Upload
nguyenmien
View
225
Download
2
Embed Size (px)
Citation preview
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
1
GUJARAT COUNCIL OF SCIENCE CITY (A Government of Gujarat Society)
TECHNICAL BID
Name of the Work :- Painting work for Thrill ride, Musical
fountain, Energy park & Various toilet blocks at science city A'bad.
city, Ahmedabad.
Gujarat Council of Science City Village Hebatpur, Sola Santej Road,
Nr. Science City Cross Road, Off Sarkhej Gandhinagar Highway, Ahmedabad -380060
Phone: 91-79-55222127, 28 Email: [email protected] Website: - www.scity.gujarat.gov.in
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
2
TENDER NOTICE
Date:
To,
Dear Sirs,
Re: Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
.
You are requested to submit your Tender as per details given below:
1. Sealed Tenders, on item rate basis, in duplicate should be addressed to The Member
Secretary, Gujarat Council of Science City, Ahmedabad
2. You are not expected to include any conditions contrary to tender provisions. However, if it is
necessary to include certain conditions, the same should be submitted in a separate sealed
cover. To facilitate the processing of your offer, two separate sealed covers, one containing
conditions or non-condition statement, along with Earnest Money Deposit, and the other
containing the Priced Tender only, in the stipulated form, should be submitted. No conditions,
etc., should be put in the second cover. The cover should be super scribed, indicating the
contents. All letters, enclosures, tenders, should be submitted in duplicate. You should clearly
indicate on each copy, whether it is the Original or Duplicate copy.
3. The first Tender cover should be accompanied by an Earnest Money Deposit of Rs. 24,000.00
(Rupees twenty four Thousand only), by Demand Drafts issued by the Nationalized Bank
only, in the name of The Member Secretary, Gujarat Council of Science City, Ahmedabad. A
tender, which is not accompanied by such a Demand Draft of Earnest Money Deposit, will be
rejected ab-initio. The Earnest Money Deposit of the unsuccessful tenderers will be returned
as soon as possible but without any interest.
4. Copies of Tender Forms can be had from the office of M/s
Gujarat Council of Science City, Sola-Santej Road, Off Sarkhej-Gandhinagar Highway,
Ahmedabad., from 24 /12/2016 to 30/12/2016, during office working hours, between 10.00
a.m. to 5.00 p.m on payment of Rs. 500.00 (Non-refundable). Plans could be inspected in the
office of The Member Secretary, Gujarat Council of Science City, Via Sola Under bridge,
Sola Santej Road, Off Sarkhej Ahmedabad Highway, Ahmedabad.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
3
5. The duration of submission of tenders, duly filled in (two sealed covers) is up to 5:00pm on
30/12/2016. The rates shall be filled in both in words and figures. No tender will be received
after aforesaid date and time, under any circumstances whatsoever.
6. The first cover containing the Technical Bid and Earnest Money Deposit will be opened at
12.30 p.m on 14/12/2016, in the office of The Executive Director, Gujarat Council of Science
City, Via Sola Under bridge, Sola Santej Road, Off Sarkhej Ahmedabad Highway,
Ahmedabad, in the presence of the Architects and authorized competent representative of the
tenderer along with authorization letter, who can take decision on the spot in the matter. The
time and date for opening of the Second Cover containing the Priced Tender will be advised
after opening of first cover.
a) Tenderer should submit the first cover, along with the Earnest Money Deposit.
b) Second cover should contain only Priced Tender (Price bid).
c) After opening the envelope containing conditions, if any, and Standardizing the
Conditions, the Contractor will have to submit their offer in a separate sealed cover,
which will be opened along with the Priced Tender submitted earlier.
d) After opening the envelope containing the offer on the Standardized Conditions and
opening of the Priced Tender, no correspondence / revised offer whatsoever, will be
entertained.
The Tenderer must check all the pages of the Tender Form at the time of collecting the Tender
from this office, if any page is found missing, if should be immediately brought to the notice of
the Architect, it may be noted that the Tender will be disqualified if any page is found missing
after opening the Tender.
7) The Member Secretary Gujarat Council of Science City, Ahmedabad, reserves the right to
accept any or reject all the tenders or split the work to any other Contractor at the time of
issuing work order or during the contract period, without assigning any reasons for doing so.
8) This tender notice shall form part of Contract & bid documents.
Yours faithfully,
Executive Director,
Gujarat Council of Science City,
Ahmedabad.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
4
(On the Letter head of Tenderer)
TENDER FORM
Date:
To,
The Executive Director
Gujarat Council of Science City,
Via Sola Under bridge,
Sola Santej Road,
Off Sarkhej Gandhinagar Highway,
Ahmedabad
Sub: Painting work for Thrill ride, Musical fountain, Energy park & Various toilet
blocks at science city A'bad.
Dear Sir,
Having examined the drawings, specifications designs and schedule of quantities relating to the
work specified in the memorandum hereinafter set out and having visited and examined the site
of the works specified in the said memorandum and having acquired the requisite information
relating thereto as affecting the tender. I/We hereby offer to execute the works specified in the
said memorandum at the rates mentioned in the attached Schedule of Quantities and in
accordance in all respects with the specifications, design, drawings and instructions in writing
referred to in conditions of tender, the Articles of Agreement, Special Conditions, Schedule of
Quantities and Conditions of Contract and with such materials as are provided for by, and in all
other respects in accordance with such conditions so far as they may be applicable.
Thanking You
Yours faithfully
For,___________________
(Director/Partner/Authorized
Signatory)
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
5
MEMORANDUM
Description of work : Painting work for Thrill ride, Musical fountain, Energy park &
Various toilet blocks at science city A'bad. via Sola Under bridge, Sola Santej
Road, Off Sarkhej Ahmedabad Highway, Ahmedabad, for Science City Project
Earnest Money: Rs. 24,000.00 to be converted into Retention Money in case of successful
contractor.
Percentage, if any to be deducted from: 10% of work done from every bill will be deducted till
Bills and total amount to be retained : it reaches to the maximum of 5% of contract value or
executed cost, whichever is higher.
Time allowed for completion of the
Works from Seventh day after the date
Of written order to commence the work : 30 Days
1) Should this tender be accepted, I / We hereby agree to abide by and fulfill the terms and
provisions of the said Conditions of Contract annexed hereto so far as they may be applicable
or in default thereof to forfeit and pay to the Gujarat Council of Science City, Ahmedabad,
the amount mentioned in the said conditions.
2) I / We have deposited a sum of Rs. 10,000.00( Rupees Ten Thousands Only) as Earnest
Money with the Gujarat Council of Science City, Ahmedabad, which amount is not to bear
any interest. Should I / We fail to execute the Contract when called upon to do so. I / we do
hereby agree that this sum shall be forfeited by me/us to Gujarat Council of Science City,
Ahmedabad.
3) Our Bankers are:
i)
ii)
The names of partners/Directors of our firm / Company are:
i)
ii)
Name of the partner of the firm
Authorized to sign
Or
Name of person having Power of
Attorney to sign the Contract.
(Certified true copy of the Power
Of Attorney should be attached.
Yours faithfully,
Signature of Tenderer
Signature and addresses of Witnesses
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
6
FORM OF ACCEPTANCE
I/We hereby accept and offer to execute work for the Gujarat Council of Science City, the Work
specified in the Notice Inviting tender and in the drawings, specifications and other Contract
Documents forming part of the Agreement within the time specified and at the rate agreed to and
entered therein and under the schedule annexed hereto and also in accordance with the
specifications, design drawings and instructions in writing referred to in the “Conditions of
Contract” and in any/all of the Contract Documents.
Should this offer be accepted in whole or in part, I/we hereby agree to strictly abide by and fulfill
all the terms and provisions of the said Conditions of Contract annexed hereto and undertake in
the event of default, to pay to GCSC or its successors or assigns in office, a sum of money as
mentioned in the Tender Documents.
I/We agree to keep the tender open as mentioned in the tender from the due date of opening of the
tenders thereof and shall not make any modifications in its terms and conditions.
I/We hereby declare that I/we shall treat the Contract Documents drawings and other records
connected with the Work as secret/confidential documents and shall not communicate nor use any
information/derived there from in any manner prejudicial to the interests of the GCSC by way of
or to aims and also undertake that such modifications/amendment/alteration shall not be
construed by me/us as a counter offer made by GCSC.
A sum of Rs.24, 000.00 ( Rupees Twenty fourThousands Only) is hereby forwarded in the shape
of demand draft no. ……………….. dated ……………… drawn in favor of Gujarat Council of
Science City, Ahmedabad, as earnest money. I/We agree that the entire sum of earnest money
will be forfeited without prejudice to any other right or remedies to the GCSC or its successor in
office, in the event I / We
1) Fail to sign the contract agreement after acceptance of the offer or
2) Fail to commence the Work within seven days of the issue of acceptance of my/our offer
3) Fails to comply with the altered/amended terms and conditions.
4) However, should I/We do not perform any/all of the acts (i) (ii) and (iii) mentioned
hereinabove; the earnest money shall stand forfeited and be retained by GCSC.
5) If the main contractor sublets entire project on back to back basis without taking consent
of Owner
I/We agree that should I/We fail to perform any/all of the acts (i) (ii) (iii) and (iv) mentioned
hereinabove, an amount equal to the amount of the earnest money mentioned in the form of
invitation of tender shall stand forfeited by GCSC and the same may at the option for the
competent authority on behalf of GCSC be recovered without prejudice to any other right or
remedy available in law out of the deposit in so far as the same may extend in terms of the said
deposit and in the event of deficiency out of any other money due to me/us under the Contract
Documents.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
7
Dated the ……………………. day of ………………: 2016
Witness
Contractor
Signature ……………………………… Signature
………………………………
Name ………………………………….. Name
…………………………………..
Address …………………………………… Address
……………………………………..
………………………………
………………………………
Occupation ………………………………Telephone ………………………………
Fax ………………………………
ACCEPTANCE
The above offer is hereby accepted by me on behalf of The Gujarat Council of Science City,
Ahmedabad.
Dated the …… day of …………………. 2016
The Executive Director
Gujarat Council of Science City,
Via Sola Under bridge,
Sola Santej Road,
Off Sarkhej Gandhinagar Highway,
Ahmedabad-382006
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
8
ARTICLES OF AGREEMENT
FOR
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
THIS AGREEMENT made at this .
BETWEEN
. (hereinafter called “Contractor” which
expression shall unless repugnant to the context or meaning thereof be deemed to include its
successors and permitted assigns) of the One Part.
OR
. a partnership firm duly registered under the provisions
of the Indian Partnership Act, 1932, and having its place of business at ,
(hereinafter referred to as the “Contractor” which expression shall unless repugnant to the context
or meaning thereof be deemed to include the partner(s) for the time being of the said firm
survivor of them and the survivors or heirs, executors, administrators and permitted assignors of
the Cost Survivor) of the One Part.
OR
_____________________, a Company incorporated under the Companies Act 1956 and having
its registered office at ___________________________, (hereinafter referred to as the
“Contractor” which expression shall unless repugnant to the context or meaning thereof be
deemed to include its successors and permitted assigns) of the One Part.
AND
Gujarat Council of Science City (GCSC), a Society registered under the Societies Registration
Act, 1860 and having its registered office at Science City, Via Sola Under bridge, Sola Santej
Road, Off Sarkhej Ahmedabad Highway, Ahmedabad, Gujarat, India (hereinafter referred to as
“Employer” or “GCSC” (which expression unless excluded by or repugnant to the context mean
and include its successors-in-interest) of the other part.
WHEREAS
1. The Contractor has offered to execute the work of Proposed Construction for finishing
works of E-library at Science City, Ahmedabad. for The Gujarat Council of Science City
(GCSC) and GCSChas accepted its tendered offer for the execution of the above
mentioned Works.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
9
2. Pursuant to acceptance by GCSC of the tendered offer of the Contractor, GCSC has paid /
has to pay a mobilization advance of Rs. ____________ (Rupees
__________________________________Only) to the Contractor.
3. GCSC desires to obtain the services of the Contractor more specifically stated in the
Tender Documents from the Contractor.
4. The Contractor is engaged in the business of construction and as such has the experience
in providing the aforesaid services.
5. The parties are desirous of recording the terms and conditions of the appointment of the
Contractor and the performance of various obligation of the Contractor in terms of this
Agreement.
Now this Agreement entered into between the parties hereto witnessed as follows:
1 In this Agreement, words and expressions shall have the same meanings as are
respectively assigned to them under the general conditions of the contract.
2 The following documents shall be deemed to form an integral part of this Agreement and
be construed as part of this Agreement. All the documents mentioned hereunder shall be
read cumulatively in order to ascertain the entire provisions, terms and conditions of this
Agreement. The documents are as follows:-
i) Contract for Works
ii) Notice Inviting Tender and Instructions to Tenderers
iii) Acceptance of Works in accordance with the Form of Acceptance.
iv) General and Special Conditions of Contract
v) Technical Specifications
vi) Bill of Quantities
vii) Drawings
viii) Agenda,
ix) Performance and Guarantee Bond
x) Bank Guarantee
xi) LOI by GCSC no. dated: - .
xii) Exchange of letters & written correspondence
Not withstanding anything contained in this contract or other document, if any deviations or
inconsistency, with or repugnant to the provisions contained in above documents shall be deemed
to be amended to the extent required to bring it to the compliance of statutory provisions & the
provision or clause mentioned in the latest document and shall be final & acceptable.
CONSIDERARATION:
1. GCSC shall pay to the Contractor as consideration for the Works undertaken by the
Contractor and performance of all obligations under the Agreement an amount of
. such
being the original contract value on item rate basis of the Works for the purposes of the
Agreement. The amount specified herein represents the full and final consideration
payable by GCSC to the Contractor. The total amount as per item rate contract shall
represent a firm fixed price and any increase in costs including in respect of taxes, duties,
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
10
levies, claims, costs and expenses shall be borne by the Contractor or as specified in the
Bill of Quantities.
2. The Terms of Payment shall be as per the provisions of Tender Documents or as may be
modified by GCSC on issue of LOI/work order.
a) Payments shall be released progressively normally within 15 days form the date of
certification of RA bills from PMC/Architect, if found in order.
b) Retention Money shall be deducted from RA bills at 10% from every bill till it reaches
5% of the total cost of the work and 50% amount shall be released after virtual
completion & remaining 50% shall be released after defects liability Period of one year.
However, the same can be released against Bank Guarantee in prescribed approved
format from nationalised bank.
3. The Contractor shall at his own cost and expense provide all labour, materials,
equipment, services, supervision and management required for the construction of the
aforesaid Works.
4. The Work will be executed strictly in accordance with the specifications and drawings
relating to the Work as shown in the Contract Documents, design drawings and also in
strict compliance with the terms and conditions of the Agreement and documents forming
part of this Agreement. GCSC shall have the right to determine whether or not the Work
is executed strictly in compliance of the specification and drawings and also in
conformity with all the other terms and conditions of this Agreement. The decision of
GCSC in this regard shall be final and binding on the Contractor.
5. Any modifications/ amendments/ alterations made by GCSC to any/all of the documents
forming part of the Agreement or part(s) thereof shall form an integral part of the
Agreement, and the Contractor shall be bound to comply with such altered terms and
conditions of the Agreement or part(s) thereof.
6. In consideration for the payments to be made by GCSC to the Contractor in respect of
completed Work, or item of Work, the Contractor hereby undertakes with GCSC to
Execute the Work diligently and in conformity with the provisions of the Contract
Documents especially but not limited to completion of Work on time, subject to the terms
relating to retention money and liquidated damages.
7. GCSC hereby undertakes to pay the Contractor, in consideration of completion of Works,
the price for the Works as specified in Clause here above of the General Terms and
Conditions of the Contract.
8. It is agreed that the Contractor shall commence performance of the Work within 7 days
from the date of letter of Intent/ work order issued by GCSC.
Compensation for Delay (Liquidated Damages):
The completion period of the entire work as stated above shall be 30 Days, Calendar Months,
from the 2nd day of issuance of LOI shall be deemed to be the essence of the contract. The time
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
11
limit specified above and as approved in writing by GCSC, shall be strictly adhered to and
followed. (i) If the Contractor fails to complete the work under contract by the stipulated date, he
shall pay liquidated damages of at the rate of 0.1 percentage of the contract value per day from
the date of delaying the said work up to the date of completion and handing over to the
Government.
(ii) However also if the contractor fails to complete any part of the work as designed in table
below by the time indicated against such part, he shall pay Liquidated damages per day from the
date of delaying the said part of the work up to the date of completion of the said designated part
at the rates shown in the said schedule of the contract value of such part for such failure till the
said designated part. is completed.
(iii) The aggregate maximum of liquidated damages payable under clause shall not exceed 0.10
Percentage of contract value per day and shall be subject to the maximum amount of ten
percentage of the final contract value.
(iv) Delays requiring payment of ten percentage liquidated damages of the accepted contractor
value for performance shall be sufficient causes for termination of contract and for forfeiture of
security deposit including amount of performance bond in respect of works estimated to cost
more than Rs.35, 000, for. Performance and registration of the contractor shall also be kept in
abeyance for three years from the date as fixed in all cases. (See table below)
(v) Liquated damages shall be recoverable from retention money and/or security deposit and/or
performance Bank guarantee and/or any sum payable to the contractor.
(vi) However the Liquated damage recovered for slow progress during original/extended time
limit shall be released if the entire work is completed within original / extended time limit, if
concluded by GCSC.
(vii) In case of delay to deliver the work within stipulated program, GCSC reserves the right to
terminate the contract by giving 7 days prior notice and get the jobs or the delayed job completed
through another agency of its choice. Any extra expenditure that GCSC will have to incur for
completion of the balance job/s through another agency on account of higher rates quoted by the
agency will be recovered from the contractor‟s account, retention money, security deposit etc.
Moreover, GCSC shall be entitled to all other legal proceedings as may be required for shortfalls
in recovery.
Bank Guarantee
The contractor shall furnish to the owner an irrevocable Performance bank guarantee of a bank
approved by GCSC and in the format acceptable to GCSC. No payment for work done of any
kind shall be released until such guarantee is furnished.
The bank guarantee shall be of the value of 2.5% of the original contract value, and the guarantee
shall remain valid and in force up to Twelve Months after the completion of contract.
In the event of the extension of the period of work as per the contract, or increase in the value of
the work as provided for in General Conditions, the Contractor shall, at its own cost, extend the
validity period and / or increase the value of its guarantee accordingly as may be called upon by
GCSC. This provision shall be applicable to every guarantee furnished by the Contractor under
the various provisions of the Contract.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
12
Third Party Inspection:
GCSC shall have right to undertake, at its own cost, continuous Third Party Inspection during
construction and up to the completion of the works, and the Contractor shall take all necessary
corrective measures as may be instructed by GCSC/Architect/PMC.
Defect Liability:
The Contractor would be responsible to correct the defects found, if any, within Twelve Months
from the date of virtual completion as certified by the GCSC/Architect/PMC.
GCSC may take possession of site/work executed “with Snag” in case of urgency to do so.
However Contractor shall be liable to complete the entire work as stipulated in tender documents.
Right of GCSC:
1. GCSC reserves the right to delete or postpone any of the item(s) from the contractor‟s
scope of work at any stage without any consequential liabilities. Further, for any reasons,
if required, GCSC can get it executed by any other agency/organization and the contractor
shall not claim for any compensation for the same.
2. GCSC also reserves right to recover loss of revenue due to defects in execution of works
by the contractor.
Insurance Policy, License of Labour Commissioner:
1. The Contractor shall be responsible for obtaining necessary Insurance Policy, License of
Labour Commissioner complying and complying with all labour laws. The Contractor
shall submit a copy of the same to our Project GCSC/Architect/PMC before executing the
agreement. Further, contractor shall submit the undertaking for non-due payments of their
labours/ working agencies along with each RA Bill. If required by GCSC, contractor will
submit the details of payment, vouchers to GCSC at any point of time. No payment shall
be released unless evidence in this regard is submitted.
Arbitration:
Any dispute arising out of this contract shall be referred to arbitration tribunal as
mentioned in conditions of the contract.
Force majeure:
This contract shall be subject to force majeure events such as riots (otherwise than in
among contractors, labour/employees) and civil commotions (in so far as both these are
uninsurable), wars (whether declared or not), invasions, act of foreign enemies,
hostilities, civil war rebellion, insurrection, military or usurped power, any act of
governments, damage from aircrafts, acts of God such as earthquake, Lightening, drought
& unprecedented floods and other causes over which the contractor has no control and
accepted as such by GCSC.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
13
Jurisdiction:
1. The jurisdiction for this contract will be the competent court at Ahmedabad, Gujarat only.
In witness thereof the parties have hereto set their respective hands and seal the day and year first
hereinabove mentioned.
For Gujarat Council of Science City (GCSC) For and on behalf
of
EMPLOYER
Member Secretary/AUTHORISED SIGNATORY Contractor
Signed ……………………………………….. Signed
……………………………………..
Name ………………………………….…….. Name
………………………………………
Designation ……………..……………… Designation
………………………………..
Date ………………………………………… Date
……………………………………….
Signed in the presence of Signed in the
presence of
1. ……………………………… …………… 1.
…………………………………………..
2. ……………………………… …………… 2.
………………………………………….
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
14
UNDERTAKING FOR CLOSURE OF CONTRACT
Gujarat Council of Science City Via Sola Under bridge, Sola Santej Road, Off Sarkhej
Ahmedabad Highway, Ahmedabad
Dear Sir,
Whereas, we M/s __________________________________________ the contractor have
successfully completed the work regarding
“___________________________________________” and the final bill of the contractor have
been finalized and certified by Architect, Project Management Consultant and also approved by
the Project Manager/ Engineer in Charge for a total value of Rs. __________(Rupees
____________________________________________ Only).
Now, we the contractor hereby agrees that the final bill is acceptable to us and we shall not claim
any further amount relating to extra item under any head including escalation of cost, additional
item, change in scope of work, liquidated damages or under any other pretext/ context as all our
claims/ demands, if any, have been covered under the final bill. Accordingly, the contract is
closed for all-purpose except to the extent of our defect liability and performance guarantee
and/or warranty as per requirement of the contract.
We further undertake that over and above our liability under defect liability clause under
agreement for the above work, we shall also be liable for performance of the bought out items
included in the above final bill.
This undertaking is executed and delivered to you in good faith without any pressure, coercion,
obligation or influences whatsoever and accordingly we have signed this understanding having
fully aware of the meaning, contents and interpretation of this undertaking.
Thanking you,
Yours faithfully,
Date:
Place:
Authorized Signatory
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
15
GENERAL INSTRUCTIONS OF CONTRACTORS AND SPECIAL CONDITIONS
1) Sealed Tender should be addressed to The Executive Director Gujarat Council of Science
City Via Sola Under bridge, Sola Santej Road, Off Sarkhej Ahmedabad Highway,
Ahmedabad, herein after referred to as employer, owner or GCSC.
2) Sealed Tenders to be submitted to the office of The Executive Director, Gujarat Council of
Science City, Via Sola Under bridge, Sola Santej Road, Off Sarkhej Ahmedabad Highway,
Ahmedabad, from 24/12//2016 to 30/12/2016 up to 5.00 p.m.. However, if that day is
declared as holiday the time shall be deemed to be extended to the next working day up to
3.30 p.m.
3) No Tender will be received after 5.00 p.m on 30/12/2016 under any circumstances
whatsoever.
4) Tenders (Technical bid) will be opened subsequently at 12.30 p.m on 30/12/2016 the
Employer in the presence of the Architect and the Tenderers, or their representative, should
they choose to be present.
5) Tenders shall remain open for acceptance by the GCSC for a period of Three months, from
the date of opening of the Tender, which period may be extended by mutual agreement and
the Tenderer shall not cancel or withdraw the Tender during this period.
6) The Tenderer must use only the Forms issued by the Architects/GCSC to fill in the rates.
7) The Tender Form must be filled in English and all entries must be made by the hand and
written in ink. If any of the documents is missing, or unsigned, the Tender may be considered
invalid by the Employer in its discretion.
8) Rates should be quoted both in figures and works in columns specified. All erasures and
alterations made while filling the Tender must be attested by initials of the Tenderer.
Overwriting of figures is not permitted; figure to comply with any of these conditions will
render the Tender void at the Owners option. No advice of any changes in the rate or
conditions after the opening of the Tender will be entertained.
9) Each of the Tender documents should be signed by the person or persons submitting the
Tender in token of his/their having acquainted himself/themselves within the General
Conditions of Contract, etc., as laid down. Any Tender with any of the documents not so
signed is liable to be rejected.
10) The Tender submitted on behalf of a Firm shall be signed by all Partners of the Firm or by a
Partner who has the necessary authority/power of attorney on behalf of the Firm to enter into
the proposed Contract. Otherwise the Owners may reject the Tender.
11) The Owners do not bind themselves to accept the lowest Tender and reserve to themselves
the right to accept or reject any or all the Tenders either in whole or in part, without assigning
any reasons for doing so.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
16
12) Intending Tenderers shall pay as Earnest Money, a sum of Rs. 24,000 (Rupees Twenty four
Thousand only), by bank Draft drawn in the name of The Executive Director, Gujarat
Council of Science City, Ahmedabad. A Tender, which is not accompanied by such, an
Earnest Money will not be considered and shall be void ab-initio. The Earnest Money will be
returned to the Tenderer if his Tender is not accepted, but without any interest.
13) The successful Tenderer shall within a week of the receipt of the advice of acceptance of the
Tender by Registered A.D., Post, Deposit as further security (for Performance), which should
be 2.5% of accepted value of the Tender.
14) On receipt of intimation from the GCSC of the acceptance of his/their Tender, the successful
Tenderer shall be bound to implement the Contract and within seven days thereof, the
successful Tenderer shall sign an Agreement in accordance with the draft Agreement and the
Schedule of Conditions, but the written acceptance by Gujarat Council of Science City,
Ahmedabad of a Tender will constitute a binding Contract between Gujarat Council of
Science City, Ahmedabad and the person so tendering whether such formal agreement is or is
not subsequently executed.
15) a) In addition to the initial Security Deposit under clause 13 and is further security for due
fulfillment of the Contract by the Contractor, 10% of the value of the work done will be
deducted by the Employer from each payment to be made to he Contractor until the Retention
Money and Earnest Money Deposit together amounts to 5%( Excluding Performance bank
guarantee) of the total amount of work done. On the Architects Certificate of virtual
completion of the work, the Contractor would be paid 50% of the total Retention Money and
remaining 50% will be released by the Employer after rectification of the defects pointed out
during the Defects Liability Period of Twelve Months. However, the same can be released
against the approved prescribed format from nationalized bank. The amount retained by the
Employer shall not bear any Interest.
b) All the compensation or other sums of money payable by the Contractor to the Employer
under there terms of this contract may be deducted from his Earnest Money and the Security
Deposit, if the amount so permits and the Contractor shall, unless such deposit has become
otherwise payable, within ten days after such deduction, make good in cash the amount so
deducted.
16) The Contractor shall not assign the Contract. He shall not sublet any portion of the Contract
except with the written consent of the Employer. In case of breach of these conditions, the
Employer may cause the Architect to serve a notice in writing on the Contractor rescinding
the contract whereupon the Security Deposit shall stand forfeited to the Employer, without
prejudice to his other remedies against the Contractor.
17) The Contractor shall carry out all the work strictly in accordance with Drawings, details and
instructions of the Architect and the Structural Consultant. If in the opinion of the Architect
or the Structural Consultant, changes have to be made in the design and with the prior
approval in writing of the Employer they desire the Contractor to carry out the same, the
Contractors shall carry out the same without any extra charge. The Architects decision in
such cases shall be final and shall not be open to arbitration.
18) The Tenderer must obtain for himself on his own responsibility and at his own expenses all
the information which may be necessary for the purpose of making a Tender and for entering
into a Contract and must examine the Drawings and must inspect the Site of the work and
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
17
acquaint himself with all local conditions, means of access to the work, nature of the work
and all matters appertaining thereto.
19) The rates quoted in the Tender shall include all charges clearing of Site before
commencement as well as after completion, water, electric consumption, meters, double-
scaffolding, centering, boxing, staging, planking, timbering and pumping out water, including
bailing, fencing, hoarding, plant and equipment, storage sheds, watching and lighting by
night as well as day, including Sundays and Holidays, temporary plumbing and electric
supply, protection of the public and safety of adjacent roads, streets, cellars, vaults, open
pavements, walls, houses, buildings and all other erections, matters or things, and the
Contractor shall take down and remove any or all such centering, scaffoldings tagging,
planking, timbering, strutting, shoring, etc., as occasion shall require or when ordered so to
do, and fully reinstate and make good all matters and things disturbed during the execution of
the work and to the satisfaction of the Architect. The rates quoted shall be deemed to be for
the finished work to be measured at Site. The rates shall also be firm and shall not be subject
to exchange variations, labour conditions, fluctuations in Railway Freights or any conditions
whatsoever. Tenderers must include in their rates Sales Tax, Excise Duty, Octroi and any
other Tax and Duty or other levy levied by the Central Government or any State Government
or Local Authority if applicable. No Claim in respect of Sales Tax on Works Contract, Excise
Duty, Octroi or other Tax, Duty or Levy whether existing or future shall be entertained by the
Employer.
20) The Contractor shall note that unless otherwise stated, the Tender is strictly item rate basis
and his attention is drawn to the fact that rates for each and every item should be correct,
workable and self-supporting. The quantities in the Schedule of Quantities approximately
indicate the total extent of work but may vary to any extent and may even be omitted thus
altering the aggregate value of the Contract. No claim shall be entertained on this account.
21) Time allowed for carrying out the work as mentioned in the memorandum shall be strictly
observed by the Contractor and it shall be reckoned from the 7th day after written order to
commence the work is issued. The work shall throughout the stipulated period of the
Contract be complete within the specified period failing which, he shall be liable to pay
compensation as defined in Clause of the Conditions of Contract “The Conditions
Hereinbefore Referred To”. The Tenderer shall before commencement of the work, prepare a
detailed work programme, which shall be approved by the Architect/PMC and the Employer.
22) Tenders will be considered only from recognized bonafide Contractors in the trade concerned
of empanelled selected Contractors.
23) Special attention of the Tenderer is drawn to the alternative items in the Schedule of Probable
Quantities; the rates and amounts for these alternative items shall be duly filled in and the
Tenderer is informed that the Tender will not be considered unless the alternative rates are
given for these items. The Employer reserves to himself the right to adopt any of the
alternative items, either in scrutinizing and deciding upon the Tender or later when the works
are being executed.
24) The Contractor shall not be entitled to any compensation for any loss suffered by him on
account of delays in commencing or executing the work, whatever the case of delays may be,
including delays arising out of modifications to the work entrusted to him or in any sub-
contract connected therewith or delays in awarding Contracts, for other trades if the Project
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
18
or in commencement or completion of such works or in procuring Government controlled or
other building materials or in obtaining water and power connections for construction
purposes or for the other reasons whatsoever and the Employer shall not be liable for any
claim in respect thereof. The Employer does not accept liability for any sum besides the
Tender amount, subject to such variations as are provided for herein.
25) The successful Tenderer is bound carry out any items of work necessary for the completion
of the job even though such items are not included in the quantities and rates. Schedule of
instructions in respect of such additional items and their quantities will be issued in writing
by the Architect with the prior consent in written of the Employer.
26) The successful Tenderer must co-operate and co-ordinate with the other Contractors
appointed by the Employer so that the work shall proceed smoothly with the least possible
delay and to the satisfaction of the Architects.
27) The Contractor must bear in mind that all the work shall be carried out strictly in accordance
with the specifications made by the Architects and also in compliance of the requirements of
the Local Authorities Concerned and no deviation on any account will be permitted.
28) The successful tenderer should make his own arrangements to obtain all materials required
for the work including Steel and Cement or otherwise as directed.
29) Water: The Owner shall provide water needed for construction at one point only and not for
drinking purposes. The Contractor shall, at its own cost make necessary arrangements for
storage and distribution of water for construction and emergencies and drinking purposes.
Electricity
The Owner may provide electrical power or DG set to the Contractor for construction or for
general lighting and other usage ONE POINT ONLY. Distribution is entirely the
responsibility of the contractor. However, if owner does not provide the same the contractor
has to arrange his source of supply entirely at his cost. Non supply of electricity by the owner
can not be taken as a reason for delay in project. The completion of schedule within the
stipulated contract duration is entirely contractor‟s responsibility.
The Contractor shall, at his own cost, provide approved temporary electrical
connections or use DG set, cable distribution boards and related equipment, as
required by the Engineer-in-Charge. Disruptions in power supply, whether due to power
failures, load shedding, generator breakdowns, or any other reason, shall not be accepted as a
valid reason for delays and deficiencies in the Work or for claims for additional payments. In
all such events, the Contractor shall be held liable and be required to pay such further and
additional sums as may be required under this Agreement on account of such delay caused in
completion of Work(s) and deficiencies in the same.
The Contractor shall strictly comply with the provision of safety code annexed hereto.
30) The Contractor shall fulfill the requirements of the Employees State Insurance Act, 1948,
applicable to all States, toward their employees and keep all the required record regarding the
same for inspection by the Authorities Concerned at any time. The Contractor shall
indemnify Gujarat Council of Science City, Ahmedabad, against any claim or legal action
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
19
arising out of the said Act due to the failure of non-compliance of the provisions of the said
Act and the penalty or any other amount levied by authorities, shall be recoverable from the
payments due to the Contractors.
31) The Contractor shall comply with the provisions of the Apprentices Act, 1961, and the Rules
and Orders issued there under from time to time. Failure to do so will be in a breach of the
Contract and the Architects and the Owner/s may in their discretion cancel the contract. The
Contractor shall also be liable for any pecuniary or other liabilities arising on account of any
violation by him of the provisions of the Act.
32) The Contractor shall be responsible for the observance of all state as well as Central Rules
and Regulations frames by the Central Government under the Contract Labour (Regulation
and Abolition) Act, 1970. The Owners shall be entitled to deduct all damages, which it might
suffer on account of non-observance of these rules by the Contractor, from the amount
payable to the Contractor.
33) The Security Deposit of the successful Tenderer will be forfeited if he fails to comply with
any of the conditions of the contract.
34) The Contractor shall visit and examine the Construction Site and satisfy himself as to the
nature of the existing roads of other means of communication, the character of the soil and
the excavation, the extent and magnitude of the work and facilities for obtaining materials
and shall obtain generally his own information on all matters affecting the execution of the
work. No extra charge made in consequence of any miss-understanding or incorrect
information or any of these points or on the grounds of insufficient description will be
allowed. All expenses incurred by the Contractor in connection with obtaining information
for submitting this Tender including his visits to the Site or efforts in compiling the Tender
shall be borne by the Tenderer and no claim for reimbursement thereof shall be entertained.
35) The Contractor shall provide for all necessary sheds of adequate dimension for storage and
protection of materials like cement, lime, timber, and such other materials including tolls and
equipment which are likely to deteriorate by the action of Sun, Wind, Rain or other natural
causes due to exposure in the open. All such sheds shall be cleared away and the whole area
left in good order on completion of the Contract to the satisfaction of the Architect.
36) Materials shall be of approved quality and the best of their kind available and shall generally
conform to I.S. Specifications. The Contractor shall order all the materials required for the
execution of work as early as necessary and ensure that such materials are on site well ahead
or requirement for use in the work. The work-involved calls for high standard of
workmanship combined with speed and to the entire satisfaction of the Architects.
37) The Contractor shall after completion of the work clear the Site of all debris and left over
materials at his own expenses to the entire satisfaction of the Architects and Municipal or
other Public Authorities.
38) Rate for variated/deviated or extra items to be worked out on the rates quoted in the tender
for the similar items only. Wherever it is not possible to base the rates for variated/deviated
or extra items on the tender quoted rates then the rate analysis as per CPWD/SOR Rate
Analysis is to be submitted by the Contractors with 15% towards Contractors overheads &
profit, in lieu of 10% of OHP as mentioned in CPWD/SOR Rate Analysis. Labour and
material constants shall be considered from CPWD Rate Analysis and labour- material basic
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
20
rate shall be taken from latest CPWD/SOR schedule of rate only. For item not available in
above-mention document, industry accepted standards shall be adopted at the discretion of
PMC subject to approval of owner. Market rate of materials & labour shall be consider duly
supported by either min. three nos of Quotation or purchase bill along with payment details
to be approved by Owner / PMC.
39) Contractors are requested to note that no extra items or deviated item of work to be executed
without taking prior permission from Owner/Architect, if the extra items or deviated items of
work is executed without taking prior permission, the owner shall not be held responsible for
the payment of such works executed.
40) The rates quoted in the tender should be inclusive of Contract Sales Tax, Turn Over Tax,
VAT, Service taxes (if applicable) etc. It is Contractors responsibility to pay the taxes to the
Authorities Concerned and produce documentary evidence of the taxes paid, to the Owner on
demand.
If Contractor fails to pay the taxes to the Authorities Concerned, the Owners reserve their
rights to recover the said amount from the amount payable to the Contractor and pay the
same to the Authorities Concerned.
The Sales Tax/ VAT on Works Contract, if applicable, will be borne by the Contractor. It is
Contractor responsibility to pay the taxes to the Authorities Concerned and produce
documentary evidence of the taxes paid, which will not be reimbursed to the Contractors.
The Contractor will be allowed to construct temporary hutments for Labourers to reside at
approved location by maintaining all statutory requirements and it is the responsibility of
contractor to clean and vacate the same after completion of work.
41) No payment shall be made to the Contractor for any damage caused by rain, snowfall, floods
or any other natural cause whatsoever during the execution of the work. The damage to the
work will be made good by the Contractor at this own cost, and no claim on this account shall
be entertained.
42) Unless otherwise provided in schedule of quantities, the rates tendered by the Contractor shall
apply for all heights, lifts, leads and depths of the work and nothing extra shall be payable on
this account.
43) The Contractor shall cover all the workers under a Block Insurance Policy, comprehensive all
Risk Policy/CAR and Fire Insurance equivalent to the cost of Project or executed cost of the
project whichever is higher within seven days from the date of letter of Intent / Work order.
44) Since the work is to be carried out in the existing premises the Contractor will have to take at
most care to not to damage any of the existing plantation & other civil constructions etc., and
if it is observed that the damage has been done by the Contractors / their workmen /
representative, it will be Contractors responsibility to make good the same at their own cost
risk.
45) Where no specifications available, BIS specifications shall be considered or shall be decided
by the Engineer-in-charge in consultation with the consultants, Quality Control & Project In-
Charge applying the best suiting engineering practice. If the item is repeating in two or more
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
21
sections, then the item in which maximum details are given the same shall be considered for
all the sections. Also the minimum quoted rate will be accepted and paid for all the items.
46) The contractors will have to keep the proper record of the cement and steel received at site.
The contractors will have to submit the statement of theoretical consumption of cement as
and when required by GCSC. If the actual consumption is less than the theoretical
consumption below 5%, the contractors will have to accept the suggestions given by the
Structural Consultant to rectify / modify / strengthen the structure or demolish and re-
construct the structure at their own cost.
47) Telephone and other communication facilities:
1 The Contractor shall at its own expense, arrange and provide for separate and
independent computer with printer, telephone, Mobile, fax connections and other
communication facilities at its site office.
2 The Owners shall not permit the use of its telephone; fax facilities or other
communication facilities by the Contractor for any purpose whatsoever.
48) Contractor shall depute a senior responsible and technically qualified person at
site/Ahmedabad with powers to take all technical and financial decisions pertaining to this
project. The Bio- data of such persons shall have to be submitted to GCSC for approval.
49) The bids submitted in 2 (two) bid system, shall be evaluated keeping the technical & financial
parameters as decided by GCSC. It is clearly understood that simply being lowest tenderer,
does not qualify for award of the work.
50) Contractor shall submit daily report, comprising of labour deployment, important activities
planned for the day and materials received the previous day etc, concrete pour cards, material
approval request form or other format approved by PMC.
I/we hereby declare that I/We have read and understood the above instructions for the
guidance of Tenderers.
Witnesses : Signature of Tendered
Date :
Address :
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
22
ANNEXURE - THE CONDITIONS HEREINBEFORE REFERED TO
1) In constructing these Conditions, the Specification Schedule of Quantities and Contract
Agreement, the following words shall have the meanings herein assigned to them expect
where the subject or context otherwise requires.
a) “Employer”,” GCSC” Or Owner :shall mean Gujarat Council of
Science City, and shall include its
assigns and successors.
b) “Contractors” shall mean (Name & Address)
and shall include his (their) legal
representative‟s assigns or successors.
c) “Site” :shall mean the Site of Contract
Works, ,i.e. at Science City Via Sola
Under bridge, Sola Santej Road, Off
Sarkhej Ahmedabad Highway,
Ahmedabad including and
building and erections thereon and any
other land (inclusively), as aforesaid,
allotted by the employer for the
Contractors use.
d) “This Contract” : shall mean Articles of Tender
Agreement, Letter of Intent the,
Special Conditions, the Conditions the
appendix, the Schedule of Quantities
and Specifications, Drawings etc.
attached hereto and duly signed.
e) “Notice in writing”: or written notice shall mean a notice in
written, typed or printed characters
sent (unless delivered personally or
otherwise proved to have been
received), by registered post to the last
known private or business address or
registered office of the addressee and
shall be deemed to have been received
within 24 hours of dispatch when in
the ordinary course of post, it would
have delivered.
f) “Act of Insolvency”: shall mean any Act of Insolvency as
defined by the Presidency Towns
Insolvency Act, or the Provincial
Insolvency Act or any amending such
original.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
23
g) “Net Prices”: If in arriving at the Contract amount
the Contractor shall have added to or
deducted from the total of the
items in the Tender any sum either as a
percentage or otherwise, then the net
price of any item in the Tender shall
be the sum arrived at by adding to or
deducting from the actual
figure appearing in the Tender as the
price of that item a similar percentage
of proportion by the Contractor of any
prime cost items and provisional sums
of money shall be deducted from the
total amount of the Tender. The
expression “net rates” or to the
Contract or accounts shall be held to
mean rates or prices so
arrived at.
h)”Work‟‟ : The expressions works or work shall
meantheworks by or by virtue of
contract contracted to be executed
whether temporary or permanent and
whether original, altered, substituted
or additional by the Contractor
i)” PMC”: Project Management Consultant
(PMC) shall mean and include
specialist consultants to supervise all
the works at the Gujarat Council of
Science City site and also to supervise
and check quality, project scheduling
cost control installation of systems (in
the Works supplied by the Contractor)
and ensure that the same is done as per
the plans approved appointed by the
GCSC and accordingly wherever the
word or expression
GCSC/Owner/Employer/Architect
used in this contract shall be replaced
by PMC to the extent required by
employer.
Words imparting persons include Firms and Corporations. Words importing the singular only also
include the plural and vise versa where the Context requires.
2) SCOPE OF CONTRACT:
The Contractor shall carry out and complete the said work in every respect in accordance
with this Contract and of with the directions of and to the satisfaction of Owner/Architect.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
24
The Architect may in his absolute discretion and from time to time issue further drawings
and/or written instructions, details directions and explanations, which are hereafter
collectively, referred to as Architects instructions.
In regard to: -
a) The variations or modification of the design quality or quantity of works of the additions
or omission or substitution of any work.
b) Any discrepancy in the drawings or between the Schedule of Quantities and/or drawings
and/or Drawings and or specification.
c) The removal from the Site of any materials brought thereon by the Contractor and the
substitution of any other material thereof.
d) The removal and/or re-execution of any works executed by the Contractor.
e) The dismissal from the works of any person employed thereupon.
f) The opening up for inspection of any work covered up.
g) The amending and making good of any defects under clause 19 hereon.
The Contractor shall for which comply with and duly execute any work, comprised in such
Architects instructions, provided always that the verbal instructions, directions, and
explanations given to the Contractor or his representative upon the works by the Architect
shall, if involving a variation, be confirmed in writing by the Contractor within seven days,
and if not dissented from in writing within a further seven days by the Architect, such shall be
deemed to be Architects instructions within the scope of the Contract.
VARIATION TO BE APPROVED BY THE EMPLOYER:-
Notwithstanding anything herein contained the Architect or his representative shall not,
without prior concurrence in writing of the Employer, issue any instructions, verbal or in
writing, which will result in the Employer having to pay the Contractor an additional and all
instructions issued to the Contractor should forth with brought to notice of the Employer. The
Contractor shall submit through the Architect, a statement of variations giving quantity and
rates duly supported by analysis of rates, vouchers, etc. The rates on scrutiny and final
acceptance by the Employer shall form a supplementary tender; the Employer shall not be
liable for payment of such variations until these statements are sanctioned by him.
3) DRAWINGS AND SCHEDULE OF QUANTITIES AND AGREEMENT: -
The Contract shall be executed in triplicate and the Architects, the Employer and the
Contractor shall be entitled to one executed copy each for his use. The Contractor on the
signing hereto shall be furnished by the Architects free of cost, one copy of each of the said
Drawing and of the Specifications and one copy of all further drawings issued during the
progress of the works, any further copies required by the Contractor shall keep one copy of
the drawing on the work the Architects or his representatives shall at all reasonable times
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
25
have access to the same before the issue of the final Certificate to the Contractor, he shall
forthwith return to the Architect all Drawings and Specifications.
4) CONTRACTOR TO PROVIDE EVERYTHING NECESSARY AT HIS COST: -
The Contractor shall provide at his cost everything necessary for the proper execution of the
works according to the intent and meaning of the Drawing, Schedule of Quantities and
Specification taken together whether the same may or may not be particular shown or
described therein, provided that the same can be reasonably be inferred therefore, and if the
Contractor finds any discrepancy in the Drawings or between the Drawings, Schedule of
Quantities and Specifications, he shall immediately and in writing refer the same to the
Architect who shall decide which is to be followed.
5) REMOVAL OF IMPROPER WORKS: -
The Architect / Owner shall, during the progress of the works, have power to order in writing
from time to time the removal from the work within such reasonable time or times as may be
specified in order, of any materials which in the opinion of the Architect / Owner are not in
accordance with the specifications or the instructions of the Architect the substitution of
proper materials, the removal and proper re-execution of any work executed with materials or
workmanship not in accordance with the Drawings and Specifications or instructions and the
Contractor shall forth with carry out such order at his own cost. In case of default on the part
of the Contractor to carry out such order, the Employer shall have the power to employ and
pay other persons to carry out the same; and all expenses consequent thereon, or incidental
thereof, shall be deducted by the Employer from any one due, or that may become due, to the
Contractor.
6) DEFECTS AFTER VIRTUAL COMPLETION: -
Any defect, shrinkage, settlement or other faults which may appear within the Defect
Liability Period stated in the Appendix hereto or, if non stated then within twelve months
after the virtual completion of the works, arising in the opinion of the Architect from
materials or workmanship not with accordance with the Contract, shall upon directions in
writing of the Architect, and within such reasonable time as shall be specified therein, be
corrected/rectified and made good by the Contractor, at his own cost.
7) CERTIFICATE OF VIRTUAL COMPLETION & DEFECTS LIABILITY PERIOD: -
The work shall not be considered as completed until the Architect has certified in writing that
they have been virtually completed. The Defect Liability Period shall commence from the
date of such Certificate.
8) INSURANCE IN RESPECT OF DAMAGE TO PERSONS AND PROPERTY: -
The Contractor shall be responsible for all injury to persons, animals or things, and for all
structural and decorative damage to property which may arise from the operation or neglect
of himself or any nominated Sub-Contractor or any employee of either, whether such damage
or injury arises from carelessness, accident or any other cause whatever in any way connected
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
26
in the carrying out of this Contract. This Clause shall be held to include internal any damage
to buildings, whether immediately adjacent or otherwise, and any damage to the roads,
streets, foot-paths, bridge or ways as well as all damage caused to the buildings and works
forming the subject of this Contract by frost, rain, wind or other inclemency of weather. The
Contractor shall indemnify the Employer and hold it harmless in respect of all and any
expenses arising from such injury or damage to persons or property as aforesaid and also in
respect of any claim made in respect of injury and damage under any Act of any Legislature
of otherwise and also in respect of any award of compensation or damages consequent upon
such claims.
The Contractor shall reinstate all damage of every sort mentioned in this Clause, so as to
deliver up the whole of the Contract Works complete and perfect in every respect and so as to
make good or otherwise satisfy all claims for damages to the property of third parties.
The Contractor shall indemnify the Employer against all claims which may be made against
the Employer by any member of the Public or third party in respect of any thing which may
arise in respect of the works or in consequence thereof and shall at his own expenses arrange
to effect and maintain, until the virtual completion of the Contract, with an approved offices,
a Policy (CAR) of insurance in the name of the Employer and the Contractor against such
risks and deposit such policies with the Architect from time to time during the currency of
this Contract. The Contractor will also similarly indemnify the Employer whether under the
Workmen‟s Compensation Act or play other statute in force during the currency of this
Contract or at Common Law in respect of any Employee of the Contractor or any Sub-
Contractor and shall at his own expense effect and maintain, until the virtual completion of
the Contract, with an approved office, a Policy of Insurance in the joint name of the
Employer and the Contractor against such risks and deposit such policy or policies with the
Architect from time to time during the currency of the Contract.
The Contractor shall be responsible for any liability which may be excluded from the
Insurance Policies above referred to and also for all other damages to any person, animal or
property arising out of incidental to the negligent or defective carry in out of this Contract. He
shall also indemnify the Employer in respect of any cost, charges or expenses arising out of
any claims or proceeding and also in respect of any award of compensation and damages
arising there from.
The Employer shall with the concurrence of the Architect, be entitled to deduct the amount of
any damage, compensation, cost, charges and expenses arising from or accruing from or in
respect or, any such claims or damage from any or all sums due or to become due to the
Contractor without prejudice to the Employers other rights in respect thereof.
9) FIRE INSURANCE: -
The Contractor shall, within seven days from the date of Commencement of Works, insure
the works at his cost and keep them insured until the virtual completion if the work,
against loss or damages by fire.
10) DELAY AND EXTENTION OF TIME: -
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
27
If in the opinion of the Architect/GCSC the work be delayed (a) by force majeure or (b) by
reason of any exceptionally inclement weather of (c) by reason of proceedings taken or
threatened by or dispute with adjoining or neighboring owners or public authorities arising
otherwise then through the Contractor own default or (d) by the works and delay of the other
Contractors or tradesmen engaged or nominated by the Employer or the Architect and not
referred to in the Schedule of Quantities and/or specification or (e) by reasons of the
Architect instructions as per Clause 2 here if or (f) by reason of civil commotion, local
combinations of workmen or strike or lock-out affecting any of the building trades or (g) in
consequence of the Contractor not having received in due time necessary instructions from
the Architect for which he shall specifically applied in writing or (h) from other causes which
the Architect may certify as beyond the control of the Contractor or (i) in the event, the value
of work exceeded the value of the Priced Schedule of Quantities owing to variation, the
Architect may with the previous approval in writing of the Employer make a fair and
reasonable extension of time for the completion of the Contract Works; in case of such strike
or lockout, the Contractor shall as soon as may be, give written notice thereof to the
Architect, but the Contractor shall nevertheless constantly use his endeavor to prevent delay
and shall do all that may reasonably be required to the satisfaction of the Architect to proceed
with the work.
11) FAILURE BY CONTRATOR TO COMPLY WITH ARCHITECT/GCSC
INSTRUCTIONS :-
If the Contractor after receipt of written notice from the Architects requiring compliance
within ten days fails to comply with such further drawings and / or Architects instructions,
the Employer may Employ and pay other persons to execute any such work whatsoever that
may be necessary to give effect thereto, and all costs incurred in connection therewith
shall be recoverable from the Contractor by the Employer on the Certificate of the Architect
as a dept. or may be deducted by him from any moneys due to the Contractor.
12) TERMINATION OF CONTRACT BY THE EMPLOYER :-
If the Contractor being a individual or a Firm, commits any act of insolvency or shall be
adjudged an insolvent or being an Incorporate Company, shall have an order for compulsory
winding up, voluntarily or subject to the supervision of the Court and the Official Assignee or
the Liquidator in such acts of insolvency and winding up, as the case may be, shall be unable
within seven days after notice to him requiring him to do so, to show the reasonable
satisfaction of the Architect that he is able to carry out and fulfill the Contract and to give
security thereof, of so required by the Architect.
Or if the Contractor (whether an individual, Firm or incorporated Company) shall suffer
execution or other process of Court attaching property to be issued to the Contractors.
Or shall suffer any payment under this Contract to be attached by or on behalf of any of the
creditors of the Contractors.
Or shall assign or sublet this Contract without the consent in writing of the Employers first
obtained.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
28
Or shall charge or encumber this Contractor or any payment due of which may become due to
the Contractor hereunder.
Or if the Architect shall certify in writing to the Employer that the Contractor:
i) Has abandoned the Contract, or
ii) Has failed to commence the works or has without any lawful excuse under these
conditions suspended the progress of the works for fourteen days after receiving from
the Architect notice to proceed or
iii) Has failed to proceed with the works with such due diligence and failed to make such
due progress as would enable the works to be completed within the time agreed upon,
or
iv) Has failed to remove materials from the Site or to pull down and replace work for
seven days after receiving from the Architect written notice that the said materials or
work were condemned and rejected by the Architect under these Conditions, or
v) Has neglected or failed persistently to observe and perform all or any of the acts,
matters or things by this Contract to be observed and performed by the Contractor to
observe or perform the same.
Then and in any of the said cases the Employer may, notwithstanding any previous waiver,
after giving seven days notice in writing to the Contractor, determined the Contractor, but
without thereby affecting the powers of the Architect or obligations of liabilities of the
Contractor, the whole of which shall continue in force as fully as if the Contract has not been
so determined, and as if the work subsequently executed had been executed by or on behalf of
the Contractor. And further, the Employer by his agent or servants may enter upon and take
possession of the work and all plant, tools, scaffoldings, shed, machinery, steam and other
power utensils and materials lying upon the premises or on the adjoining land or roads and
use the same as his own property or may employ the same by means of his own servants and
workmen in carrying on and completing the works or by employing any other Contractor
shall not in any way interrupt or do any act, matter or things to prevent or hinder such other
Contractor or other person employed for completing or finishing or using the materials and
plant for the work. When the work shall be completed or as soon as thereafter as convenient
the Architect shall give a notice to the Contractor to remove his surplus materials and plant
and should the Contractor fail to do so within the period of fourteen days after receipt thereof
by him, the Employer may sell the same by public auction, and give credit to the Contractor
for the net amount realize. The Architect shall thereafter ascertain and certify in writing under
his hand what (if anything) shall be due or payable to, or by the Employer, for the value of the
said plant and materials so taken possession by the Employer and the expenses and loss which
the Employer shall have been put to in procuring the works to be completed and the amount,
if any, owing to the Contractor and the amount which shall thereupon be paid by the
Employer to the Contractor or by the Contractor to the Employer, as the case may be and the
Certificate of the Architect shall be final and conclusive between the parties
.
13) TERMINATION OF CONTRACT BY THE CONTRACTOR: -
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
29
If the payment of the amount payable by the Employer under certificate of the Architect shall
be in arrears and unpaid for thirty days after notice in writing requiring payment of the
amount as aforesaid shall have been given by the Contractor to the Employer, or if the
Employer interferes with or obstructs the issue of any such certificates, or if the Employer
shall repudiate the under the order of the Architect or the Employer or by any injunction or
other order or any Court of Law, then and in any of the said cases the Contractor shall be at
the Employer, through the Architect, and he shall be entitled to recover from the Employer,
payment for all works executed and for any loss he may sustain upon any plant or materials
supplied or purchased or prepared for purpose of the Contract.
14) CERTIFICATE AND PAYMENTS: -
The Contractor shall be paid by the Employer from time to time installments under Interim
Certificates to be issued by the Architects to the Contractor on account of the works executed
when in the opinion of the of the Architect, work to the value named in the Appendix as value
of work for Interim Certificates (or less at the reasonable discretion of the Architect) has been
executed in accordance with this Contract, subject, however, to a retention of the percentage
of such value named in the appendix hereto as retention percentage for Interim Certificates,
until the total amount retained shall reach the named in the Appendix as limit for Retention
Money, after which time to the installments shall be upto the full value of the work
subsequently so executed and fixed in the building. The Architect may in his discretion
include the Interim Certificate, such amount, as he may consider proper on accounts of
materials delivered upon the site by the Contractor for use in the Works. And when the works
have been virtually completed and the Architect shall have certified in writing that they have
been completed the Contractor shall be paid by the Employer in accordance with the
Certificate to be issued by the Architect the sum of money named in the Appendix
Installment after Virtual Completion and the Contractor shall be entitled to the payment of
the Final Balance in accordance with the Final Certificate to be issued in writing by the
Architect at the expiration of the period referred to as the Defect Liability Period in the
appendix hereto from the date of Virtual Completion or as soon after the expiration of such
period as the works shall be finally completed and all defects made good according to the true
intent and meaning and hereof whichever shall last happen provided always that the issue of
the Architect of any certificate during the progress of the work or at or after the completion
shall not relieve the Contractor from his Liability under Clause 2 and 20 nor relieve the
Contractor of his inability in case of fraud, dishonesty or fraudulent concealment relating to
the works or materials or to any matter dealt with in the Certificate, and in case of all the
defects and insufficiencies in the works or material which a reasonable examination would
not have disclosed. No Certificate of the Architect shall of itself be conclusive evidence that
any works or materials to which it relates are in accordance with the Contract, neither will the
Contractors have a claim for any amounts which the Architects might have certified in any
interim bill and paid by the Employer and which subsequently be discovered as not payable
and in this respect the Employer decision shall be final and binding.
The Architect/GCSC shall have power to withhold any Certificate if the work or any parts
thereof are not being carried out to his satisfaction.
The Architect/GCSC may by any certificate make any correction in any previous certificate,
which shall have been issued by him.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
30
Architect shall issue no Certificate of payment if the Contractor fails to insure the work and
keep them insured till the issue of Virtual Completion Certificate.
Payments upon the Architects Certificate shall be made within the period named in the
Appendix as Period of honoring Certificates after such Certificates have been delivered to the
Employer.
15) DELAY PAYMENT: -
No interest shall be paid for delayed payment due to reasons whatsoever.
16) SETTLEMENT OF DISPUTES BY ARBITRATION: -
All disputes or differences of any kind whatsoever which shall at any time arise the parties
hereto touching them or concerning the work or execution or maintenance thereof this
Contract or the construction operation or effect thereof or to the rights or liabilities of the
parties or arising out of or in relation thereto whether during or after determination,
foreclosure or breach of this contract (other than those in respect of which the decision of any
person is by the contract expressed to be final and binding) shall after written notice by either
party to the contract or the other of them and to the Appointing Authority who shall be
appointed for this purpose by the Employer, be referred for adjudication to a sole arbitrator to
be appointed as hereinafter provided.
For the purpose of appointing the sole Arbitrator referred to above, the Appointing Authority
will send within thirty days of receipt by him of the written notice aforesaid to the Contractor,
a panel of the three names of persons who shall be presently unconnected with the
organization for which the work is executed.
The Contractor shall on receipt by him of the names as aforesaid, select any one of the
persons named to be appointed as a sole Arbitrator and communicate his name to the
Appointing Authority within thirty days of receipt by his the names. The Appointing
Authority shall thereupon without any delay appoint the said person as the sole Arbitrator, if
the Contractor fails to communicate such selections as provided above within the period
specified, the appointing authority shall made the selection and appoint the selected person as
the sole Arbitrator.
If the appointing Authority fails to send the Contractor the panel of three names as aforesaid
within the period specified, the Contractor shall send the Appointing Authority a panel of
three names of persons who shall be unconnected with either party. The Appointing
Authority shall on receipt by him of the names as aforesaid select any one of the persons
named and appoint him as a sole Arbitrator. If the Appointing Authority fails to select the
person and appoint him as the sole Arbitrator within 30 days of receipt by him of the panel
and inform the Contractor accordingly, the Contractor shall be entitled to appoint one of the
person from the panel as a sole arbitrator and communicate his name to the Appointing
Authority.
If the Arbitrator so appointed is unable or unwilling to act or resign is appointment or vacate
his office due to any reason whatsoever another sole arbitrator shall be appointed as
aforesaid.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
31
The work under the Contract shall, however continue during the Arbitration proceeding and
no payment due or payable to the Contractor shall be withheld notice on account of such
proceedings.
The Arbitrator shall be deemed to have entered on the reference on the date he issues notice
to both the parties fixing the date of the first hearing.
The Arbitrator may from time to time, with the consent of the parties, enlarge the time for
making and publishing the Award.
The Arbitrator shall give a separate award in respect of each dispute in accordance with the
terms of the Contract and give a reasonable award.
It is also a term of the Contract that if Contractor (s) do/does not make any demand for
arbitration in respect from the Clients / Architects that the bill after due verification is passed
for payment of a lesser amount, or otherwise, the arbitration shall be deemed to have been
forfeited and Client / Architects shall be relieved and discharged of their liability under this
agreement in respect of such claim(s). Further, it is agreed that for the purpose of this clause
such notice is deemed to have been received by the Contractor(s) within 2 days of posting of
the letter by Clients / Architects or when delivered by hand immediately after receipt thereof
by the Contractor(s), whichever is earlier. Further, a letter signed by the officials of Clients /
Architects that the letter was so posted to the Contractor(s) shall be conclusive.
The Fees, if any of the Arbitrator shall, if required be paid before the award, be paid half and
half by each of the parties. The costs of the reference and of the award including the fees, if
any of the Arbitrator who may direct to and by whom and in what manner, such costs or any
part thereof shall be paid and may fix of settle the amount of costs to be so paid.
The award of the Arbitrator shall be final and binding on both the parties.
Subject to a fore said, the provisions of the Arbitration and Conciliation Act 1996, or any
statutory modification of re-enchantment there of and the rules made there under, and for the
time being in force, shall apply to the Arbitration proceeding under this Clause.
17) RIGHT OF TECHNICAL SCRUTINY OF FINAL BILL: -
The Employer shall have right to cause a technical examination of the works and the final bill
of the Contractor including all supporting vouchers abstracts, etc., to be made at the time of
payment of the final bill. If as a result of this examination or otherwise any sum is found to
have been overpaid or over certified, it shall be lawful for the Employer to recover the same.
18) EMPLOYER ENTITLED TO RECOVER COMPENSATION PAID TO WORKMEN:
-
If, for any reason, the Employer is obliged, by the virtue of the provision of the Workmen‟s
Compensation Act, 1923, or any Statutory modification or re-enactment thereof to pay
compensation to a workman employed by the Contractor in execution of the works, the
Employer shall be entitled to recover from the Contractor the amount of compensation so
paid, and without prejudice to the rights of the employer, under the said Act. The employer
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
32
shall be at liberty to receive such amount or any part thereof by deducting or from the
Security Deposit or from any sum due to the Contractor under this contract or otherwise. The
Employer it under the said Act, except on the written request of the Contractor and upon his
giving to the Employer full security to the satisfaction of the Employer for all costs for which
the Employer might become liable in consequence of contesting such claim.
19) ABANDONMENT OF WORKS: -
If at any time after the acceptance of the Tender, the Employer shall for any reasons
whatsoever not require the whole or any part of the works to be carried out, the Architect
shall give notice in writing to the Contractor who shall have no claim to any payment of
compensation or otherwise whatsoever on account of any profit or advantage which he might
have derived from the execution of the whole works.
APPENDIX HEREINBEFORE REFERRED TO
1) Name of work Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
2) Defects Liability Period : Twelve Months from date of virtual Completion
3) Date of Commencement : 2 days from the date of issue of Letter of Intent/
work
Order
4) Date / Time of Completion : 30 days
5) Liquidated Damages / Penalty : 2.5%of the contract amount per week of delay
subject to a
Ceiling 10% of the Final contracted amount.
6) Value of Works for Interim : Rs.50,000.00 (Rupees fifty Thousand only)
Certificate
7) Earnest Money Deposit : Rs. 24,000-, (Rupees Twenty
fourThousand Only) by Bank Draft /
Pay order to be converted in Initial
Security deposit in case of successful
bidder
8) Installment after completion : 50% on virtual completion of the work
Certificate and balance 50% after Defects
Liability Period of one year.
(Release of Retention Money)
9) Period for Honoring : 1) Fifteen days for R.A.Bills.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
33
Certificates 2) The Final Bill will be submitted by
the Contractor within one month
from the date of completion of work
and payment shall be made within two
months from the date of receipt of
the final bill if no rectification is
found.
10) Insurance : CAR policy and all other insurance
11) Retention money/ Security Deposit : Retention Money shall be deducted from
RA bills at 10% from every bill till it
reaches 5% of the total cost of the work and
50% amount shall be released after virtual
completion & 50% amount shall be released
after defects liability Period of one year.
_____________________
Executive Director, GCSC Contractor
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
34
SAFETY CODE
1) There shall be maintained a readily accessible place first aid appliances including adequate
supply of sterilized dressings and cotton wool.
2) An injured person shall be taken to public hospital without loss of time, in case where injury
necessitates hospitalization.
3) Suitable and strong scaffolds should be provides for workmen for all works that cannot safety
be dome from ground.
4) No portable single ladder shall be over 8 meters in length. The width between the side rails
shall not be less than 30 cm. (clear) and the distance between two adjacent rungs shall not be
more than 30 cm. When a ladder is used, an extra mazdoor shall be engaged for holding the
ladder.
5) The excavated material shall not be placed within 1.5 meters of the edge of the trench or half
of the depth of trenches whichever is more. All trenches and excavations shall be provided
with necessary fencing and lighting.
6) Every opening in the floor of a building or in a working platform be provided with suitable
means to prevent the fall of person or materials by providing suitable fencing or railing whose
minimum height shall be one meter.
7) No floor, roof or other part of the structure shall be so overloaded with debris or materials as
to render it unsafe.
8) Workers employed on mixing and handling material such as asphalt, cement mortar or
concrete and lime mortar shall be provided with protective footwear and rubber hand-gloves.
9) Those engaged in welding works shall be provided with welder‟s protective eye-shields and
gloves.
10) i) No paint containing lead or lead products shall be used except in the form of paste or
ready-made paint.
ii) Suitable facemasks should be supplied for use by Worker when the paint is applied in form
of spray or surface having lead paint dry rubbed and scrapped.
11) Overall shall be supplied by the Contractor to the painters and adequate facilities shall be
provided to enable the working painters to wash during the period of cessation of work.
12) Hoisting machines and tackle used in the works, including their attachments, anchorage and
supports shall be in perfect condition.
13) The ropes used hoisting or lowering material or as a means of suspension shall be of durable
quality and adequate strength and free from defects.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
35
14) The entire work site shall be adequately lighted Temporary fencing around excavated areas;
opening may be provided, if advised for safety reasons.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
36
APPENDIX
IRREVOCABLE CONFIRMED BANK GUARANTEE PROFORMA
Bank Guarantee No.
The Gujarat Council of Science City
Via Sola Under bridge, Sola Santej Road, Off Sarkhej Ahmedabad Highway, Ahmedabad
We are aware the M/s_________________________________________ having their registered
office at_________________________________ have offered to construct Proposed
Construction of Fencing the internal road dividers at Science City, Ahmedabad. and
further that you have accepted their offer and entered into a contract with them in that regard. We
herewith guarantee to pay to you the maximum of Rs.______________
(Rupees_____________________________ only) in the event of the failure of
M/s_____________________________________ to fulfill any or all of their contractual
obligations or in the event of their committing any breach of the conditions of your Contract, read
with all appendices and annexure, as determined by you and entirely in your unquestioned
opinion.
Within ten days of the receipt of demand from you, we shall, without demur, pay you the sum or
sums mentioned in your demand up to a total sum not exceeding Rs.________________ We do
recognize your authority to demand a total of the above sum, without having to assign any reason
or to offer any proof or to substantiate the grounds of your demand. We admit our liability to
make payment to you as and when demanded.
We confirm that this guarantee shall remain in force for a period of ______________months that
is until__________ or any extension of this period. We moreover affirm that this is an irrevocable
confirmed guarantee and shall not be withdrawn nor cancelled before the aforementioned date.
Insofar as you do not encash this guarantee wholly at one time, it shall remain valid and in force
in the sum equal to the difference between the total amount of Rs.___________________ and the
amounts paid to you against your demands.
We undertake to renew this guarantee or to extend the period of its validity within one month
before its expiry, upon being called upon by you to do so. If, for any reason whatever and under
circumstance whatsoever, this guarantee is not renewed or extended, we undertake to pay you the
full amount of the guarantee on demand and without demur.
Signature, seal and designation of duly authorized bank representative.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
37
DETAILS OF TECHNICAL SUBMISSION
(To be submitted in a separate envelope along with Technical Bid)
1. Experience of Similar kind of work :
(With supporting documentary proof)
2. Resource Mobilization and allocation :
For this specific project
(With supporting documents)
3. Completion time and period as :
envisaged by bidder
4. Experience of co-coordinating with :
nominated/specialized contractors:
6. Quality accreditation certificate :
7. Any other specific information :
which you feel will help in better
evaluation of your offer, as may
be deemed fit.
N.B. : Please give Annexure number of each evidence.
PREQUALIFICATION CRITERIA
1. Turn Over – Minimum average turnover should be Rs.8 Lacs average for last
three years.
2. Minimum value of single work order – Rs. 8.00 Lacs building like works
3. Net Worth – Should be positive
4. Solvency Certificate – Rs.5.00 Lacs
5. Working Capital – Rs. 8.00 Lacs
Bidders have to full fill all the above criteria failing which they will be disqualified..
Decision of GCSC shall be final and binding on all concerned.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
38
SECTION – B: MATERIALS
1) Material shall be of best-approved quality obtaining and they shall comply with
the respective Indian Standard Specification.
2) Samples of all materials shall be got approved before placing order and the
approved sample shall be deposited with the Architect / PMC/Owner.
3) In case of non-availability of materials in metric sizes the nearest size in FPS
units shall be provided with prior approval of the Architects for which neither
extra will be paid nor any rebates shall be recovered.
4) If directed, materials shall be tested in any approved Testing Laboratory and the
test certificates in original shall be submitted to the Architect / PMC and repeated
testing including charges for repeated tests, if ordered, shall be borne by the
Contractor.
5) It shall be obligatory for the Contractor to furnish certificate, if deemed by the
Architects/ PMC, from manufacturer or the material supplier that the work has
been carried out by using their material and as per their recommendations.
6) All materials supplied by the Employer / any other Specialist Firms shall be
properly stored and the Contractor shall be responsible for its safe custody until
they are required on the works and till the completion of the work.
7) Unless otherwise shown on the Drawings or mentioned in the “Schedule of
Quantities” or special specification, the quality of materials, workmanship,
dimensions, etc., shall be as specified as hereunder.
8) All equipment and facilities for carrying out field tests on materials shall be
provided by the Contractor without any extra cost.
PAINTING
Indian Standards to be followed for the work are :
1. IS 75 Specification for linseed oil, raw and refined.
2. IS 345 Specification for wood filter, transparent, liquid.
3. IS 348 Specification for French polish.
4. IS 427 Specification for distemper - dry colour (as required)
5. IS 428 Specification for distemper oil emulsion colour
(as required)
6. IS 533 Specification for gum spirit of turpentine (oil of
turpentine).
7. IS 1477 Code of practice for painting or ferrous metals in
buildings:
Part 1 Pretreatment
Part 2 Painting
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
39
8. IS 2338 Code of practice for finishing of wood and wood
based materials:
Part 1 Operation and workmanship
Part 2 Schedule
9. IS 2395 Code of practice for painting concrete, masonry &
plaster surfaces.
10. IS 2932 Specification for enamel synthetic exterior (a) under
coating (b) finishing.
11. IS 2933 Specification for enamel exterior, (a) under coating
(b) finishing
12. IS 3140 Code of practice for painting asbestos cement
building products.
13. IS 3537 Specification for ready mixed paint finishing interior
for general purposes to IS colours.
14. IS 3631 Specification for ready mixed paint for finishing
exterior (I) Alkyd, (ii) non-Alkyd, for general
purposes to IS colours.
15. IS 4597 Code of practice for finishing of wood and wood
based products with nitrocellulose and cold
catalyzed materials.
16. IS 5410 Specification for cement paints
17. IS 6005 Code of Practice for phosphating of Iron and steel.
18. IS 6278 Code of practice for white washing and colour
washing.
MODE OF MEASUREMENTS
Painting, White washing, colour washing and distempering :
All painting work shall be measured in square meters.
Net are of surface painted shall be measured. No deductions will be made for unpainted
surfaces of ends of joists, beams, posts etc., and opening not exceeding 0.5 sq.m. each and no
additions shall be made for reveals, jambs, soffits, sills, etc., of these openings.
No coefficient will be considered for painting over sponge finished or sand faced plaster.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
40
General :
Wherever scaffolding is necessary, it shall be double scaffolding.
The surface shall be thoroughly brushed free from mortar droppings and foreign matter. All steel
work shall be cleaned of loose rust, mill scales etc. so as to expose the original surface. All
broken edges, cracks, loose plaster and wavy surface shall be brought up either by patch plaster
work or by plaster of paris.
All materials viz., dry distemper, oil bound distemper, oil paint, flat oil paint, synthetic enamel
paint, plastic emulsion paint, cement primer, red lead and other primers and metallic paints shall
conform to respective I.S. specifications and shall be obtained from approved manufactures. All
paints shall be brought on site in sealed thins in ready mixed form and shall be applied direct with
the addition of thinner, if recommended by the manufacturers.
White Washing:
White was shall be prepared from lime slaked on spot, mixed and stirred with sufficient water to
make a thin cream. This shall be allowed to stand for 24 hours and shall be screened through
clean cloth. Four kg. gum dissolved in hot water shall be added to each cubic meter of the cream
(115 gm. per cft.).
Blue shall be added to give required whiteness. The approximate quantity of water to be added in
making cream shall be five liters per kg. Of lime.
White wash shall be applied in specified coats by using flat brushes or spray pumps. Each coat
shall be allowed to dry before next coat is applied. If additional coats than what have been
specified, are necessary to obtain uniform and smooth finish, it shall be given at no extra cost.
The finished dry surface shall not show any signs of cracking and peeling nor shall it come off
readily on the hand when rubbed.
If directed by the Architects one coat of chalk and glue shall be applied before application of
white / colour wash at no extra cost.
Colour Wash:
Colour wash shall be prepared by adding mineral colours not affected by lime to white wash. No
colour wash shall be done until a sample of the colour wash to the required tint or shade has been
got approved form the Architects.
Colour wash shall be applied as specified under white wash.
Dry Distemper:
Shade shall be got approved from the Architects before application of distemper.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
41
The surface shall be prepared as specified earlier. A primer coat using approved primer or sizing
shall be applied. Distemper prepared as per manufacturers directions shall be applied and each
coat shall be allowed to dry before subsequent coat is applied. The finished surface shall be free
form chalking when rubbed, even uniform and shall show not brush marks. If additional coats are
necessary, they shall be given at no extra cost.
Oil Bound Distemper:
The surface shall be prepared as specified above. A primer coat of either cement primer or any
approved distemper primer shall be applied.
After the primer coat has dried, the surface shall be lightly sand papered and dusted to make to
smooth to receive distemper.
Distemper shall be prepared as per the directions of the manufacturer and conforming to shade
approved. It shall be applied in specified coats, taking care to allow for drying of each coat before
subsequent coats are applied.
Water-proof Cement Paint:
The surface shall be prepared as specified above and thoroughly wetted with clean water before
water-proof cement paint is applied.
The paint shall be prepared strictly as per manufacturers specifications and in such quantities as
can be used up in an hour of its mixing, as otherwise the mixture will set and thicken, affecting
flow and finish.
The paint thus prepared shall be applied on clean and wetted surface with brush or spraying
machine. The solution shall be kept stirred during the period of application. It shall be applied on
the surface, which is on the shady side of the building so that the direct heat of the sun on the
surface is avoided. The completed surface shall be watered after the days work. Number of coats
shall be s specified in the item.
Painting – Oil / Enamel / Plastic Emulsion etc. :
Ready mixed oil paint, flat oil paint, plastic emulsion paint, ready mixed synthetic enamel paint,
etc., shall be brought in original containers and in sealed tins. If for any reason thinner is
necessary, the brand and quantity of thinner recommended by the manufacturer or as instructed
by the Architect shall be used.
The surface shall be prepared as specified above and a coat of approved primer shall be applied.
After 24 hours drying approved or specified quality paint shall be applied evenly and smoothly. A
filler putty coating may be given to give a smooth finish. Each coat shall be allowed to dry out
thoroughly and then lightly rubbed down with sand paper and cleaned of dust before the next cost
is applied. Number of coats shall be as specified in the item and if the finish of the surface is not
uniform, additional coats as required shall be applied to get good and uniform finish at no extra
cost. After completion no hair marks from the brush or clogging of paint puddles in the corners of
panels, angles or mouldings etc., shall be left on the work. The glass panes, floor etc. shall be
cleaned of stains.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
42
When the final coat is applied, if directed, the surface shall be rolled with a roller of if directed, it
shall be stippled with a stippling brush.
Painting, White washing, colour washing and distempering :
All painting work shall be measured in square meters.
Net area of surface painted shall be measured. No deductions will be made for unpainted
surfaces of ends of joists, beams, posts etc., and opening not exceeding 0.5 sq.m. each and no
additions shall be made for reveals, jambs, soffits, sills, etc., of these openings.
No coefficient will be considered for painting over sponge finished or sand faced plaster.
Area painted over sand cement plaster, sponge finished / sand faced plaster will paid for net
area painted without considering any coefficient for painting over sand faced plaster.
Plastic Emulsion painting on wall & ceiling
General
Plastic emulsion paints are not suitable for application on external wood and iron surfaces and
which are liable to heavy condensation and are to be used generally on masonry or plastered
surfaces. Suitable primer as per manufacturer shall be provided.
Paint
Plastic emulsion paint of approved brand and manufacture and of the required shade as
proposed and approved by Architect/ Engineer in charge shall be used.
Preparation of surface
The surface shall be thoroughly cleaned of dust, old white or colors wash by washing and
scrubbing. The surface shall than be allowed to dry for at least 48 hours. It shall then be
sand papered to give a smooth and even surface. Any unevenness shall be made good by
applying putty, made of plaster of Paris mixed with water on the entire surface including
filling up the undulation and then sand papering the same after it is dry.
Application
The number of coats shall be as stipulated in the item.
The paint will be applied in the usual manner with brush or roller.
The paint dries by evaporation of the water content and as soon as the water has
evaporated the film gets hard and the next coat can be applied. The time of drying varies
from one hour on absorbent surfaces to 2 to 3 hours on non-absorbent surface.
The thinning of emulsion is to be done with water and not with turpentine.
Thinning with water will be particularly required for the undercoat which is applied on
the absorbent surface. The quantity of thinner to be added shall be as per manufacturer‟s
instructions.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
43
The surface on finishing shall present a flat velvety smooth finish. If necessary more
coats will be applied till the surface presents a uniform appearance.
Precautions
(A) Old brushes if they are to be used with emulsion paints
should be completely dried of turpentine or oil paints by
washing in warm soap water. Brushes should be quickly
washed in water immediately after use and kept immersed
in water during break periods prevent the paint from
hardening on the brush.
(B) In the preparation of walls for plastic emulsion painting no
oil base putties shall be used in filling cracks, holes etc.
(C) Splashes on floors etc. shall be cleaned out without delay
as they will be difficult to remove after hardening.
(D) Washing of surface treated with emulsion paint shall not be
done within 3 to 4 weeks of application.
Other Details:
These shall be as per specification for “Painting” as far as they are applicable.
POLISHING AND VARNISHING
French Polishing:
French spirit polish shall be of an approved make conforming to IS: 348. If it has to be prepared
on site, dissolving 0.7 kg shall make the polish. of best shellac in 4.5 liters of methylated spirit
without heating. To obtain required shade pigment may be added and mixed.
Surface shall be cleaned. All unevenness shall be rubbed down smooth with sand paper and well
dusted. Knots, if visible, shall be covered with a preparation of red lead and glue. Resinous or
loose knots and gaps shall be filled with season timber pieces and make level with rest of the
surface. Holes and indentations on surface shall be filled with putty made of whiting and linseed
oil. Surface shall be give a coat of filler made of 2.25 kg. of whiting in 1.5 liter of methylated
spirit. When it dries, surface shall again be rubbed down perfectly smooth with sand paper and
wiped clean.
Piece of clean fine cotton cloth and cotton wool made into shape of pad shall be used to apply
polish. The pad shall be moistened with polish and rubbed hard on the surface applying the polish
sparingly but uniformly and completely over the entire surface. It shall allowed to dry and another
coat applied in the same way. To give finishing coat, the pad shall be covered with a fresh piece
of clean fine cotton cloth, slightly damped with methylated spirit and fubbed lightly and quickly
with a circular motion, till the finish surface attains uniform texture and high gloss.
Wax Polishing:
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
44
Wax polish shall either be prepared on site or obtained readymade from market. Polish made on
the site shall be prepared from a mixture of pure bees wax, linseed oil, turpentine oil and varnish
in the ratio of 2:1.5:1:1/2 by weight. The bees wax and the boiled linseed oil shall be heated over
a slow fire. When the wax is completely dissolved the mixture shall be cooled till it is just warm,
and turpentine oil and varnish added to it in the required proportions and the entire mixture is
well stirred.
Surface shall be prepared as described under French polishing except that the final rubbing shall
be done with sand paper, which has been slightly moistened with linseed oil.
Mixture or polish shall be applied evenly, with a clean cloth pad in such a way that no blank
patches are left, and rubbed continuously for half an hour. When the surface is quite dry a second
coat shall be applied in the same manner and rubbed continuously for an hour or until the surface
is dry. Final coat shall then be applied and rubbed for two hours or more if necessary, until the
surface has assumed a uniform gloss and is quite dry showing no sign of stick ness when touched.
Gloss of the polish depends on the amount of rubbing, therefore rubbing must be continuous and
with uniform pressure and frequent change in direction.
Varnishing:
Surface shall be prepared as described above. After preparation of surface, two coats of clean
boiled linseed oil shall be applied at sufficient interval of time. After the linseed oil has dried two
coats of varnish obtained from approved manufacturer shall be applied at sufficient interval of
time. If the surface fails to produce the required gloss an additional coat shall be applied without
any extra cost.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
45
ADDITIONAL CONDITIONS OF CONTRACT
A GENERAL NOTES:
1. All items of work under contract shall be executed strictly in accordance with the
description of the item in the schedule of quantities, relevant drawings and
specifications read in conjunction with the appropriate Indian standard Specification and
conditions of the contract.
2. The rate for each item of work included in the schedule of quantities shall unless
expressly stated otherwise include cost of:
2.0 All materials, fixing materials, accessories, appliances, tools, plant, equipment,
transport, labour and incidentals required and completion of the work called for in the
item and as per specifications and drawings completely.
2.1 Waste on materials and labour.
2.2 Loading, transporting, unloading, handling / double handling, hoisting to all levels,
setting, fitting and fixing in position, protecting, disposal of debris and all other labour
necessary in and for the full and entire execution and to fully complete the job in
accordance with the contract documents, good practice and recognized principles.
2.3 Liabilities, obligations, and risks arising out of conditions of contract.
2.4 All requirements of specifications, whether such requirements are mentioned in the item
or not. The specifications and drawings where available are to be read as complimentary
to any part of the schedule of quantities and any work called for in one shall be taken as
required for all.
2.5 In the event of conflict between schedule of quantities and other documents including
the specifications the most stringent shall apply and the interpretation of the consultants
shall be final and binding.
3. The Contractor shall be paid for the actual quantity of work executed by him in
accordance with drawings at the contract rates.
4. This schedule shall be fully priced and the extensions and totals duly checked. The rates
for all items shall be fixed in INK. The entries under amount column shall be rounded
off to the nearest Rupee.
5. No alteration whatsoever is to be made to the text of quantities of the schedule of
quantities unless such alteration is authorized in writing by the Consultant / Employer.
Any such alterations, notes or additions shall unless authorized in writing be
disregarded when tender documents are considered.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
46
6. In event of an error occurring in the amount column of the schedule, as result of long
extension of unit rate and quantity, the unit rate quoted by the tenderer shall be regarded
as firm and the extensions shall be amended on the basis of rates.
7. All errors in totaling in the amount, and in carrying forward totals shall be corrected.
8. Unless otherwise stated all measurements shall be taken in accordance with Indian
Standard.
9. Any error (s) in description or in quantity or omission of items from the contract
schedule shall not vitiate this contract but shall be corrected and deemed to be a
variation required by the Consultant / Employer.
10. Rates have been called for a number of items of work, as alternatives which for the
present do not form part of the total value of tender. The rates for these items shall be
quoted, with due care so that in the event of choice of an alternative item of work, the
said rate shall form part of the contract and shall not vitiate the contract in any way.
B DRAWINGS AND DATA:
Within 15 days of placement of order / letter of Intent Contractor shall furnish detailed
working drawings / data for approval of GCSC.
All drawings will be in AUTOCAD 2003 - 2010.
The contractor shall consult specifications, drawings and the bill of quantities, to get the
clear idea for the work.
Guarantee
1. After completion of work, the work must remain under guarantee for a period of one
year.
2. During guarantee, any defect of in workmanship/material that has been supplied as
per this order shall be replaced / repaired free of cost by the contractor.
3. On completion of the work, contractor shall furnish Guarantee bond in the specified
format on stamp paper about the defect liability.
4. Balance security deposit/retention money shall be released only after satisfactory
completion of the defect liability period of one years.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
47
LIST OF MATERIALS OF APPROVED BRAND AND THEIR
MANUFACTUERS
1) Paints:
2) Synthetic Enamel/ Epoxy Paint : Asian, Garware, British Paint,
Johnson Nicholson, Berger, ICI, Nerolac or other GCSC
approved make.
3) Glazing: Triveni Glass Ltd., Indo Asahi Glass Co.Ltd, Saint Gobain,
.Modi, HNG, or other approved make.
4) Marine Plywood: Century, Green Ply, Kitply or any other approved make.
5) Cement: Ultra Tech, A.C.C, Birla, Sanghi, Rajashree & Ambuja or
equally approved make.
6) a) Reinforcement Steel: Tested quality TMT Steel with TMT Mark of RINL, SAIL or
Tisco
b) Structural Steel: RINL, TATA, SAIL
7) Plywood: Century, Green, Kit ply
8) Hard ware Fittings Ozon, Everite,Dunex Ebco, Sterling or Equivalent.
9) Waterproofing material/Polymer : Pidilite, Sika, Choksey or eq. as approved.
10) Flooring adhesive : Balandru, Perma, Pidilite or other approved
make.
11) Glazed Tiles :1st Quality tiles H & R Johnson, Kajaria , Nitco ,
Somany, Pilkington , Orient or other approved make.
12) Ceramic Tiles :Spartek,Kajaria, Naveen, Orient, Johnson , Shon or
other approved make.
(Note: - Where other materials are proposed to be used, these should be approved by the
GCSC / Architect/ PMC).
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
48
MATERIAL TEST
The Contractors will have to take necessary material test (if asked by GCSC) at their own
cost for the supplied materials for the work periodically or as and when required by the
Architects / Consulting Engineer/EIC of GCSC.
The materials should got tested in an approved Laboratory as per IS standard and test
reports in duplicate should be submitted to the Architect‟s Office.
1) Paint material :a) Synthetic paint.
b) Plastic paint.
a) Enamel paint.
b) Primer
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
49
ADDITIONAL GENERAL CONDITIONS
1. CONTRACT PERIOD –
The contract work shall have to be finished within the stipulated time period. Rates quoted shall be inclusive of all current taxes/duties, Service tax, sales tax, VAT,
Royalty and levies. Bidder has to obtain „no due certificate‟ from Royalty Department
and other required statutory clearance certificates.
2. TERMS OF PAYMENT
Payments shall be made on contractor‟s submitted bill after due certification of
PMC/GCSC. Bills become payable after deducting following:
A) Adhoc deductions as recommended by the project office, if any.
B) Income Tax and T.D.S. , Works Contract Tax (Sales Tax) as per Provision of I.T.
Act and Sales Tax Act.
C) Security Deposit & Retention Money.
D) Cost of any service / material provided by the employer.
E) Labour cess and Other deductions as applicable, if any.
The payment to the Bidder shall be released in Indian Rupees by A/c payee cheque only.
3. RECOVERY CLAUSE i) In case of any damage of equipments/machinery due to negligence of contractor
or any other reasons attributed to contractor the decision of Engineer-In-Charge regarding the amount of recovery shall be final and binding. However amount shall be restricted to 10% of the contract value. Recovery will be affected from monthly bills and/or retention money/security deposit.
ii) If the contractor fails to execute the work as per directions of GCSC‟s Engineers
(I/c) within the time frame given, GCSC shall get the work done by third party at
the risk & cost of the contractor.
4. ASSIGNMENT AND SUBLETTING OF THE CONTRACT The contractor shall not assign or sublet any part of the contract to any other party or agency.
5. TERMINATION OF THE CONTRACT
GCSC may terminate the contract after due recoveries of pending jobs/damages after giving 15 days notice to the Contractor, if any of the following event occurs. i. Contractor is adjudged as insolvent.
ii. Contractor has abandoned the contract.
iii. Contractor fails to proceed with the work with due diligence as per the
requirements of the contract.
iv. Contractor has neglected or failed persistently to observe or perform any of
the acts, matters or things, which as per the contract are to be observed and
performed by the contractor. v. Any major contradiction of applicable labour laws etc.
vi. Any other matter irrespective of the contract.
6. INTERPRETATION OF THE CLAUSE In case of any dispute as regards interpretation of any of the clause or specification, the decision of Executive Director (GCSC) shall be final and binding on the contractor.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
50
7. WORKMEN’S COMPENSATION INSURANCE The Contractor shall take all Risk Insurance Policy to cover all his workmen, staff applicable under the Workmen‟s Compensation Act, 1923 or any amendment thereof, as also insurance cover for third party liability. The Contractor shall keep GCSC indemnified from all liabilities arising out of his action in pursuance in this contract. The W.C. Policy should be obtained from Ahmedabad Jurisdiction and shall be assigned to GCSC.
8. STATUTORY REQUIREMENTS
The Contractor has to fulfill the statutory compliance of labour laws.
8.1 Wages to be Paid and time of Payment etc by the Contractor:
A. The Contractor shall pay minimum of wages per day fixed under the Minimum
Wages Act. The wages of every contract labour employed by him under this contract shall be paid him before the expiry of 7
th day of the last day of the
month in respect of which the wages are payable (i.e. Wages of a month have to be paid by him in the first week of the next month).
B. The contractor shall give his telephone number and address to GCSC so that in
case of troubles etc. information can be made. The contractor shall arrange
to have his office outside the premises and the contractor keep himself
present through out of working hours.
8.2 Labour Laws:
Contractor shall follow all labour laws for payments, working etc as specified by Labour
department, Government of India.
8.3 Maintenance of registers and records:
The contractor shall employ adequate number of experienced staff at site for daily
supervision and for maintenance of various registers and records required under the law
and contract. No payment for supervision shall be admissible.
a) The contractor shall be solely responsible for any accident to his workers
and should adhere to all the rules / regulations as per Labour law of Government
and other statutory laws as applicable.
b) The Contractor should register himself under the Contract labour Act,
Workmen‟s compensation Act and PF Act (Code No. to be mentioned) and
submit the copy of registration certificate and should possess the same from the
date of commencement of work, failing which the contract is liable to be
cancelled.
c) Contractor will have to insure his workmen/ supervisor under the group
insurance scheme, so that there will not be any problem after any accident and it
may also cover the liability under the Workman Compensation Act.
d) All Contractor‟s employees should maintain due discipline and respect local
sentiments. GCSC reserves the right to direct the Contractor for suitable actions in
respect of such persons who do not comply above requirement.
9. TOOLS & TACKLES & INSPECTION INSTRUMENTS/EQUIPMENTS For proper maintenance of the plant, the contractor is required to maintain and make
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
51
available all tools & tackles in good working condition at the site. The Contractor is also required to maintain and make available all instruments/equipments required for proper performance of the contract. Any additional tools & tackles, required for work/job shall be arranged by the contractor immediately with no extra cost to GCSC.
10. GENERAL TERMS AND CONDITIONS OF THE CONTRACT (GTCC)
1. All tool and Tackles to execute the contract are in the scope of the contractor. The
contractor should ensure that tools are in healthy condition.
2. Provision of scaffolding material for maintenance work will be in the scope of the
contractor. The scaffolding shall be with pipe and clamps, metallic jalies etc.
3. The decision of the E-I-C shall be final and binding on the contractor for defining the
terms and conditions included in this contract.
4. Inspection of work may be done at any time by E-I-C or his authorized representative.
If work is not found satisfactory E-I-C reserves the right to take suitable action.
5. The contractor shall be required to furnish satisfactory job completion report in
approved format to GCSC.
6. Irrespective of inspection, repair and approval of intermediate stages of work contractor
shall be responsible of making good any defects found during final
inspection/guarantee period/defect liability period.
7. If any equipments or part are found damaged due to negligent / faulty
maintenance of the equipment, cost of such damages shall be recovered from
the contractor‟s bill / retention money/ security deposit.
8. Contractor has to do quality job as per specifications and directions of EIC. No
negotiation shall be made in execution of contract work. In case of poor quality of the
work the contractor may be asked to rework the job and for that no extra cost will be
made.
9. Time schedule given is the standard time required for respective activities of work
as mentioned.
10. GCSC will provide the open free space at appropriate place in plant area suitable for
keeping tools and tackles and for making temporary office. On expiry of contract,
contractor shall have to clean & vacate the premises immediately after it; otherwise the
rent will be recovered as concluded by GCSC.
11. Arrangement of lighting at the work spot has to be made by the contractor. He has to
arrange lighting equipment such as power cable, hand lamps etc. The Contractor has
to take prior approval for taking electrical power supply.
12. Bidder should visit the site to understand and familiarize themselves thoroughly with the
site condition / equipments and system before quoting and submitting the tender.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
52
13. Rates quoted should be firm throughout the contract period. No price escalation will be
counted for billing purpose.
14. The contractor has to take group insurance policy for their workmen. The contractor has
to submit labor license and PF account number to the engineer in charge before start the
work.
15. Safety: Contractor shall be solely responsible for the safety of his workmen. He shall
ensure that no damage to the equipment is caused by him or his workmen. He shall
abide by the safety rules and regulation as per exiting law. He shall provide personal
protective equipment to his workmen and shall ensure safe working conditions
and precautions while working atheights and hazardous condition. In case of
violation of safety norms, rules & regulation, E-I-C is authorized to remove the
person or equipment if it felt as safety hazard and may take necessary action against
the Contractor.
STATUTORY INSPECTIONS, PERMISSIONS, LICENSES:
The contractor shall be fully responsible for meeting all the statutory obligations and local inspectorates
pertaining to the works carried out by them including items supplied by owners. The contractor should prepare
all working drawings and obtain approval of competent authorities and also have the equipment and
installation inspected and got approved. All official fees will be paid by clients directly against demand in
writing from the appropriate authority and all other expenses for submission and approval of the various and
relevant statutory / bodies shall be embodied in the tender prices. The contractor will also be responsible for
load sanction from appropriate authorities.
SAFETY PRECAUTIONS:
A competent and authorised supervisor shall be on the site whenever the contractor‟s men are at work. The
supervisor should ensure that all plant and machinery used on the site are rendered safe for working and meet
with the Indian or International safety standards applicable for the use and operation of such machinery. The
supervisor should also ensure that the workmen are supplied with and made to use safety appliances such as
safety belts, life lines, helmets etc.
Smoking shall not be encouraged on the site but altogether strictly prohibited in area where combustible and
inflammable goods / materials are stored or lying about.
And hot job such as welding, soldering, gas cutting shall not be carried out without the permission of the
Engineer – in – charge. Such jobs shall not be carried out where inflammable materials are stored or lying
about. All electric connections shall be through adequately sized mechanically protected cables without any
joints and with proper and adequate terminals. All power supplies shall be through properly rated fuses with
isolating devices. No such hot jobs shall be carried out on holidays and without the presence of the Contractors
Supervisor.
It is entirely the responsibility of the Contractor to practice the principles of “Safety First” during the entire
tenure of work with adequate insurance. Covering injury or death to workmen, loss by theft or damage to
materials and property in position or not and third party.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
53
The contractor should clear the site of all debris every day to avoid accidents. In case this is not done, the
owners may engage necessary labour to maintain the cleanliness of the premises, and removal of debris, and
debit all or part of the expenditure so incurred the contractor/s.
SPECIFICATIONS FOR INSTALLATION:
1. Electrical installation work shall be carried out only by Licensed Electrical Contractor.
2. The Contractors shall supply all supervision, labour, tools and tackles, materials and hardware etc. as
required and necessary for the erection assembly of the equipment covered herein.
3. Transportation to site, unloading, moving to actual location, assembly, erection wiring and connections,
checking, testing and commissioning of all equipment supplied shall be included in the quoted price.
4. The contractors shall employ skilled labour duly certified and licensed by competent authority for the
electrical work. A qualified, experience supervisor duly authorised to received instructions shall be placed
at site.
Note:- All material shall be approved prior to procurement. Other makes (if suggested),
shall got approved by Architect/PMC/GCSC.
Signature of Contractor Executive Director
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
54
Name of Work: - Painting work for Thrill ride, Musical fountain, energy park
& various toilet blocks, at science city, A’bad
DETAIL SPECIFICATIONS
1) Material shall be of best-approved quality, make as approved and they shall comply
with the respective Specification.
2) All material shall got approved before supply and the approved make shall be
supplied as directed.
3) If directed, materials shall be tested by GCSC for its specification and quality.
4) It shall be obligatory for the Contractor to furnish certificate, if deemed by GCSC,
from manufacturer or the material supplier that the work has been carried out by
using their material and as per their specified procedure.
5) All materials and parts supplied by the Employer / any other Specialist Firms shall be
properly stored and the Contractor shall be responsible for its quality and
performance.
6) Unless otherwise shown in the documents or mentioned in the “Schedule of
Quantities” or special specification, the quality of materials, workmanship,
dimensions, etc., shall be as specified as hereunder.
7) All equipment and facilities for carrying out field tests on materials shall be provided
by the Contractor without any extra cost.
8) The work shall be done in such a manner that no damage to the existing structure or
property may occur, else the same shall be rectified by the contractor at his own cost.
9) The curing shall be followed as per requirement and directed by EIC to be carried out
by the contractor, after completion of the work of cement items or flooring.
10) All general specification of the item as under shall be followed for methodology of
working.
11) The paint material- enamel paint, plastic paint, exterior paint etc shall be of best
make. Work shall be carried out as directed by GCSC as per manufacturer‟s
specifications. The approved make shall be Pidilite, Sika, Choksey or eq. as approved
by GCSC.
12) Contractor shall be responsible to get insurance of their labour working at the site.
Additional insurance and care shall be taken by the contractor for working at higher
heights. Agency shall take all the precautions to avoid any accident during the
working with respect to scaffolding, equipment and machineries. Safety belts shall be
used for working at such heights. All the responsibilities shall be taken by contractor.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
55
DETAIL ITEM SPECIFICATIONS
(ADDITIONAL SPECIFICATIONS)
Item No. 1 – Providing and applying two coats of plastic royal approved make Paint with
a coat of primer and three coats of lapi on walls. Surface preparation shall be made prior
to application of above treatment by brushing to remove all dirt and remains of loose
powdered materials as directed as per drawings/ details, specifications and instructions of
the engineer-in-charge/company.
The work is to be carried out for painting of hall of space building. The work is to be
carried out with due prior cleaning / wire brushing of the wall or any surface for removal
of previous paint, lumps, droppings etc. No powder or loose material shall remain on the
surface to be painted. The surface should be thoroughly dry to receive coat of primer and
lapi work. Only the approved make lapi shall be used for wall finishing so that no
undulation remains and surface be perfectly vertical with sharp edges in proper
alignment. The additional coat of lapi finish and primer shall be applied on requirement
of the surface. After completion of the base coat of lapi and primer, systematic
application of plastic paint on the wall/surface shall be carried with due care of protection
of existing floor, exhibit machineries, light and other electrical fixtures or other painted
surfaces. Contractor shall give sample paint work for shade/ workmanship etc at specified
place for approval of GCSC and after its acceptance the work shall be initiated.
Contractor shall arrange for all necessary material for application like rollers, various size
brushes, turpentine, floor coverings etc. as required at site of work. Proper time interval
shall be kept between various coats as directed. The final surface should exhibit proper
uniform shade to match with other surfaces else it shall be reworked. On completion of
the work, the site shall be cleared of debris and stains etc to make it as per original as
directed. All general specifications of the tender document shall be followed strictly. The
work shall be carried out as directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 2 - Wall painting (two coats) with plastic emulsion paint of approved brand &
manufacture on under coated wall surface to give an even shade including thoroughly
brushing to free from mortar droppings and other foreign matter and sand papered
smooth.
All detail specification of the above Item No-1 shall be followed for the work except
application of the work as specified in the item description. Sample preparation shall be
done prior to application for approval of EIC. The final surface should exhibit proper
uniform shade to match with other surfaces else it shall be reworked. On completion of
the work, the site shall be cleared of debris and stains etc to make it as per original as
directed. All general specifications of the tender document shall be followed strictly. The
work shall be carried out as directed by EIC.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
56
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 3 - Finishing wall with weather proof exterior emulsion paint on wall/floor
surface (two coats) to give required shape even shade after thoroughly brushing the
surface to remove all dirt, and remains of loose powdered materials.etc complete.
Terracota shade.
The surface shall be prepared for painting by removing all loose material, carrying out
patch work with rich cement mortar as directed by GCSC to exhibit proper floor surface
to match with surrounding floor. It shall be cured for period as specified by EIC. All
loose material shall be properly broomed to clear all debris. Approved exterior paint like
apex ultima- weather proof coat shall be applied on the floor. Sample shade shall be
applied for approval of GCSC to match with surrounding surface. All detail specification
of the above Item No-1 shall be followed for the work except application of the work as
specified in the item description. The final surface should exhibit proper uniform shade to
match with other surfaces else it shall be reworked. On completion of the work, the site
shall be cleared of debris and stains etc to make it as per original as directed. All general
specifications of the tender document shall be followed strictly. The work shall be carried
out as directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 4 Painting two coats (excluding priming coat) over previously painted column
surfaces with enamel paint, brushing, interior to give an even shade including cleaning
the surface of all dirt, dust and other foreign matter.
All detail specification of the above Item No-1 shall be followed for the work except
application of the work as specified in the item description with use of proper enamel
paint as approved by GCSC in terms of make grade etc. Sample preparation shall be done
prior to application for approval of EIC. The final surface should exhibit proper uniform
shade to match with other surfaces else it shall be reworked. On completion of the work,
the site shall be cleared of debris and stains etc to make it as per original as directed. All
general specifications of the tender document shall be followed strictly. The work shall
be carried out as directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
57
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 5 Providing exterior painting work with Apex ultima or Equivalent approved
exterior Paint on wall surface with two coats of an approved brand manufactures and of
required shade after thoroughly brushing the surface to remove all dirt and pertains of
loose powdered materials, with all material, labour, taxes, scaffolding complete. For all
heights of the building surfaces.
All detail specification of the above Item No-1 shall be followed for the work except
application of the work as specified in the item description with use of proper exterior
paint as apex ultima or eq. as approved by GCSC. Sample preparation shall be done prior
to application for approval of EIC. The final surface should exhibit proper uniform shade
to match with other surfaces else it shall be reworked. The rate is for painting of all
exterior walls of building having height about 15M or more. Contractor shall arrange for
proper scaffolding work to make platform for painting as required. On completion of the
work, the site shall be cleared of debris and stains etc to make it as per original as
directed. All general specifications of the tender document shall be followed strictly. The
work shall be carried out as directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 6 Applying priming coat over plastered wall surfaces after including preparing
the surface by thoroughly cleaning oil, grease, dirt and other foreign matter, sand
papering & knotting ready mixed paint, brushing with wall primer at all heights to make
ready the surface for coats of paint.
All detail specification of the above Item No-1 shall be followed for the work except
application of the work as specified in the item description with use of proper wall primer
to receive coat of plastic paint as approved by GCSC, in terms of make grade etc. The
final surface should exhibit proper uniform shade/layer else it shall be reworked. On
completion of the work, the site shall be cleared of debris and stains etc to make it as per
original as directed. All general specifications of the tender document shall be followed
strictly. The work shall be carried out as directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
completion of the work, the site shall be cleared of debris and stains etc to make it as per
original as directed. All general specifications of the tender document shall be followed
strictly. The work shall be carried out as directed by EIC.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
58
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Item No. 07 Providing & fixing scaffolding using bamboos, wooden supports, flats etc to
enable painting work of Auditorium 1 & 2 walls , planet earth toilet block walls for hight
more than 3 m .` Following code of practice shall be followed.
IS 4014 Code of practice for steel tubular scaffolding.
(Part 1 & 2)
The scaffolding work shall be designed properly to take all loads during execution of the
work. Preferable scaffolding shall be done with H frames with different sizes. The
platform erected shall be of sufficient thickness so that no deflection may occur. All
members shall be connected with proper tie using steel wire or strings with sufficient
number of overlaps. The work shall got approved prior to commencement of the work on
it. Proper tie shall be provided with the building members to avoid any sliding and undue
stresses in structure. All general specifications of the tender document shall be followed
strictly. On completion of the work, the site shall be cleared of debris and member
wastages etc to make it as per original as directed. The work shall be carried out as
directed by EIC.
The measurement of the work shall be on Square meter basis of dimension of the area of
work done.
Signature of Agency Executive Director
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
59
GUJARAT COUNCIL OF SCIENCE CITY (A Government of Gujarat Society)
PRICE BID
Painting work for Thrill ride, Musical fountain, energy park & various toilet blocks,
at science city, A’bad.
Gujarat Council of Science City Village Hebatpur, Sola Santej Road,
Nr. Science City Cross Road, Off Sarkhej Gandhinagar Highway, Ahmedabad -380060
Phone: 91-79-55222127, 28 Email: [email protected] Website: - www.scity.gujarat.gov.in
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
60
Sr.
No. Item Per Qty Rate Amount
1 . Providing and applying two coats of plastic royal
approved make Paint with a coat of primer and three
coats of lapi on walls. Surface preparation shall be
made prior to application of above treatment by
brushing to remove all dirt and remains of loose
powdered materials as directed as per drawings/ details,
specifications and instructions of the engineer-in-
charge/company. Sq.mt 500
2 Wall painting (two coats) with plastic emulsion paint of
approved brand & manufacture on under coated wall
surface to give an even shade including thoroughly
brushing to free from mortar droppings and other
foreign matter and sand papered smooth Sq.mt 1200
3 Finishing wall with weather proof exterior emulsion
paint on wall/floor surface (two coats) to give required
shape even shade after thoroughly brushing the surface
to remove all dirt, and remains of loose powdered
materials.etc complete. Terracota shade. Sq.mt 1600
4 Painting two coats (excluding priming coat) over
previously painted column surfaces with enamel paint,
brushing, interior to give an even shade including
cleaning the surface of all dirt, dust and other foreign
matter. Sq.mt 3000
5 Providing exterior painting work with Apex ultima or
Equivalent approved exterior Paint on wall surface
with two coats of an approved brand manufactures and
of required shade after thoroughly brushing the surface
to remove all dirt and pertains of loose powdered
materials, with all material, labour, taxes, scaffolding
complete. For all heights of the building surfaces. Sq.mt 3200
6 Applying priming coat over plastered wall surfaces
after including preparing the surface by thoroughly
cleaning oil, grease, dirt and other foreign matter, sand
papering & knotting ready mixed paint, brushing with
wall primer at all heights to make ready the surface for
coats of paint. Sq.mt 500
7 Providing & fixing scaffolding using bamboos, wooden
supports, flats etc to enable painting work of MS
Girder, Earthstation walls, staircase walls etc at level
more than 4 M. Sq.mt 1700
Total Amount Rs.
BOQ
Painting work for Thrill ride, Musical fountain, Energy park & Various toilet blocks at science city A'bad.
61
Notes :-
The rates shall be inclusive of all material, labour, quality testing,
installation work at all heights at site, taxes, carting complete as directed.
Quantities may vary depending upon GCSC requirements.
Only the approved brand as directed by GCSC shall be supplied by the
agency .
Prior approval of EIC regarding quantities and make, shade, texture etc
shall be taken before material procurement for present work.
The complete work shall got verified by contractor to EIC and any defect
or snag shall be cleared immediately.
The work shall provide guarantee for period of not less than 1 years
which shall be considered as defect liability period.
Signature of the Contractor with stamp Executive Director