hutchinson v. Harris [1978] 10 BLR 19, CA (Eng) 23
Independent Broadcasting Authority v. EMI Electronics Ltd and
BICC Construction Ltd [1980] 14 BLR 1, HL
17, 19
Interpro Engineering Pte Ltd v. Sin Heng Construction Co Pte
Ltd [1998] 1 SLR 694
44
James Png Construction Pte Ltd v. Tsu Chin Kwan Peter [1991]
1 MLJ 449, [1990] SLR 1132
23
Jennings v. Tavener [1955] 2 All ER 769, [1955] 1 WLR 932 18
John Jarvis Ltd v. Rockdale Housing Association Ltd [1986] 36
BLR 48, 10 Con LR 51, CA (Eng)
36
J. M. Hill v. London Borough of Camden [1980] 18 BLR 31. 33, 34, 56, 60,
66, 110, 116,
119, 122, 129
Jurong Engineering Ltd v. Paccan Building Technology Pte Ltd
[1999] 3 SLR 667
98, 99, 100,
101
King v. Victor Parsons & Co [1972] 2 All ER 625, [1972] 1
WLR 801
18
Lawrence v. Cassel [1930] 2 KB 83, CA (Eng) 18
Ling Heng Toh Co v. Borneo Development Corporation Sdn
Bhd [1973] 1 MLJ 23, FC
36
Lintest Builders Ltd v. Roberts [1978] 10 BLR 120; affd [1980]
13 BLR 39, CA (Eng)
23, 56, 66, 92,
105, 123, 128
London Borough of Hillingdon v. Cutler [1968] 2 All ER 361 52
xviii
CASES PAGE
London Borough of Hounslow v. Twickenham Garden
Developments Ltd [1971] Ch 233
26, 27, 56, 61,
62, 65, 66, 67,
69, 71, 74, 80,
83, 81, 87, 94,
95, 107, 110,
122, 127
Lubenham Fidelities and Investments Co Ltd v. South
Pembrokeshire District Council [1986] 33 BLR 39, 6 Con LR
85, CA (Eng)
36
Lyncb v. Thorne [1956] 1 All ER 744, [1956] 1 WLR 303, CA
(Eng)
18
Main Roads Comr v. Reed Stuart Pty Ltd [1974] 48 ALJR 461,
12 BLR 55
13
Marsden v. Sambell [1880] 28 WR 952 34
Mckey v. Rorison [1953] NZLR 19
Mersey Steel & Iron Co Ltd v. Naylor Benzon & Co [1884] 9
App Cas 434
31, 52
Merton London Borough v. Stanley Hugh Leach Ltd [1985] 32
BLR 51
121
Miller v. Cannon Hill Estates Ltd [1931] 2 KB 113, DC (Eng) 18
Mohan and Homes v. Dundalk, Newry and Greenore Rly Co
[1880] 6 LR Ir 477
33, 34
Moorcock [1889] PD 64 43
Myers v. Brent Cross Service Co [1934] 1 KB 46 18
National Coal Board v. William Neill & Son (St Helens) Ltd
[1985] QB 300, [1984] 1 All ER 555
14
N C Chan v Chung Lee Construction Co (Chung Kee) (a firm)
[1964] HKLR 254
34
Nene Housing Society Ltd. v. National West-minister Bank Ltd.
[1980] 16 BLR 22
13,15
Neodox v. Swinton and Pendlebury Borough Council [1958] 5
BLR 34
14
xix
CASES PAGE
Peak Construction (Liverpool) Ltd v. Mckinney Foundation Ltd
[1970] 69 LGR 1
45
Pearce v. Tucker [1862] 3 F & F 136 18, 19
Perry v. Sharon Development Co Ltd [1937] 4 All ER, CA
(Eng)
18
Petowa Jaya Sdn Bhd v. Binaan National Sdn Bhd [1988] 2
MLJ 261
102, 123, 124,
129
Pigott Foundations Ltd v. Shepherd Construction Ltd [1993] 67
BLR 48
44
Pong Wing-sbiu v. Albambra Investment Co Ltd [1965] HKLR
163, CA (HK)
18
Produce Brokers Co Ltd v. Olympia Oil & Coke Co Ltd [1916]
AC 314
42
P & M Kaye v. Hosier and Dickinson Ltd [1972] 1 All ER 121,
[1972] 1 WLR 146, HL
13
Rainer v. Miles [1981] AC 1050 (HL) 28
R B Burden Ltd v. Swansea Corpn [1957] 3 All ER 243, [1957]
1 WLR 1167, HL
36
Re Garrud, ex p Newitt [1880] 16 Ch D 522, CA (Eng) 33, 34
Reigate v. Union Manufacturing Co Ltd [1918] 1 KB 592 43
Re Walker; ex p Baxter; ex p Black [1884] 26 Ch D 510, CA
(Eng)
33
Roberts v. Bury Improvement Comrs [1870] LR 5 CP 310, Ex
Ch
33, 36
Robin Ellis Ltd v. Vinexsa International Ltd [2003] EWHC
1352 (TCC)
117, 122, 130
Rouch v. Great Western Rly Co [1841] 1 QB 51 34
R. W. Green Ltd v. Cade Bros. Farms [1978] 1 Lloyd’s Rep.
602
45
Sharpe v. San Paulo Rly Co [1873] LR 8 Ch App 597 13, 14
Shirlaw v. Southern Foundries (1926) Ltd [1939] KB 206 43
Sindall Ltd v. Solland and Others [2001] 80 ConLR 152 119, 130
xx
CASES PAGE
Smith v. Howden Union RSA and Fowler [1890] 2 Hudson’s BC
(4th Edn) 156, DC (Eng), (10th Edn) 461, 709, 711, DC (Eng)
36
Simplex Floor Furnishing Appliance Co v. Duranceau [1941] 4
DLR 260
13
Stadbard v. Lee [1863] 3 B & S 364 33
Stag Line Ltd v. Tyne Shiprepair Group Ltd, the Zinnia [1984] 2
Lloyd’s Rep 211
23
Stevens v. Taylor [1860] 2 F & F 419 34
Stewart v. Reavell’s Garage [1952] 2 QB 545, [1952] 1 All ER
1191
18
Success Well Investment Limited v. Bank of China Group
Insurance Co Ltd v. Wai Bo Construction and Engineering
(HK) Co Ltd [2000] HKCU 440
88, 119, 122,
128
Surrey Heath Council v. Lovell Construction Ltd and Hayden
Young Ltd (third party) [1988] 42 BLR 25 Con LR 68
23
Teh Khem On & Anor v. Yeoh & Wu Development Sdn Bhd
[1995] 2 MLJ 663
18
Tersons Ltd v. Stevenage Develoment Corp [1965] 1 QB 37;
[1963] 1 Lloyd’s Rep 333
45
Test Valley Borough Council v. Greater London Council [1979]
13 BLR 63, CA (Eng)
18
Thomas Feather & Co. (Bradford) Ltd. v. Keighley Corporation
[1953] 52 L.G.R. 30
32, 34
Tooth v. Hallett [1869] 4 Ch App 242 34
Tridant Engineering Company Limited v. Mansion Holdings
Limited and Others [2001] HKCU 636
106, 121, 129
University of Warwick v. Sir Robert McAlpine [1988] 42 BLR 1 19
University Court of the University of Glasgow v. William
Whitfield and John Laing (Constructions) Ltd [1988] 42 BLR
66, 19 Con LR 11
23
Viking Grain Storage Ltd v. T H White Installation Ltd [1985]
33 BLR 103, 3 Con LR 52
18
xxi
CASES PAGE
Walker v. London and North Western Rly Co [1876] 1 CPD 518 34
Wells v. Army & Navy Co-operative Society [1902] 86 LT 764 46
West Faulkner Associates v. London Borough of Newham
[1992] 31 Con LR 105
57
West Faulkner Associates v. London Borough of Newham
[1994] 71 BLR 1 (CA)
25, 26, 58, 61,
63, 65, 66, 68,
69, 70, 71, 78,
92, 95, 105,
108, 110, 119,
121, 122, 127
Williams v. Fitzmaurice [1858] 3 H & N 844 13,14
Yong Mok Hin v. United Malay States Sugar Industries Ltd
[1966] 2 MLJ 286, [1967] 2 MLJ 9, FC
36
Yong Ung Kai v. Enting [1956] 2 MLJ 98. 43
Young and Marten Ltd v. McManus Childs Ltd [1969] 1 AC
454, [1968] 2 All ER 1169, HL
17, 18
xxii
LIST OF APPENDICES
APPENDIX TITLE PAGE
A List of Malaysia Cases (Determination by the
Employer on the Ground of “Failed to Proceed
Regularly and Diligently”)
143
CHAPTER 1
INTRODUCTION
1.1 Background Studies
Construction in Malaysia spans a wide spectrum of activities stretching from
simple renovation works for private homes to massive construction projects. Every
such building activity may create its own unique set of requirements and
circumstances. The standard form of building contract is one of the key methods of
ameliorating a potentially fractious relationship to achieve a common end. A
standard form of building contract would therefore be useful in expressing the
obligation of the parties and setting out with reasonable clarity the scope of project.1
Most construction contracts specify time for performance in achieving
completion of the whole of the works and many have additional requirements for
phased or sectional hand-over.2 It is because delay in the completion of the work is
one of the most common causes of trouble encountered during administration of
1 Sundra Rajoo, “The Malaysian Standard Form of Building Contract (The PAM 1998 Form).” Second Edition. (Kuala Lumpur: Malayan Law Journal Sdn Bhd, 1999), p. 3. 2 Brian Eggleston, “Liquidated Damages and Extensions of Time.” Second Edition. (Victoria: Blackwell Publishing, 1998), p. 21.
2
building contracts. It is also one of the most justifiable causes of criticism of the
building industry.3
The contractor’s obligations begin with the obligation to construct the works
in accordance with the documents within the required time.4 The contractor’s
obligation as to time will depend upon the express term of the contract and on the
terms implied as a matter of business efficacy.5 Generally, obligations of the
contractor consists of the obligation to complete, obligation as to design and quality
of materials and works, obligation as to progress, obligation as to cost and obligation
as to defects and defective materials.6
For obligation as to progress, in the absence of express provisions, a
contractor must complete within a reasonable time. In addition to express provisions
for completion by a stated date, virtually all construction contracts, for very good
practical reason, also contain provisions requiring due diligence or expedition by the
contractor at all times prior to completion.7
Thus, the English standard forms provide that the contractor “shall …
regularly and diligently proceed with the works” and “shall proceed the works with
due expedition and without delay”, but in fact, even in the absence of such
provisions, it is submitted that there must be an implied term that contractor will
proceed with reasonable diligence.8 In some sub-contract forms the sub-contractor’s
3 Brian Bagnall, “Contract Administration for Architects and Quantity Surveyors.” Sixth Edition. (London: Collin Professional and Technical Books, 1986), p. 73. 4 John Murdoch and Will Hughes, “Construction Contracts: Law and Management.” Third Edition. (London: Spon Press, 2000), p. 147. 5 Daniel Atkinson, “Delay and Disruption – The Contractor’s Obligation as to Time.” (London: Daniel Atkinson Limited, 2001), p. 1. 6 Duncan Wallace, “Hudson’s Building and Engineering Contracts Including the Duties and Liabilities of Architect, Engineers and Surveyors.” Eleventh Edition. Volume 1. (London: Sweet & Maxwell, 1995), p. 469. 7 Duncan Wallace, “Hudson’s Building and Engineering Contracts Including the Duties and Liabilities of Architect, Engineers and Surveyors.” Eleventh Edition. Volume 2. (London: Sweet & Maxwell, 1995). p. 563. 8 Ibid., p. 564.
3
obligation to progress the sub-contract work is stated in terms that progress must be
in accordance with the progress of the main contract works.9
However, in Malaysia, there are several types of Standard Form of Contract
available to use in construction, such as PWD, PAM, CIDB, IEM and etc. For
example, PWD 203A provides that upon obtaining possession of the site and subject
to the provision of the performance bond and insurance policies, the contractor is
then obliged to forthwith commence the execution of the works regularly and
diligently and complete the works on or before the date for completion.10
On the other hand, PAM 98 provides that the contractor’s primary obligation
is to complete the works by the contractual date for completion. As his secondary
obligation, the contractor is then to begin the work and proceed regularly and
diligently so as to complete the work ‘on or before’ the completion date set out in the
Appendix of the PAM 1998 Form.11
Consequently, failure by the contractor to even if diligently, or alternatively
if he fails to proceed diligently although regularly, he will be in breach of this
provision.12 The employer under most standard forms of contract is entitled to
determine the contractor’s employment if he fails to proceed regularly and diligently
with the works.13
9 Supra note 5. 10 Lim Chong Fong, “The Malaysian PWD Form of Construction Contract.” (Selangor: Sweet & Maxwell Asia, 2004), p. 81. 11 Supra note 1, p. 183. 12 Neil F. Jones, “The JCT Major Projects Form.” (Oxford: Blackwell Publishing, 2004), p. 79. 13 PWD 203A clause 51(a)(ii); PAM 98 clause 25.1(ii); Roger Knowles, “One Hundred Contractual Problems and Their Solutions.” (London: Blackwell Publishing, 2000), p. 184.
4
1.2 Problem Statement
Construction contracts usually impose an express duty on the contractor to
complete the works by a specified date or within a specific period.14 Many standard
forms of contract include an express obligation for the contractor to proceed
regularly and diligently with the works. If the contractor does complete in time, but
it can be shown that there was a breach of contract if the work did not proceed
regularly and diligently.15 This requirement to regularly and diligently proceed with
the work should be of much more practical use to the employer than the obligation
on the contractor to complete by a certain date.16
For example, clause 21.1 of the PAM Private Edition 1998 with Quantities
provides that:
“On the Date of Commencement stated in the Appendix, possession of
the site shall be given to the Contractor who shall thereupon begin the
Works, and regularly and diligently proceed with the same and
complete the same on or before the Date for Completion stated in the
Appendix subject to any extension of time in accordance with clause
23.0 and/or sub-clause 32.1 (iii).”
It is difficult to see what remedy an employer would have if he could
establish that the contractor was in breach of this clause alone. However the PAM
98 forms give the obligation considerable force by providing that a failure by the
contractor to comply entitles the employer to determine the contractor’s
employment.17
14 Andrew Tobin, “Regularly and Diligently: You’ll Know it when You See it.” (Royal Institution of Chartered Surveyors, 22 July 2004), pp. 1-2. 15 Vivian Ramsey, “Construction Law Handbook.” (London: Thomas Telford, 2000), p. 4.1/15. 16 Neil F. Jones and Simon E. Baylis, “Jones & Bergman’s JCT Intermediate Form of Contract.” Third Edition. (London: Blackwell Publishing, 1999), p. 78. 17 See, for example, clause 25.1 (ii) of the same PAM 98 Form.
5
In the light of the widespread use of PAM forms of contract, the phrase
regularly and diligently has become commonly used in the construction industry.
However, when the phrase has come before the Courts, it has become evident that
trying to define what it actually means in practice is by no means any easy task.18
Furthermore, lengthy and complex of document is drafted in difficult, obscure
language which invites different interpretation.19
The employer’s right to determine is therefore dependent on the correct use
of the notification requirements, together with an assessment of the contractor’s
failure to proceed regularly and diligently with the works. However, there is a great
deal of uncertainty as to the exact circumstances in which a contractor could be said
to be failing to proceed regularly and diligently with the works.20
It was contended on behalf of the architect that in order to meet the
requirements of this clause, it had to be shown that the contractor was proceeding
neither regularly nor diligently and that, although there could be no doubt that he
was not proceeding regularly, nonetheless he was doing his best to proceed
diligently. The contention was rejected emphatically.21
A slow rate of progress judged against the performance of other contractors
is an indicator that the contractors is not proceeding regularly and diligently although
low productivity on site may well be explained by other factors are outside the
contractor’s control.22 However, merely failing to comply with your programme is
not failure to proceed regularly and diligently, although some architects seems to
think that it is. This is very difficult ground for the employer to establish and,
18 Supra note 14. 19 Tan Gim Ean, “New Building Contract Clarified.” (New Strait Times, 30 June 1999), p. 1. 20 Billie Bingham, “Terminating for the Failure to Proceed ‘Regularly and Diligently’.” (Royal Institution of Chartered Surveyors, 10 August 2006), pp. 1-2. 21 Nicholas J. Carnell, “Causation and Delay in Construction Disputes.” Second Edition. (Victoria: Blackwell Publishing, 2005), p. 74. 22 Vincent Powell-Smith and David Chappell, “A Building Contract Dictionary.” Third Edition. (London: Blackwell Publishing, 2001), p. 348.
6
depending on circumstances.23 In the arbitration proceeding, the arbitrator held that
the obligation on the contractor to execute works regularly and diligently were not
limited to progress but also referred to the manner of working.24
The words regularly and diligently will be interpreted in the light of the facts,
but it seems clear that simply going slow will not necessarily be taken to mean that
the contractor is not proceeding diligently. Failure on the part of the contractor to
keep his programme would hardly qualify under this head unless such failure was
gross.25 In practice, there may be instances where it may be difficult to show that the
contractor has failed to work regularly and diligently.26
Whether a term that the contactor must proceed regularly and diligently
would be implied in this instance is open to question. The employer’s liability to
terminate on failure to proceed regularly and diligently emphasizes the importance of
understanding its meaning.27 It is the most difficult ground to establish in practice,
and essentially it is a question of fact.28 However, it is submitted that circumstances
would need to be quite extreme before a sub-contractor could be sure that a
contractor was not proceeding regularly and diligently with the main contract
works.29
Hence, the issues derived from the statement above are what are the judicial
interpretations on the phrase ‘regularly and diligently’ in construction industry?
23 Vincent Powell-Smith, John Sims and Christopher Dancaster, “Contract Documentation for Contractors.” Third Edition. (London: Blackwell Publishing, 2000), p. 183; David Chappell, “The JCT Minor Works Building Contract 2005.” Fourth Edition. (Oxford: Blackwell Publishing, 2005), p. 79. 24 Anthony P. Lavers, “Case Studies in Post-Construction Liability and Insurance.” (New York: Spon Press, 1999), p. 162. 25 David Chappell, “Understanding JCT Standard Building Contracts.” Seventh Edition. (New York: Spon Press, 2003), p. 10. 26 Ibid., p. 115. 27 David Chappell, “The JCT Minor Works Building Contract 2005.” Fourth Edition. (Oxford: Blackwell Publishing, 2005), p. 79. 28 Supra note 1, p. 248. 29 Peter Barnes, “The JCT 05 Standard Building Sub-Contract.” (Oxford: Blackwell Publishing, 2007). p. 295.
7
What are the exact circumstances in which a contractor could be said to be failing to
proceed regularly and diligently with the works? Thus, the above-mentioned
question forms the basis for this research which intends to identify the closest
answers of it.
1.3 Objective of Research
Following the issues stated above, this research attempts to:-
1. To identify judicial interpretations on the phrase ‘regularly and diligently’
in construction industry.
1.4 Scope of Research
The following are the scopes for this study: -
1. Only construction cases will be discussed in the study.
2. The study only examines the contracts between employers and
contractors, contractors and sub-contractors, and contractors and
suppliers.
8
1.5 Importance of Research
The importance of this study is to give an insight of judicial interpretations
on the phrase ‘regularly and diligently’ to the parties in construction industry. The
study may help the parties to the contracts to have a more complete understanding on
the exact circumstances in which a contractor could be said to be failing to proceed
regularly and diligently with the works.
1.6 Research Process and Methods of Approach
Research process and method of approach will be used as guidelines so that
the research could be done in a systematic way to achieve the research objective.
Basically, the research process consists of 4 major stages, which involve initial
study, data collection, data analysis, and completion. The following will be the
research process and the methods of approach used for this research (refer to figure
1.1).
1.6.1 Initial Study
First stage of research involves initial study. Firstly, initial literature review
was done in order to obtain the overview of the concept of this topic. At the same
time, discussions with supervisors, lecturers, as well as friends, were held so that
more ideas and knowledge relating to the topic could be collected. After the initial
study, the rough idea of the research topic is obtained. The objective and scope of
the research are identified then. Afterward, a research outline will be prepared in
9
order to identify what kind of data will be needed in this research. Sources of data
will be identified as well.
1.6.2 Data Collection
Collection of relevant data and information can be started in this stage. Data
will be collected mainly through documentary analysis. All collected data and
information were recorded systematically. Data collected to analyse mainly from
Malayan Law Journal, Singapore Law Report, Building Law Report, Construction
Law Report and other law journals. It is collected through the Lexis-Nexis legal
database. All the cases relating to the research topic will be sort out from the
database. Important cases will be collected and used for the analysis at the later
stage.
In addition, secondary data also collected from books, articles reports,
seminar papers, newspaper as well as from the internet. Books relating to
obligations of the contractor, time for performance, determination and interpretation
of the contract will be read to know in depth the theories relating to the research
field. All the relevant books will be obtained from the library of Universiti
Teknologi Malaysia. In the other hand, seminar papers, articles, reports and
newspapers will be the sources to strengthen the theories found in books. All
sources are important to complete the literature review chapter.
10
1.6.3 Data Analysis and Interpretation
In this stage, all the collected data, information, ideas, opinions and
comments were arranged, analysed and also interpreted. This process is to process
and convert the data collected to information that is useful for the research.
Arrangement of data tends to streamline the process of writing of the paper.
1.6.4 Completion
The last stage of the research process mainly involved the writing up and
checking of the writing. Conclusion and recommendations were made based on the
findings during the stage of analysis.
11
1st stage
2nd stage
3rd stage
4th stage
Figure 1.1 : Research Process and Methods of Approach
Identify the research topic
Identify the research objective, scope and prepare the research outline
Data Collection
Data Analysis and Interpretation
Data Arrangement
Completion
Writing and Checking
Identify type of data needed and sources of data
Approach: Documentary Analysis • Law Journals, e.g. Malayan Law Journal,
Singapore Law Report, Building Law Report, etc. • Books • Other Journals
Data and Information Recording
Literature Review and Discussion
Initial Study