1135VRV Air Condition

8/17/2019 1135VRV Air Condition

1/14

P a g e | 1

TENDER

FOR

SUPPLY, INSTALLATION, TESTING & COMMISSIONING OF

VRV/VRF TYPE AIR-CONDITIONING SYSTEMFOR KIDNEY TRANSPLANT UNIT

TENDER NO.1796 / RMLIMS/EE DATED: 04.07.2015

(a) Last date for submission: 20.07.2015 upto 5:00 PM(b) Date of opening of Tender: 21.07.2015 at 11:30 AM.(c) The technically qualified bidders will be informed to be present at the

time of Price-bid opening.

Tender cost is Rs. (500 + VAT@5%)

Dr. Ram Manohar Lohia Institute of Medical Sciences,

Vibhuti Khand, Gomti Nagar, LucknowPhone No. 0522-4918504, 4918512 Fax No.- 0522-4918506

Website:www.rmlims.in


2/14

P a g e | 2

Short Term Tender Notice

Ref. No. 1796 /RMLIMS/EE Dated: 04.07.2015

Sealed tenders are here by invited in two bid system from manufacturers/Authorised

dealers for the work mentioned hereunder:-

Name of the Work: Supply, Installation, Testing and Commissioning of VRV/VRF AirConditioning system and associated electric work executed on turnkey basis in Kidneytransplant unit at 4th F of Main Hospital Building.

Tender fee: Rs.500/-+VAT@5% (Non-refundable)

EMD: Rs. 30000.00

Period of downloading tender document: 06.07.2015 to 17.07.2015

Last Date of Submission of tender: 20.07.2015 up to 5.00 pm

Date of opening of tender: 21.07.2015 at 11.30 am

The detailed NIT and tender documents can be seen /downloaded from thewebsite: www.rmlims.in. Dully filled tender documents shall be sent to the Director,Dr. Ram Manohar Lohia Institute of Medical Sciences, Vibhuti Khand, Gomti Nagar,Lucknow- 226010 by registered/speed post only.

Director reserves the right to accept or reject any or all applications or cancel the tenderwithout assigning any reason.

Director


3/14

P a g e | 3

DETAILS OF NOTICE INVITING TENDER

1. Competitive sealed tenders are hereby invited by the Director, Dr. RMLIMS, GomtiNagar, Lucknow from the reputed manufacturers or their authorised dealers of VRV/VRFAir Conditioning system and associated electric work executed on turnkey basis inKidney transplant unit of Main Hospital Building. The bidders must have proper and

regular “After Sales Service” outlet at Lucknow.

2. Minimum eligibility criteria/ Experience: - The bidder should have satisfactorilycompleted at least one works of similar nature costing not less than 15.00 Lakh duringthe last three years with any Central Government Organisation /public sectorUndertakings/state Government or local Bodies. The successful completion certificateissued by client should contain date of start, date of completion, value on completion

etc. Similar works means Design, supply & Installation of VRF/VRV Air conditioningsystem.

3. The tender documents can be seen/ downloaded from our website: www.rmlims.in.

4. Tenders received without tender cost and EMD will be invalid.

5. The entire supply and installation should be completed within 02 months (two months)of releasing purchase/work order.

6. The tenders will be in two-bid system. Part–I shall be superscribed as “TechnicalBid” (Annexure-II) and shall contain the following.

i) Tender fee of Rs.500/-+VAT@ 5% (Non-refundable) by the way of demand draft of aNationalised/scheduled bank and drawn in favour of Finance Controller, Dr. RMLIMS,Lucknow

ii) Earnest Money Deposit (EMD) of Rs.30000/-. (Refundable) by the way of D.D. of aNationalised/scheduled bank and drawn in favour of Finance Controller, Dr. RMLIMS,

Lucknow.iii) Sales Tax/VAT registration No. (Please enclose certificate)

iv) PAN card Number. (Please enclose certificate)v) Tender documents complete including Notice Inviting Tender duly signed & stamped(each page).Unsigned and unstamped Tenders will not be accepted.vi) Copy of the Latest ITR.

vii) Copy of certificate for manufacturer/authorized dealer (please attached relevantcertificate).viii) Proof of experience (Work Completion) during last three years as described above.

All the documents (i to viii) to be placed in a sealed envelope and marked as Part I-Technical Bid.

7. Part-II should be superscribed as “Price-Bid” (Annexure-IV) and should containonly the Agencies quoted rates in the given format. Envelope of Part–II will be openedonly if the Committee constituted by Director, Dr RMLIMS, Lucknow is satisfied with the

technical bid (Part–I), which will be opened first.

8. Both the Part I and Part II shall be placed and submitted in another Envelope superscribed “Tender for Supply, Installation, Testing & Commissioning of VRV/VRF Air-Conditioning System and associated electric Work in KTU of Main Hospital Building” andaddressed to the Director, Dr. RMLIMS, Vibhuti Khand, Gomtinagar, Lucknow (UP)-226010.

9. The EMD will be returned to the tenderer if his/their tender is not accepted by theInstitute. The EMD paid by the successful tenderer shall be held by the Institute assecurity for execution and fulfilment of the work. No interest shall be paid on this

http://www.rmlims.in/http://www.rmlims.in/http://www.rmlims.in/http://www.rmlims.in/


4/14

P a g e | 4

deposit. This security deposit shall be forfeited if he/they fail to comply with any of theconditions of the Contract.

10. SUBMISSION OF TENDERS: The duly completed tenders will be sent to theDirector, Dr.RMLIMS, Vibhuti Khand, Gomti Nagar, Lucknow by registered/Speed postonly and reached in the office upto 5:00pm on 20.07.2015 . This will be opened on thenext day 21.07.15 at 11.30 am; Bidder/Authorised representative of bidders may attend

the bid opening.

11. Dr. RMLIMS, Lucknow will not be responsible for any postal delay.

12. The successful agency shall execute an agreement on a stamp paper of requiredvalue for due performance of the contract within a week.

13. Before submitting the tender, please go through the all Terms and Conditions onwhich the work will be awarded and shall be executed by the successful tenderer.

14. Tenders submitted shall remain valid for 90 days from the date of opening for thepurpose of acceptance and award of work, Validity beyond 90 days from the date of

opening shall be by mutual consent.

15. Before tendering, the tenderer shall inspect the site to fully acquaint himself aboutthe conditions in regard to accessibility of site, nature and extent of ground workingconditions of site and locality including stacking of materials, installations of tools &plants etc., conditions affecting accommodations and movement of labour etc. required

for the satisfactory execution of the work. No claim whatsoever on such accounts shallbe entertained by the Institute in any circumstances.

16. Except writing rates and amount, the tenderer should not write any conditions ormake any changes, additions, alterations and modifications in the printed form oftenders, desire to offer rebate, the same should be brought out separately in the

covering letter and submitted along with the tender.

17. The Director, Dr. RMLIMS, Lucknow reserves the right to accept or reject any or alltender bids without assigning any reasons whatsoever and his decision will be binding onall the parties.

Director


5/14

P a g e | 5

General Terms and Conditions

1. The bidder must be either sole Manufacturer or the authorized dealer of the VRV/VRFAir conditioning system. In the case of authorized dealer, certified copy of authorizationissued by the OEM should be enclosed with the tender.

2. Details / Scope of work executed on turnkey basis: -

Sr.No.

Items Description Unit Qty Size of Rooms

Variable Refrigerant Volume/Flow System (Manufacturer:

Daikin/Mitsubishi Electric/O-General/Trane)

1.

Hall/Ward-

101 Sqm

2. Room no.1-

12 Sqm

3.

Room no.2-11 Sqm

4. Room no.3-

10 Sqm

Supply of Inverter Based variable refrigerant volume/flow modulartype air-conditioning system of R410A having combination of allInverter based DC Scroll compressor and having following items:

1 Supply & installation of Outdoor Units

1.a 16 HP Nos. 1

1.b Connection Kit Nos. 1

2 Supply & Installation of Indoor Units 2.a Cassette Type Units: 3.3 Tons Nos. 3

2.b Cassette Type Units: 1.65 Tons Nos. 1

2.c Cassette Type Units: 1.08 Tons Nos. 2

3 Supply & installation of Corded Remote Controls Nos. 6

4 Supply & installation Imported Refrigerant Joints Nos. 5

5 Refrigerant Charging

Commissioning Charges and topping up Gas job. 1

6 Refrigerant Piping & Slotted angle support

Interconnecting refrigerant pipe work suitable for refrigerant with(19mm/13 mm thick) closed cell elastomeric nitrile rubbertubular insulation between each set of indoor & outdoor units. Allpiping inside the room shall be properly supported with MShanger and all external piping shall run in covered 1.6 mm thickG.I tray along with support and base frame (all outside piping-Exposed insulation with UV Coating protections).

6.a 28.6 mm O.D. (insulation : 19 mm) with slotted angle Rmt. 25

6.b 22.2 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 206.c 19.1 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 406.d 15.9 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 606.e 12.7 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 406.f 9.5 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 206.g 6.4 mm O.D (insulation : 13 mm) with slotted angle Rmt. 607 Drain Piping

Providing and fixing rigid PVC piping complete with fittings,

supports as per norms and duly insulated with 6 mm thick closedcell nitrile rubber insulation. 7.a 40 mm dia with slotted angle Rmt. 25

7.b 32 mm dia with slotted angle Rmt. 100

8 Power Cabling & Earthing

Providing and fixing PVC sheathed 10 sqmm (4core) copper cablefor ODU & IDUs through walls/ceiling with appropriate clamps &fixing arrangement as per site requirements complete withEarthing as per requirement on site and as per given bellow.i) 4 core 10 sqmm copper cable 80 Rmt. for ODU & 80 Rmt. 4sqmm wire for Earthingii) 3 core 2.5 sqmm copper cable 150 Rmt. for IDUs

Lot. 1

9 Transmission Wiring

Providing & fixing control cum transmission wiring of 2 core x 1.5

Sqmm copper in suitable conduits between indoor and outdoorunits.

Rmt. 100


6/14

P a g e | 6

10 Controller Wiring

Providing & fixing control wiring of 2 core x 1.5 Sqmm copperbetween indoor units and their wired remotes.

Rmt. 60

11 Electric Panel for ODU & IDUs

Supply & installation of electrical distribution/panel board cubiclecompartmentalised wall mounted made of 2.0 mm thick steel sheetduly painted complete with, incoming outgoing feeders CTscontactors, incoming MCCB, outgoing MCCB/MCBs as perrequirement complete in all respects.

Lot. 1

3. Prices: - The rate quoted should be F.O.R. at Dr. RMLIMS in rupees & inclusive of alltaxes & charges e.g. packing, forwarding local taxes, railway freight and transitinsurance. Escalation in prices will not be payable for any reason whatsoever throughoutthe contract period.

4. Payment Schedule: (i) 80% (Eighty Percent) of the contract value shall be released on delivery and due

installation of the Air conditioning along with all the associated items given in theSchedule of Quantities including any other item which is required to complete thesystem.

(ii) Further 20% (twenty Percent) of the contract value shall become payable on thesuccessful testing, commissioning and handing over the system and submission ofPBG/FDR of 10% of contract value for warranty period one year.

(iii) Income tax may be deducted by the Institute as per rules

5. Facilities for Test & Examination:- If the material supplied by the manufacture/supplier or performance of the material and/ or stores during inspection and tests is notfound satisfactory, the Institute reserves the right at his discretion and without any claimfor compensation to the Contractor, either cancel the order altogether or modify thequantity ordered.

6. WARRANTY FOR PRODUCT PERFORMANCE:Items shall be under minimum warranty for a period of one year from the date ofsuccessful installation. The contractor shall replace any defective goods free of charge orthe repair of defective goods/stores within the warranty period.

7. Time of completion:- The entire supply and installation should be completed within 02 months (two months) of releasing purchase/work order

8. Compensation for delay: - Charged 0.5% of total amount per week or part of the

week for the delayed period.

9. Acceptance of Offers: - Order will be placed after the tender has been examinedand negotiations with the tenderer, if considered necessary, have been completed. The

purchaser may accept the tender for a part or whole of the quantity offered or reject thesame without assigning any reason.

10. CAMC (Comprehensive Annual Maintenance Contract):- Institute reserves theright to enter into CMC of VRV/VRF Air conditioning system after warranty period andbidder should be furnish price schedule of CMC (General terms and conditions for CMCmentioned in Annexure-I)

11. ELECTRICAL WORKS: - Power supply will be provided at the ODU by the successfultenderer. Cabling work (i.e. from main electrical panel of the floor to ODU & indoor unitsetc.) is in the scope of the tenderer.


7/14

P a g e | 7

12. SPACE FOR OUTDOOR UNITS:-Suitable space to install the ODU shall be provided by the Institute as required.

13. Losses or damage in transit will be borne by the Bidder. The bidder may, if he sodesires, get the goods insured and include such charges in the tendered rate.

14. Warranty certificate against all the items developed defects covering warranty

period, shall be given at the time of handing over the air conditioning system.

15. During the warranty period whenever the firm is called upon to attend the

rectification of the defects/faults in the consignments or replacement, the firm shallattend the complaint immediately on same day.

16. Failure to comply with all the terms and conditions mentioned in the tender beingsummarily rejected. Conditional tenders will not be accepted.

17. OTHER CONDITIONS:-

a) Quantities mentioned under BOQ are approximate only. So the successful biddershould supply items listed in this section as and when required during the execution of

the work. The payment will be made only for actual/supply/executed/utilized quantities& labour at the site.

b) The contractor shall supply the technical literature, maintenance schedule andoperation manual of the equipment for the record and reference of Institute.c) Contractor should take care of workers safety and discipline while carrying out the

job. All the required safety equipment have to be provided to workers by the contractor

during the work. Institute will not be responsible for any casualty or incidents.d) Contractor must comply all the statutory provisions as per the Govt. of India rulesand act applicable for executing such jobs.

e) Proper electrical safety will be exercised during the work and all the personnelprotective equipment and tools like helmets’, gloves, safety belts, shoes etc. Will beprovided by the contractor during the work at his own cost.

f) Contractor will ensure proper cleaning of site and hygiene during the work on regularbasis.g) The work quality should be high and the workmanship must be in accordance with thebest engineering practice to ensure the satisfactory performance of the systemthroughout the service life.h) Contractor has to submit the completion certificate with all the required reports andapprovals at the end of work.i) All legal and other statutory responsibilities regarding securities of materials, labour,payments, accident, insurance and law suits during the work will be solely borne bycontracting agency and Dr. RMLIMS shall not be responsible in any manner whatsoever.The contracting agency will ensure proper and disciplined behaviour of the workman. Ifany damages are caused by the contracting agency to the property to the Institute, the

same shall be recovered from contracting agency’s bill. j) All the items covered in the schedule of the requirements, shall carry minimum oneyear’s onsite Comprehensive guarantee, and commence from the date of completion of

entire job. The after- sales service support/ warranty services has to be provided at Dr.RMLIMS. The repairing/rectification, if any of the items under warranty must be done atsite only within 24 hours. Prompt and efficient after sales service must be free within thewarranty period.k) Wherever required, the contractor shall prepare and produce instruction, operationand maintenance manuals in English for the use, operation and the maintenance of thesupplied equipment and installations, and submit to the Engineer-in-Charge (i.e. hard &

soft copies for each equipment) at the time of handing over.

18. Arbitration: Any dispute or difference under or arising out in respect of theagreement/purchase/supply order be referred to the Director of the Dr. RMLIMS,

Lucknow or his authorised representative as sole arbitrator and the decision of the sole


8/14

P a g e | 8

arbitrator on the matter in dispute shall be find and binding on the both. The arbitrationshall be carried but as per Arbitration Act & Rule 1996 made there under as amendedform time to time.

19. Jurisdiction: In case of any dispute, arising out of this tender shall be subject tothe Jurisdiction of "The Courts in Lucknow".

Place: Lucknow Signature of the ContractorDate: Name & Seal of the firm


9/14

P a g e | 9

Annexure-ICOMPREHENSIVE MAINTENANCE OF AIR-CONDITIONING SYSTEM

AFTER WARRANTY PERIOD.SCOPE OF WORK:1. The work shall be carried out as per OEMs.2. Regular inspection of the VRV/VRF system should be carried out at least once in a

month by the service provider.3. The complaints received should be attended within 4 hours of their receipts where asmajor repair like replacement/repair of compressor, gas charging, replacement of fan/

blower motor shall have to be rectified within 48 hours failure to do so a penalty of Rs.1000/- per day.4. All the preventive and breakdown maintenance work done should be recorded inservice report and be deposited in Institute.5. In addition to breakdown maintenance, the agency shall carry out monthly preventiveMaintenance of VRF system & submit the report to department accordingly.6. Half yearly payment shall be released to the contractor.

7. 5% performance guarantee will be taken before commencement of CMC work fromthe contractor.

8. Income tax, work contract tax would be deducted as per rule whenever required.9. CAMC will be awarded initially for one year and will be renewed every next year if

services of agency found satisfactory. (or as per recommendation of OEMs)10. The contractor shall arrange all the materials, labour etc. required for the work.11. The contractor should quote his rates including service tax and other taxes.12. The comprehensive maintenance contract includes electrical and electronic system

components and accessories repair/ replacement of all faulty parts/ spares parts fromMain electrical panel to ODU, IDU, Inline Fans including electronic, electrical andmicroprocessor based controls and displays, remote controls, cables and wires etc. not

limited to the same.13. The comprehensive maintenance contract includes Mechanical System componentsand accessories repair/ replacement of all faulty parts/ spares parts such as

compressors, refrigerant circuits, ducting, drain lines, copper tubing along withinsulation, fans etc. not limited to the same.14. All the spares, consumables and materials required for breakdown works/preventivemaintenance works/overhauling of the above equipment’s are covered under the CAMC.15. Spares and consumables are to be used of manufacturers make or recommendedmakes.16. Special care and attention be given to ensure that no damage is done to the

equipment in terms of: -

Usage of eco-friendly chemicals/cleaning agents for de-scaling/coil cleaning etc.Every breakdown /preventive maintenance service shall be followed by necessary

Service Report indicating details of consumables/spares used separately. Compressors units shall be replaced with either Factory new compressors of the

same make in case of requirement. In case, the insulation/ cladding is removed during breakdown / preventive

maintenance works shall be reinstalled/repaired/ replaced immediately. All control & power wiring between indoor & outdoor units. Any other associated

work for proper & specified functioning of air conditioning system.

Any other item/ activities associated with proper functioning of comprehensiveAMC.

17. TOOLS, TACKLES AND MEASURING INSTRUMENTS: All the necessary Tools,

Tackles and Measuring Instruments required during preventive Maintenance works/Breakdown Maintenance works/Overhauling works/While conducting tests are to bearranged from your end as and when required at no extra cost. Maintenance of completeair conditioning system deemed to have been included in the scope of work.


10/14

P a g e | 10

18. Attending to complaintsThe contractor will furnish Telephone No. and his contact person to whom the complainthas to be lodged.

19. Maintenance schedulesIn addition to attending to complaints, the contractor will be required to carry out

prescribed maintenance schedules/ preventive maintenance. The maintenance andPreventive maintenance schedules and the work to be done in each schedule shall be

jointly decided in consultation with Engineer-in-charge.


11/14

P a g e | 11

Annexure-II

PART-I: TECHNICAL BID(Information to be furnished by the bidders)

Name of work- Supply, Installation, Testing and Commissioning of VRV/VRF Air

Conditioning system and associated electric work executed on turnkey basis in Kidney

transplant unit at 4th

F of Main Hospital Building

Sr.No. Particulars Information

1. Name of the Agency/firm

2. Year of Establishment/Registration

3. Address & Contact number of the Agency/firm

4. Name of person, who has signed the tender

5. Details of EMD (DD no. and Amount)

6. Details of Tender cost (DD no. and Amount)

6. Permanent Account Number(copy should be attached)

7. Sales tax/VAT registration number (copy should

be attached)

8. Details of satisfactorily completed at least one

works of similar nature costing not less than15.00 Lakh during the last three years withany Central Government Organisation /publicsector Undertakings/ state Government (copyshould be attached)

9. Manufacturer/ authorized dealer(copy of certificate should be attached)

10. Copy of latest Income Tax Return

11. Attach Copy of Product brochure

I ……………………………………………………..Son of …………………………………………………… resident of

……………………………………….. who is …………………………… (Proprietor/ partner/ Director

etc.) of M/s…………………………………………………. with sound mind and without any

pressure. If any document or information furnished with tender is found forged or

fabricated at any time, the Institute has full right to terminate the contract and forfeit

my/our EMD or Security Deposit.

Place : Signature of Bidder with seal

Date: Name & Address


12/14

P a g e | 12

Annexure – „III‟

To,The Director,Dr RMLIMS, Vibhuti Khand,

Gomti Nagar, Lucknow.

Subject: Tender for Supply, Installation, Testing and Commissioning of VRV/VRF Air

Conditioning system and associated electric work executed on turnkey basis in Kidneytransplant unit at 4th F of Main Hospital Building at Dr RMLIMS, Lucknow.

Dear Sir,

Please refer to your web site advertisement & the terms & conditions for the supply &installation of air conditioners as given in detail. Having examined the site, contract

documents, specifications and schedule of quantities, Further, I / we herewith deposit30000/- as Earnest Money Deposit as per the Terms of Contract and our offer. In the

event of my / our tender being accepted, I/we agree to enter into and execute thenecessary contract required by you. I am /We are aware that the Institute intends to

complete the entire work as covered in the scope of this tender within scheduledcompletion period with time being essence of the contract. I/we agree to complete theworks within the said period. As required by you, I / we are returning herewith thetender documents duly signed by us at each page in token of our acceptance of the

provisions in the documents.

Yours faithfully,

(Name of the agency)Sign & Designation of Authorised official

Seal

Date:

Place:


13/14

P a g e | 13

Annexure – IV

PRICE BID(Bill of Quantity)

Sr.No. Items Description Unit Qty Rate AmountVariable Refrigerant Volume/Flow System

(Manufacturer: Daikin/Mitsubishi Electric/O-General/Trane)Supply of Inverter Based variable refrigerantvolume/flow modular type air-conditioning system ofR410A having combination of all Inverter based DCScroll compressor and having following items:

1 Supply & installation of Outdoor Units

1.a 16 HP Nos. 1

1.b Connection Kit Nos. 1

2 Supply & Installation of Indoor Units

2.a Cassette Type Units: 3.3 Tons Nos. 3

2.b Cassette Type Units: 1.65 Tons Nos. 1

2.c Cassette Type Units: 1.08 Tons Nos. 2

3 Supply & installation of Corded Remote Controls Nos. 64 Supply & installation Imported Refrigerant Joints Nos. 5

5 Refrigerant Charging

Commissioning Charges and topping up Gas job. 1

6 Refrigerant Piping & Slotted angle support

Interconnecting refrigerant pipe work suitable forrefrigerant with (19mm/13 mm thick) closed cellelastomeric nitrile rubber tubular insulationbetween each set of indoor & outdoor units. Allpiping inside the room shall be properly supportedwith MS hanger and all external piping shall run incovered 1.6 mm thick G.I tray along with support andbase frame (all outside piping-Exposed insulation withUV Coating protections).

6.a 28.6 mm O.D. (insulation : 19 mm) with slotted angle Rmt. 256.b 22.2 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 20

6.c 19.1 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 40

6.d 15.9 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 60

6.e 12.7 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 40

6.f 9.5 mm O.D. (insulation : 13 mm) with slotted angle Rmt. 20

6.g 6.4 mm O.D (insulation : 13 mm) with slotted angle Rmt. 60

7 Drain Piping

Providing and fixing rigid PVC piping complete withfittings, supports as per norms and duly insulated with6 mm thick closed cell nitrile rubber insulation.

7.a 40 mm dia with slotted angle Rmt. 25

7.b 32 mm dia with slotted angle Rmt. 1008 Power Cabling & Earthing

Providing and fixing PVC sheathed 10 sqmm (4core)copper cable for ODU & IDUs through walls/ceiling withappropriate clamps & fixing arrangement as per siterequirements complete with Earthing as perrequirement on site and as per given bellow.i) 4 core 10 sqmm copper cable 80 Rmt. for ODU & 80Rmt. 4 sqmm wire for Earthingii) 3 core 2.5 sqmm copper cable 150 Rmt. for IDUs

Lot. 1

9 Transmission Wiring

Providing & fixing control cum transmission wiring of 2core x 1.5 Sqmm copper in suitable conduits betweenindoor and outdoor units.

Rmt. 100

10Controller Wiring

Providing & fixing control wiring of 2 core x 1.5 Sqmmcopper between indoor units and their wired remotes.

Rmt. 60


14/14

P a g e | 14

11 Electric Panel for ODU & IDUs

Supply & installation of electrical distribution/panelboard cubicle compartmentalised wall mounted madeof 2.0 mm thick steel sheet duly painted completewith, incoming outgoing feeders CTs contactors,incoming MCCB, outgoing MCCB/MCBs as per

requirement complete in all respects.

Lot. 1

Total

12 CAMC Amount for 1st year after warranty

13 CAMC Amount for 2nd year

14 CAMC Amount for 3rd year

15 CAMC Amount for 4th year

16 CAMC Amount for 5th t year

Grand total

Note:- L1 will be decided on Grand Total.

Place: Lucknow Signature of the Contractor

Date: Name & Seal of the firm

Documents

1135VRV Air Condition